36C24422B0005 0002.docx

5. PROJECT NUMBER (if applicable)

CODE

7.

ADMINISTERED BY

2. AMENDMENT/MODIFICATION NUMBER

CODE

6. ISSUED BY

8. NAME AND ADDRESS OF CONTRACTOR

4. REQUISITION/PURCHASE REQ. NUMBER

3. EFFECTIVE DATE

9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED

PAGE OF

PAGES

10A. MODIFICATION OF CONTRACT/ORDER NUMBER

10B. DATED

BPA NO.

1. CONTRACT ID CODE

FACILITY CODE

CODE

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

E. IMPORTANT:

is extended,

(a) By completing Items 8 and 15, and returning __________ copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE

OF YOUR

ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY is not extended.

12. ACCOUNTING AND APPROPRIATION DATA

(REV. 11/2016)

is required to sign this document and return ___________ copies to the issuing office.

is not, A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO. IN ITEM 10A.

15C. DATE SIGNED

B. THE ABOVE NUMBERE

D CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES

SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendmen t, and is received prior to the opening hour and date specified.

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER

Contractor

16C. DATE SIGNED

14. DESCRIPTION OF AMENDMENT/MODIFICATION

16B. UNITED

STATES OF AMERICA

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER

16A. NAME AND TITLE OF

CONTRACTING OFFICER

15B. CONTRACTOR/OFFEROR

STANDARD FORM 30

PREVIOUS EDITION NOT USABLE

Prescribed by GSA - FAR (48 CFR) 53.243 (Type or print) (Type or print) (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

(Number, street, county, State and ZIP Code) (If other than Item 6) (Specify type of modification and authority) (such as changes in paying office, appropriation date, etc.)

(If required)

(SEE ITEM 11)

(SEE ITEM 13)

(X)

CHECK

ONE

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF

SOLICITATIONS

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

(Signature of person authorized to sign) (Signature of Contracting Officer) 693-22-2-594-0028 693-20-107 00244 Department of Veterans Affairs Network Contracting Office 4

00244 Department of Veterans Affairs Network Contracting Office 4

To all Offerors/Bidders

36C24422B0005 08-16-2022

X X

X Amendment is issued to provide additional information as a result of the September 7, 2022 site visit.

Luzerne County Wage rates updated on 9/2/22 and are attached.

Scot Plank Contracting Officer

REPLACE ROOF, BUILDING #1

ROOFS #8&#9

Roof #9

· ADD 110FT of roofing down the walkway. (See drawing add it roofing is in GREEN)

· Use a coating on the on top of the metal on the parapet and on the brick wall up 2FT. Reseal on the outside of the parapet wall at the base where it meets the overhang. (Type of product that can be used “ARMOUR PROOF AP-510 Moisture Cure Polyurethane).

· Reset the drains.

· Walking mat from the door to roof #8.

Roof #8

· Parapet wall needs to be raised 6” higher than the finished roof.

· Walking mats from Roof#9 to the Penthouse door.

· Needs new fasten handrailing.

· Needs new drains.

ROOF #21

Roof #21

· All dormers will get cover on all sides.

· All hood will al stays

· Walking pads in the same locations that there are in now.

Here are the test cores for all the roofs.

Roof# 8 High point - 5" Low point - 1.5" Steel deck Existing roof - TPO

Roof # 9 High point - 6" Low point - 4" Concrete deck Existing roof - rubber

Roof # 21 High point - 10.5" Low point - 3.5" Concrete deck Dens deck Tampered ISO George Town roof

Section 075323 Ethylene-Propylene-Diene-Monomer Roofing - Verisco

PART 1 GENERAL

SECTION INCLUDES

Adhered roof system with ethylene-propylene-diene-monomer (EPDM) roofing membrane.

Vapor retarder.

Cover boards.

RELATED REQUIREMENTS

Section 070150.19 - Preparation for Re-Roofing.

Section 076200 - Sheet Metal Flashing and Trim: Counterflashings and reglets.

REFERENCE STANDARDS

ASCE 7 - Minimum Design Loads and Associated Criteria for Buildings and Other Structures Most Recent Edition Cited by Referring Code or Reference Standard.

ASTM C1289 - Standard Specification for Faced Rigid Cellular Polyisocyanurate Thermal Insulation Board 2022.

ASTM C1325 - Standard Specification for Fiber-Mat Reinforced Cementitious Backer Units 2021.

ASTM D4637/D4637M - Standard Specification for EPDM Sheet Used in Single-Ply Roof Membrane 2015 (Reapproved 2021).

ASTM D6163/D6163M - Standard Specification for Styrene Butadiene Styrene (SBS) Modified Bituminous Sheet Materials Using Glass Fiber Reinforcements 2021.

FM (AG) - FM Approval Guide current edition.

UL 790 - Standard for Standard Test Methods for Fire Tests of Roof Coverings Current Edition, Including All Revisions.

SUBMITTALS

See Section 013000 - Administrative Requirements for submittal procedures.

Product Data: Provide manufacturer's written information listed below.

Product data indicating membrane materials, flashing materials, insulation, vapor retarder, surfacing, and fasteners.

Warranty Documentation.

Submit manufacturer warranty and ensure that forms have been completed in Owner's name and registered with manufacturer.

Submit installer's certification that installation complies with required warranty conditions for waterproofing membrane.

QUALITY ASSURANCE

Manufacturer Qualifications: Company specializing in manufacturing the products specified in this section with at least twenty years of documented experience.

Installer Qualifications: Company specializing in performing work of type specified and with at least five years documented experience.

Approved by membrane manufacturer.

DELIVERY, STORAGE, AND HANDLING

See Section 017419 - Construction Waste Management and Disposal for packaging waste requirements.

Deliver products in manufacturer's original containers, dry, undamaged, with seals and labels intact.

Protect foam insulation from direct exposure to sunlight.

Provide Safety Data Sheets (SDS) at project site during transportation, storage, and installation of materials.

Comply with requirements from Owner to prevent overloading or disturbance of structure when loading materials onto roof.

FIELD CONDITIONS

Do not apply roofing membrane during unsuitable weather, and refer to manufacturer's written installation instructions.

Do not apply roofing membrane when ambient temperature is below 40 degrees F (5 degrees C) or above [___] degrees F ([___] degrees C).

Do not apply roofing membrane to damp or frozen deck surface or when precipitation is expected or occurring.

Do not expose materials vulnerable to water or sun damage in quantities greater than can be weatherproofed that same day.

Proceed with work so new roofing materials are not subject to construction traffic as work progresses.

Do not allow grease, oils, fats, or other contaminants to come into direct contact with roofing membrane.

WARRANTY

See Section 017800 - Closeout Submittals for additional warranty requirements.

System Warranty: Provide manufacturer's system warranty agreeing to repair or replace roofing membrane that leaks or is damaged due to wind or other natural causes.

System Warranty Term: 20 years.

For repair and replacement include costs of both material and labor in warranty.

PART 2 PRODUCTS

MANUFACTURER

Versico Roofing Systems; [_____]: www.versico.com/#sle.

ROOFING APPLICATIONS

Ethylene-Propylene-Diene-Monomer (EPDM) Membrane Roofing: Single-ply membrane.

Adhered, over insulation.

PERFORMANCE / DESIGN CRITERIA

Roof Covering External Fire Resistance Classification: Class A when tested in accordance to UL 790.

Wind Uplift:

Designed to withstand wind uplift forces calculated in accordance with ASCE 7.

Design Wind Speed: In accordance with local building code and authorities having jurisdiction (AHJ).

Drainage: No standing water within 48 hours after precipitation.

ROOFING MEMBRANE MATERIALS

Single Source Responsibility: Provide and install products from single source.

Base Sheet: ASTM D6163/D6163M, Type I, Grade S, glass-fiber reinforced, modified SBS sheet.

Products:

Versico Roofing Systems; SureMB 90 Base Sheet.

Membrane: Ethylene-propylene-diene-monomer (EPDM); ASTM D4637/D4637M, Type I - Non-Reinforced.

Membrane Thickness: 60 mils, 0.060 inch (1.5 mm), minimum.

Sheet Width: Factory fabricated into largest sheets possible.

Color: Black.

Products:

Versico Roofing Systems; VersiGard Non-Reinforced EPDM.

COVER BOARDS

Cover Board: Cement roof board, complying with ASTM C1325.

Board Size: [____] by ___ inches (___ by ___ mm).

Board Thickness: 1/2 inch (13 mm).

Cover Board: Polyisocyanurate (ISO) foam insulation complying with ASTM C1289, Type II, Class 4 with glass fiber reinforced facers on both sides, and Grade 1 with 80 psi (551 kPa), minimum, compressive strength.

Board Thickness: 1/2 inch (12.7 mm).

Products:

Versico Roofing Systems; SecurShield HD Polyiso.

ACCESSORIES

Prefabricated Flashing Accessories:

See Section 076200 for metal counterflashing and trim information.

Corners and Seams:

Inside/Outside Corner: 60 mil, 0.060 inch (1.5 mm) thick, 7 by 9 inches (178 by 229 mm) precut, uncured EPDM with 30 mil, 0.030 inch (0.76 mm) thick factory-applied tape.

Products:

Versico Roofing Systems; VersiGard.

Curb Flashing: 60 mil, 0.060 inch (1.5 mm) thick, 20 inches (508 mm) wide, cured EPDM with 30 mil, 0.030 inch (0.76 mm) thick by 5 inches (127 mm) wide factory-applied tape along one edge.

Products:

Cured Cover Strip: 40 mil, 0.040 inch (1.0 mm) thick, cured EPDM laminated to 30 mil, 0.030 inch (0.76 mm) thick factory-applied tape.

Products:

Versico Roofing Systems; VersiGard Quick-Applied.

T-Joint Covers: 40 mil, 0.040 inch (1.0 mm) thick, uncured EPDM laminated to 30 mil, 0.030 inch (0.76 mm) thick factory-applied tape.

Products:

Versico Roofing Systems; VersiGard Quick-Applied.

Uncured Flashing: 60 mils, 0.060 inch (1.5 mm) thick, uncured EPDM laminated to 30 mil, 0.030 inch (0.76 mm) thick factory-applied tape.

Products:

Versico Roofing Systems; VersiGard Quick-Applied.

Penetrations: Same material as membrane, with manufacturer's standard cut-outs, rigid inserts, clamping rings, and flanges.

Pipe Seals: Provide factory-applied tape on deck flange.

Products:

Sealant Pockets: Same material as membrane, with manufacturer's standard accessories, in manufacturer's standard configuration.

Pourable Sealant Pocket: 2 inches (51 mm) wide plastic support strip with factory-applied, adhesive-backed uncured EPDM flashing.

Pocket Diameter: 4 inch (102 mm), nominal.

Products:

Versico Roofing Systems; VersiGard Quick-Applied.

Reinforced Termination Strip (RTS): 45 mils, 0.045 inch (1.1 mm) thick, reinforced EPDM membrane with 3-inch (76-mm) wide by 30 mils, 0.030 inch (0.76 mm) thick cured synthetic rubber.

Width: 6 inches (152 mm), nominal.

Pressure-sensitive adhesive laminated to one edge.

Products:

Versico Roofing Systems; VersiGard Quick-Applied.

Insulation Adhesive: Two component polyurethane, expanding foam.

Products:

Versico Roofing Systems; Flexible DASH Dual Tanks.

Versico Roofing Systems; Flexible DASH 5-Gallon Jug.

Fasteners: Appropriate for application indicated as recommended and approved by membrane manufacturer.

Length as required for thickness of membrane and insulation material and penetration of deck substrate; with metal washers.

Fasteners, Wood/Steel Drill-in: Corrosion-resistant #15 threaded drill-in fastener with #3 Phillips drive for attachment through fastening plate into steel with 22 gauge, 0.0299 inch (0.76 mm) or greater thickness, and wood plank or CDX plywood roof decks with 15/32 inch (12 mm) or greater thickness.

Products:

Versico Roofing Systems; HPV Fasteners.

Base Sheet Fasteners and Plates: Manufacturer's pre-assembled, 1.8 inch (46 mm) long, galvanized steel tube and 2.7 inch (69 mm) diameter galvalume plate with high tensile steel wire locking staple.

FM (AG) listed and labeled.

Products:

Versico Roofing Systems; Dual Prong Base Sheet Fasteners.

Metal, Seam Fastening Plates: Galvalume coated metal plate, 22 gauge, 0.0366 inch (0.853 mm) minimum thickness, with 2 inch (51 mm) nominal diameter, used for insulation attachment on mechanically fastened systems or membrane securement at angle changes on adhered systems with appropriate fastener.

Products:

Versico Roofing Systems; 2 Inch Seam Fastening Plates.

Membrane Adhesive: As recommended by membrane manufacturer.

Seam Tape: Black colored, 3-inch (76-mm) or 6-inch (152-mm) wide seam tape, 100 ft (30.5 m) long.

Products:

Versico Roofing Systems; VersiGard QA (Quick-Applied) Seam Tape.

Bonding Adhesive/Primer: Low-VOC, TPO and EPDM membrane bonding adhesive, rubber/solvent blend base, and light green colored.

Products:

Versico Roofing Systems; CAV-GRIP 3V Low-VOC Adhesive/Primer.

Sealants: As recommended by membrane manufacturer.

Lap Sealant: Butyl-based contact cement, black or white colored.

Water Cut-Off Mastic Sealant: One-component, low-viscosity, self-wetting, butyl-blend mastic sealant used between membranes terminated with compression-based seal.

Products:

Versico Roofing Systems; G-500 CM Water Cut-Off Mastic.

Sealant: One-component, 100 percent solids, solvent-free, polyether sealant used to provide weather-tight seal.

Products:

Versico Roofing Systems; Universal Single-Ply Sealant.

Pourable Sealant: One-component, moisture curing, elastomeric polyether sealant, black colored.

Products:

Versico Roofing Systems; One-Part Pourable Sealant.

Membrane Cleaner: Manufacturer's standard, clear, and solvent-based membrane cleaner.

Applications: Used for cleaning in-service and new EPDM black or white membrane and TPO membrane in preparation for application of primer, adhesives, seam tape, and flashing.

Products:

Versico Roofing Systems; Weathered Membrane Cleaner.

Primer: Manufacturer's recommended product.

Primer: Solvent-based and used for one-step priming of EPDM or TPO membrane surfaces.

Products:

Versico Roofing Systems; Low-VOC EPDM and TPO Primer.

PART 3 EXECUTION

VERIFICATION OF CONDITIONS

Verify that surfaces and site conditions are ready to receive work.

Verify deck is supported and secure.

Verify deck is clean and smooth, flat, free of depressions, waves, or projections, properly sloped and suitable for installation of roof system.

Verify deck surfaces are dry and free of snow or ice.

Verify that roof openings, curbs, and penetrations through roof are solidly set, and cant strips, nailing strips, and reglets are in place.

SURFACE PREPARATION

Clean substrate thoroughly prior to roof application.

See Section 070150.19 for additional re-roofing preparation information.

INSTALLATION - GENERAL

Install roofing system in accordance with manufacturer's instructions, as well as NRCA (RM) and NRCA (WM) applicable requirements.

Application of roofing membrane during unsuitable weather is not permitted.

Application of roofing membrane when ambient temperature is outside temperature range recommended by manufacturer is not permitted.

Application of roofing membrane to damp or frozen deck surface or when precipitation is expected or occurring is not permitted.

Exposing materials vulnerable to water or sun damage in quantities greater than can be weatherproofed the same day is not permitted.

INSULATION APPLICATION

Attachment of Insulation:

Attachment of Insulation:

Embed first layer of insulation in full bed of adhesive in accordance with roofing and insulation manufacturer's instructions.

Installing wet, damaged, or warped insulation boards is not permitted.

Apply subsequent layers of insulation with joints staggered minimum 6 inches (152 mm) from joints of preceding layer.

Apply boards with edges in moderate contact without forcing, and with gap between boards no greater than 1/4 inch (6 mm) wide; cut insulation to fit neatly to perimeter blocking and around penetrations through roof.

Only apply quantity of insulation than can be completely waterproofed in same day.

MEMBRANE APPLICATION

Roll out membrane, free from wrinkles or tears; place sheet membrane into place without stretching.

Shingle joints on sloped substrates in direction of drainage.

Overlap edges, ends, and seal seams by contact adhesive, minimum 3 inches (75 mm) wide, sealing permanently waterproof.

At membrane intersections with vertical surfaces, provide the following:

Extend membrane over and up cant strips at least 4 inches (102 mm) onto vertical surfaces.

Fully adhere flexible flashing over membrane and up to nailing strips.

Coordinate installation of roof related flashings, sumps, and drains; locate field splices away from low areas and roof drains, and shingle lap upslope sheets over downslope sheets.

Daily Seal: Provide daily seal in accordance with manufacturer's installation instructions at end of each work day to prevent infiltration of water at incomplete flashings, terminations, and other unfinished membrane edges.

CLEANING

See Section 017000 - Execution and Closeout Requirements for additional requirements.

Remove wrappings, empty containers, paper, and other debris from roof daily, and dispose of debris in compliance with local, State, and Federal regulations.

Remove bituminous markings from finished surfaces.

In areas where finished surfaces are soiled by work of this section, consult manufacturer of surfaces for cleaning advice and comply with their documented instructions.

Repair or replace defaced or damaged finishes caused by work of this section.

PROTECTION

Protect installed roofing and flashings from construction operations.

Where traffic must continue over finished roof membrane, protect surfaces using durable materials.

END OF SECTION

General Decision Number: PA20220095 09/02/2022

Superseded General Decision Number: PA20210095 State: Pennsylvania Construction Type: Building County: Luzerne County in Pennsylvania.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $15.00 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2022. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $11.25 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2022. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at https://www.dol.gov/agencies/whd/government-contracts.

Modification Number Publication Date 0 01/07/2022 1 01/14/2022 2 02/11/2022 3 02/25/2022 4 04/01/2022 5 06/10/2022 6 07/08/2022 7 09/02/2022

* ASBE0038-006 07/01/2022

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR (MECHANICAL- Duct, Pipe & Mechanical System Insulation)......................$ 37.43 23.57

BOIL0013-008 01/01/2022

Rates Fringes

BOILERMAKER......................$ 50.17 34.96

BRPA0005-072 05/01/2018

Rates Fringes

TILE FINISHER....................$ 28.94 14.60

TILE SETTER......................$ 31.45 15.50

BRPA0005-078 05/03/2020

Rates Fringes

BRICKLAYER (Including Pointing, Caulking, and Cleaning)........................$ 34.94 17.70

MASON - STONE....................$ 34.94 17.70

CARP0445-001 06/01/2021

Rates Fringes

CARPENTER (Including Acoustical Ceiling Installation; Drywall Hanging; Floor Laying-Carpet and Vinyl; Form Work)............$ 31.78 18.31

ELEC0163-007 06/01/2021

Rates Fringes

ELECTRICIAN (Includes Installation of Sound and Communication Systems, HVAC/Temperature Controls Installation, and Low Voltage Wiring)..........................$ 37.36 23.37

ELEV0084-005 01/01/2022

Rates Fringes

ELEVATOR MECHANIC................$ 54.10 36.885+a+b

FOOTNOTES:

A. VACATION CREDIT: Employer contributes 8% basic hourly rate for 5 years or more of service as vacation pay credit, and 6% for 6 months to 5 years of service.

B. Eight Paid Holidays (provided employee has worked 5 consecutive days before and the working day after the holiday): New Years's Day; Memorial Day; Independence Day; Labor Day; Veteran's Day; Thanksgiving Day and the Friday after Thanksgiving Day, and Christmas Day.

ENGI0066-039 06/12/2017

Rates Fringes

POWER EQUIPMENT OPERATOR

Pump........................$ 29.58 20.15

ENGI0542-038 05/01/2018

Rates Fringes

POWER EQUIPMENT OPERATOR

Backhoe/ Excavator/ Trackhoe, Bulldozer, Hoist (With Two Towers), Mechanic, Loader............$ 35.73 24.71 Bobcat/ Skid Steer/ Skid Loader, Roller..............$ 35.73 24.71 Concrete Pump...............$ 38.26 25.46 Crane.......................$ 38.26 25.46 Forklift (20 ft and over, excludes masonry work)......$ 35.73 24.71 Forklift (Lull or similar, excludes masonry work)......$ 33.01 23.90 Hoist (Single Drum), Forklift (under 20 ft)......$ 33.01 23.90 Oiler.......................$ 30.54 23.18

IRON0404-028 07/01/2022

Rates Fringes

IRONWORKER (Ornamental, Structural, & Reinforcing).......$ 35.26 31.13

LABO0130-011 05/01/2017

Rates Fringes

LABORER

Asbestos Abatement:

Removal from Floors, Walls, Ceilings and Mechanical Systems..........$ 22.80 16.88 Common or General;

Concrete Worker.............$ 20.80 16.88 Forklift (Masonry Work Only).......................$ 24.82 16.88 Mason Tender-Brick..........$ 23.32 16.88 Mason Tender-Stone..........$ 23.32 16.88 Scaffold Builder (Brick and Masonry only)...........$ 23.32 16.88

PAIN0041-002 05/01/2014

Rates Fringes

PAINTER (Brush, Roller, Spray, and Drywall Finishing/Taping)................$ 27.95 16.12

PLAS0592-038 06/01/2022

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 36.48 13.80

PLUM0524-011 12/01/2021

Rates Fringes

PLUMBER..........................$ 46.24 21.57

PLUM0524-012 12/01/2021

Rates Fringes

PIPEFITTER (Includes HVAC Pipe Installation)...............$ 46.24 21.57

ROOF0030-004 05/01/2021

Rates Fringes

ROOFER (Excludes Metal Roof Installation and Waterproofing)...................$ 31.00 20.86

SFPA0669-004 04/01/2022

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 42.29 27.23

SHEE0044-010 05/01/2021

Rates Fringes

SHEET METAL WORKER (Includes HVAC Duct and Metal Roof Installation)....................$ 31.60 26.65

* UAVG-PA-0020 01/01/2016

Rates Fringes

LABORER: Mason Tender - Cement/Concrete..................$ 24.12 15.99

SUPA2011-053 08/20/2014

Rates Fringes

OPERATOR: Drill.................$ 28.55 15.78

OPERATOR: Gradall...............$ 32.70 18.43

OPERATOR: Grader/Blade..........$ 32.51 17.98

OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 33.01 18.37

ROOFER: Waterproofing Only.......$ 28.60 18.02

TRUCK DRIVER: Dump Truck........$ 23.36 7.60

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion dateV for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requestsfor summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

See attached document: S02 Dwg Roof 9 additional work.

End of Document