36C24619Q0605-003.docx

36C24619Q0605

PAGE OF PAGES

THIS RFQ IS

IS

NOT A SMALL BUSINESS SET-ASIDE

1. REQUEST NO.

2. DATE ISSUED

3. REQUISITION/PURCHASE REQUEST NO.

4.

CERT. FOR NAT. DEF.

RATING

UNDER BDSA REG. 2

AND/OR DMS REG. 1

5A. ISSUED BY

6. DELIVER BY (Date) 5B. FOR INFORMATION CALL: (No collect calls)

7. DELIVERY

NAME

TELEPHONE NUMBER

FOB DESTINATION

(See Schedule)

OTHER

AREA

CODE

NUMBER

9. DESTINATION

a. NAME OF CONSIGNEE

8. TO:

a. NAME

b. COMPANY

b. STREET ADDRESS

c. STREET ADDRESS

c. CITY

d. CITY

e. STATE

f. ZIP CODE

d. STATE

e. ZIP CODE 10.

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE ON

OR BEFORE CLOSE OF BUSINESS (Date) This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

ITEM NO.

SUPPLIES/SERVICES

QUANTITY

UNIT

UNIT PRICE

AMOUNT

(a) (b) (c) (d) (e) (f)

a. 10 CALENDAR DAYS %

b. 20 CALENDAR DAYS %

c. 30 CALENDAR DAYS %

d. CALENDAR DAYS

NUMBER

PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

14. SIGNATURE OF PERSON AUTHORIZED TO SIGN QUOTATION

15. DATE OF QUOTATION

a. NAME OF QUOTER

b. STREET ADDRESS

16. SIGNER

a. Name (Type or print)

b. TELEPHONE

c. COUNTY

AREA CODE

d. CITY

e. STATE

f. ZIP CODE

c. TITLE (Type or print)

NUMBER

IMPORTANT:

11. SCHEDULE (Include applicable Federal, State and local taxes)

12. DISCOUNT FOR PROMPT PAYMENT

(THIS IS NOT AN ORDER)

AUTHORIZED FOR LOCAL REPRODUCTION

STANDARD FORM 18

REV. 6-95)

Previous edition not usable Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

REQUEST FOR QUOTATIONS

X 36C24619Q0605 06-06-2019

TBD

Vangie Miller Department of Veterans Affairs Network Contracting Office 6 100 Emancipation Drive Hampton VA 23667 Vangie Miller 757-315-3999 Department of Veterans Affairs Network Contracting Office 6 100 Emancipation Drive Hampton

VA

23667 06-21-2019 See CONTINUATION Page PROJECT TITLE: Parking Lot Improvements 4B PROJECT LOCATION: H.H. MCGUIRE VAMC, 1201 Broad Rock Blvd.

Richmond VA 23249 Please review the SCOPE OF WORK, Specifications and Drawings for additional information about the project requirements.

THIS IS A 100% SERVICE DISABLED VETERAN OWNED SMALL BUSINESS

(SDVOSB) SET-ASIDE IAW 38.U.S.C 8127 (d).

The SDVOSB is required to perform a minimum of 15% of the construction work on the project with its own labor force.

This does not include paperwork, submittals, and project management.

The SDVOSB must be a small business under the relevant NAICS Code 238990 /Size Standard $15M X Scope of Work Hunter Holmes McGuire VA Medical Center Richmond Virginia Project Name –Parking 4B 652-17-923

Overview: Contractor shall provide all equipment, labor, materials and supervision as necessary to prepare parking lot 4B for the construction of a new building addition by cutting in a road extension from 2nd street. This work is to comply with current VA standards for hospital construction, patient care and with local building codes.

Description of Work: This phased project will consist of demolition and excavating 1300 square feet of embankment and refilling, doing 6-inch curbs, place one sidewalk and then compacting and then placing a 3-inch layer of asphalt. Four damaged areas in neighboring lots will be fixed each is a 4’x4’ area, Prepping and planting bushes and trees, stump grinding and fire lane painting. Three concrete jersey barriers will need moved and various concrete parking stops relocated and pinned after taken up.

Areas of Work: Parking lots 4B and 6A General Requirements for excavation: Comply with 02 41 00 A. Division 31: 31-20-00 Earthworks B. Place 80 interlocking orange fillable Jersey Barriers C. Remove and re-install light base and light D. Curb removal E. Excavation of dirt to the side walk and new road area F. All re-filled excavation shall be compacted to an 85% proctor whether soils or aggregates. No lifts can exceed 12 inches without the 85% proctor.

General Requirements for concrete: Comply with 03 30 00 A. Division 30: 30-30-00 Cast in place Concrete B. Prepare sub course, all concrete shall be placed over a bed of compacted crush and run aggregate.

C. Form and pour 6-inch curbs D. Form and pour 6-inch sidewalks E. Form and pour light pole for removed light including mounting hardware F. All concrete shall be inspected and tested by an independent, certified consultant with samples pulled for compression testing.

G. All concrete shall be a 3000-lb. mix H. Sidewalks shall have a control joint every 4 feet with an expansion joint every 16 feet. Control joints shall be ½ inch deep and expansion joints shall be ¼ expansion material. Finish will be a light broom finish I. All demo material and debris will be transported off site for disposal. A concrete wash station shall be constructed and disposed of upon job completion.

General Requirements for paving: Comply with 32-12-16 A. Division 32: 32-12-16 Asphalt Paving B. Prepare sub-course C. Sub course must be dry with a surface temperature at or above 60 degrees D. Saw cut rounded or jagged edges to make a smooth edge E. Fill with stone, level and compact F. Apply a prime coat over prepared sub course G. Supply and place a 3-inch SM-2A surface course temperature of mix between 250’ & 350’ H. Compaction of asphalt of breakdown, intermediate and finish rolling using steel wheeled rollers I. Finish grade should be completely level with adjoining surfaces J. Protect fresh asphalt for 24 hours after finish rolling K. Sweep and seal coat all new parking areas in preparation of painting General Requirements for painting: Comply with 32-17-23 A. Division 32: 32-17-23 Pavement Markings B. Clean all spaces before painting, blending/blacking out current paint, and painting new parking lot including as listed C. 6 Single parking spaces D. 1 Handicap parking space E. 4500 sqft of red fire lanes 6-inch height for demarcation and emphasis lines F. Paint white 6-inch letters with “NO PARKING” centered in fire lanes G. Asphalt surface clean and dry with a surface temperature at or above 60 degrees General Requirements for planting: Comply with 34-71-13 A. Division 34: 34-71-13 Passive Vehicle Barriers B. Stump grind 14 stumps 4 inches below surface C. Install plants in 16 areas D. Excavate the islands of 4 inches of dirt E. Plant 12 Nandina domestica Firepower 3 gallon per island F. Plant one Lagerstroemia indica x fauriei “Comanche” 8’-10’ G. Cover remaining island dirt with ground cloth and pin per directions H. Cover island with 4 inches of mulch I. Mulch shall be black dyed Comply with following additional requirements:

A. 01-00-00 General Requirements B. 01-33-23 Drawings and Data and Samples C. 01-35-26 Safety Requirements D. 01-74-19 Construction Waste Management E. 02-41-00 Demolition

Completion Time: Construction is anticipated to take thirty (30) days after the notice to proceed.

Additional notes:

Critical elements will the demo, excavation and installation of an asphalt drive connecting parking lots 6A and 6B to 4A.

Four (4) damaged asphalt areas to be fixed using a 4’x4’ saw cut, primed coated and then asphalted.

Contractor shall field verify all measurements, material quantities, and site conditions prior to submitting a bid.

Contractor shall store all materials offsite and only bring materials to be installed the same day to the project site. Contractor shall coordinate delivery, storage, and handling of all materials with the COR to designated prepared areas to minimize site storage time, impact to the hospital, and potential damage to stored materials, unless project has a specified lay dawn area.

Contractor shall protect all existing equipment, utilities, structures, etc. to remain. When the space is turned over to the contractor, the contractor will be responsible for repairing all damage within the construction site. If any damage is noticed prior to starting work that may be misconstrued as damage caused by the contractor, the COR shall be notified immediately, and the damage documented as existing prior to beginning demolition.

Table of Contents

INFORMATION REGARDING BIDDING MATERIAL, BID GUARANTEE AND BONDS

(a) 40 U.S.C. chapter 31, subchapter III, Bonds (formerly known as the Miller Act), requires performance and payment bonds for any construction contract exceeding $150,000, except that this requirement may be waived--

(1) By the contracting officer for as much of the work as is to be performed in a foreign country upon finding that it is impracticable for the contractor to furnish such bond; or

(2) As otherwise authorized by the Bonds statute or other law.

(b)

(1) Pursuant to 40 U.S.C. 3132, for construction contracts greater than $35,000, but not greater than $150,000, the contracting officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selected alternatives:

(i) A payment bond.

(ii) An irrevocable letter of credit (ILC).

(iii) A tripartite escrow agreement. The prime contractor establishes an escrow account in a federally insured financial institution and enters into a tripartite escrow agreement with the financial institution, as escrow agent, and all of the suppliers of labor and material. The escrow agreement shall establish the terms of payment under the contract and of resolution of disputes among the parties. The Government makes payments to the contractor’s escrow account, and the escrow agent distributes the payments in accordance with the agreement or triggers the disputes resolution procedures if required.

(iv) Certificates of deposit. The contractor deposits certificates of deposit from a federally insured financial institution with the contracting officer, in an acceptable form, executable by the contracting officer.

(v) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(2) The contractor shall submit to the Government one of the payment protections selected by the contracting officer.

(c) The contractor shall furnish all bonds or alternative payment protection, including any necessary reinsurance agreements, before receiving a notice to proceed with the work or being allowed to start work.

(a) All types of bid guarantees are acceptable for supply or service contracts (see annual bid bonds and annual performance bonds coverage in 28.001). Only separate bid guarantees are acceptable in connection with construction contracts. Agencies may specify that only separate bid bonds are acceptable in connection with construction contracts.

INSTRUCTIONS, CONDITIONS AND OTHER STATEMENTS TO BIDDERS/OFFERORS

SUBMISSION OF BIDS/OFFER

The bidder/offeror shall submit the following in response to this Request for proposal:

(a) A completed and signed Standard Form 1442.

(b) A completed copy of the Representations and Certifications (See FAR 52.204-8 Annual Representations and Certifications (MAR 2012)).

(c) A fully executed bid bond.

(d) Documentation of their safety record.

(e) All forms and/or certifications as directed in the solicitation and basis for award, including the specifications.

SAFETY AND ENVIRONMENTAL RECORD: In order to be eligible for consideration and award, the contractor shall have no more than three serious, or one repeat, or one willful OSHA or EPA violation(s) in the past 3 years and have an Experience Modification Rate (EMR) of equal to or less than 1.0.

All Offerors shall submit the following information pertaining to their past Safety and Environmental record with their proposal.

1. A self-certification on company letterhead that the bidder has no more than three (3) serious, or one (1) repeat or one (1) willful OSHA or any EPA violation(s) in the past three years. Bidders shall submit copies of their OSHA logs (OSHA Form 300A) for the past three years with their bid. If the firm has been in business for less than three years, they shall submit copies of their OSHA logs for the period of time they have been in business.

1. Information regarding their current Experience Modification Rate (EMR) equal to or less than 1.0. This information shall be obtained from the bidder’s/offeror’s insurance company and be furnished on the insurance carrier’s letterhead.

Self-insured contractors or other contractors that cannot provide their EMR rating on insurance letterhead must obtain a rating from the National Council on Compensation Insurance, Inc. (NCCI) by completing/submitting form ERM-6 and providing the rating on letterhead from NCCI. Note: Self-insured contractors or other contractors that cannot provide EMR rating on insurance letterhead from the states or territories of CA, DE, MI, NJ, ND, OH, PA, WA, WY, and PR shall obtain their EMR rating from their state-run worker’s compensation insurance rating bureau.

DESCRIPTION OF WORK: See SCOPE OF WORK.

COST RANGE: $100,000 - $250,000

NAICS: The NAICS Code for this procurement is 238990, All Other Specialty Trade Contractors, with a maximum small business size standard of $15 million.

TIMELINE:

Solicitation issued- 06/06/2019 Site visit- 06/06/2019 10:00 AM EST RFI due - NLT 06/10/2019 5:00 PM EST Government Response - On or about 06/13/2019 Proposals Due - On or about 06/21/2019 SDVOSB SET-ASIDE: Effective June 20, 2007, Public Law 109-461, the Veterans Benefits, Health Care, and Information Technology Act of 2006 allow procurements to be set-aside for SDVOSBs and VOSBs. This procurement is 100% set-aside for Service-Disabled, Veteran-Owned Small Business (SDVOSB). Bids are solicited only from SDVOSB concerns and bids received from concerns that are not SDVOSB concerns shall be rejected. In order to be considered, the firm must be shown in the Center for Business Enterprise (VetBiz) website as verified at the time of submission of their bid. No award can be made unless the vendor is registered.

SECURITY REQUIREMENTS: VA Handbook 5400.3 requirements for Certification and Accreditation of the contractor’s computer system (if used) do not apply to this acquisition. If the contractor opts to use a computer or computer system for processing of contract documents, the requirements of FIPS 140-2 for encryption of contract documents must be met.

Plans/Drawings/Specifications: Drawings and specifications are attached in electronic format to this solicitation. Offerors are responsible for downloading and printing their own bid sets. The VA will not provide hard copies of the drawings and specifications to any offeror. Contractors are responsible for ensuring that any construction document package used for bidding or construction is complete and up-to-date.

RESIDENT PROJECT ENGINEER: All reference to "Resident Project Engineer" in the solicitation will be changed to "Contracting Officer’s Representative" or “COR.”

GENDER: Wherever masculine gender is used in the solicitation and contract documents, it shall be considered to include both masculine and feminine.

DEPARTMENT OF VETERANS AFFAIRS: All reference to "Veteran's Administration" or "VA" in the solicitation will be changed to Department of Veterans Affairs".

METRIC PRODUCTS: Products manufactured to metric dimensions will be considered on an equal basis with those manufactured using inch-pound units, providing they fall within the tolerances specified using conversion tables and contained in the latest revision of Federal Standard No. 376, and all other requirements of this document are met.

If a product is manufactured to metric dimensions and those dimensions exceed the tolerances specified in inch-pound units, a request should be made to the Contracting Officer, in writing, to determine if the product is acceptable. The Contracting Officer, in concert with the Contracting Officer’s Representative (COR), will accept or reject the product.

CONTRACTOR RESPONSIBILITY: Contractor shall be required to complete all contract work and schedule a final inspection within the specified contract performance period. Should the Contractor fail to complete the contract work (including scheduling of the final inspection), and it is determined by the Government to be a Contractor-caused delay, the Contractor shall be in default status. If the Government determines it to be in the best interest of the Government to allow the Contractor to continue to perform contract work, the Contractor shall provide equitable consideration to the Government for additional time granted for completion of contract work. Such agreement shall not be deemed a waiver of the Government’s right to terminate this contract in the event the Contractor fails to complete the contract work (including scheduling of the final inspection) on or before the completion date.

TRAINING: Effective July 1 2005, all employees of the general contractor and subcontractors shall have the 10-hour OSHA certified construction safety course and/or other relevant competency training, as determined by the COR with input from the ICRA (Infection Control Risk Assessment) team. The General Contractor’s competent person shall have completed the 30-hour OSHA certified construction safety course. Documentation of training shall be submitted to the Contracting Officer for review and approval prior to any work being performed. No ID badge will be issued to an employee who does not provide this documentation. There shall be no exceptions to this requirement.

TUBERCULOSIS (TB) TESTING: It is the responsibility of the contractor to provide TB training annually and a PPD test annually for any employee(s) providing services at Hunter Holmes McGuire VAMC, Richmond, Virginia. The Government reserves the right to review the contractor’s records.

PRE-PROPOSAL CONFERENCE: A pre-proposal conference has been scheduled for June 6, 2019, at 10:00 AM in Main Medical Center (Bldg. 500), 1ST Floor, Conference Room; Hunter Holmes McGuire VA Medical Center, Richmond, VA. This pre-bid conference will be the only opportunity for potential bidders to visit the site. All potential bidders, subcontractors, and suppliers are strongly encouraged to attend the pre-proposal conference.

NOTE: QUESTIONS REGARDING THIS SOLICITATION MUST BE SUBMITTED BY E-MAIL TO (vangie.miller@va.gov); NO TELEPHONE QUESTIONS WILL BE ACCEPTED. CUT OFF FOR RFI QUESTIONS IS 5:00 PM (LOCAL TIME), June 10, 2019.

KEYS: All keys provided the Contractor for use during the project shall be returned to the Contracting Officer's Representative (COR) at completion of the work or upon request. No keys shall be reproduced by the Contractor. There shall be a charge of $10.00 for each key that is lost or not returned to the COR. Payment shall be made to the Hunter Holmes McGuire VA Medical Center, Richmond, Virginia upon receipt of a Bill of Collection.

PREPARATION OF PROPOSALS: Neither the VAMC nor the VISN 6 NCO will pay for any costs incurred in preparation and submission of proposals.

PRIVACY AND CONFIDENTIALITY: Contractors to the Department of Veteran Affairs may be unintentionally exposed to sensitive information. Information may be overheard, seen on documents or electronic devices, or observed that could potentially violate the privacy and confidentiality of our veterans, employees, volunteers, and their families. Regulations such as, but not limited to the Health Insurance Portability and Accountability Act of 1996 (HIPAA), Freedom of Information Act (FOIA) and Privacy Act of 1974 have been enacted to protect sensitive information from being improperly disclosed. Information should not be divulged or released to anyone unless specifically authorized by this contract or its’ attached documents in accordance with the contracted services. Failure to comply with applicable statutes and regulation can result in the termination of this contract and civil and criminal penalties, including fines and imprisonment. All suspected or actual breeches of privacy and confidentiality should be reported immediately to the Contracting Officer, Contracting Officer’s Representative (COR) or the Facility Privacy Officer.

The C&A requirements do not apply, and a Security Accreditation Package is not required. If the contractor opts to use a computer or computer system for processing contract documents, the requirements of FIPS 140-2 for encryption of contract documents must be met.

VETS 100: Title 38, USC Section 4212(d) and Public Law 105-339, requires that federal contractors report, at least annually, the number and category of veterans who are within their workforce. Submission of the VETS 100 reporting information can be done electronically at: http://vets100.cudenver.edu. Award cannot be made unless the awardee has filed their VETS 100 report; therefore, all bidders/offerors are encouraged to file every year.

SYSTEM FOR AWARD MANAGEMENT (SAM): Federal Acquisition Regulations require that federal contractors register in the System for Award Management (SAM) database at http://www.sam.gov and enter all mandatory information into the system. Award cannot be made until the contractor has registered. Bidders are encouraged to ensure that they are registered in SAM prior to submitting their offer.

PROPOSAL SUBMISSION DUE DATE: All proposals shall be submitted by the prime contractor, VIA E-MAIL to (vangie.miller@va.gov); NO HARD COPY PROPOSALS OR FACSIMILES WILL BE ACCEPTED. All proposals are due by 6/21/2019 5:00 PM, EST.

NOTE: To be considered and accepted as timely the proposal must be uploaded in its entirety prior to the deadline. Failure to provide a proposal in its entirety prior to the deadline will render the proposal nonresponsive.

Basis of Award Project 652-17-923: Parking Lot Improvements 4B: Hunter Holmes McGuire VA Medical Center, Richmond, Virginia

A. BASIS FOR AWARD.

The quote will be evaluated and considered of the following factors:

Offerors capability to demonstrate a clear understanding of meeting the entire Project Scope Offerors shall submit a capability statement demonstrating a clear understanding of the statement of work, including operations and maintenance problems presented therein. The offeror should provide evidence of sufficient planning to show that work will be accomplished as required and on schedule, utilizing all available resources to meet requirements.

Relevant Experience/Past Performance Performance evaluation will assess the relative risks associated with an offeror's likelihood of success in performing the solicitation's requirements as indicated by that offeror's record of Relevant Experience/Past Performance.

• Offerors must provide a reference and a successfully completed contract that demonstrate recent and relevant record of performance in supplying services that meet the requirements described in the RFQ. Provide description of projects, dollar value, and Point of Contact(s) including phone/FAX numbers.

Price The total evaluated price will consist of the offeror’s proposed price. Price reasonableness will be performed by the Contracting Officer.

Offeror must provide with their submitted offer:

• Registration as Service Disabled Veteran Owned–Small Business Vendor

• https://www.vip.vetbiz.gov/

• Active Sam at the time of submission

• Osha Cert Person Name and Credentials

2.1 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—SECONDARY SITE OF THE WORK (MAY 2014) (a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

(End of Provision)

2.2 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction," and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the—

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is

CITY OF RICHMOND, VIRGINIA

(End of Provision)

2.3 52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American—Construction Materials" (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of Provision)

2.4 52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds—

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or 3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of Provision)

2.5 52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for— June 6, 2019 at 10:00AM EST

(c) Participants will meet at— VAMC RICHMOND, 1st floor Multi-purpose Room.

(End of Provision)

2.6 52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html http://www.va.gov/oal/library/vaar/

(End of Provision)

2.7 VAAR 852.228-72 ASSISTING SERVICE-DISABLED VETERAN-OWNED AND VETERAN-OWNED SMALL BUSINESSES IN OBTAINING BONDS (DEC 2009) Prime contractors are encouraged to assist service-disabled veteran-owned and veteran-owned small business potential subcontractors in obtaining bonding, when required. Mentor firms are encouraged to assist protégé firms under VA's Mentor-Protégé Program in obtaining acceptable bid, payment, and performance bonds, when required, as a prime contractor under a solicitation or contract and in obtaining any required bonds under subcontracts.

(End of Clause)

REPRESENTATIONS AND CERTIFICATIONS

3.1 52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2018)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238990.

(2) The small business size standard is $15 Million.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204–7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements—Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations—Representation.

(vii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance—Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xvii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xviii) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xix) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xx) 52.225-4, Buy American—Free Trade Agreements—Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $80,317, the provision with its Alternate II applies.

(D) If the acquisition value is $80,317 or more but is less than $100,000, the provision with its Alternate III applies.

(xxi) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan—Certification. This provision applies to all solicitations.

(xxiii) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certifications. This provision applies to all solicitations.

(xxiv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(A) Solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions; and

(B) For DoD, NASA, and Coast Guard acquisitions, solicitations that contain the clause at 52.219-23, Notice of Price Evaluation Adjustment for Small Disadvantaged Business Concerns.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[X](i) 52.204-17, Ownership or Control of Offeror.

[X](ii) 52.204-20, Predecessor of Offeror.

[](iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[](iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment—Certification.

[](v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services—Certification.

[](vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[](vii) 52.227-6, Royalty Information.

[](A) Basic.

[](B) Alternate I.

[](viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of Provision)

GENERAL CONDITIONS

4.1 52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

(End of Clause)

4.2 52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision— "Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means—

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in—

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

(End of Provision)

4.3 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) ALTERNATE I (APR 1984) The Contractor shall be required to (a) commence work under this contract within 15 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 days after receipt of notice to proceed. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 7/15/2019. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor…