27-03 RRC Exterior Painting.pdf

L E G A L N O T I C E

The Town of Ridgefield invites all interested parties to submit sealed bids on the following:

BID DUE DATE: July 30, 2026

BID DUE TIME: 11:00 am EST

BID ITEM: Ridgefield Recreation Center Exterior Painting

BID NUMBER: 27-03

Terms and conditions as well as the description of items being bid are stated in the specifications. Specifications may be obtained at the following address:

Town of Ridgefield David McFate 400 Main Street Ridgefield, CT. 06877

(203) 431-2720

Bids must be received no later than the date and time stated above at the Purchasing Director’s office on the second floor or via email. For further information, please call David McFate at (203) 431-2720 or email at purchasing@ridgefieldct.gov

Results may be viewed at https://www.ridgefieldct.gov/departments/ purchasing/bid_notices.php after the bid opening.

Bids shall be submitted via email to the following:

purchasing@ridgefieldct.gov SUBJECT: 27-03 (Company Name) Bid Package https://www.ridgefieldct.gov/node/24703

TOWN OF RIDGEFIELD PARKS & RECREATION DEPARTMENT

BID SPECIFICATION

Exterior Wood Cleaning, Preparation and Staining

Ridgefield Recreation Center 195 Danbury Road

Ridgefield, Connecticut

1. GENERAL

The Town of Ridgefield is requesting sealed bids from qualified painting contractors for the complete preparation and staining of all exterior wood siding, trim, exposed beams and related wood components at the Ridgefield Recreation Center.

The intent is to restore and protect all exterior wood surfaces while maintaining the existing appearance of the facility.

2. SCOPE OF WORK

The Contractor shall furnish all labor, supervision, materials, equipment, lifts, tools, safety equipment and incidentals necessary to complete the project.

The work shall include, but not necessarily be limited to:

Surface Preparation

Contractor shall:

• Inspect all exterior wood surfaces.

• Pressure wash all wood surfaces using environmentally safe cleaning products suitable for wood siding.

• Remove dirt, mildew, mold, oxidation and loose stain.

• Light sand weathered areas and raised grain.

• Scrape all loose or failing stain.

• Feather all transition areas.

• Mask and protect windows, doors, roofing, masonry, landscaping, lighting fixtures and adjacent surfaces.

Repairs

Prior to staining, contractor shall inspect for:

• rotten wood

• deteriorated trim

• damaged siding

• loose boards

• failed fasteners

Repairs are not included in the base bid.

Contractor shall submit written documentation of any repairs required.

The Town may:

• authorize repairs by change order,

• perform repairs separately,

• or eliminate repairs.

Provide unit pricing with the bid for:

• Carpenter

• Painter

• Laborer

Hourly rates shall include overhead and profit.

Staining Existing finish is believed to be solid stain. Contractor shall verify compatibility with proposed new finish.

Apply two (2) complete coats of premium exterior solid-color stain. Approved products:

• Sherwin-Williams WoodScapes Exterior Acrylic Solid Color Stain

• Sherwin-Williams WoodScapes Exterior Latex Stain

• Approved equal

Color shall match the existing building.

Color sample shall be approved by the Town prior to application.

Application methods may include:

• brush

• spray and back-roll

• brush and roll

Final finish shall be uniform with no holidays, lap marks, runs or overspray.

Metal Components

Clean, prepare and repaint:

• exposed steel braces

• metal end caps

• miscellaneous painted metal associated with the building exterior

Finish shall consist of:

• surface preparation

• primer where required

• two finish coats of Sherwin-Williams DTM Acrylic or approved equal.

Protection

Contractor shall protect:

• roofing

• sidewalks

• landscaping

• vehicles

• HVAC equipment

• windows

• lighting

• playground

• adjacent facilities

Plywood protection shall be used under ladders where work occurs over roofing.

Overspray shall not be permitted.

Site Cleanup

Contractor shall:

• remove all masking

• collect debris daily

• dispose of waste legally

• leave the site broom clean each workday

3. MATERIALS

Only premium commercial-grade coatings shall be used.

Products shall be new and unopened.

Contractor shall submit product data sheets before beginning work.

No substitutions shall be made without written approval.

4. EQUIPMENT

Contractor shall provide all necessary:

• boom lifts

• scissor lifts

• ladders

• scaffolding

• fall protection

• safety equipment

The Town will not furnish equipment.

5. WORK HOURS

Normal or extended work hours:

Monday–Friday 7:00 AM – 7:00 PM

Contractor shall insure public access to RRC facilities is unimpeded during work.

Weekend work requires prior written approval.

6. PROJECT SCHEDULE

Contractor shall begin work within 30 days of Notice to Proceed.

Substantial Completion: Within 20 calendar days, weather permitting.

7. QUALITY CONTROL

The Contractor shall:

• follow manufacturer's application requirements

• maintain wet edge

• ensure proper film thickness

• protect finishes from rain

• repair all damaged work

The Town reserves the right to reject work that does not meet industry standards.

8. WARRANTY

Provide a minimum:

Three (3) Year Warranty against:

• peeling

• blistering

• excessive fading

• adhesion failure resulting from workmanship

Normal weathering excluded.

9. CONTRACTOR QUALIFICATIONS

Bidder shall have:

• Minimum five years commercial exterior painting experience.

• Minimum three projects of similar size.

• Connecticut Home Improvement or applicable Contractor License.

• OSHA compliant safety program.

Provide references with bid.

10. EXCLUSIONS

Unless specifically authorized by change order, the following are excluded:

• Structural repairs

• Rot replacement

• Caulking beyond minor preparation

• Hazardous material abatement

• Lead paint remediation

• Asbestos

• Electrical work

• Landscaping restoration beyond incidental damage

11. ALTERNATE PRICING

Provide separate pricing for:

Alternate No. 1

Replace deteriorated wood siding

Price:

Per linear foot

Alternate No. 2

Replace deteriorated trim

Price:

Per linear foot

Alternate No. 3

Carpentry Labor

Hourly Rate

Alternate No. 4

Additional Painting Labor

Hourly Rate

12. BID SHALL INCLUDE

The lump sum bid shall include:

• all labor

• materials

• lifts

• mobilization

• masking

• protection

• cleanup

• disposal

• supervision

• permits (if required)

• insurance

• overhead

• profit

No additional compensation shall be made except by approved change order.

TOWN OF RIDGEFIELD

CONNECTICUT

BOARD OF SELECTMEN

INSTRUCTIONS TO BIDDERS

1. Bids shall be submitted via email to purchasing@ridgefieldct.gov. The time stamp of the email shall be on or before the bid due date.

2. Withdrawals of or amendments to bids received later than the time and date specified for bid opening will not be considered.

3. The Board of Selectpersons of the Town of Ridgefield reserves the right to accept or reject any or all options, bids or proposals; to waive any technicality in any bid or part thereof, and to accept any bid deemed to be in the best interest of the Town of Ridgefield, Connecticut.

4. Bidders may be present at the opening of bids.

5. Bids may be held by the Town of Ridgefield for a period not to exceed sixty (60) days from the opening of bids for the purpose of reviewing the bids and investigating the qualifications of bidders prior to the awarding of the contract.

6. Insurance requirements: must be submitted with the bid. This includes any Hold Harmless requirements as well as Certificates of Insurance for the full amounts specified. Unauthorized changes to these forms, i.e.

adding, striking out and/or changing any words, language or limits will cause the bidder to be disqualified.

a. Please Note: Prior to the start of work, the Town of Ridgefield and/or the Board of Education shall be endorsed on the Contractor’s policies of insurance as additional insured. The Contractor shall obtain a policy of insurance, with minimum limits of liability as specified containing an endorsement that covers this agreement to indemnify, defend and hold harmless the Town/City and/or Board of Education or any of their officers, employees, agents, servants and volunteers. The Contractor shall obtain an mailto:purchasing@ridgefieldct.org endorsement to said insurance policy stating that the Contractor’s insurance is primary and any insurance obtained, or self insurance provided, by the Town of Ridgefield and/or Board of Education is excess. The Contractor’s insurance carrier will waive all rights of subrogation against the Town of Ridgefield and/or Board of Education, and all of their respective officers, employees, agents, servants and volunteers. The Contractor shall furnish a copy of the insurance policy that meets all of the above requirements before any work or use of the property commences. Failure to do so will result in disqualification of the Bid. There will be no exceptions.

7. Permits: It is the Contractor’s responsibility to obtain any necessary permits prior to the start of construction. All work shall be completed in compliance with the latest edition of the prevailing fire prevention and building codes in effect in the State of Connecticut, the latest edition of the State of Connecticut Department of Transportation Standard Specifications for Roads, Bridges and Incidental Construction, Town of Ridgefield Road Construction Standards, or as set forth in these specifications. Any local (Town of Ridgefield) permits will have the permit fee waived.

8. Emergency Work: The Contractor shall file with the Engineer a telephone number of a person authorized by them who may be contacted regarding emergency work at the job site that may be required during non-working hours for reasons of public safety. The person shall be readily available and have full authority to deal with any emergency that may occur.

9. Sales Tax: In accordance with the provisions of Special Act No. 77-98, as amended, and Section 12-412(a) of the Connecticut General Statutes, sales of tangible personal property and services to the Town are not subject to the Connecticut Sales and Use Tax, and such tax shall not be included as part of the bid.

10.Contractor’s Qualification Statement: The Contractor’s Qualification Statement must be filled out as part of the bid package and the experience and references listed therein will be one to the determining factors in the awarding of the bid.

11.Hold Harmless Agreement: In order for the bid to be considered valid, the Contractor must sign the enclosed hold harmless agreement. Bids submitted without the signed hold harmless agreement will be rejected.

12. Prevailing Wage Rates: This project is not subject to the State of Connecticut prevailing wage rate requirements.

13. SBE/MBE and Contract Compliance Requirements: This project is not subject to State of Connecticut SBE/MBE set aside and contract compliance requirements.

14. Bonds: Bonds are not required for this project.

15. Time of Completion: Contractor shall begin work not later than 30 days following Notice to Proceed. Work shall be substantially complete within 20 calendar days of work start date, weather permitting.

16. Weather Delays: Weather delays shall be determined by the Town based upon conditions unsuitable for proper surface preparation or coating application.

17. Project Location: The project is located at the Ridgefield Recreation Center, 195 Danbury Rd, Ridgefield CT. Contractors intending to submit a bid must familiarize themselves with the project location. Contractors are strongly encouraged to visit the site prior to submitting bids.

18. Bid Schedule:

a. RFB Issued: July 9, 2026

b. RFI’s Due: Thursday July 23, 2026 at 11:00 AM

c. Proposals Due: Thursday July 30, 2026 at 11:00 AM

19. RFB Submissions: The following items shall be submitted for a RFB to be considered complete:

(a) Project Cost and Schedule

(b) Hold Harmless Agreement

(c) Contractor’s Qualification Statement

(d) Contractor’s List of Subcontractors

(e) Contractor's Certificates of Insurance

20. Requests for Information: Questions or requests for information must be submitted in writing. All questions or requests for information shall be submitted to David McFate, Purchasing and Finance Manager, at purchasing@ridgefieldct.gov.

mailto:purchasing@ridgefieldct.gov mailto:purchasing@ridgefieldct.gov

GENERAL CONDITIONS GC-1

GENERAL CONDITIONS

1. CONTRACTOR'S UNDERSTANDING:

It is understood and agreed that the Contractor has, by careful examination, satisfied himself as to the nature and location of the work, the conformation of the ground, the character quality and quantity of materials to be encountered, the character of equipment and facilities needed preliminary to and during the prosecution of the work, the general and local conditions, and all other matters which can in any way affect the work under this Contract. No verbal agreement or conversation with any officer, agent or employee of the Owner, either before or after the execution of this contract, shall affect or modify any of the terms or obligations herein contained.

2. DEFINITIONS:

OWNER: The word "Owner" when it appears in the Contract Documents shall mean The Town of Ridgefield, Connecticut.

ENGINEER: The word "Engineer" when it appears in the contract Documents shall mean:

Jacob Muller, Director of Facilities, or his specifically designated Agent.

CONTRACTOR: The word "Contractor" when it appears in the Contract Documents shall mean the party to whom the Contract has been awarded.

3. MATERIALS, APPLIANCES AND EMPLOYEES:

Unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor, water, tools, equipment, light, power, transportation and other facilities necessary for the execution and completion of the work. Unless otherwise specified, all materials shall be new and both workmanship and materials shall be of good quality. The Contractor shall, if required, furnish satisfactory evidence as to the kind and quality of materials.

The Contractor shall at all times endorse strict discipline and good order among their employees, and shall not employ on the work any unfit person or any one not skilled in the work assigned to him.

GENERAL CONDITIONS GC-2

4. PROTECTION OF WORK AND PROPERTY:

The Contractor shall continuously maintain adequate protection of all their work from damage and shall protect the Owner's property from injury or loss arising in connection with this Contract. They shall make good any such damage, injury or loss, except such as may be directly due to errors in the Contract Documents or caused by agents or employees of the Owner. They shall adequately protect adjacent property as provided by law and the Contract Documents. They shall provide and maintain all passageways, guard fences, lights and other facilities for protection required by public authority or local conditions.

In an emergency affecting the safety of life or of the work or of adjoining property, the Contractor, without special instruction or authorization from the Engineer, is hereby permitted to act at their discretion, to prevent such threatened loss or injury, and they shall so act, without appeal, it so instructed or authorized. Any compensation claimed by the Contractor on account of emergency work, shall be determined by agreement or arbitration.

5. CHANGES IN THE WORK:

The Owner, without invalidating the Contract, may order extra work or make changes by altering, adding to or deducting from the work, the Contract Sum being adjusted accordingly. All such work shall be executed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of ordering such change.

In giving instructions, the Engineer shall have authority to make minor changes in the work, not involving extra cost, and not inconsistent with the purposes of the work, but otherwise, except in an emergency, endangering life or property, no extra work or change shall be made unless in pursuance of a written order by the Engineer, and no claim for an addition to the Contract Sum shall be valid unless so ordered.

The value of any such extra work or change shall be determined in one or more of the following ways:

(a) By estimate and acceptance in a lump sum.

(b) By unit prices named in the Contract subsequently agreed upon.

(c) By cost and percentage or by cost and a fixed fee.

If none of the above methods is agreed upon, the Contractor, provided they receive an order as above, shall proceed with the work. In such case, and also under case (c), they shall keep and present in such form as the Engineer may direct, a correct account of the net cost of labor and materials, together with

GENERAL CONDITIONS GC-3

vouchers. In any case, the Engineer shall certify to the amount, including reasonable allowance for overhead and profit, due to the Contractor. Pending final determination of value, payments on account of changes shall be made on the Engineer's estimate.

6. CLAIMS FOR EXTRA COST:

If the Contractor claims that any instructions by drawings or otherwise involve extra cost under this Contract, they shall give the Engineer written notice thereof within a reasonable time after the receipt of such instructions and in any event before proceeding to execute the work, except in emergency endangering life or property, and the procedure shall then be as provided for changes in the work. No such claim shall be valid unless so made.

7. SUSPENSION OF WORK:

The Owner may at any time suspend the work, or any part thereof by giving 24 hours notice to the Contractor in writing. The work shall be resumed by the Contractor within ten (10) days after the date fixed in the written notice from the owner to the Contractor to do so. The Owner shall reimburse the Contractor for expense incurred by the Contractor in connection with the work under this contract as a result of such suspension.

8. THE OWNER'S RIGHT TO DO WORK:

If the Contractor should neglect to prosecute the work properly or fail to perform any provision of this Contract, the Owner, after three days written notice to the Contractor may, without prejudice to any other remedy they may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor.

9. PAYMENTS WITHHELD:

The Owner may withhold or, on account of subsequently discovered evidence, nullify the whole or part of any certificate to such extent as may be necessary to protect him from loss on account of the following:

(a) Defective work not remedied.

(b) Claims filed or reasonable evidence indicating probable filing of claims.

(c) Failure of the Contractor to make payments properly to subcontractors or for material or labor.

(d) A reasonable doubt that the Contract can be completed for the balance then unpaid.

(e) Damage to another Contractor.

When the above grounds are removed, payment shall be made for amount withheld because of them.

GENERAL CONDITIONS GC-4

10. CONTRACTOR'S LIABILITY INSURANCE:

The Contractor shall maintain such insurance as will protect him from claims under workmen’s compensation acts and from any other claims for damages for personal injury, including death, which may arise from operations under this Contract, whether such operations be by himself or by any subcontractor or anyone directly or indirectly employed by either of them. Certificates of such insurance shall be filed with the engineer, if they so require and shall be subject to their approval for adequacy of protection.

11. INDEMNITY:

The Contractor shall indemnify and save harmless the Owner from and against all losses and all claims, demands, payments, suits, actions, recoveries and judgments of every nature and description brought or recovered against him, by reason of any act or omission of the said Contractor, their agents or employees, in the execution of the work or in the guarding of it.

The Contractor shall, and is hereby authorized to maintain and pay for such insurance, issued in the name of the Owner, as will protect the Owner from their contingent liability under this Contract, and the Owner’s right to force against the Contractor any provision of this article shall be contingent upon the full compliance by the Owner with the terms of such insurance policy or policies, a copy of which shall be deposited with the Owner.

12. DAMAGES:

Any claim for damage arising under this Contract shall be made in writing to the party liable within a reasonable time of the first observance of such damage and not later than the time of final payment, except as expressly stipulated otherwise in the case of faulty work or materials, and shall be adjusted by agreement or arbitration.

13. ASSIGNMENT:

Neither party to the Contract shall assign the Contract or sublet it as a whole without the written consent of the other, nor shall the Contractor assign any moneys due to or to become due to him hereunder, without the previous written consent of the Engineer.

14. ENGINEER'S STATUS:

The Engineer shall have general supervision and direction of the work. He has authority to stop the work whenever such stoppage may be necessary to insure the proper execution of the Contract. He shall also have authority to reject all work and materials which do not conform to the Contract, to direct the application of forces to any portion of the work, as in his judgment is required, and to order the force increased or diminished, and to decide questions which arise in the execution of the work.

GENERAL CONDITIONS GC-5

15. METHOD OF PAYMENT:

At the end of each calendar month, the Contractor shall submit to the Engineer a requisition for payment which requisition shall be based upon the actual amount of the work performed during the previous month. The requisition may include materials stored on the site but not installed. The Engineer shall, within ten (10) days, check the requisition against their review of the work which has been done and submit it to the Owner, a written statement as to the validity of the requisition. The Owner shall then pay to the Contractor one hundred percent (100%) of the amount stated in the Engineer's report. No payment shall be made until the Contractor has satisfied all prevailing wage reporting requirements if prevailing wages are a part of this contract.

In the event that this contract is subject to the State of Connecticut SBE/MBE set aside and contract compliance requirements, the Contractor’s attention is directed to Appendix “B”, State of Connecticut SBE/MBE requirements regarding the withholding of 2% of the State Funded portion of the contract value each month if the contract value exceeds $500,000, pending the review and approval of the Contractor’s Affirmative Action Plan by CHRO.

16. FINAL PAYMENT:

When the Contract has been completed, the Contractor shall notify the Engineer in writing. Upon receipt of this notification, the Engineer shall proceed to make final measurements of the work done under the provisions of this Contract. The Engineer shall then submit to the Owner a written statement setting forth these final measurements and the amount due the Contractor consistent with the unit prices and lump sum bid in the bid. The Owner shall within sixty (60) days pay to the Contractor this sum except that they may deduct any moneys which are to be retained under the terms of the Contract for repairs or otherwise.

17. ORDER OF THE WORK:

The order of the work shall be subject to the approval of the Engineer in all cases. The Contractor may be required to submit a work schedule in writing to the Engineer for his approval.

18. (OMITTED)

19. PROTECTION TO PUBLIC:

The Contractor shall conduct the work in such a manner as to offer minimum disturbance to the traveling public. They shall not close off traffic without specific permission of the Engineer and shall provide flagmen if such becomes necessary, in the opinion of the Engineer. Proper barricades, lights, and other protective devices shall be supplied at the Contractor’s expense and properly maintained during the entire course of the work.

GENERAL CONDITIONS GC-6

20. GUARANTEE:

The Contractor guarantees that the work to be done under this Contract and the materials furnished by him and used in the construction of the project are free from defects or flaws. The guarantee is for a term of one (1) year from and after the date upon which the final estimate of the Engineer is formally approved by the party of the first part. It is hereby agreed and understood that this guarantee shall not include any repairs made necessary by any cause or causes other than defective materials furnished by or defective work done by the Contractor. Where warranty requirements conflict, the project-specific warranty requirements shall govern.

21. RATE OF PROGRESS AND TIME OF COMPLETION:

The Contractor shall commence work within 30 days of notice to proceed.

Work shall be substantially complete within 20 calendar days of work start date.

22. EXTENSION OF TIME:

The Contractor expressly covenants and agrees that, in undertaking to complete the work within the time specified, they have taken into consideration and made allowance for all of the ordinary delays and hindrances incident to such work, whether growing out of delays in securing materials, workmen, or otherwise. Should the Contractor, however, be substantially delayed in the prosecution and completion of the work by any changes, additions, or omissions therein ordered in writing by the engineer, or by fire, lightning, earthquake, tornado, cyclone, riot, insurrection of war, or by the abandonment of the work by the workmen engaged therein, through no fault of the Contractor, or by the discharge of all or any material number of workmen in consequence of difficulties arising between the Contractor and such workmen, or by the neglect, delay, or default it of any other contractor of the town, then the Contractor may, within five (5) days after the occurrence of the delay for which they claim allowance, notify the Engineer in writing, and thereupon, and otherwise, the Contractor shall be allowed such additional time for the completion of the work, as the Engineer in his discretion shall award in writing, and his decision shall be final and conclusive upon the parties. Such additional time shall be the sole and exclusive remedy for any delay claimed by the Contractor.

23. SALES TAX:

In accordance with the provisions of Special Act No. 77-98, as amended, and Section 12-412(a) of the Connecticut General Statutes, sales of tangible personal property and services to the Town are not subject to the Connecticut Sales and Use Tax, and such tax shall not be included as part of the bid.

24. Termination of the Contract:

If the Owner fails to make payment thereon for a period of 30 days, the Contractor may, upon seven additional days written notice to the Owner, GENERAL CONDITIONS GC-7 terminate the Contract and recover from the Owner payment for work executed and for proven loss with respect to materials, equipment tools, and construction equipment and machinery, including reasonable overhead, profit and damages applicable to the project.

If the contractor defaults or persistently fails or neglects to carry out the work in accordance with the Contract Documents or fails to perform a provision of the Contract, the Owner, after seven days written notice to the Contractor and without prejudice to any other remedy the Owner may have, may make good such deficiencies and may deduct the cost thereof, including compensation for the Engineer’s services and expenses made necessary thereby, from the payment then or thereafter due the Contractor. Alternatively, at the Owner’s option, and upon certification by the Engineer that sufficient cause exists to justify such action, the Owner may terminate the Contract and take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor and may finish the Work by whatever method the Owner may deem expedient. It the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including compensation for the Engineer’s services and expenses made necessary thereby, such excess shall be paid to the Contractor, but if such costs exceed such unpaid balance, the Contractor shall pay the difference to the Owner.

Town of Ridgefield

CONTRACTOR’S QUALIFICATION STATEMENT Q-1

CONTRACTOR’S QUALIFICATION STATEMENT

List below references for similar projects, including all information requested. This page must be completed and submitted with the bid.

1. Client: _____________________________________________________________

Project Address: _________________________________________________________

Approximate Value: ____________ Date: Started __________Completed __________

Contact: Name _______________________________________Telephone ___________

2. Client: ______________________________________________________________

Project Address: _________________________________________________________

Approximate Value: ____________ Date: Started __________Completed __________

Contact: Name _______________________________________Telephone ___________

3. Client: _______________________________________________________________

Project Address: _________________________________________________________

Approximate Value: ____________ Date: Started __________Completed __________

Contact: Name _______________________________________Telephone ___________

4. Client: _______________________________________________________________

Project Address: _________________________________________________________

Approximate Value: ____________ Date: Started __________Completed __________

Contact: Name _______________________________________Telephone ___________

Company: ___________________________ Bid Title: _____________________

Street: ______________________________ Bid No.: ______________________

City, State: __________________________Telephone No.: ________________

Firm Address Point of Contact Name Point of Contact Number Type of Work Performed

CONTRACTOR'S LIST OF SUBCONTRACTORS

List below the subcontractors intended to be utilized for this project. This page must be completed and submitted with the bid.

General Contractor: ____________________________________

Address: ____________________________________________

Phone Number: _______________________________________

Bid Number: _______________

INSURANCE REQUIREMENTS IR-1

Purchasing Department, Town of Ridgefield,400 Main Street, Ridgefield,CT.

06877

203-431-2720 & purchasing@ridgefieldct.gov

APPENDIX - INSURANCE REQUIREMENTS

Each bidder shall carry and maintain the following insurance coverage during the period of the contract : The Certificate of Insurance for the Limits of Liability stated below should be submitted with your bid to the Purchasing Department at Town Hall. Bidders may not perform any work until all insurance requirements are met.

1. Comprehensive General Liability Insurance as will protect him, the Town, and any subcontractor performing work covered by this Contract, from claims for damages for personal injury, including accidental or wrongful death, as well as claims for property damages, which may arise from operations under this Contract whether such operations be by himself or by any subcontractor or by anyone directly or indirectly employed by either of them. Liability insurance shall include premises and operations, products, contractual, owners, and contractors protective. The minimum amounts of such insurance shall be as follows:

Bodily Injury Liability and Property Damage Liability:

$1,000,000 each occurrence.

The Town shall be named as an Additional Insured This MUST be stated explicitly on the Certificate or you will be disqualified

2. for all of his employees, employed at the site and in case any work is sublet, the Contractor shall require the subcontractor similarly to provide Work Compensation Insurance for all employees of the later unless such employees are covered by the protection afforded by the Contractor.

Statutory Limits

3. Comprehensive Auto Liability Insurance:

Bodily Injury Insurance and Property Damage Insurance covering the operation of all Motor Vehicles owned, hired and/or non-owned by the Contractor, or used by the Contractor in the Prosecution of the work

INSURANCE REQUIREMENTS IR-2

under the Contract, shall be in the minimum of $1,000,000 each occurrence.

All policies relating to this Contract shall be so written so that the Town shall be notified of cancellation or change at least thirty (30) days prior to the effective date for each policy and type of coverage except for nonpayment which shall be ten (10 ) days prior to the cancellation. Renewal certificate covering the renewal of all policies expiring during the life of the Contract shall be filed with the Town not less than ten (10) days before the expiration of such policies. Failure to due so will result in work stoppage and possible contract cancellation.

HOLD HARMLESS AGREEMENT

The undersigned covenants and agrees to and shall at all times indemnify, protect and save harmless the Town of Ridgefield from and against all costs or expenses resulting from any and all losses, damages, detriments, claims, demands, cost and charges including attorneys fees the Town of Ridgefield may directly or indirectly suffer, sustain or be subjected to by reason or on account of the work to be performed pursuant to this Contract or any activities in connection with said Contract whether such losses and damages be suffered or sustained by the Town of Ridgefield directly or by its employees, licenses or invitees or be suffered or sustained by other persons or corporations who may seek to hold the

Town of Ridgefield liable therefore.

The Contractor shall comply with the Provisions of the Immigration Reform and

Control Act of 1986 effective and enforceable as of June 6, 1987 which Act makes unlawful the hiring for employment or subcontracting individuals failing to provide documentation of legal eligibility to work in the United States. The

Contractor shall hold the Town of Ridgefield harmless for the failure of the

Contractor to comply with the provisions of said Act.

IN WITNESS WHEREOF, the parties hereto have set their hand and seal this on the_________________ day of_____________

Signed, Sealed and Delivered in the

Presence of:

Signed:

Notary Public

13. BID SHALL INCLUDE

Untitled