6973GH-18-R-00132 (1).1

PROPOSALS DUE 1700 CST, 20 JUNE 2018

Section B - Supplies or Services/Prices

Section B - Schedule

All work performed and all materials and equipment used will be subject to approval by the COR. This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications

Scope of Work

C.1 Scope of Work

(a) The contractor shall provide all labor, materials and equipment required to perform the work shown on the drawings and described herein. All work performed and all materials and equipment used will be subject to approval by the COR. This shall include but not be limited to testing, inspection, scheduling, reporting, and submittals.

C.2 Bid vs. Offer

Reference to the terms “bid”, “bidder”, etc. throughout the specification are intended to mean “offer, “offeror”, etc.

C.3 Scope of Work

The following Scope of Work (SOW) is applicable to this SIR.

(a) Scope of Work for Mission Bay VOR Design and Build Repair Work.

Clause List

Section D - Packaging and Marking

Clause List

There are no applicable Section D clauses.

Section E - Inspection and Acceptance

Clause List

3.10.4-10 INSPECTION OF CONSTRUCTION (SEP 2009)

(a) 'Work' includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) below.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, without additional charge, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer.

The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless the Government determines that it is in the public interest to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may:

(1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or

(2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(j) In the absence of any formal disputes, a project will be deemed physically and financially complete within one year after final acceptance and excess funds will be deobligated at that time.

(End of clause)

Section F - Deliveries or Performance

Clause List

F.1 WORKING HOURS

Work hours shall not exceed 50 hours per week and shall normally be performed between the hours of 7:00 am and 5:30 pm Monday through Friday. No work will be performed on weekends or Federal holidays. Any work beyond these limitations shall be coordinated with the project engineer and System Support Center (SSC), with the Contracting Officer's (CO) approval , an exception may be granted based on circumstances. The contractor shall coordinate in advance all work hours with the resident engineer. The contractor will not be allowed access to or to work at the site without the resident engineer.

F.2 UTILITY OUTAGES AND SHUTDOWN

Utility outages and shutdown shall be coordinated with the COR. Outages affecting FAA operations are required to be accomplished at night, on weekends or designated government holidays, with CO approval. Prior to any outage or shutdown, seven (7) working days notification must be made to coordinate scheduling of any work to be performed during any hours.

F.3 CONTRACTOR USE OF PREMISES

Contractor's Use of Premises - Contractor shall have shared use of the premises within the construction staging area limits for the execution of the work. Contractor shall assume full responsibility for the protection and safekeeping of products stored on the site. The contractor and any subcontractors shall maintain the job site in a neat and orderly condition. This includes the daily removal of rubbish, waste and tools, equipment and materials not required for the work in progress.

F.4 CONTRACTOR'S CONSTRUCTION SCHEDULE

The contractor shall prepare and submit the construction work schedule to the COR and Contracting Officer (CO) for approval within fourteen (14) days of the date established for “Commencement of Work” in accordance with Clause 3.2.2.3-56, which is incorporated by reference.

Construction Schedule: Work shall take place between October 2018 and March 2019 with no deviation due to protected species breeding season in work area. The performance period shall be 270 days for Design and Construction Phases.

3.10.1-9 STOP-WORK ORDER (OCT 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

3.10.1-11 GOVERNMENT DELAY OF WORK (APR 1996)

(a) If the performance of all or any part of the work of this contract is delayed or interrupted (1) by an act of the Contracting Officer in the administration of this contract that is not expressly or impliedly authorized by this contract, or (2) by a failure of the Contracting Officer to act within the time specified in this contract, or within a reasonable time if not specified, an adjustment (excluding profit) shall be made for any increase in the cost of performance of this contract caused by the delay or interruption and the contract shall be modified in writing accordingly. Adjustment shall also be made in the delivery or performance dates and any other contractual term or condition affected by the delay or interruption. However, no adjustment shall be made under this clause for any delay or interruption to the extent that performance would have been delayed or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an adjustment is provided or excluded under any other term or condition of this contract.

(b) A claim under this clause shall not be allowed:

(1) for any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved, and

(2) unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the delay or interruption, but not later than the day of final payment under the contract.

(End of clause)

AC1817 ACCELERATED DELIVERY (JAN 1997)

Any Schedule for delivery or performance may be expedited at the contractor's option, if without additional expense to the Government.

Section G - Contract Administration Data

Clause List

3.10.1-23 CONTRACTING OFFICER'S REPRESENTATIVE-CONSTRUCTION CONTRACTS (APR

2012)

(a) The Contracting Officer may appoint other Government personnel to accomplish certain contract administration matters. While there shall be various titles and divisions of duties for these individuals, generically they are known as Contracting Officer's Representatives (CORs). The Contracting Officer will provide written notice of COR appointment(s), setting forth the authorities and limitations, to the Contractor within ____ calendar days prior to the notice to proceed. COR duties may include, but are not limited to:

(1) Perform as the authorized representative of the Contracting Officer for technical matters, including interpretation of specifications and drawings, and inspection and review of work performed.

(2) Perform as the authorized representative of the Contracting Officer for administrative matters, including reviewing payments, and updated delivery schedules.

(b) These representatives are authorized to act for the Contracting Officer in all specifically delegated matters pertaining to the contract, except:

(1) contract modifications that change the contract price or cost, technical requirements or time for performance, unless delegated field change order authority;

(2) suspension or termination of the Contractor's right to proceed, either for default or for convenience;

(3) final decisions on any matters subject to appeal, e.g., disputes under the "Contract Disputes" clause; and

(4) final acceptance under the contract.

(End of clause)

AC0135 INVOICING PROCEDURES - GENERAL (JAN 2017)

(a) In addition to the requirements set forth at AMS Clause 3.3.1-17, Prompt Payment, for the submission of a proper invoice, the contractor shall submit a separate invoice for (1) each month of performance of services, or (2) those items of supplies furnished, as follows:

(1) The original to: 9-AMC-AMZ-FAA-APInvoices@faa.gov (Preferred) or mail to:

DOT/FAA AMK-311/314

P.O. Box 25710

Oklahoma City, OK 73169-0710

(2) One Copy to janice.hammonds@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Office of Acquisition Services (AAQ-(insert routing symbol))

P.O. Box 25082

Oklahoma City, OK 73l25

(3) One Copy to mary.ctr.littlefield@faa.gov or:

FAA, Mike Monroney Aeronautical Center

P.O. Box 25710

Oklahoma City, OK 73l25

(b) Each invoice shall highlight the following information:

(1) Contract number and applicable Delivery Order number.

(2) Noun description of services and/or supplies, including applicable line item number(s) and quantity(s) that were provided.

(3) Extended totals for invoiced quantities.

(c) All contractors invoicing services to the FAA in labor hours shall maintain on file, and submit when required for verification or audit, certified time logs showing a daily start and ending work times, the daily total of productive hours charged to the contract, a daily entry for any non-productive work-hours and cumulative totals for each pay period.

AC1227 RELEASE FORM (JAN 1997)

The contractor will be required to execute Contractor's Release Form DOT F 4220.4 (2-71) prior to final payment under the contract. (Note: A copy of Form DOT F 4220.4 (2-71) is attached hereto for information purposes.)

AC1405 AVAILABILITY AND USE OF UTILITY SERVICES (JAN 1997)

The contractor may use existing utilities without charge, if available; however, the contractor at his own expense and in a workmanlike manner satisfactory to the Contracting Officer, shall furnish, install, and maintain all necessary temporary connections and distribution lines, and shall remove same prior to final acceptance of the construction.

AC2916 PAYMENT PROCEDURES (JUL 1997)

(a) The contractor shall submit original invoices, including applications for installment payments, directly to:

FAA, Mike Monroney Aeronautical Center

Financial Operations Division (AMZ-100)

P.O. Box 25710

Oklahoma City, OK 73125-4913

(b) Payment for work performed or items furnished under this contract is subject to approval by the Contracting Officer. The contractor shall submit 2 copies of all invoices, including applications for installment payments, to:

FAA, Mike Monroney Aeronautical Center

Janice Hammonds, AAQ-722

6500 South MacArthur Boulevard

P.O. Box 25082

Oklahoma City, OK 73125

(c) Each invoice, including applications for installment payments, must reflect the contract number, delivery order number, and a description of the work, services, or items being invoiced.

Section H - Special Contract Requirements

Clause List

H.1 PERMITS AND RESPONSIBILITIES

The Contractor shall secure and pay for all permits, licenses, special inspections, etc., required in the execution of the work, whether of a permanent or temporary nature.

H.2 ACCIDENT AND FIRE REPORTING

(a) The Contractor shall report to the CO any accident or fire occurring at the site of the work which causes:

(1) A fatality or as much as one lost workday on the part of any employee of the Contractor or subcontractor at any tier;

(2) Damage of $1,000 or more to Federal property, either real or personal;

(3) Damage of $1,000 or more to Contractor or subcontractor owned or leased motor vehicles or mobile equipment; or

(4) Damage for which a contract time extension may be requested.

(b) Accident and fire reports required by paragraph (a) above shall be accomplished by the following means:

(1) Report immediately by telephone to the CO or his/her authorized representative and shall be confirmed by email or facsimile transmission within 24 hours to the Contracting Officer. Such email or facsimile transmission shall state all known facts as to extent of injury and damage and as to cause of the accident or fire.

(2) Accident and fire reports required by paragraph (a) above may be reported by the Contractor using a state, private insurance carrier, or Contractor accident report form which provides for the statement of:

(i) The extent of injury; and

(ii) The damage and cause of the accident or fire.

Such report shall be mailed or otherwise delivered to the Contracting Officer within 48 hours of the occurrence of the accident or fire.

(c) The Contractor shall assure compliance by subcontractors at all tiers with the requirements of this clause.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2013)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

Contractors may use the following means of electronic signature technology such as digital signatures..

(End of Clause)

3.13-15 CONFIDENTIALITY OF DATA AND INFORMATION (NOV 2016)

(a) In performance of this contract, the contractor and any of its subcontractors, may need access to and use various data and information in the possession of the Government.This data and information may have been obtained under conditions which restrict the Government's right to use and disclose this data and information or which may be adverse to the interests of the Government or other parties if it is disseminated or used in a capacity other than in performance of this contract. Therefore, the contractor and its subcontractors agree to abide by any restrictive use conditions on such data and not to: (1) knowingly disclose such data and information to others without written authorization from the Contracting Officer, unless it is already publically available; or (2) use for any purpose other than the performance of this contract any data or information which bears a restrictive marking or legend which the contractor has gained access to through the performance of this contract, or information that should be marked according to FAA Order 1600.75 "Protecting Sensitive Unclassified Information (SUI)". For the sole purpose of this clause, "information" means any communication or representation of knowledge such as facts, data, or opinions in any medium or form, including textual, numerical, graphic, cartographic, narrative or visual form.

(b) In the event the work required to be performed under this contract requires access to proprietary data and information of other companies, the contractor must obtain agreement from such other companies for such use unless such data are provided or made available to the contractor by the Government. Two copies of such company-to-company agreements must be furnished promptly to the Contracting Officer for information only. These agreements must prescribe the scope of authorized use and disclosure of the proprietary data and information as well as any other terms and conditions to be agreed upon between the parties thereto. It is agreed by the contractor that any such data or information, whether obtained by the contractor pursuant to the aforesaid agreement or from the Government, must be protected from unauthorized use by or unauthorized disclosure to any individual, corporation, or organization so long as it remains proprietary.

(c) The contractor agrees to conduct formal training to make employees aware of the requirement to maintain confidentiality of data and information as required above. The contractor must obtain from each employee in connection with this contract a signed Non-Disclosure Agreement. This agreement must provide that the employee will not, during employment or anytime thereafter, disclose or use for current or future benefit of any party any of the data (to include any form of Sensitive Unclassified Information (SUI) described in FAA Order 1600.75) or information not publically available received in connection with the work under the contract.

(d) The contractor agrees to hold the Government harmless and indemnify the Government as to any cost/loss resulting from the unauthorized use or disclosure of third party data or software by the contractor, its employees, subcontractors, or agents.

(e) The contractor agrees to include the substance of this clause in all subcontracts awarded under this contract. The Contracting Officer will consider case-by-case exceptions to this requirement for individual subcontracts in the event that: (1) the contractor considers this clause to be inappropriate and unnecessary in the case of a particular subcontract; (2) the contractor provides a written statement affirming absolute unwillingness of a subcontractor to perform, absent some relief from the substance of this prohibition and the reason why; (3) use of an alternate subcontract source would unreasonably detract from the quality of effort; and (4) the contractor provides the Contracting Officer timely written advance notice of these and any other extenuating circumstances.

(f) Except as the Contracting Officer specifically authorizes in writing, upon completion of all work under this contract, the contractor must return all such data and information described above obtained from the Government, including all copies, modifications, adaptations, or combinations thereof, to the Contracting Officer. Data obtained from another company must be disposed of in accordance with the contractor's agreement with that company, or if the agreement makes no provision for disposition, must be returned to that company. The contractor must further certify in writing to the CO that all copies, modifications, adaptations, or combinations of such data or information which cannot reasonably be returned to the Contracting Officer (or to the appropriate company), have been deleted from the contractor's (and any subcontractor's) records and destroyed. The FAA reserves the right to audit the deletion. The FAA must provide notice of the audit 10 calendar days prior to the audit.

(g) These restrictions do not limit the contractor's (or subcontractor's) right to use and disclose any data and information obtained from another source without restriction.

(End of clause)

AC1231 NOTIFICATION REQUIREMENTS WHEN FRIABLE ASBESTOS MATERIAL IS

REMOVED/DISTURBED (JAN 1997)

(a) Prior to any planned and/or scheduled disturbance of friable asbestos material, mainly CAFCO ceilings, the contractor shall present a written plan to the Contracting Officer. The plan shall include, but not be limited to, location, type facility, size of area to be disturbed or removed, method of containment to be used, disposal procedures, clean-up procedures, number of employees involved, protective clothing/equipment to be used, the date and time removal/disturbance is planned and any other information requested by the Contracting Officer. The contractor shall not proceed with any removal or disturbance of friable asbestos material without written approval from the Contracting Officer.

(b) If during the performance of the contract the contractor inadvertently disturbs friable asbestos material, mainly CAFCO ceilings, the contractor shall immediately cease operations and notify the Contracting Officer. The contractor shall remain at the site of disturbance for the Contracting Officer's instructions.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses

Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2011)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

http://conwrite.faa.gov.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (AUG 1997)

3.1.7-5 DISCLOSURE OF CONFLICTS OF INTEREST (MAR 2009)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-42 DIFFERING SITE CONDITIONS (JUL 2004)

3.2.2.3-43 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (JUL 2004)

3.2.2.3-45 MATERIAL AND WORKMANSHIP (JUL 2004)

3.2.2.3-46 SUPERVISING THE CONTRACT WORK (JUL 2004)

3.2.2.3-47 PERMITS AND RESPONSIBILITIES (JUL 2004)

3.2.2.3-48 OTHER CONTRACTS (MAR 2009)

3.2.2.3-49 PROTECTING EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND

IMPROVEMENTS (JUL 2004)

3.2.2.3-50 PROPERTY PROTECTION (OCT 2014)

3.2.2.3-51 OPERATIONS AND STORAGE AREAS (APR 2012)

3.2.2.3-52 USE AND POSSESSION BEFORE THE PROJECT IS COMPLETE (JUL 2004)

3.2.2.3-53 CLEANING UP AND ROADWAY MAINTENANCE (JUL 2004)

3.2.2.3-54 PREVENTING ACCIDENTS (JUL 2004)

3.2.2.3-56 SCHEDULES FOR CONSTRUCTION CONTRACTS (JUL 2004)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009)

3.2.2.3-64 DISMANTLING AND DEMOLISHING OF PROPERTY (JUL 2004)

3.2.2.3-66 CONTRACTOR'S DAILY LOG (JUL 2004)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS

(OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 1996)

3.2.5-3 GRATUITIES OR GIFTS (JAN 1999)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2010)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-2 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (APR 1996)

3.3.1-9 INTEREST (SEP 2009)

3.3.1-10 AVAILABILITY OF FUNDS (APR 2014)

3.3.1-16 PROHIBITION OF ASSIGNMENT OF CLAIMS (APR 1996)

3.3.1-19 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS (OCT

2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD MANAGEMENT

(AUG 2012)

3.3.2-1 FAA COST PRINCIPLES (JAN 2016)

3.4.1-7 NOTICE TO PROCEED (APR 1996)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT 1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (APR 2013)

3.5-1 AUTHORIZATION AND CONSENT (JAN 2009)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JAN

2009)

3.5-4 PATENT INDEMNITY - CONSTRUCTION CONTRACTS (JAN 2009)

3.5-10 PATENT RIGHTS - OWNERSHIP BY THE CONTRACTOR (JAN 2009)

3.6.1-1 NOTICE OF TOTAL SMALL BUSINESS SET-ASIDE (JAN 2010)

3.6.1-3 UTILIZATION OF SMALL, SMALL DISADVANTAGED AND WOMEN-OWNED, AND

SERVICE-DISABLED VETERAN OWNED SMALL BUSINESS CONCERNS (MAR 2009)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (OCT 2016)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (JAN 2011) - ALTERNATE I (JAN 2012)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (APR 1996)

3.6.2-18 DAVIS BACON ACT (APR 2017)

3.6.2-20 PAYROLLS AND BASIC RECORDS (APR 2017)

3.6.2-21 APPRENTICES, TRAINEES, AND HELPERS (APR 2017)

3.6.2-22 SUBCONTRACTS (LABOR STANDARDS) (APR 2017)

3.6.2-23 CERTIFICATION OF ELIGIBILITY (APR 2017)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (AUG 1998)

3.6.2-39 TRAFFICKING IN PERSONS (OCT 2015)

3.6.3-13 AFFIRMATIVE PROCUREMENT OF RECYCLED CONTENT AND PRODUCTS UNDER

SERVICE AND CONSTRUCTION CONTRACTS (OCT 2016)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (OCT 2016)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (OCT 2016)

3.6.3-24 ASBESTOS NESHAP COMPLIANCE (OCT 2015)

3.6.4-5 BUY AMERICAN - STEEL AND MANUFACTURED PRODUCTS (JUL 2010)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.9.1-1 CONTRACT DISPUTES (OCT 2011)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-8 SUSPENSION OF WORK (SEP 1998)

3.10.1-15 CHANGES-CONSTRUCTION, DISMANTLING, DEMOLITION, OR REMOVAL OF

IMPROVEMENTS (JUL 1996)

3.10.1-16 CHANGES AND CHANGED CONDITIONS (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.2-1 SUBCONTRACTS (FIXED-PRICE CONTRACTS) (APR 1996)

3.10.4-23 CONTRACTOR AND SUBCONTRACTOR COMPLIANCE WITH FASTENER ACT (NOV 1997)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT 1996)

3.10.6-6 DEFAULT (FIXED PRICE CONSTRUCTION) (OCT 1996)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.13-14 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS

(OCT 2012)

3.14-3 FOREIGN NATIONALS AS CONTRACTOR EMPLOYEES (APR 2014)

3.2.2.3-37 NOTIFICATION OF OWNERSHIP CHANGES (JUL 2004)

(a) The Contractor (you) must notify FAA in writing within 30 days when you become aware that a change in ownership has occurred or will occur and that the change could affect the value of your capitalized assets in the accounting records, asset valuations, or cause any other cost changes.

(b) You must:

(1) Maintain current, accurate, and complete inventory records of assets and their costs;

(2) Provide the Contracting Officer (CO) access to the records on request;

(3) Ensure that all individual and grouped assets, their capitalized values, accumulated depreciation or amortization, and remaining useful lives are identified accurately before and after each of your ownership changes; and

(4) Retain and maintain depreciation and amortization schedules based on the asset records maintained before each ownership change.

(c) You must include the substance of this clause in all subcontracts under this contract with a value exceeding $1,000,000 and that require cost and price data.

(End of clause)

3.2.2.3-41 PERFORMING WORK (JUL 2004)

The Contractor (you) must perform, using your own organization, work equivalent to at least 100% percent of the total amount of work under the contract on the site. The CO may modify this contract to reduce this percentage if you request a reduction and the CO determines that it would be to the Government's advantage to do so.

(End of clause)

3.2.2.3-44 PHYSICAL DATA (JUL 2004)

Data and information the FAA (we, us) provides or refers to below is for the Contractor's (your) information. We are not responsible for your interpretation of or conclusions based on the data or information. Further, we do not warrant construction methodology which may be included in these documents.

(a) The descriptions of physical conditions on the drawings and in the specifications are the result of site investigations by the on-site engineer who will be performing duties as the COR..

(b) Other relevant information is that it is the Contractor's responbility to obtain weather patterns for the area, inspect the site in a manner which will provide the Contractor4 sufficient information concerning the site conditions in order to complete the project within the stated amount of time..

(End of clause)

3.2.2.3-55 AVAILABILITY AND USE OF UTILITY SERVICES (JUL 2004)

(a) FAA (we, us) will make all reasonable required utilities amounts available to the Contractor (you) from existing outlets and supplies, as the contract specifies. You must pay for each utility service you use at the prevailing rates we are charged, or at rates the Contracting Officer (CO) determines to be reasonable. You must carefully conserve any utilities we provide.

(b), You must install and maintain all necessary temporary connections and distribution lines, and all meters required to measure each utility used. You must do this at no cost to us and in a workmanlike manner satisfactory to

us. Before our final acceptance of your work, you must remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

(End of clause)

3.2.2.3-60 SPECIFICATIONS, DRAWINGS, AND MATERIAL OFFERS (MAR 2009) - ALTERNATE I

(MAR 2009)

(a) If either the specifications or the drawings (but not both) mention tasks, the Contractor (you) must assume that the tasks are in both. If the drawings and specifications differ, the specifications govern. If there is a discrepancy in the figures, in the drawings, or in the specifications, submit the matter promptly to the Contracting Officer (CO), who will promptly determine which governs, and notify you in writing. Any adjustment you make without the CO's determination is at your own risk and expense. From time to time the CO will provide necessary detailed drawings and other information, unless otherwise provided.

(b) Wherever in the specifications or the drawings FAA (we, our) uses "directed," "required," "ordered," "designated," "prescribed," or similar words, they refer to the CO's requirements. Similarly, "approved,"

"acceptable," "satisfactory," or similar words refer to the CO's approval, unless otherwise expressly stated. You must have a complete set of plans and specifications on site and available for our use.

(c) Where we use "as shown," "as indicated," "as detailed," or similar words, they refer to the drawings accompanying this contract, unless stated otherwise. The word "provided" means "provided and installed."

(d) Omissions from the drawings and specifications or the erroneous description of details of work which are necessary to carry out the intent of the drawings and specifications, or which are customarily performed, does not relieve you from performing those omitted or erroneously described details of the work. You must perform them as if fully and correctly set forth and described in the drawings and specifications.

(e) You must check all drawings we provide to you before starting work and must promptly notify the CO of any discrepancies. In general you should follow figures marked on drawings, rather than scale measurements. In general, large scale drawings have precedence over small scale drawings. You must compare all drawings and verify the figures before laying out the work. If you do not verify the figures, you will be responsible for any errors you might have avoided had you verified them.

(f) "Shop drawings" means drawings, you or any subcontractor submit to us under a construction contract, showing in detail the proposed fabrication and assembly of structural elements and the installation (that is, form, fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials you provided to explain in detail specific portions of the work the contract requires.

FAA may duplicate, use, and disclose in any manner and for any purpose shop drawings you deliver under this contract.

(g) If this contract requires material offers (for example, shop drawings, catalog cuts, certificates of conformance), you must coordinate all of your offers, and review them for accuracy, completeness, and compliance with contract requirements. You must provide evidence that you approve the submittals. If you submit materials to us without this evidence, we may return them and ask you to resubmit them. The CO will indicate whether he or she approves or disapproves your offer, and if the CO does not approve it as submitted, will indicate our reasons for rejecting it. Any work done before the CO's approval is at your risk. The CO's approval does not relieve you from responsibility for any errors or omissions in the submittals, nor from responsibility for complying with the contract requirements, except as described under (h).

(h) If you submittals vary from the contract requirements, you must describe the variations in writing, separate from the submittal, when you submit them. Send this description, a copy of the offer, and a proposal to incorporate it into the contract directly to the CO. If the CO approves a variation, the CO must issue an appropriate contract modification, unless the variation is minor or does not involve a change in price or in time of performance.

(i) You must submit to the CO for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. The CO will keep three sets (unless otherwise indicated) of all offers and will return one set to you.

(j) You must insert this clause, with appropriate changes in the designation of the parties, in all subcontracts.

(k) When you finish the work under this contract, you must provide the COR complete reproducible sets of all shop drawings as we finally approve them. These drawings must show all changes and revisions made up to the time you finish the work and we accept it.

3.2.2.3-62 PRECONSTRUCTION CONFERENCE (JUL 2004)

The successful offeror must attend a pre-construction conference at a site the Contracting Officer designates before starting the work.

(End of clause)

3.2.2.3-68 SAFETY AND HEALTH (OCT 2014) - ALTERNATE I (JUL 2004)

(a) Before beginning work, the Contractor (you) must:

(1) Perform a hazards analysis of the work specified in this contract. Consider both the site and adjacent conditions.

Identify all significant hazards. Some of the hazards you might encounter are falling from structure/s, tripping, and falling debris.

(2) Submit a safety plan for dealing with each specific hazard identified, whether you or FAA identified it.

(3) Meet with the CO's representatives during the preconstruction conference to discuss and to develop a mutual understanding about the content and implementation of the plan.

(4) The CO or her or his representatives may require other hazards to be added to the plan. If the CO determines that your planned hazard avoidance measures are insufficient, the CO or a designated representative may require you to revise the plan. You may not begin work involving identified hazards unless you have submitted adequate plans to the CO and the CO has reviewed them. This approval does not relieve you of your liability for safe performance.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 10 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 31 March 2019. The time allowed for completion must include final cleanup of the premises.

(End of clause)

3.2.2.3-71 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (JUL 2004) -

ALTERNATE I (JUL 2004)

The Contractor (you) must

(a) begin work under this contract within 10 calendar days after the date you receive the notice to proceed,

(b) perform the work diligently, and

(c) complete the entire work ready for use not later than 31 March 2019. The time allowed for completion must include final cleanup of the premises.

(d) The completion date assumes that the successful offeror will receive the notice to proceed by 18 September 2018. The CO will extend the completion date by the number of calendar days after the above date that you receive the notice to proceed, except to the extent that the delay in issuing the notice to proceed results from your failure to execute the contract and give the required performance and payment bonds to FAA within the time specified.

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (OCT 2016)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor shall provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) change the name in the SAM database;

(B) comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor shall not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees shall be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.4.1-4 PERFORMANCE BOND REQUIREMENTS (JAN 2017)

(a) The contractor is required to submit a performance bond in a penal amount equal to 100 percent of the contract price, but for this contract the amount required by the Contracting Officer is not utilizing a seperate amount to fulfill this requirement.

(b) The bond must be executed on specified forms, and sureties must be acceptable to the Federal Aviation Administration. Corporate sureties must appear on the list in Treasury Circular 570, and the amount of the bond may not exceed the underwriting limit stated for the surety on that list.

(c) Failure to submit an acceptable bond may be cause for termination of the contract for default.

3.4.1-5 PAYMENT BOND REQUIREMENTS (JAN 2017)

(a) The contractor is required to submit a payment bond in the penal amount of the total awarded amount of the contract within the time required by the Contracting Officer.

(b) The bond must be executed on the forms attached to this SIR, and sureties must be acceptable to the Federal Aviation Administration. Corporate sureties must appear on the list in Treasury Circular 570, and the amount of the bond may not exceed the underwriting limit stated for the surety on that list.

(c) Failure to submit an acceptable bond may be cause for termination of the contract for default.

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JUL 1996)

(a) The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in the "Schedule" or elsewhere in the contract.

(b) Before commencing work under this contract, the Contractor shall certify to the Contracting Officer in writing by letter or certificate of insurance, reflecting the FAA's contract number, that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Federal Aviation Administration's interest shall not be effective:

(1) for such period as the laws of the State in which this contract is to be performed prescribe, or

(2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

(c) The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the "Schedule" or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors' proofs of required insurance, and shall make copies (reflecting the FAA's contract number to ensure proper filing of documents) available to the Contracting Officer upon request.

(End of clause)

3.6.2-9 EQUAL OPPORTUNITY (AUG 1998)

(a) If, during any 12-month period (including the 12 months preceding the award of this contract), the Contractor has been or is awarded nonexempt Federal contracts and/or subcontracts that have an aggregate value in excess of $10,000, the Contractor shall comply with subparagraphs (b)(1) through (11) below. Upon request, the Contractor shall provide information necessary to determine the applicability of this clause.

(b) During performing this contract, the Contractor agrees as follows:

(1) The Contractor shall not discriminate against any employee or applicant for employment because of race, color, religion, sex, or national origin.

(2) The Contractor shall take affirmative action…