47PM0518R0019_Solicitation_Package.pdf

Table Of Contents

Section Description Page Number Standard Form Standard Form 1 Volume 1 - RFP Volume 1 - RFP 4

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

14/4/2018

4:00 PM (EST)

5/4/2018

47PM0518R0019

EQWPIDBB-18-0010

202-690-9499Michael Spriggs

Standard Form Page 1

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

27. PAYMENT WILL BE MADE BY

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Isaac Karto

Standard Form Page 2

PAGE

GENERAL SERVICES ADMINISTRATION

OF

ITEM NO., FORM OR

STOCK NUMBER DESCRIPTION OF ARTICLES OR SERVICES QUAN-

TITY

UNIT

OF

ISSUE

UNIT

PRICE

AMOUNT

FURTHER INFORMATION, PLEASE

identified transformers to be identified transformers (9 KVA –

PoP: 06/29/2018 - 08/05/2019

– 1), (300 KVA; Total: 106

Contractor shall provide all

Washington, DC 20585. FOR kind) Replacement of the

OUTLINED IN SOW

PoP: 06/29/2018 - 08/05/2019 at 1000 Independence Ave. SW, REPLACEMENT - DOE FORRESTAL BLDG throughout the Forrestal complex

KVA – 9), (150 KVA -2), (225 KVA

the size equivalent (like in

DOE CHILD DEVELOPMENT CENTER, AS

(202) 708-6415

KVA – 40), (75 KVA – 32), (112.5

DESIGN BUILD TRANSFORMER

REPLACE ELECTRICAL TRANSFORMERS

design documentation and perform

KYLE LEAR ON (301) 606-0258 OR

transformers are located

CHILD DEV CTR

replaced. All identified supervision to provide complete

EA

(25 KVA – 2), (30 KVA- 11), (45

CONTACT GSA PROJECT MANAGER,

1), (14 KVA – 1), (15 KVA -6),

TRANSFORMER REPLACEMENT - DOE

labor, material, equipment and

EA

Standard Form Page 3

GSA Solicitation No. 47PM0518R0019

Document: C201-SB / DEC 2016 (The Solicitation) Pages 1 of 27

Construction Contract for DRY-TYPE TRANSFORMER

REPLACEMENT

The Solicitation

Notice to Offerors of Total Service-Disabled Veteran-Owned Small Business Set-Aside

The General Services Administration (GSA) is setting aside the contract under the following clause found in the Agreement:

52.219-27, Notice of Total Service-Disabled Veteran-Owned Small Business Set-Aside

Volume 1 - RFP Page 4

(The Solicitation) Pages 2 of 27

Table of Contents

I. General Information

A. The Solicitation and Contract B. List of Solicitation Documents C. Authorized Representatives

D. Pre-Proposal Conference

E. Estimated Price Range

F. FAR 52.228-1 Bid Guarantee

G. FAR 52.236-27 Site Visit - Construction

H. Receipt of Offers

II. Proposals

A. Proposal Contents

B. Proposal Format C. Price Proposal D. Technical Proposal E. Other Information to be Submitted with Proposal F. Requirements for Joint Venture Offerors

III. General Provisions

A. Availability of Funds B. Requests for Clarification or Interpretation C. Notice to Small Business Firms D. Information Concerning the Disclosure of Solicitation Results E. Affirmative Procurement Program F. Notice Concerning Preparation of Proposals G. Contractor Performance Information H. Safeguarding Documents Designated as Sensitive But Unclassified I. Additional Security Requirements

IV. FAR/GSAR Solicitation Provisions

A. FAR 52.215-1 Instructions to Offerors—Competitive Acquisition B. FAR 52.216-1 Type of Contract C. FAR 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work D. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal

Employment Opportunity for Construction E. FAR 52.233-2 Service of Protest F. Buy American G. Buy American Exceptions H. Special 8(a) Requirements I. FAR 52.252-1 Solicitation Provisions Incorporated by Reference J. GSAR 552.102 Incorporating Provisions and Clauses by Reference

Volume 1 - RFP Page 5

(The Solicitation) Pages 3 of 27

V. Additional Solicitation Provisions and Instructions

A. FAR 52.211-1 Availability of Specifications Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29

B. FAR 52.211-3 Availability of Specifications Not Listed in the GSA Index of Federal Specifications, Standards and Commercial Item Descriptions

C. Additional Provisions D. Additional Clauses E. FAR 52.222-62 Paid Sick Leave F. FAR 52.222-60 Paycheck Transparency

VI. Method of Award

A. Evaluation of Offers

B. Determination of Responsibility

C. Price Reasonableness / Price Realism

D. Unbalanced Prices

E. Total Evaluated Price

F. Non-Price Factors

G. Evaluation of Joint Venture Offerors

Volume 1 - RFP Page 6

(The Solicitation) Pages 4 of 27

I. General Information

I.A. The Solicitation and Contract

(1) This Solicitation is set-aside for Service-Disabled Veteran-Owned Small Businesses within a 50 mile radius of Washington. DC in accordance with FAR 19. This Solicitation sets forth requirements for proposals for a Contract to construct the Project described in the attached Agreement. Proposals conforming to the Solicitation requirements will be evaluated in accordance with the Method of Award set forth herein. The Government will award the Contract to the selected Offeror, subject to the conditions set forth herein.

(2) Neither the Solicitation nor any part of an Offeror's proposal shall be part of the Contract except to the extent expressly incorporated therein by the Contracting Officer.

(3) The Offeror's proposal submitted in response to this Solicitation shall constitute a firm offer.

No contract shall be formed unless and until the Contracting Officer has countersigned the SF 1442 submitted by an Offeror, and delivered to the Contractor a copy of the SF 1442 with original signatures together with the Agreement reflecting the Offeror's proposed prices.

I.B. List of Solicitation Documents

The Solicitation Documents are comprised of:

(1) The Solicitation

(2) Offeror Representations and Certifications Form

(3) Other Forms Required For Submission with Proposals

(4) Standard Form (SF) 1442 – Solicitation Offer and Award

(5) The Agreement and Attachments to the Agreement

(6) Other Attachments

I.C. Authorized Representatives

The following individuals are designated as the authorized GSA representatives under this Solicitation:

(1) Contracting Officer

Name: Isaac Karto

Address: 301 7th St. SW Washington, DC 20024 Telephone: 817-505-5020

Email: Isaac.karto@gsa.gov

(2) Alternate Point of Contact

Name: Michael Spriggs Address: 301 7th St. SW Washington. DC 20024

Telephone: 202-297-7813 Email: Michael.spriggs@gsa.gov

I.D. Pre-Proposal Conference

(1) A pre-proposal conference regarding this Solicitation is scheduled as follows:

Volume 1 - RFP Page 7

(The Solicitation) Pages 5 of 27

I.E. Estimated Price Range

The estimated price range for the Project is between $2,000,000.00 and $2,6000,000.00.

I.F. FAR 52.228-1 Bid Guarantee (SEP 96)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

I.G. FAR 52.236-27 Site Visit - Construction (FEB 95)

(1) The clauses at FAR 52.236-2, Differing Site Conditions, and FAR 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation and are in the attached Agreement. Accordingly, Offerors are urged and expected to inspect the site where the work will be performed.

(2) Site visits will be held at the following dates and times:

Date: 4/12/18

Time: 10:00am

Volume 1 - RFP Page 8 http://www.acquisition.gov/far/current/html/52_233_240.html#wp1113365 http://www.acquisition.gov/far/current/html/52_233_240.html#wp1113375

(The Solicitation) Pages 6 of 27

(3) Pre-registration is required for all attendees to the pre-proposal Site Visit. The Site Visit shall be limited to not more than three (3) representatives from each Offeror. Offerors shall submit a Visit Authorization Request (VAR) identifying all attendees from their respective team.

Participants must have a valid, Government issued picture identification, driver’s license preferred, to gain access for the pre-proposal Site Visit. Notification of the location of entry, where attendees are required to meet, and all other requirements for the Site Visit will be issued to the Offerors. Submit the VAR to the point of contact listed below.

For further information about the site visit or access requirements, please contact:

Name: [Michael Spriggs ] Address: [301 7th St. SW Washington, DC 20024 ]

Telephone: [202-297-7813 ] Email: [Michael.spriggs@gsa.gov ]

Questions regarding this RFP will be addressed at a pre-proposal conference. All prospective Offerors shall submit in advance and in writing any questions they may have to Michael Spriggs at michael.spriggs@gsa.gov. The submission of written questions will not preclude anyone from posing questions during the pre-proposal conference.

(4) Failure of a prospective Offeror to attend the pre-proposal conference will be construed to mean that the Offeror fully understands all requirements of the solicitation. Prospective Offerors are advised that the pre-proposal conference will be held solely for the purpose of explaining the concepts involved in the, specifications, terms, drawings and conditions of this solicitation. Interested Offerors are strongly encouraged to attend the pre-proposal conference. A site visit will be included as part of the pre-proposal conference.

I.H. Receipt of Offers

(1) In order to be considered for award, offers conforming to the requirements of the Solicitation must be received at the following office no later than 4:00 pm local time on the following date and at the following address:

Date: 5/4/18

Address: Michael.spriggs@gsa.gov

(2) Offers sent by commercial package delivery and hand delivery shall be deemed received as of the date and time of delivery to the office designated for receipt of offers.

(3) Offers sent by United States Mail shall be deemed timely if delivered to the address of the government installation designated for receipt of offers on or before the date established for receipt of offers.

Volume 1 - RFP Page 9

(The Solicitation) Pages 7 of 27

II. Proposals

II.A. Proposal Contents

Proposals shall consist of the following documents, completed and executed in accordance with this Solicitation:

(1) Price Proposal

(2) Technical Proposal

(3) Representations and Certifications (C301)

(4) Bid Guarantee, using Standard Form 24

(5) GSA Form 527 – Contractor’s Qualification and Financial Information

Form 527 will requested from the highest evaluated offeror after evaluations are complete.

(6) Other Documents as Required

II.B. Proposal Format The proposal shall be submitted electronically to Michael Spriggs via email at Michael.spriggs@gsa.gov.

II.C. Price Proposal

(1) Contents

The Price Proposal shall consist of the SF 1442 and the Agreement, with prices and/or rates indicated for each price element shown on the pricing form included in Section II of the Agreement. Indicate the Base Contract Price, or if no such distinction is made, the Contract Price, in Block 17 of the SF 1442, which must be fully executed by the Offeror.

(2) Qualifications, Exclusions and Conditions

If the Offeror communicates in its proposal any qualifications, exclusions, or conditions to the proposed prices not provided for in the Contract Documents, the Contracting Officer may reject the proposal and exclude the Offeror from further discussions.

(3) Additional Price Proposal Requirements: Please make sure your price provides a full breakdown of your pricing including all labor hours, labor rates, material quantities, material cost, overhead, profit, etc.

II.D. Technical Proposal

The Technical Proposal shall include the information requested below for the non-price factors described in Section VI.

1) Resource Availability, 30%

2) Key Personnel, Weight 20%

3) Technical and Management Approach, Weight: 20%

4) Past Experience, Weight: 15%

Volume 1 - RFP Page 10 mailto:Michael.spriggs@gsa.gov

(The Solicitation) Pages 8 of 27

5) Past Performance, Weight: 15%

1) FACTOR: Resource Availability (Weight 30%):

Description:

This factor considers the resource availability of the proposed personnel to preform work on this project.

Submittal Requirement:

Offerors are required to indicate on their staffing plan the availability of their proposed key personnel to perform work on this contract.

Offerors are required to provide the information below for all key personnel:

- Current and future projects key personnel have been assigned

- When each team member is available to perform work on this contract

- Amount of time individual will dedicate to this project

Offerors are required to demonstrate that they have the available resources regarding

Contractor owned such as but not limited to:

-Tools

-Equipment

-Technology

-Transportation

In order to meet all phases and work packages awarded under this Government Contract.

The offerors must also demonstrate that they have the knowledge and experience of the Market

Research of the transformer Industry in providing equipment, materials and design services to meet both the awarded contact requirements and the period of performance with the minimal or no delay's to the project.

Standard for Evaluation:

The standard is met when:

The Offeror submits the information, as described in the Submittal Requirements

Key personnel are available to perform work on this project, without conflicts from other project obligations.

2) FACTOR: Key Personnel (Weight 20%):

This factor considers the education, knowledge, experience, and expertise of the offeror’s key personnel proposed to be assigned directly to the contract. Key personnel include, Project

Manager or Coordinator, On-Site Superintendent, Design Team, and Construction Supervisor.

- Offerors are required to show a staffing plan that indicates responsibilities of key personnel and how they interface with major subcontractors.

- Offerors are required to provide resumes of key personnel that contain the following information:

Volume 1 - RFP Page 11

(The Solicitation) Pages 9 of 27

- Names of key personnel and title

- Training, Certificates/Licenses, Trade associations belonging to and/or involved with

- Experience and duties

- List 3 similar projects on which key personnel have successfully completed in the last 5 years from the date of issuance of this solicitation. All 3 projects must be submitted in the format listed below (each key personnel member must be listed on at least 3 projects, one project can reference multiple members of the key personnel):

- Project title and contract number

- Key personnel who performed on this contract, and what role they played

- Contract period and project size in square footage for construction services

- Name and current phone number of owner representative most familiar with the project

- Project description

- Completed construction amount and amount of liquidated damage assessed, if any

If experience of key personnel was obtained while in the employment of another firm, identify the firm and a representative of that firm by name, address, and current phone number.

The Offeror submits a staffing plan that clearly that indicates the responsibilities of key personnel and how they interface with major subcontractors.

The Offeror submits resumes for all of the key personnel proposed for the contract.

All resumes for key personnel contain all of the Submittal Requirements listed above.

All key personnel have participated in at least three similar projects performed within the last 5 years.

All resumes for the key personnel show the required qualifications, experience, skills and abilities to successfully manage task orders to be awarded under this contract.

3) FACTOR: Technical and Management Approach (Weight 20%)

This factor considers the Offeror’s proposed technical and management approach to perform the work under this project, including the general scope and approach to meet the project goals.

The Offeror shall submit a narrative describing their:

- Plan for organizing and controlling the project cost and schedule

- An understanding of the project scope and goals (Design and Construction Services)

- Plan outlining the proposed technical approach to complete the project

- Plan outlining of the proposed Risk Management, Quality Control, Safety, Organization and Communication

The Offeror submits a narrative containing all the items of the Submittal Requirements.

Volume 1 - RFP Page 12

(The Solicitation) Pages 10 of 27

The submitted plan demonstrates that the Offeror has a clear understanding of the project scope and their proposed technical and management approach meets the project goals related to design and construction of electrical and fire alarm systems.

4) FACTOR: Past Experience (Weight 15%)

This factor considers the quality of the Offeror's experience in carrying out work of a similar nature, in the same geographic location, with respect to design and construction.

Considerations will be given to success in areas of technical quality, delivery, timeliness and completion within budget.

Submittal Requirement: Provide samples of five (5) projects successfully completed in the past five (5) years from the date of issuance of this solicitation. Three (3) of the five projects submitted should meet the definition of similar.

The Offeror submits five projects performed within the last 5 years, at least three of these meet the definition of similar (electrical work).

The submitted projects demonstrate successful completion by the Offeror.

The total electrical project construction cost was at least $3.0 million and in an occupied and functional building.

5) FACTOR: Past Performance (Weight 15%):

Information to be evaluated includes timeliness of delivery/performance, including adherence to contract schedules and timely submission or performance of design submissions and submittals. Resolution of disputes and delays, number of contract extensions, conformance to contract requirements, including quality of workmanship, ability to correct deficiencies in a timely manner, number and extent of warranty problems. The offeror's history for reasonable and cooperative behavior and commitment to customer satisfaction; and generally, the offeror's business-like concern for the interest of the customer.

List five (5) construction projects that your firm has successfully completed over the last 5 years from the date of issuance of this solicitation. All 5 projects must, at a minimum, contain the following:

- Project title and contract number

- Offeror’s role in the contract (prime or subcontractor); if subcontractor, list name, address, and phone number of prime contractor

- Name of person representing the customer who is familiar with the project and their current phone number

Volume 1 - RFP Page 13

(The Solicitation) Pages 11 of 27

- Project description and place of performance

- Contract period

- Project size in square footage for construction services

- Description of work done directly by offeror

- Description of work done by subcontractor(s), if applicable (subcontracting plan)

- Original construction award amount

- Actual completion amount

- Number of customer initiated change orders and number of contractor initiated change orders

- Planned completion date and actual completion date

- Amount of liquidated damages assessed

- Name of Offeror’s project manager for the project

At least 3 of the above projects shall demonstrate the offeror's past performance with projects of similar scope/type of work items.(electrical work)

NOTE: According to FAR 15.305(a)(2)(iv); Offerors will not be rated favorably or unfavorably for having no relevant past performance. A rating of Neutral will be given for this evaluation factor if the Offeror has no relevant past performance.

The Offeror submits five construction projects performed within the last 5 years. Three of the projects listed are of similar scope/type of work items.

The submitted projects demonstrate successful completion by the Offeror.

II.E. Other Information to Submit with Proposal

(1) Representations and Certifications

Offerors submitting a proposal in response to this Solicitation shall complete electronic Annual Representations and Certifications in conjunction with required Entity registration in the System for Award Management (SAM), accessed via https://www.sam.gov. Offerors shall also submit with their proposal, the Annual Representations and Certifications (FAR 52.204-8), using the attached Offeror’s Representations and Certifications (C301).

(2) Qualifications of Offerors

Offerors submitting a proposal in response to this Solicitation shall submit with their proposal evidence of their financial responsibility and capacity to perform the Contract. Offerors shall submit this information on GSA Form 527 – Contractor’s Qualifications and Financial Information. Where applicable, point of contact, including names and telephone numbers, are required for all contracts listed.

Volume 1 - RFP Page 14 https://www.sam.gov/

(The Solicitation) Pages 12 of 27

II.F. Requirements for Joint Venture Offerors

(1) All offers submitted by joint ventures must include a copy of an executed joint venture agreement (with original signatures) which fully discloses the legal identity of each member of the joint venture, the relationship between the members, the form of ownership of each member, and any limitations on liability or authority for each member.

(2) An authorized representative of each member of the joint venture must sign the SF 1442 accompanying an offer regardless of any agency relationship established between the members.

(3) In the case of corporations that are joint venture members, the corporation secretary must certify that the corporation is authorized to participate in the joint venture, either by so certifying in the joint venture agreement, or by submitting a separate certification to the Government. The joint venture must also provide a certificate that identifies a principal representative of the joint venture with full authority to bind the joint venture.

(4) Representations and certifications, financial information, and past performance information must be submitted for each member of the joint venture.

III. General Provisions

III.A. Availability of Funds

Issuance of this Solicitation does not warrant that funds are presently available for award of a Contract. Award of the contract shall be subject to the availability of appropriated funds, and the Government shall incur no obligation under this Solicitation in advance of such time as funds are made available to the Contracting Officer for the purpose of contract award.

III.B. Requests for Clarification or Interpretation

The Government will attempt to answer all requests for clarifications or interpretations of the Solicitation Documents prior to the date set for receipt of offers, but does not warrant that all such requests will be answered within 15 calendar days. Prospective Offerors should make such requests not less than 15 calendar days prior to the date set for receipt of offers.

III.C. Notice to Small Business Firms

A program for the purpose of assisting qualified small business concerns in obtaining certain bid, payment, or performance bonds that are otherwise not obtainable is available through the Small Business Administration (SBA) (www.sba.gov). For information concerning SBA's surety bond guarantee assistance, contact your SBA District Office.

III.D. Information Concerning the Disclosure of Solicitation Results

This acquisition is being conducted under the provisions of FAR Part 15 as a negotiated procurement. In accordance with FAR 3.104 and FAR 15.207, after receipt of proposals, no information regarding the identity of those submitting offers, the number of offers received, or the information contained in such offers will be made available until after award except as provided by FAR 15.503.

III.E. Affirmative Procurement Program

Volume 1 - RFP Page 15 http://www.sba.gov/

(The Solicitation) Pages 13 of 27

GSA has implemented an Affirmative Procurement Program (APP) intended to maximize the use of recovered materials, environmentally preferable, and bio-based products. Offerors should familiarize themselves with the requirements for using and reporting on the use of such materials in performance as set forth in the Agreement. Refer to clauses FAR 52.204-4 requiring double sided printing on recycled paper for all reports and FAR 52.223-10 encouraging vendors to practice waste reduction.

III.F. Notice Concerning Preparation of Proposals

Offerors are cautioned to carefully read the entire Solicitation and the Agreement to be included in the Contract contemplated by the Solicitation in order to be fully aware of all requirements and clauses in the contemplated Contract. Verify that all blanks requiring information to be supplied in an Offer have been properly filled out, that all pricing and other numerical data is accurately calculated, and that all copies of the Offer contain the same information.

III.G. Contractor Performance Information

(1) Evaluating Contractor Performance: The General Services Administration is using the Contractor Performance Assessment Reporting System (CPARS) module as the secure, confidential, information management tool to facilitate the performance evaluation process.

CPARS enables a comprehensive evaluation by capturing comments from both GSA and the contractor. The website for CPARS is http://www.cpars.gov

Completed CPARS evaluations are sent to the Past Performance Information Retrieval System (PPIRS) which may then be used by Federal acquisition community for use in making source selection decisions. PPIRS assists acquisition officials by serving as the single source for contractor past performance data.

(2) CPARS Registration: Each award requiring an evaluation must be registered in CPARS.

The contractor will receive several automated emails. Within thirty days of award, the contractor will receive an e-mail that contains user account information, as well as the applicable contract and order number(s) assigned. Contractors will be granted one user account to access all evaluations.

(3) Contractor CPARS Training: Contractors may sign up for CPARS training. A schedule of classes will be posted to the CPARS training site (http://www.cpars.gov/allapps/cpcbtdlf.htm) and updated as needed.

(4) Contractor Representative (CR) Role: All evaluations will be sent the Contractor Representative (CR) named on your award. The CR will be able to access CPARS to review and comment on the evaluation. If your CR is not already in the CPARS system, the contracting officer will request the name and email address of the person that will be responsible for the CR role on your award.

Once an evaluation is ready to be released the CR will receive an email alerting them the evaluation is ready for their review and comment. The email will indicate the time frame the CR has to respond to the evaluation; however, the CR may return the evaluation earlier than this date.

GSA shall provide for review at a level above the contracting officer (i.e., contracting director) to consider any disagreement between GSA and the contractor regarding GSA’s evaluation of the contractor. Based on the review, the individual at a level above the contracting officer will issue the ultimate conclusion on the performance evaluation.

Volume 1 - RFP Page 16 http://www.cpars.gov/ http://www.cpars.gov/allapps/cpcbtdlf.htm

(The Solicitation) Pages 14 of 27

Copies of the evaluations, contractor responses, and review comments, if any, will be retained as part of the contract file.

III.H. Safeguarding Documents Designated as Sensitive But Unclassified

Certain information contained in the Solicitation Documents may have been designated as Sensitive but Unclassified (SBU) building information. With respect to such information, Offerors shall agree to the terms for receipt of such information, as set forth in the provision “Administrative Matters” in Section III of the Agreement, as a condition of receipt of such information.

III.I. Additional Security Requirements

(1) FAR 52.204-9, Personal Identity Verification of Contractor Personnel, January 2011

(2) GSAR Clause 552.204-9, Personal Identity Verification Requirements, October 2012

IV. FAR/GSAR Solicitation Provisions

IV.A. FAR 52.215-1 Instructions to Offerors—Competitive Acquisition (JAN 04)

(a) Definitions. As used in this provision— “Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer’s discretion, result in the offeror being allowed to revise its proposal.

“In writing,” “writing,” or “written” means any worded or numbered expression that can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation’s closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time,” if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and

(ii) showing the time and date specified for receipt, the solicitation number, and the name and

Volume 1 - RFP Page 17

(The Solicitation) Pages 15 of 27 address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show—

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror’s behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal.

Proposals signed by an agent shall be accompanied by evidence of that agent’s authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii) (A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and—

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation

Volume 1 - RFP Page 18

(The Solicitation) Pages 16 of 27 authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225- 17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall—

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed—in whole or in part—for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of—or in connection with—the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award.

(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government’s interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

Volume 1 - RFP Page 19

(The Solicitation) Pages 17 of 27

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government’s best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government. (f)(4) The Government intends to evaluate proposals and award a contract after conducting discussions with offerors whose proposals have been determined to be within the competitive range. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals. Therefore, the offeror's initial proposal should contain the offeror's best terms from a price and technical standpoint.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more contract line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency’s evaluation of the significant weak or deficient factors in the debriefed offeror’s offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

Volume 1 - RFP Page 20

(The Solicitation) Pages 18 of 27

IV.B. FAR 52.216-1 Type of Contract (APR 84)

The Government contemplates award of a Firm-Fixed-Price contract resulting from this solicitation.

IV.C. FAR 52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

(MAY 14)

(a) (1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b) (1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

IV.D. FAR 52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction (FEB 1999)

(Applicable to solicitations resulting in construction contracts in excess of $10,000.)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade

Goals for Female Participation for Each Trade

29%.

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative

Volume 1 - RFP Page 21

(The Solicitation) Pages 19 of 27

Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the--

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is:

Washington, DC

IV.E. FAR 52.233-2 Service of Protest (SEP 06)

(a) Protests, as defined in section 31.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and…