6973GH-22-R-00023 12-15-2021.pdf

SOLICITATION, OFFER AND AWARD

3. SOLICITATION TYPE1. CONTRACT NO. 2. SOLICITATION NUMBER

6. ISSUED BY CODE 7. ADDRESS OFFER TO (If other than Item 6)

5. REQUISITION/PURCHASE NUMBER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder"

NEGOTIATED BID (RFP)

SEALED BID (IFB)

4. DATE ISSUED

PAGE OF PAGES

1 60

C. E-MAIL ADDRESS

EXT.NUMBERAREA CODE

B. TELEPHONE (NO COLLECT CALLS)A. NAME

9. FOR

INFORMATION

CALL

CAUTION: LATE Submissions, Modifications and Withdrawals. All offers are subject to all terms and conditions contained in this solicitation.

(Date)(Hour) local timeuntildepository located in copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 7, or if hand carried, in the

SOLICITATION

8. Sealed offers in original and

PART IV - REPRESENTATIONS AND INSTRUCTIONS

OTHER STATEMENTS OF OFFERORS

EVALUATION FACTORS FOR AWARD

INSTR., CONDS., AND NOTICES TO OFFERORS

REPRESENTATIONS, CERTIFICATIONS AND

LIST OF ATTACHMENTS

CONTRACT CLAUSES

PART III - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACH.

I

J

K

L

M SPECIAL CONTRACT REQUIREMENTS

CONTRACT ADMINISTRATION DATA

DELIVERIES OR PERFORMANCE

INSPECTION AND ACCEPTANCE

PACKAGING AND MARKING

DESCRIPTION/SPECS./WORK STATEMENT

SUPPLIES OR SERVICES AND PRICE/COST

SOLICITATION/CONTRACT FORM

PART II - CONTRACT CLAUSESPART I - THE SCHEDULE

H

G

F

E

D

C

B

A

SEC. DESCRIPTION PAGE(S) (X) DESCRIPTION SEC. (X)

10. TABLE OF CONTENTS

17. OFFER DATE16. SIGNATURE

SUCH ADDRESS IN SCHEDULE.

IS DIFFERENT FROM ABOVE - ENTER

14C. CHECK IF REMITTANCE ADDRESS

EXT.NUMBERAREA CODE

14B. TELEPHONE NUMBER

(Type or print)AND

ADDRESS

OF

OFFEROR

CODE FACILITY

15. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER14A. NAME

DATEAMENDMENT NO.DATEAMENDMENT NO.

and related documents numbered and dated):

amendments to the SOLICITATION for offerors

(The offeror acknowledges receipt of

13. ACKNOWLEDGEMENT OF AMENDMENTS

CALENDAR DAYS (%)30 CALENDAR DAYS (%)20 CALENDAR DAYS (%)10 CALENDAR DAYS (%)12. DISCOUNT FOR PROMPT PAYMENT the designated point(s), within the time specified in the schedule.

by the offeror) from the date for receipt of offers specified above , to furnish any or all items upon which prices are offered at the price set opposite each item , delivered at

11. In compliance with the above, the undersigned agrees, if this offer is accepted within ______________ calendar days (60 calendar days unless a different period is inserted

NOTE: Item 11 does not apply if the solicitation includes Minimum Bid Acceptance Period .

OFFER (Must be fully completed by offeror)

IMPORTANT - Award will be made on this Form, or by other authorized official written notice.

27. AWARD DATE

(Signature of Contracting Officer)

26. CONTRACT AUTHORITY

24. PAYMENT WILL BE MADE BY

25. NAME OF CONTRACTING OFFICER (Type or print)

CODE 23. ADMINISTERED BY (If other than Item 6)

ITEM

(4 copies unless otherwise specified)

22. SUBMIT INVOICES TO ADDRESS SHOWN IN21. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

20. ACCOUNTING AND APPROPRIATION19. AMOUNT18. ACCEPTED AS TO ITEMS NUMBERED

AWARD (To be completed by CONTRACT AUTHORITY)

CODE

AC-22-00648

X

AAQ0731-AFN

AAQ-731 FAC. & AVIATION SAFETY ACQ

FAA AERONAUTICAL CENTER

PO BOX 25082

BLDG 014-AHQ, ROOM 233A

OKLAHOMA CITY OK 73125

1500 CS 01/24/2022

Kimberly D. Sites 405 Kimberly.Sites@faa.gov

954-7755

X

X

X

X

X

X

X

X

X

X

X

X

X

PAGE(S)

Kimberly D. Sites

6973GH-22-R-00023

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 60

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

6973GH-22-R-00023

Purchase of Laboratory Information Management

System (LIMS) Toxicology Database (ToxDB)

Software Solution

The Line Items listed on this SF30 (cover and continuation pages) are for Government use only.

Please reference Section B/Pricing of this instrument for the contract line items.

Delivery Location Code: A6973E3M

A6973E3M

6973E3 DOT FAA AAM 600

CIVIL AEROSPACE MEDICAL RESEARCH

PO BOX 25082 DIV RM 102 M

OKLAHOMA CITY OK 731250082 US

Period of Performance: 02/28/2022 to 02/27/2023

00001 Laboratory Information Management System (LIMS)

Toxicology Database (ToxDB) Software Solution:

Licensing - 25 licenses

Electronic & IT: 03

00002 Laboratory Information Management System (LIMS)

Toxicology Database (ToxDB) Software Solution:

Implementation with Data Migration

Electronic & IT: 03

00003 Laboratory Information Management System (LIMS)

Toxicology Database (ToxDB) Software Solution:

Configuration of software - Programming time

Electronic & IT: 03

00004 Laboratory Information Management System (LIMS)

Toxicology Database (ToxDB) Software Solution:

On-Site training

Electronic & IT: 03

00005 Estimated Travel Costs - Not to Exceed $25,000

Electronic & IT: 03

Section A - Solicitation/Contract Form

Section B - Supplies or Services/Prices Section B - Schedule

See Section J, Attachment 1 for the Section B Contract Line Items/Pricing applicable to this instrument

Clause List

The remainder of this page has been intentionally left blank.

Section C - Description/Specifications Scope of Work

The contractor shall perform the requirements listed in the Statement of Work (Section J - Attachment 2) in accordance with all terms, conditions, and provisions set forth herein.

Clause List

AC4563 EMERGENCY SITUATIONS AND EXERCISES DURING CONTRACT PERFORMANCE

AT THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (NOV 2015)

(a) Emergency situations and exercises are temporary exceptions to the prohibition of contractor personnel being subject to the direction and control of Government personnel when performing non-personal contract services in Government facilities.

(b) All contractor personnel at a Government work site or facility during an actual emergency must conform to the procedures posted or directed by Government officials responsible for emergency response at that site or facility.

Such officials include evacuation wardens/monitors, security personnel, Emergency Readiness Officers, management, Contracting Officer’s Representative (COR), etc.

(c) Contractor personnel must participate in all emergency exercises, including evacuations, as part of performance under this contract. On rare occasions, based on advance arrangements that are then announced at the time of an exercise, contractor personnel may be excused from evacuations.

(d) Contractor management/site supervisors must ensure that each contractor employee assigned to work in Government facilities possesses a general awareness of emergency and evacuation procedures at all locations where the employees might be during an emergency or exercise. Contractor Management/Site Supervisors are responsible for accounting for their employees during an actual emergency or exercise, and are subsequently required to report this information to their COR as soon as practical based on the situation. Information on emergency procedures may be requested from the COR or a designated Government contact point at the work site.

(e) When there are disruptions to Government operations at the Mike Monroney Aeronautical Center, Contractor Management/Site Supervisor should ensure that all employees are aware of the following methods of obtaining the Center’s status:

The Center Status website: https://employees.faa.gov/org/centers/mmac/employee_services/facility_status/

Status Phone number; 954-0040, and local TV/Radio news channels.

(f) If the Center is OPEN during inclement weather, it’s business as usual. Any need for unscheduled leave is between the contractor employee and their contractor management, not the FAA.

(g) When the Center is OPEN with a Delayed Arrival Time, contractors may allow their employees to arrive at the worksite in accordance with the Delayed Arrival Time under which the Center is operating. However, the government will not pay for hours not worked on other than firm fixed price type contracts and discussions on accounting for time on any other contract type should be between Contractor Management/Site Supervisor and COR or CO.

(h) When the Center is CLOSED, contractor employees should not report to the Center unless they have been informed in advance that they are considered ‘mission critical’ employees or their contractor management/site supervisor has provided other direction. The government will not pay for hours not worked on other than firm fixed price type contracts. Any discussions on accounting for time on any other contract type should be between the contractor management/site supervisor and the COR or CO.

(i) If an alternative duty location is activated that includes contractor employees, all contractor employees will be made aware of that location through their contractor management/site supervisor.

Section D - Packaging and Marking Clause List

Section E - Inspection and Acceptance Clause List

3.10.4-2 INSPECTION OF SUPPLIES - FIXED PRICE (NOV 1997)

3.10.4-4 INSPECTION OF SERVICES - BOTH FIXED-PRICE & COST REIMBURSEMENT (APR

1996)

3.10.4-16 RESPONSIBILITY FOR SUPPLIES (APR 1996)

AC1908 INSPECTION AND ACCEPTANCE AT DESTINATION (JUN 2015)

(a) Final inspection and acceptance shall be at destination.

(b) Although source inspection by the Government is not anticipated under this contract, the provisions of this clause shall in no way be construed to limit the rights of the Government under the clause entitled []

Section F - Deliveries or Performance Clause List

3.10.1-9 STOP-WORK ORDER (OCT 1996)

3.10.1-24 NOTICE OF DELAY (MAR 2009)

3.11-34 F.O.B. DESTINATION (APR 1999)

AC1604 CONTRACT PERIOD (JUN 2015)

The effective period of this contract is 1 year from date of award.

Section G - Contract Administration Data Clause List

3.10.1-22 CONTRACTING OFFICER'S REPRESENTATIVE (APR 2012)

AC0135 INVOICING PROCEDURES - GENERAL (JAN 2017)

(a) In addition to the requirements set forth at AMS Clause 3.3.1-17, Prompt Payment, for the submission of a proper invoice, the contractor shall submit a separate invoice for (1) each month of performance of services, or (2) those items of supplies furnished, as follows:

(1) The original to: 9-AMC-AMZ-FAA-APInvoices@faa.gov (Preferred) or mail to:

DOT/FAA AMK-311/314

P.O. Box 25710

Oklahoma City, OK 73169-0710

(2) One Copy to kimberly.sites@faa.gov or:

FAA, Mike Monroney Aeronautical Center

Office of Acquisition Services (AAQ-731)

P.O. Box 25082

Oklahoma City, OK 73l25

(3) One Copy to tracy.streagle@faa.gov or:

FAA, Mike Monroney Aeronautical Center

[Tracy Streagle AAM-500]

P.O. Box [ 25082]

Oklahoma City, OK 73l25

(b) Each invoice shall highlight the following information:

(1) Contract number and applicable Delivery Order number.

(2) Noun description of services and/or supplies, including applicable line item number(s) and quantity(s) that were provided.

(3) Extended totals for invoiced quantities.

(c) All contractors invoicing services to the FAA in labor hours shall maintain on file, and submit when required for verification or audit, certified time logs showing a daily start and ending work times, the daily total of productive hours charged to the contract, a daily entry for any non-productive work-hours and cumulative totals for each pay period.

AC4529 WARRANTY - COMMERCIAL PRODUCTS AND SERVICES (JUN 2006)

The contractor’s standard commercial warranty shall be deemed to be a part of this contract unless otherwise specified. If the contractor does not have a standard warranty, the warranty provisions of UCC Article 2 shall apply.

mailto:tracy.streagle@faa.gov

AC4550 DELIVERIES TO THE MIKE MONRONEY AERONAUTICAL CENTER (MMAC) (JUL

2015)

(a) Security procedures at the MMAC require that all mail, materials, packages or parcels of any kind be delivered to a central screening point, for inspection by the FAA. This affects mail and other deliveries destined for all organizations located on MMAC property, including government organizations, contractors and permit holders.

After passing security inspection, the mail or material may be handled and delivered by the FAA. FAA will make every reasonable effort to conduct inspections and handle items in a careful manner so as to avoid damage or delay.

(b) This inspection is for the benefit of the FAA only. The FAA makes no representation that any material passing inspection is without hazard, poses no threat, or that it conforms in form, fit, function or quantity to the expectations of the intended recipient.

(c) The FAA shall not be liable for any 1) loss, damage or shortage of any mail or materials, 2) injury, or 3) delay in performance resulting from such inspection and handling, unless liable under the Federal Tort Claims Act (28 U.S.C. 2671-2680).

(d) Any item destined for the contractor that fails to pass inspection remains the property of the contractor, who is responsible for its disposition and coordination with law enforcement agencies as necessary.

Section H - Special Contract Requirements Clause List

H.1 STAFFING/RESOURCE UTILIZATION

The Contractor shall assure that all persons employed on this contract possess the required skills and are assigned duties consistent with the job classifications for which they are employed. Any Department of Labor imposed fine, penalty, or upward salary adjustment resulting from the Contractor's failure to properly utilize classified employees, shall be the contractor's responsibility and shall not be allowed for the purposes of reimbursement under this contract.

3.1.9-1 ELECTRONIC COMMERCE AND SIGNATURE (JUL 2020)

(a) The Electronic Signatures in Global and National Commerce Act (E-SIGN) establishes a legal equivalence between:

(1) Contracts written on paper and contracts in electronic form;

(2) Pen-and-ink signatures and electronic signatures; and

(3) Other legally-required written records and the same information in electronic form.

(b) With the submission of an offer, the offeror acknowledges and accepts the utilization of electronic commerce as part of the requirements of this solicitation and the resultant contract.

(c) Certain documents may need to be provided or maintained in original form, such as large-scale drawings impractical to convert to electronic format or a document with a raised seal signifying authenticity. This clause does not change or affect any other requirements that a document must be in paper format to satisfy legal requirements such as for certain real estate transactions.

(d) The use of electronic signature technology is authorized under this solicitation and the resulting contract.

(e) Contractors must not digitally sign any documents with software that uses the Secure Hash Algorithm 1 (SHA- 1). All digitally signed documents and contracts sent to the FAA must use a SHA-256 or higher hash algorithm. This is based on the National Institute of Standards and Technology (NIST) Policy Statement on Hash Functions dated August 5, 2015. Further guidance on the use of SHA-256 is in NIST Special Publication (SP) 800-57 Part 1, section

5.6.2 as amended and SP 800-131A, Revision 1 dated November 6, 2015. Additional guidance on the use of SHA-3 is in NIST SP 800-185 as amended.

(f) Contractors do not have to update documents previously digitally signed using SHA-1 hash algorithms unless the document requires updating. The FAA and contractors may continue to use SHA-1 for the following applications:

Verifying old digital signatures and time stamps, generating and verifying hash-based message authentication codes (HMACs), key derivation functions (KDFs), and random bit/number generation.

(End of Clause)

3.13-15 CONFIDENTIALITY OF DATA AND INFORMATION (NOV 2016)

(a) In performance of this contract, the contractor and any of its subcontractors, may need access to and use various data and information in the possession of the Government.This data and information may have been obtained under conditions which restrict the Government's right to use and disclose this data and information or which may be adverse to the interests of the Government or other parties if it is disseminated or used in a capacity other than in performance of this contract. Therefore, the contractor and its subcontractors agree to abide by any restrictive use conditions on such data and not to: (1) knowingly disclose such data and information to others without written authorization from the Contracting Officer, unless it is already publically available; or (2) use for any purpose other than the performance of this contract any data or information which bears a restrictive marking or legend which the contractor has gained access to through the performance of this contract, or information that should be marked according to FAA Order 1600.75 "Protecting Sensitive Unclassified Information (SUI)". For the sole purpose of this clause, "information" means any communication or representation of knowledge such as facts, data, or opinions in any medium or form, including textual, numerical, graphic, cartographic, narrative or visual form.

(b) In the event the work required to be performed under this contract requires access to proprietary data and information of other companies, the contractor must obtain agreement from such other companies for such use unless such data are provided or made available to the contractor by the Government. Two copies of such company-to-company agreements must be furnished promptly to the Contracting Officer for information only. These agreements must prescribe the scope of authorized use and disclosure of the proprietary data and information as well as any other terms and conditions to be agreed upon between the parties thereto. It is agreed by the contractor that any such data or information, whether obtained by the contractor pursuant to the aforesaid agreement or from the Government, must be protected from unauthorized use by or unauthorized disclosure to any individual, corporation, or organization so long as it remains proprietary.

(c) The contractor agrees to conduct formal training to make employees aware of the requirement to maintain confidentiality of data and information as required above. The contractor must obtain from each employee in connection with this contract a signed Non-Disclosure Agreement. This agreement must provide that the employee will not, during employment or anytime thereafter, disclose or use for current or future benefit of any party any of the data (to include any form of Sensitive Unclassified Information (SUI) described in FAA Order 1600.75) or information not publically available received in connection with the work under the contract.

(d) The contractor agrees to hold the Government harmless and indemnify the Government as to any cost/loss resulting from the unauthorized use or disclosure of third party data or software by the contractor, its employees, subcontractors, or agents.

(e) The contractor agrees to include the substance of this clause in all subcontracts awarded under this contract. The Contracting Officer will consider case-by-case exceptions to this requirement for individual subcontracts in the event that: (1) the contractor considers this clause to be inappropriate and unnecessary in the case of a particular subcontract; (2) the contractor provides a written statement affirming absolute unwillingness of a subcontractor to perform, absent some relief from the substance of this prohibition and the reason why; (3) use of an alternate subcontract source would unreasonably detract from the quality of effort; and (4) the contractor provides the Contracting Officer timely written advance notice of these and any other extenuating circumstances.

(f) Except as the Contracting Officer specifically authorizes in writing, upon completion of all work under this contract, the contractor must return all such data and information described above obtained from the Government, including all copies, modifications, adaptations, or combinations thereof, to the Contracting Officer. Data obtained from another company must be disposed of in accordance with the contractor's agreement with that company, or if the agreement makes no provision for disposition, must be returned to that company. The contractor must further certify in writing to the CO that all copies, modifications, adaptations, or combinations of such data or information which cannot reasonably be returned to the Contracting Officer (or to the appropriate company), have been deleted from the contractor's (and any subcontractor's) records and destroyed. The FAA reserves the right to audit the deletion. The FAA must provide notice of the audit 10 calendar days prior to the audit.

(g) These restrictions do not limit the contractor's (or subcontractor's) right to use and disclose any data and information obtained from another source without restriction.

(End of clause)

AC0090 ENVIRONMENTAL, SAFETY AND HEALTH (JULY 2016)

(a) The Contractor shall ensure that no person employed on this contract works in surroundings or under conditions that are unsanitary, hazardous, or dangerous to their health or safety. The contractor shall also ensure that all employees receive appropriate and required training for safety, health, environmental, and equipment operations. In fulfilling these requirements, the Contractor shall comply with:

(1) Applicable Federal, State, and local environmental and safety requirements. This includes, but is not limited to, requirements contained in the U.S. Code of Federal Regulations (e.g. 29 CFR, 40 CFR, and 42 CFR) and/or requirements issued by the Oklahoma Department of Environmental Quality and the Oklahoma Corporation Commission.

(2) Supplemental Federal and FAA environmental, safety and health requirements contained in Executive Orders, FAA, and Mike Monroney Aeronautical Center (MMAC) Environmental, Safety and Health Orders, or elsewhere in the contract. Other standards used by the FAA include those sponsored by the National Fire Protection Association (NFPA), the American National Standards Institute (ANSI), the American Society of Testing and Materials (ASTM), etc. This list of standards or laws is not inclusive.

(3) The MMAC Environmental, Occupational Safety and Health Policy states:

-The FAA Mike Monroney Aeronautical Center is fully committed to excellence and leadership in protecting the environment, and the health and safety of our employees and neighbors. It is our policy to ensure that employees, contractors, students, and visitors are provided with workplaces that are free from recognized hazards that may cause death, illness, or injury. Additionally, we will accomplish our mission in a manner that will minimize environmental consequences. All organizations at the Aeronautical Center are responsible to ensure that environmental, safety, and health considerations are integrated into their daily activities and operations. In keeping with this commitment, we will implement, maintain, and continually improve our environmental, safety, and health performance by utilizing a comprehensive Environmental, Occupational Safety and Health Management System which:

-Ensures compliance with all applicable environmental, occupational safety, and health requirements

-Establishes environmental, occupational safety and health metrics

-Prevents injury and illness

-Minimizes pollution and waste; conserves natural resources and improves energy efficiency

-Identifies hazards, assesses risks, and implements controls

Aeronautical Center personnel demonstrate their commitment to this policy by providing products and services in a manner that demonstrates our good stewardship of the environment, and in a manner that ensures a safe and healthy work environment for employees, contractors, students, and visitors.

(4) The environmental requirements of the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) are modeled after the specifications found in the International Standard for Environmental Management, ISO 14001: 2004. The health and safety requirements of the MMAC Environmental, Occupational Safety and Health System (EOSHMS) are modeled after the specifications found in the Occupational Health and Safety Assessment Series, BS OHSAS 18001: 2007. The MMAC EOSHMS requires that all contractors that provide goods and services that can affect MMAC's environmental, occupational safety and health programs shall, prior to start of performance of work under this contract:

(i) Ensure that all employees supporting the contract work activities are:

-Aware of the MMAC Environmental, Occupational Safety and Health Policy as set forth in paragraph (a)(3) above;

-Aware of and conform with the Operational Control documents referenced as attachments in Section J of this solicitation/contract;

-Competent to perform assigned job functions and maintain appropriate records of training or equivalent experience as identified in the above referenced Operational Control documents. Such records shall be made available to the CO or COR upon request.

(ii) Ensure that employees requiring unescorted access to the site have received the MMAC Environmental, Occupational Safety and Health Management System (EOSHMS) General Awareness Briefing, eLMS course # FAA30050017. This training is available on-line at:

https://ksn2.faa.gov/arc/amc/amp/amppublic/SitePages/Training%20-%20Mandatory%20Training.aspx .

(iii) Complete and sign the 'Certification of Contractor Conformance to the MMAC EOSHMS' included in Section K of this solicitation/contract. Contractor's signature of this certification certifies that the contractor has verified that all MMAC EOSHMS requirements have been or will be met and that work performed hereunder shall be in conformance with the MMAC EOSHMS. Submission of this certification is a prerequisite for contract award.

(b) If the Contractor works more than 1000 employee-hours in one quarter on the MMAC Campus, the Contractor shall prepare and submit an annual report of injury and illness information regarding this workforce as specified in 29 CFR 1904. The report shall be submitted to the Contracting Officer not later than November 30 of each year and contain the following information (Note: the following references to fiscal year refer to the Governmental fiscal year, October 1 through September 30):

(1) The number of employee-hours worked during the preceding fiscal year;

(2) The number of OSHA recordable cases (defined as mishaps that result in fatalities, lost workdays, medical treatment, restricted workdays or a loss of consciousness) that occurred during the preceding fiscal year;

(3) The number of cases which resulted in days away and/or restricted/transferred duty that occurred during the preceding fiscal year.

(c) If there are conflicts between any of the requirements referenced in this contract, the more stringent requirement will prevail.

(d) If the Contractor fails or refuses to promptly comply with any environmental, safety or health requirements stated in this Clause, the Contracting Officer's Representative (COR) will notify the Contractor of any such noncompliance and the Contractor shall take immediate corrective action. Such notice, whether oral or written, when served on the Contractor or any of its employees at the site of the work, shall be deemed sufficient. All oral notices will be followed up with a written notice to the Contractor. If the Contractor fails or refuses to promptly correct the condition, the COR may stop all or any portion of the work. When satisfactory corrective action has been taken, the contractor shall request permission to resume work from the COR. No time extension or additional costs, resulting from the directive to stop work shall be allowed. Failure of the COR to provide notice of noncompliance or to stop work shall not relieve the Contractor of its responsibility for the safe performance of the work.

(e) The Contractor shall require contract personnel to wear personal protective equipment when it is necessary because of the hazards on the job and in most instances will provide the equipment and corresponding training, except that which has been specified to be furnished by FAA. All personal protective equipment worn by contractors shall comply with applicable industry standards.

(f) Contractors shall include a clause in all subcontracts to require subcontractors to comply with this clause.

AC3402 FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (MAY 2019)

FAA FACILITY REGULATIONS FOR MMAC CONTRACTORS (APR 2016) CLA.3402

Contractor personnel, including employees of subcontractors at any tier, suppliers, etc., working at or visiting the FAA Mike Monroney Aeronautical Center (MMAC) facility, shall abide by all applicable regulations in effect at the MMAC facility governing their conduct, including, but not limited to, those regulations pertaining to traffic, parking, security, and airport matters. A non-inclusive list of such regulations is provided below. The full text of these are available at the website shown or can be obtained by contacting your Contracting Officer (CO)/Contracting Officer's Representative (COR).

FAA ORDERS/DIRECTIVES

*Contractor & Industrial Security Program FAA Order 1600.72A https://www.faa.gov/documentLibrary/media/Order/ND/1600.72A.pdf

Note: All contractors with access to government computer systems are required to take annual Security Awareness Virtual Initiative (SAVI) training. Information on how to accomplish this training is located at:

https://my.faa.gov/org/linebusiness/ash/programs/savi.html

*Accountability Board FAA Order 1110.125B https://www.faa.gov/documentLibrary/media/Order/FAA_Order_1110.125B.pdf

*FAA Occupational Safety & Health Policy FAA Order 3900.19C https://www.faa.gov/documentLibrary/media/Order/FAA_Order_3900.19C.pdf

*FAA Information Security and Privacy Program and Policy FAA Order 1370.121 https://employees.faa.gov/documentLibrary/media/Order/1370.121.pdf

*Ground Vehicle Operations to include Taxiing, or Towing Aircraft on Airports

Advisory Circular AC 150/5210-20A https://www.faa.gov/airports/resources/advisory_circulars/index.cfm/go/document.information/documentID/102808

*Parking and Traffic AC 1600.21 H Chapter 7 https://ksn2.faa.gov/arc/amc/amp/amppublic/Traffic%20Safety/Forms/AllItems.aspx

*Documents are only available by request from the Contracting Officer.

AC4555 NOTICE OF CONTRACTOR TESTIMONY (SEP 2006)

(a) The contractor shall notify the Contracting Officer promptly in writing of its intention, or the intention of its employees, subcontractors of any tier, or subcontractor employees, either voluntarily or under compulsion of competent authority, to provide sworn testimony on any matter related to or arising under the work required by and/or performed under, this contract. Such written notification at a minimum shall consist of the date and time of the testimony, identification of the court, board, or other body before which the testimony is made, the nature of the testimony to be given to the extent it is known at the time of this report, the nature of the contractor’s involvement in the proceeding and any other circumstances related to the work performed under or related to the contract and the proceeding in which the testimony will be taken.

(b) The contractor shall include the substance of this clause, including this paragraph (b), in all subcontracts executed under this contract and shall require all subcontractors to provide the required report to the contractor.

AC4556 PERSONNEL AND SUPERVISION (JUL 2015)

The contractor shall designate sufficient supervisory personnel to meet task outcomes. Contract supervisors will provide day-to-day supervision of contract personnel including, but not limited to, work monitoring, payroll records, leave, etc. At no time will FAA personnel assume any responsibility for the supervision of contractor personnel.

Government assistance will be available to provide technical and policy guidance through the assigned Contracting Officer’s Representative (COR).

AC4557 STRIKES OR PICKETING

Notwithstanding any other provision hereof, the Contractor is responsible for delays arising out of labor disputes, including but not limited to strikes, if such strikes are reasonably avoidable. A delay caused by a strike or by picketing which constitutes an unfair labor practice is not excusable unless the Contractor takes all reasonable and appropriate action to end such a strike or picketing, such as the filing of a charge with the National Labor Relations

Board, the use of other available Government procedures, and the use of private boards or organizations for the settlement of disputes.

Section I - Contract Clauses Clause List

3.1-1 CLAUSES AND PROVISIONS INCORPORATED BY REFERENCE (JUL 2019)

This screening information request (SIR) or contract, as applicable, incorporates by reference the provisions or clauses listed below with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available, or offerors and contractors may obtain the full text via Internet at:

https://fast.faa.gov/contractclauses.cfm.

(End of clause)

3.1.7-2 ORGANIZATIONAL CONFLICTS OF INTEREST (JUL 2018)

3.2.2.3-29 INTEGRITY OF UNIT PRICES (JUL 2004)

3.2.2.3-33 ORDER OF PRECEDENCE (MAR 2009)

3.2.2.3-83 PROHIBITION AGAINST CONTRACTING WITH INVERTED DOMESTIC

CORPORATIONS (OCT 2015)

3.2.2.7-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (APR 2011)

3.2.2.7-8 DISCLOSURE OF TEAM ARRANGEMENTS (APR 2008)

3.2.2.8-1 MATERIAL REQUIREMENT (OCT 2019)

3.2.5-1 OFFICIALS NOT TO BENEFIT (APR 2021)

3.2.5-3 GRATUITIES OR GIFTS (OCT 2019)

3.2.5-4 CONTINGENT FEES (OCT 1996)

3.2.5-5 ANTI-KICKBACK PROCEDURES (OCT 2019)

3.2.5-8 WHISTLEBLOWER PROTECTION FOR CONTRACTOR EMPLOYEES (APR 1996)

3.3.1-1 PAYMENTS (JUL 2018)

3.3.1-8 EXTRAS (JUL 2018)

3.3.1-15 ASSIGNMENT OF CLAIMS (JUL 2018)

3.3.1-17 PROMPT PAYMENT (JAN 2021)

3.3.1-20 PROVIDING ACCELERATED PAYMENT TO SMALL BUSINESS SUBCONTRACTORS

(OCT 2012)

3.3.1-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER- SYSTEM FOR AWARD

MANAGEMENT (JUL 2018)

3.4.1-10 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (OCT 2020)

3.4.1-12 INSURANCE (OCT 2019)

3.4.2-6 TAXES - CONTRACTS PERFORMED IN U.S. POSSESSIONS OR PUERTO RICO (OCT

1996)

3.4.2-8 FEDERAL, STATE, AND LOCAL TAXES - FIXED PRICE CONTRACT (JUL 2019)

3.5-1 AUTHORIZATION AND CONSENT (JAN 2019)

3.5-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT

(JAN 2009)

3.5-3 PATENT INDEMNITY (APR 2017)

3.5-13 RIGHTS IN DATA - GENERAL (OCT 2014)

3.5-18 COMMERCIAL COMPUTER SOFTWARE LICENSE (JAN 2009)

3.6.1-15 POST-AWARD SMALL BUSINESS PROGRAM RE-REPRESENTATION (JAN 2021)

3.6.2-2 CONVICT LABOR (APR 1996)

3.6.2-9 EQUAL OPPORTUNITY (JUL 2020)

3.6.2-12 EQUAL OPPORTUNITY FOR VETERANS (JUL 2020)

3.6.2-13 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUL 2020)

3.6.2-16 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (OCT 2018)

3.6.2-35 PREVENTION OF SEXUAL HARASSMENT (OCT 2018)

3.6.2-39 TRAFFICKING IN PERSONS (APR 2019)

3.6.2-44 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS

ACT (JAN 2019)

3.6.3-14 USE OF ENVIRONMENTALLY PREFERABLE PRODUCTS (JAN 2020)

3.6.3-16 DRUG FREE WORKPLACE (MAR 2009)

3.6.3-23 DELIVERY OF ELECTRONIC AND PAPER DOCUMENTS (JAN 2020)

3.6.4-10 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JAN 2010)

3.6.4-23 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND

VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (JAN 2021)

3.8.2-19 PROHIBITION ON ADVERTISING (JUL 2019)

3.9.1-1 CONTRACT DISPUTES (JAN 2020)

3.9.1-2 PROTEST AFTER AWARD (AUG 1997)

3.10.1-7 BANKRUPTCY (APR 1996)

3.10.1-12 CHANGES - FIXED-PRICE (APR 1996)

3.10.1-12 CHANGES - FIXED-PRICE (APR 1996) - ALTERNATE II (APR 1996)

3.10.1-25 NOVATION AND CHANGE-OF-NAME AGREEMENTS (OCT 2007)

3.10.2-1 SUBCONTRACTS (FIXED-PRICE CONTRACTS) (JAN 2019)

3.10.3-2 GOVERNMENT PROPERTY - BASIC CLAUSE (APR 2019)

3.10.6-1 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED PRICE) (OCT

1996)

3.10.6-4 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (JAN 2020)

3.13-5 SEAT BELT USE BY CONTRACTOR EMPLOYEES (OCT 2001)

3.13-11 PLAIN LANGUAGE (JUL 2006)

3.13-13 CONTRACTOR POLICY TO BAN TEXT MESSAGING WHILE DRIVING (JAN 2011)

3.14-5 SENSITIVE UNCLASSIFIED INFORMATION (SUI) (JUL 2013)

3.14-6 PRIVACY OR SECURITY SAFEGUARDS (NOV 2016)

3.2.4-34 OPTION TO EXTEND SERVICES (OCT 2019)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of performance hereunder must not exceed 6 months. The Contracting Officer may exercise the option by written notice to the Contractor within the period specified in the Schedule.

(End of clause)

3.3.1-11 AVAILABILITY OF FUNDS FOR THE NEXT FISCAL YEAR (APR 1996)

Funds are not presently available for performance under this contract beyond the current fiscal year. The FAA's obligation for performance of this contract beyond that date is contingent upon the availability of appropriated funds from which payment for contract purposes can be made. No legal liability on the part of the FAA for any payment may arise for performance under this contract beyond the current fiscal year, until funds are made available to the Contracting Officer for performance and until the Contractor receives notice of availability, to be confirmed in writing by the Contracting Officer.

(End of clause)

3.3.1-33 SYSTEM FOR AWARD MANAGEMENT (JUL 2018)

(a) Definitions. As used in this clause

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts for the same parent concern.

"Registered in the SAM database" means that the Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the SAM database.

"System for Award Management (SAM) Database" means the primary Government repository for Contractor information required for the conduct of business with the Government.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee must be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror must enter, in Representations, Certifications and Other Statements of Offerors Section of the solicitation, the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number

(i) If located within the United States, by calling Dun and Bradstreet at 1-866-705-5711 or via the Internet at http://fedgov.dnb.com/webform; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if different from physical street address).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer may proceed to award to the next otherwise successful registered offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the SAM database, and for any liability resulting from the Government's reliance on inaccurate or incomplete data. To remain registered in the SAM database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the SAM database to ensure it is current, accurate and complete. Updating information in the SAM does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document. If registered in SAM as a Service-Disabled Veteran-Owned Small Business (SDVOSB), by submission of an offer, the offeror acknowledges that they are designated as a SDVOSB by the Department of Veterans Affairs, and this designation appears as such on the Veteran Affairs website, https://www.vip.vetbiz.gov.

(g)(1)(i) If a Contractor has legally changed its business name, "doing business as" name, or division name (whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in AMS Procurement Guidance, the Contractor must provide the responsible Contracting Officer a minimum of one business day's written notification of its intention to:

(A) change the name in the SAM database;

(B) comply with the requirements of AMS regarding novation and change-of-name agreements; and

(C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide the Contracting Officer with the notification, sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph (g)(1)(i)(C) of this clause, and, in the absence of a properly executed novation or change-of-name agreement, the SAM information that shows the Contractor to be other than the Contractor indicated in the contract will be considered to be incorrect information within the meaning of the "Suspension of Payment" paragraph of the electronic funds transfer (EFT) clause of this contract.

(2) The Contractor must not change the name or address for EFT payments or manual payments, as appropriate, in the SAM record to reflect an assignee for the purpose of assignment of claims. Assignees must be separately registered in the SAM database. Information provided to the Contractor's SAM record that indicates payments, including those made by EFT, to an ultimate recipient other than that Contractor will be considered to be incorrect information within the meaning of the "Suspension of payment" paragraph of the EFT clause of this contract.

(h) Offerors and Contractors may obtain information on registration and annual confirmation requirements via the internet at http://www.sam.gov.

(End of Clause)

3.3.1-40 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS (JAN 2021)

(a) Definitions. As used in this clause-

(1) "Contract financing" is a contractual authorization for payments to a contractor prior to acceptance of products or services by FAA.

(2) "Payment request" means a bill, voucher, invoice, or request for contract financing payment or invoice payment with associated supporting documentation. The payment request must comply with the requirements identified in this clause, and the applicable Payment clause and invoicing requirements included in this contract

(3) "Electronic form" means an automated system transmitting information electronically according to the accepted electronic data transmission methods and formats identified in paragraph (c) of this clause. Facsimile, email, and scanned documents are not acceptable electronic forms for submission of payment requests.

(4) "Invoice payment" means a Government disbursement of monies to a Contractor under a contract or other authorization for supplies or services accepted by the Government. This includes payments for partial deliveries that have been accepted by the Government, final payments under T&M and labor-hour contracts, and final cost or fee payments where amounts owed have been settled between the Government and the Contractor.

(b) Electronic payment requests. Except as provided in paragraph (f) of this clause, the contractor must submit payment requests in electronic form. Purchases paid with a Government purchase card are considered to be an electronic transaction for purposes of this rule, and therefore no additional electronic invoice submission is required.

(c) The Federal Aviation Administration utilizes the Delphi eInvoicing web-portal for processing invoices.

Contractors submitting invoices are required to submit invoices via the Delphi eInvoicing web portal which is accessed and authenticated via www.login.gov

(d) In order to receive payment and in accordance with prompt payment standards, contractors must submit a proper invoice. All invoices submitted as attachments in the Delphi eInvoicing web-portal must contain the following:

(1) Invoice number and invoice date.

(2) Period of performance covered by invoice.

(3) Contract number and title.

(4) Task/Delivery Order number and title (if applicable).

(5) Amount billed (by CLIN), current and cumulative.

(6) Total ($) of billing.

(7) Cumulative total billed for all contract work to date.

(8) Name, title, phone number, mailing address, and email address (if available) of person to be contacted in the event of a defective invoice.

If the contract includes allowances for travel, all invoices which include charges pertaining to travel expenses will catalog a breakdown of reimbursable expenses with the appropriate receipts to substantiate the travel expenses.

(e) Payment system registration. All persons accessing the Delphi eInvoicing web-portal will be required to have their own unique user Delphi eInvoicing ID and password and be credentialed through login.gov.

(1) Electronic authentication. See www.login.gov for instructions. Click on the following link for instructions on establishing a login.gov account: https://login.gov/help/creating-an-account/how-do-i-create-an-account-with-logingov/.

(2) To create a login.gov account, the user will need a valid email address and a working phone number. The user will create a password and then login.gov will reply with an email confirming the email address.

(3) DELPHI registration instructions. New users should navigate to http://einvoice.esc.gov to establish an account.

Users are required to log in every 45 days to keep it active.

(4) Training on DELPHI. To facilitate use of DELPHI, comprehensive user information is available at http://einvoice.esc.gov

(5) Account Management. Contractors are responsible to contact the DELPHI Help Desk when their firm's points of contacts will no longer be submitting invoices so they can be removed from the system. Instructions for contacting the DELPHI Help D can be found at http://einvoice.esc.gov

(f) Waivers: If the contractor does not believe electronic invoicing can be used if they are awarded this contract, the contractor must respond accordingly to 3.3.1-41 "Electronic Invoicing-Representation". Waiver requests must be approved by the FAA and DOT and will be processed expeditiously upon contract award. If the waiver request is not approved, the contractor must use electronic invoicing consistent with this clause. If the waiver request is approved, conversion to electronic invoicing at a later date may be required. While the waiver is in effect, the current invoicing process must be used per AMS Guidance T3.3.1A.14 and the terms of the contract. The decision regarding a waiver request is not subject to the "Contract Disputes" clause AMS 3.9.1-1.

3.6.2-14 EMPLOYMENT REPORTS ON VETERANS (JAN 2020)

(a) Unless the contractor is a State or local government agency, the contractor must report at least annually, as required by the Secretary of Labor, on:

(1) The total number of employees in the contractor's workforce, by job category and hiring location, who are disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans,

(2) The total number of new employees hired during the period covered by the report, and of the total, the number of disabled veterans, other protected veterans, Armed Forces service medal veterans, and recently separated veterans; and

(3) The maximum number and minimum number of employees of the Contractor or subcontractor at each hiring location during the period covered by the report.

(b) The above items must be reported by completing the VETS-4212 "Federal Contractor Veterans' Employment Report" (see "VETS-4212 Federal Contractor Reporting" and "Filing Your VETS-4212 Report" at http://www.dol.gov/vets/vets4212.htm).'

(c) The VETS-4212 Report must be submitted no later than September 30 of each year.

(d) The employment activity report required by paragraph (a)(2) of this clause must reflect total hires during the most recent 12-month period as of the ending date selected for the employment profile report required by paragraph (a)(1) of this clause. Contractors may select an ending date: (1) As of the end of any pay period during the period January through March 1st of the year the report is due, or (2) as of December 31, if the contractor has previous written approval from the Equal Employment Opportunity Commission to do so for purposes of submitting the Employer Information Report EEO-1 (Standard Form 100).

(e) The count of veterans reported according to paragraph (a) of this clause must be based on data known…