36C24624Q0929_1.docx

1. SOLICITATION NUMBER

2. TYPE OF SOLICITATION

3. DATE ISSUED

PAGE OF PAGES

4. CONTRACT NUMBER

5.

REQUISITION/PURCHASE REQUEST NUMBER

6. PROJECT NUMBER

7. ISSUED BY

CODE

8. ADDRESS OFFER TO

a. NAME

b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE

DOCUMENTS (

Title, identifying number, date) 12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12b. CALENDAR DAYS

13. ADDITIONAL

SOLICITATION REQUIREMENTS:

STANDARD FORM 1442 (REV. 8/2014)

STANDARD FORM 1442

Prescribed by GSA-FAR (48 CFR) 52.236-1(d)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

SOLICITATION

SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR INFORMATION

CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SEALED BID (IFB)

NEGOTIATED (RFP)

1. The Contractor shall begin performance within ____________ calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See

YES

NO

a.

Sealed offers in original and ___________________copies to perform the work required are due at the place specified in Item 8 by _____________ (hour) local time _____________________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, the date and time offers are due.

b.

An offer guarantee is, is not required.

c.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d.

Offers providing less than ____ ___________________ calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

36C24624Q0929 X 07-29-2024 565-24-109 Department of Veterans Affairs Network Contracting Office 6 201 Hay Street, Suite 304 Fayetteville NC 28301 Department of Veterans Affairs Network Contracting Office 6 201 Hay Street, Suite 304 Fayetteville NC 28301 Wayne Goodmond 910.824.9189 Replace Fire/Smoke Dampers Bldg. 1

Issue Date: July 29, 2024 Site Visit: August 6, 2024 RFI Due Date: August 9, 2024 Solicitation Due: August 29, 2024

REQUIRED CERTIFICATION: THE CERTIFICATION CITED AT 852.219-75, VA NOTICE OF

LIMITATIONS ON SUBCONTRACTING –

CERTIFICATE OF COMPLIANCE FOR SERVICES

AND CONSTRUCTION (SEP 2021) (DEVIATION) –

This certification is required to be completed and accompany your submitted bid.

Failure to complete will result in your bid to be determined non-Responsive.

Reference page 52 and 53 of 69

X X 52.211-10 X 15:00

EDT

08-29-2024 X

14. NAME AND ADDRESS OF

OFFEROR

15. TELEPHONE NUMBER

16. REMITTANCE ADDRESS

CODE

FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of the solicitation, if this offer is accepted by the Government in writing within __________ calendar days after the date offers are due.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

ITEM

25. OTHER THAN FULL

AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c 41 U.S.C. 3304(a) (

26. ADMINISTERED BY

27. PAYMENT WILL BE MADE BY

PHONE:

FAX:

28. NEGOTIATED AGREEMENT

29. AWARD

Your Contractor agrees offer on this solicitation is hereby accepted as to the items listed. This to furnish and deliver all items or perform all work requirements identified award consummates the contract, which consists of (a) the Government on this form and any continuation sheets for the consideration stated in solicitation and your offer, and (b) this contract award. No further cont-this contract. The rights and obligations of the parties to this contract ractual document is necessary.

shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31a. NAME OF CONTRACTING OFFICER

TO SIGN

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. AWARD DATE

BY

OFFER

AWARD

STANDARD FORM 1442 (REV. 8/2014) BACK

(Include ZIP Code) (Include area code) (Include only if different than Item 14.)

(Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each) (Type or print) (4 copies unless otherwise specified) (Type or print) (Type or print) (Contractor is required to sign this document and return _______ copies to issuing office.)

(Contractor is not required to sign this document.)

(Must be fully completed by offeror) (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

Base Bid (See A3 Price Cost Schedule) Department of Veterans Affairs Network Contracting Office 6 201 Hay Street, Suite 304 Fayetteville NC 28301 Department of Veterans Affairs Financial Services Center P.O. Box 149971 Austin TX 78714-9971 512-460-5049 512-460-5221

Table of Contents

VA Engineering 2300 Ramsey Street Building #45 Fayetteville, N.C. 28301 Scope of Work for:

Replace the below listed existing fire dampers with new. Work includes all efforts to remove, replace, test and document.

1. A fd 054 approx. 16” x 16”

2. A fd 049 approx. 10” x 10”

3. A fd 062A approx. 16” x 16”

4. A fd 063A approx. 10” x 12”

5. A fd 066 approx. 16” x 22”

6. A fd 069D (53564502) approx. 8” x 8”

7. A fd 069H (53564505) approx. 12” x 28”

8. A fd 048 approx. 12” x 12”

9. 53564527 approx. 12” x 14”

10. 53564532 approx. 16” x 16”

11. 53564533 approx. 20” x 18”

12. 53564535 approx. 12” x 12”

13. 53564536 approx. 12” x 12”

14. 53564538 approx. 12” x 12”

15. 53564539 approx. 12” x 12”

16. 53564545 approx. 10” x 10”

17. 53564546 approx. 24” x 24”

18. 53564549 approx. 8” x 8”

19. 53564550 approx. 8” x 8”

20. 53564552 approx. 12” x 24”

21. 53564554 approx. 10” x 10”

22. 53564556 approx. 14” x 14”

23. 53564557 approx. 12” x 12”

24. 53564558 approx. 10” x 10”

25. 53564559 approx. 8” x 8”

26. 53564560 approx. 8” x 8”

27. 53564561 approx. 12” x 12”

28. 53564563 approx. 10” x 10”

29. 53564564 approx. 16” x 16”

30. 53564565 approx. 16” x 16”

31. 53564566 approx. 12” x 12”

32. 53564567 approx. 10” x 10”

33. 53564568 approx. 10” x 10”

34. 53564569 approx. 10” x 10”

35. 53564570 approx. 12” x 12”

36. 53564571 approx. 12” x 12”

37. 53564572 approx. 16” x 16”

38. 53564585 approx. 15” x 18”

39. 53564590 approx. 24” x 16”

40. 53564608 approx. 10” x 10”

A.3 PRICE/COST SCHEDULE

ITEM INFORMATION

The contractor shall provide all labor, materials, equipment, and supervision necessary to complete the removal and replacement of Fire/Smoke dampers identified below.

Installation Requirements

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

Page 1 of Page 1 of

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

SUBMISSION OF BIDS

The bidder shall submit the following in response to this Invitation for Bids:

(a) A completed and signed Standard Form 1442.

(b) A completed copy of the Representations and Certifications (See FAR 52.204-8 Annual Representations and Certifications (MAR 2012)).

(c) A fully executed bid bond.

(d) Documentation of their safety record.

(e) All forms and/or certifications as directed in the solicitation, including the specifications.

NOTE: Email all required documents to wayne.goodmond@va.gov BID DUE DATE: August 29, 2024 – 3:00 PM EASTERN

Virtual Bid Opening Information:

All bids received, on or before, the date and time specified above will be held unopened until the virtual bid opening which will be conducted on August 29, 2024, at 4:00 PM. To attend the virtual bid opening the following information is provided.

Microsoft Teams meeting Join on your computer, mobile app or room device Click here to join the meeting Meeting ID: 259 654 233 369 Passcode: JVhKD9 Download Teams | Join on the web Or call in (audio only) +1 872-701-0185,,309825629# United States, Chicago Phone Conference ID: 309 825 629# Find a local number | Reset PIN

SAFETY AND ENVIRONMENTAL RECORD: In order to be eligible for consideration and award, the contractor shall have no more than three serious, or one repeat, or one willful OSHA or EPA violation(s) in the past 3 years and have an Experience Modification Rate (EMR) of equal to or less than 1.0.

All Bidders/Offerors shall submit the following information pertaining to their past Safety and Environmental record with their bid.

1. A self-certification on company letterhead that the bidder has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years. Bidders shall submit copies of their OSHA logs (OSHA Form 300A) for the past three years with their bid. If the firm has been in business for less than three years, they shall submit copies of their OSHA logs for the period of time they have been in business.

2. Information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information shall be obtained from the bidder’s/offeror’s insurance company and be furnished on the insurance carrier’s letterhead.

Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self-insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state run worker’s compensation insurance rating bureau.

NOTE: Failure to submit this documentation with the bid shall be grounds for rejection of the bid as non-responsive.

DESCRIPTION OF WORK: See “Statement of Work”.

COST RANGE: $25,000.00 - $100,000.00

NAICS: The NAICS Code for this procurement is 238220, Commercial and Institutional Building Construction, with a maximum small business size standard of $19 million.

COMPLETION TIME: All work shall be completed within One Hundred Sixty (160) calendar days from receipt of the Notice to Proceed.

SDVOSB SET-ASIDE: This procurement is 100% set-aside for Service-Disabled, Veteran-Owned Small Business (SDVOSB). Bids are solicited only from SDVOSB concerns and bids received from concerns that are not SDVOSB concerns shall be rejected. In order to be considered, the firm must be shown in the www.sam.gov website as verified at the time of submission of their bid.

CONTRACTOR RESPONSIBILITY: Contractor shall be required to complete all contract work and schedule a final inspection within the specified contract performance period. Should the Contractor fail to complete the contract work (including scheduling of the final inspection), and it is determined by the Government to be a Contractor-caused delay, the Contractor shall be in default status. If the Government determines it to be in the best interest of the Government to allow the Contractor to continue to perform contract work, the Contractor shall provide equitable consideration to the Government for additional time granted for completion of contract work. Such agreement shall not be deemed a waiver of the Government’s right to terminate this contract in the event the Contractor fails to complete the contract work (including scheduling of the final inspection) on or before the completion date.

REQUIRED CERTIFICATION: THE CERTIFICATION CITED AT 852.219-75, VA NOTICE OF LIMITATIONS ON SUBCONTRACTING – CERTIFICATE OF COMPLIANCE FOR SERVICES AND CONSTRUCTION (SEP 2021) (DEVIATION) – This certification is required to be completed and accompany your submitted bid. Failure to complete will result in your bid to be determined non-Responsive.

TRAINING: All employees of the general contractor and subcontractors shall have the 10-hour OSHA certified construction safety course and/or other relevant competency training, as determined by the COR with input from the ICRA (Infection Control Risk Assessment) team. The General Contractor’s competent person shall have completed the 30-hour OSHA certified construction safety course. Documentation of training shall be submitted to the Contracting Officer for review and approval prior to any work being performed. No ID badge will be issued to an employee who does not provide this documentation. There shall be no exceptions to this requirement.

TB TESTING:

In accordance with VHA Directive 2011-036, CEOSH Construction Safety Guidebook, 2012 1.1.1 VHA Policy, CDC 2005 Guidelines for Preventing the Transmission of Mycobacterium tuberculosis in Health-Care Settings.

(a) The contractor must provide written certification that all contract employees assigned to the work site have had a pre-placement tuberculin screening within 90 days prior to assignment to the worksite and been found have negative TB screening reactions. Contractors will be required to show documentation of negative TB screening reactions for any additional workers who are added after the 90-day requirement before they will be allowed to work on the work site.

NOTE: This can be the Center for Disease Control (CDC) and Prevention and two-step skin testing or a Food and Drug Administration (FDA)-approved blood test.

(b) Contract employees manifesting positive screening reactions to the tuberculin must be examined according to current CDC guidelines prior to working on VHA property.

(c) Subsequently, if the employee is found without evidence of active (infectious) pulmonary TB, a statement documenting examination by a physician must be on file with the employer (construction contractor), noting that the employee with a positive tuberculin screening test is without evidence of active (infectious) pulmonary TB.

(d) If the employee is found with evidence of active (infectious) pulmonary TB, the employee would require treatment with a subsequent statement to the fact on file with the employer before being allowed to return to work on VHA property.

PRE-BID CONFERENCE: August 5, 2024. 10:00 AM : BLDG. 45 All potential bidders, subcontractors, and suppliers are strongly encouraged to attend this pre-bid conference.

KEYS: All keys provided the Contractor for use during the project shall be returned to the Contracting Officer's Representative (COR) at completion of the work or upon request. No keys shall be reproduced by the Contractor. There shall be a charge of $10.00 for each key that is lost or not returned to the COR. Payment shall be made to the VA Medical Center, Fayetteville, North Carolina upon receipt of a Bill of Collection.

PREPARATION OF BIDS/OFFERS/PROPOSALS: Neither the VAMC nor the VISN 6 NCO will pay for any costs incurred in preparation and submission of bids or proposals.

PRIVACY AND CONFIDENTIALITY: Contractors to the Department of Veteran Affairs may be unintentionally exposed to sensitive information. Information may be overheard, seen on documents or electronic devices, or observed that could potentially violate the privacy and confidentiality of our veterans, employees, volunteers, and their families. Regulations such as, but not limited to the Health Insurance Portability and Accountability Act of 1996 (HIPAA), Freedom of Information Act (FOIA) and Privacy Act of 1974 have been enacted to protect sensitive information from being improperly disclosed. Information should not be divulged or released to anyone unless specifically authorized by this contract or its’ attached documents in accordance with the contracted services. Failure to comply with applicable statutes and regulation can result in the termination of this contract and civil and criminal penalties, including fines and imprisonment. All suspected or actual breeches of privacy and confidentiality should be reported immediately to the Contracting Officer, Contracting Officer’s Representative (COR) or the Facility Privacy Officer.

The C&A requirements do not apply and a Security Accreditation Package is not required. If the contractor opts to use a computer or computer system for processing contract documents, the requirements of FIPS 140-2 for encryption of contract documents must be met.

VETS 100: Title 38, USC Section 4212(d) and Public Law 105-339, requires that federal contractors report, at least annually, the number and category of veterans who are within their workforce. Submission of the VETS 100 reporting information can be done electronically at: http://vets100.cudenver.edu. Award cannot be made unless the awardee has filed their VETS 100 report; therefore, all bidders/offerors are encouraged to file every year.

SYSTEM FOR AWARD MANAGEMENT (SAM): Federal Acquisition Regulations require that federal contractors register in the System for Award Management (SAM) database at http://www.sam.gov and enter all mandatory information into the system. Award cannot be made until the contractor has registered. Bidders are encouraged to ensure that they are registered in SAM prior to submitting their bid.

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAY 2024)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220.

(2) The small business size standard is $19 Million.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition—

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services—Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals—Representation. This provision applies to solicitations that include the clause at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X] (i) 52.204-17, Ownership or Control of Offeror.

[X] (ii) 52.204-20, Predecessor of Offeror.

[] (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[] (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[] (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[] (vi) 52.227-6, Royalty Information.

[] (A) Basic.

[] (B) Alternate I.

[] (vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

3.2 52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021) The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it ‘‘does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument’’ in paragraph (c)(1) in the provision at 52.204–26, Covered Telecommunications Equipment or Services—Representation, or in paragraph (v)(2)(i) of the provision at 52.212–3, Offeror Representations and Certifications–Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it ‘‘does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services’’ in paragraph (c)(2) of the provision at 52.204–26, or in paragraph (v)(2)(ii) of the provision at 52.212–3.

(a) Definitions. As used in this provision— Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204–25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115–232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to—

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services.”

(d) Representations. The Offeror represents that—

(1) It [ ] will, [ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds “will’’ in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that— It [ ] does, [ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds “does’’ in paragraph (d)(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded “will’’ in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded “does’’ in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment—

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services—

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of Provision)

3.3 52.204-29 FEDERAL ACQUISITION SUPPLY CHAIN SECURITY ACT ORDERS—REPRESENTATION AND DISCLOSURES (DEC 2023)

(a) Definitions. As used in this provision, Covered article, FASCSA order, Intelligence community, National security system, Reasonable inquiry, Sensitive compartmented information, Sensitive compartmented information system, and Source have the meaning provided in the clause 52.204–30, Federal Acquisition Supply Chain Security Act Orders— Prohibition.

(b) Prohibition. Contractors are prohibited from providing or using as part of the performance of the contract any covered article, or any products or services produced or provided by a source, if the prohibition is set out in an applicable Federal Acquisition Supply Chain Security Act (FASCSA) order, as described in paragraph (b)(1) of FAR 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition.

(c) Procedures. (1) The Offeror shall search for the phrase ‘‘FASCSA order’’ in the System for Award Management (SAM)(https://www.sam.gov) for any covered article, or any products or services produced or provided by a source, if there is an applicable FASCSA order described in paragraph (b)(1) of FAR 52.204–30, Federal Acquisition Supply Chain Security Act Orders—Prohibition.

(2) The Offeror shall review the solicitation for any FASCSA orders that are not in SAM, but are effective and do apply to the solicitation and resultant contract (see FAR 4.2303(c)(2)).

(3) FASCSA orders issued after the date of solicitation do not apply unless added by an amendment to the solicitation.

(d) Representation. By submission of this offer, the offeror represents that it has conducted a reasonable inquiry, and that the offeror does not propose to provide or use in response to this solicitation any covered article, or any products or services produced or provided by a source, if the covered article or the source is prohibited by an applicable FASCSA order in effect on the date the solicitation was issued, except as waived by the solicitation, or as disclosed in paragraph (e).

(e) Disclosures. The purpose for this disclosure is so the Government may decide whether to issue a waiver. For any covered article, or any products or services produced or provided by a source, if the covered article or the source is subject to an applicable FASCSA order, and the Offeror is unable to represent compliance, then the Offeror shall provide the following information as part of the offer:

(1) Name of the product or service provided to the Government;

(2) Name of the covered article or source subject to a FASCSA order;

(3) If applicable, name of the vendor, including the Commercial and Government Entity code and unique entity identifier (if known), that supplied the covered article or the product or service to the Offeror;

(4) Brand;

(5) Model number (original equipment manufacturer number, manufacturer part number, or wholesaler number);

(6) Item description;

(7) Reason why the applicable covered article or the product or service is being provided or used;

(f) Executive agency review of disclosures. The contracting officer will review disclosures provided in paragraph (e) to determine if any waiver may be sought. A contracting officer may choose not to pursue a waiver for covered articles or sources otherwise subject to a FASCSA order and may instead make an award to an offeror that does not require a waiver.

(End of Provision)

3.4 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

3.5 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

(End of Provision)

3.6 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie…