IFB_Asbestos.pdf

SOLICITATION,OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

15B2111900000001

X SEALED BID (IFB)

NEGOTIATED (RFP)

2. TYPE OF SOLICITATION 3. DATE ISSUED

11/08/2018

IMPORTANT -The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

CODE7. ISSUED BY

FCI Otisville P.O Box 600

Joshua Bird

(O) 845-386-6803 j1bird@bop.gov

8. ADDRESS OFFER TO

9. FOR INFORMATION CALL: a. NAME b. TELEPHONE NO. (Include area code)(NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

11. The Contractor shall begin performance calendar days and complete it within calendar days after receiving10 30 award, X notice to proceed. This performance period is X mandatory negotiable. (See __________________________.)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12b).

X YES NO

12b. CALENDAR DAYS

Sealed offers in original and copies to perform the work required are due at the place specified in item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

a.

b. An offer guarantee is, X is not required.

All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.c.

15d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

13. ADDITIONAL SOLICITATION REQUIREMENTS:

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

IFB2111900000001 Page 1 of 21

Selected contractor shall provide all materials, labor, and equipment to Abate the Floor tile and mastic in unit EA at FCI Otisville, Otisville NY.

*Include the Following Information*

Tax ID#

DUNS#

Email Address:

bop45087 Typewritten Text Otisville NY 10963 bop45087 Typewritten Text FCI Otisville 2 MIle Dirve Otisville NY, 10963 bop45087 Typewritten Text emailed offers will be accepted bop45087 Typewritten Text 845-386-6803 bop45087 Typewritten Text Joshua Bird bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text 11am bop45087 Typewritten Text Nov 28 2018 bop45087 Typewritten Text bop45087 Typewritten Text Abate Floor Tile and Mastic Unit EA bop45087 Typewritten Text

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ___________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY 15B211

Federal Bureau of Prisons FCI Otisville 2 Mile Drive

OTISVILLE, NY 10963

27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __________ copies to issuing office) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a.NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

Joshua Bird

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 4-85)BACK

IFB2111900000001 Page 2 of 21

Federal Bureau of Prisons FCI Otisville 2 Mile Drive

OTISVILLE, NY 10963

bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text bop45087 Typewritten Text

Table of Contents

Section Description Page Number

1 Solicitation, Offer and Award 2 Commodity or Services Schedule 3 Special Contract Requirements

FAO-0001 Bonds FAO-0003 Required Insurance FAO-0004 Pre-Construction Conference FAO-0005 Submittals FAO-0006 Contractor Use of Premises FAO-0007 Payment Services FAO-0009 Contract Security (Program Statement 3000.03 Human Resource Management Manual) FAO-0010 Assignment of Contract Administration Office and Functions FAO-0012 Progress Meetings 52.24-403-70 Notice of Contractor Personnel Security Requirements (OCT 2005)

52.27-103-72 DOJ CONTRACTOR RESIDENCY REQUIREMENT BUREAU OF PRISONS (JUNE

2004)

52.218-000 CONTINUING CONTRACT PERFORMANCE DURING A PANDEMIC INFLUENZA

OR OTHER NATIONAL EMERGENCY (May 2008) 2852.223-70 Unsafe Conditions Due to the Presence of Hazardous Material (June 1996) FAO-0002 Magnitude

4 Contract Clauses 52.204-21 Basic Safeguarding of Covered Contractor Information Systems (June 2016) 52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984) FAO-0015 Changes FAO-0016 Equitable Adjustments: Waiver and Release of Claims 52.225-9 Buy American - Construction Materials (May 2014)

5 Attachments 6 Solicitation Provisions

52.216-1 Type of Contract (Apr 1984) 52.236-27 Site Visit (Construction) (Feb 1995)

7 Representations and Certifications FAO-0020 List of References and Bank Information

IFB2111900000001 Page 3 of 21

Section 2 - Commodity or Services Schedule

Asbestos Abatement and Encapsulation for EA

SCHEDULE OF SUPPLIES/SERVICES

CONTINUATION SHEET

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 Selected contractor shall provide all materials, labor, and equipment to Abate the Floor tile and mastic in unit EA at FCI Otisville, Otisville NY.

1.000000 JB $____________ $___________________

Small Business Set Aside

IFB2111900000001 Page 4 of 21

The Successful Contractor shall be responsible for all applicable federal, state, and local taxes. No tax exemption cerficitaion will be issued by the Federal Bureau of PRisons. The total price shall be written on line item 17 of the standard form 1442.

Section 3 - Special Contract Requirements

Clauses By Full Text

FAO-0001 Bonds

(a) Bid Guarantee. Each bidder shall submit with his bid a Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in provision 52.228-1, in the form of twenty percent (20) of the bid price or not to exceed $3,000,000. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be ex-pressed in dollars and cents. A bid bond is not required for bids of $150,000 or less. (FAR 28.102-1)

(b) Performance and Payment Bonds. Within 10 days after award the contractor shall execute and submit to the Contracting Of-ficer two bonds, each with good and sufficient surety or sureties acceptable to the Government, as follows; a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds will be as follows: (Not required for contracts of $150,000 or less)

(1) Performance Bond: The penal sum of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bond: The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(c) For construction contracts greater than $30,000 but not greater than $150,000, the Contracting Officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selec-ted alternatives (FAR 28.102-1(b)(1)):

(1) A Payment Bond;

(2) An irrevocable letter of credit (ILC);

(3) A tripartite escrow agreement;

(4) A Certificate of Deposit; or

(5) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(d) Individual Sureties.

(1) Bidders may elect to furnish individual surety bonds. If individual surety bonds are furnished for bid guarantees, payment or performance bonds, the individual sureties must submit their bonds proof of ownership and value of the assets which they claim in their net worth at time of bid opening. The Government's preferred method of proof is to have a statement of net worth prepared by a

IFB2111900000001 Page 5 of 21

Certified Public Accountant (CPA) in accordance with Generally Accepted Accounting Principles (GAAP). Statements from a CPA that contain disclaimers are not acceptable. The statement of net worth on the Standard Form 28, Affidavit of Individual Surety, is in-sufficient and will not be accepted without additional proof of value and ownership.

(2) Bidders are cautioned that individual sureties must provide complete and detailed information in Block 9 of Standard Form 28 concerning other contracts on which they have provided bonds. This information shall include contract number, contract location, amount, and type of bond and telephone number of the involved contracting office. Failure to provide the proof and information re-quired may result in rejection of the bid or termination of the contract for failure to provide adequate bonds.

(a) Bid Guarantee. Each bidder shall submit with his bid a Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in provision 52.228-1, in the form of twenty percent (20) of the bid price or not to exceed $3,000,000. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be ex-pressed in dollars and cents. A bid bond is not required for bids of $150,000 or less. (FAR 28.102-1)

(b) Performance and Payment Bonds. Within 10 days after award the contractor shall execute and submit to the Contracting Of-ficer two bonds, each with good and sufficient surety or sureties acceptable to the Government, as follows; a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds will be as follows: (Not required for contracts of $150,000 or less)

(1) Performance Bond: The penal sum of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bond: The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(c) For construction contracts greater than $30,000 but not greater than $150,000, the Contracting Officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selec-ted alternatives (FAR 28.102-1(b)(1)):

(1) A Payment Bond;

(2) An irrevocable letter of credit (ILC);

(3) A tripartite escrow agreement;

(4) A Certificate of Deposit; or

(5) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(d) Individual Sureties.

(1) Bidders may elect to furnish individual surety bonds. If individual surety bonds are furnished for bid guarantees, payment or performance bonds, the individual sureties must submit their bonds proof of ownership and value of the assets which they claim in their net worth at time of bid opening. The Government's preferred method of proof is to have a statement of net worth prepared by a Certified Public Accountant (CPA) in accordance with Generally Accepted Accounting Principles (GAAP). Statements from a CPA that contain disclaimers are not acceptable. The statement of net worth on the Standard Form 28, Affidavit of Individual Surety, is in-sufficient and will not be accepted without additional proof of value and ownership.

IFB2111900000001 Page 6 of 21

(2) Bidders are cautioned that individual sureties must provide complete and detailed information in Block 9 of Standard Form 28 concerning other contracts on which they have provided bonds. This information shall include contract number, contract location, amount, and type of bond and telephone number of the involved contracting office. Failure to provide the proof and information re-quired may result in rejection of the bid or termination of the contract for failure to provide adequate bonds.

FAO-0003 Required Insurance

See FAR 52.228-5, Insurance - Work on a Government Installation.

The Contractor shall, at its own expense, provide and maintain during the entire performance period of this contract, at least the kinds and minimum amounts of insurance required in the Schedule or elsewhere in the contract.

TYPE AMOUNT

(1) WORKERS COMPENSATION & EMPLOYER'S LIABILITY $100,000

The required Workmen's Compensation Insurance shall extend to cover employee's liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.

(2) COMPREHENSIVE GENERAL LIABILITY with a minimum limit of:

PER ACCIDENT OR

OCCURRENCE FOR BODILY INJURY $500,000

This insurance shall include contractor's protective and contractual liability.

(3) COMPREHENSIVE AUTOMOBILE LIABILITY with the following minimum limits:

PER PERSON $200,000

PER OCCURRENCE FOR BODILY INJURY $500,000

PER OCCURRENCE FOR PROPERTY DAMAGE $ 20,000

FAO-0004 Pre-Construction Conference

(a) Prior to the start of construction, Contracting Officers shall call a conference with the contractor, subcontractor(s), Warden, Controller/Business Administrator, Safety Manager, Facilities Administrator, Project Representative, A&E firm, Captain and other in-terested personnel to discuss the statutory labor standards, prevailing wage requirements, submission of the contractor's payrolls, sub-contractor's responsibilities, institution work schedules, local policies, contraband, parking, storage of vehicles and equipment, etc.

Minutes of the conference shall be recorded, listing the names and titles of all attendees, and the subject matter of all items covered.

The minutes shall be signed by the contractor and the Contracting Officer, and a signed copy placed in the contract file.

(b) The Contractor shall familiarize himself/herself with all procedures involved in normal institution routines. Any requirements which may constitute a problem or result in conflict, will be brought to the attention of the Contracting Officer or his representative for determination.

FAO-0005 Submittals

Within 10 calendar days after commencement of work or as otherwise established by the Contracting Officer, all materials and articles requiring approval, as contemplated by the Materials and Workmanship clause, shall be submitted by the contractor.

The submittal process is in place to allow the Government the opportunity to determine whether materials or procedures used by the contractor are in accordance with contract requirements. It is ultimately the Contractor's responsibility via the quality control process to ensure submittal items installed under the contract and work performed on site are in accordance with industry standards and gener-al practices.

(a) The types of submittal requirements specified in this contract may include, but is not limited to; shop drawings, product data, samples, certificates of conformance or compliance, certified test or inspection reports, equipment, materials, and miscellaneous work

IFB2111900000001 Page 7 of 21 related submittals for construction. Individual submittal requirements are generally specified in applicable sections for each unit of work in the specifications and/or as a whole in one section in the statement of work.

(b) The Bureau of Prisons (BOP) Contracting Officer’s Representative (COR) shall act for the Contracting Officer in the review and acceptance of all submittals. The Contractor shall submit submittals as required by the contract/specifications to the COR for transmittal to the Contracting Officer. Fabrication of any work or purchase or use of any submittals (such as materials for which samples are required or equipment, etc.) shall not take place until written acceptance is given by the COR, except at the Contractor's own risk.

(c) The Contractor shall submit all shop drawings and submittals sufficiently in advance (unless otherwise specified in the spe-cifications) of the construction requirements to allow ample time for checking, re-submitting, and re-checking.

(d) Failure of any materials to pass their specified tests shall be sufficient cause for refusal to consider, under this contract, any fur-ther samples of the same brand or make of that material. The Government reserves the right to disapprove any material or equipment which has previously proven unsatisfactory in service.

(e) The Contracting Officer’s or designee’s approval or acceptance of submittals is not to be construed as a complete check. Ap-proval or acceptance will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor is responsible for the satisfactory construction of all work. The Contractor is responsible for delivering a final product/system that is operational as intended by the contract requirements, regardless of any Government approvals or acceptance of submittals. The Government assumes no liability during the submittal approval/acceptance process. It is the sole responsibility of the Contractor to deliver a properly func-tioning product or system.

FAO-0006 Contractor Use of Premises

Work Hours The project schedule is based on a normal forty (40) hour work week, eight (8) hours per day, Monday through Friday, excluding Fed-eral holidays. The Contracting Officer’s Representative (COR) shall establish the work hour time frames for the duration of the project, subject to the approval of the Contracting Officer. Work hours and work days may be altered only with a 48 hour advance ap-proval of the Contracting Officer.

NOTE: Access to the site will be available during normal working hours except during emergencies. It shall be the responsibility of the Contractor to familiarize himself, his employees, and his subcontractors of the working hours and conditions in the correctional fa-cility, as working hours may not constitute a full eight hour day. The Government assumes no responsibility to the Contractor, nor to any of his subcontractors, for shorter hours due to institutional emergencies or entry and/or exit of workers necessitated by normal in-stitution routines. The procedures and institutional entrance/exit routines applicable to this project will be explained at both the pre-bid conference/site visit and the pre-construction meeting.

Contraband The Contractor shall inform his employees that intoxicating beverages, drugs, weapons, etc., will not be allowed on the site. Introduc-tion of contraband shall be subject to the penalties prescribed by Title 18 USC-1791.

Explosives The use of explosives is absolutely forbidden without written authorization from the Contracting Officer.

Parking and Temporary Office Parking will be available at the site to the extent it does not interfere with construction activities. Otherwise, parking shall be provided for by the Contractor, at his expense, off the site for workmen employed on the project. Any temporary field office used by the Con-tractor shall be located in an area approved by the COR.

Safety and Accident Prevention In performing work under this contract the contractor shall:

(a) Conform to the specific safety requirements established by this contract;

(b) Comply with the safety rules of the Government institution that concern related activities not directly addressed in this con-tract;

(c) Take all reasonable steps and precautions to prevent accidents and preserve the life and health of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(d) Take such additional immediate precautions as the Contracting Officer and/or COR may reasonably require for safety and acci-dent prevention purposes.

IFB2111900000001 Page 8 of 21

FAO-0007 Payment Services

(a) Original application for payment shall be prepared on AIA (American Institute of Architects) Form G-702 "Application and Certificate for Payment" and submitted to the Contracting Officer. The contractor may use another form; however, it shall contain similar information as the AIA Form G-702. The Contracting Officer will approve the amount of payment by signing and forwarding the application and certificate as follows: Original to Accounting; Copy for Contract Award File.

(b) All small business contractors are required to self-certify on all invoices their small business status.

FAO-0009 Contract Security (Program Statement 3000.03 Human Resource Management Manual)

The following security measures will be applied to all contract employees who will be working under the terms of the contract:

National Crime Information Center (NCIC) Check Name Check Fingerprint Check (FD-258) OF-306, Declaration for Federal Employment, and Appropriate Resume or Optional Application Contract Pre-employment Form Release of Information

FAO-0010 Assignment of Contract Administration Office and Functions

Pursuant to FAR 42.201 and 42.202, the assigned Contract Administration Office is listed in Block 26 of the Standard Form 1442 Back. This assignment carries with it the authority to perform all of the contract administration functions listed in FAR 42.302(a) and 42.302(b) to the extent that those functions apply to the contract.

FAO-0012 Progress Meetings

The Administrative Contracting Officer (ACO) shall conduct progress meetings at the project site on a monthly basis, or at intervals as determined by the ACO.

(a) At a minimum, the attendees shall include but is not limited to:

(1) FBOP: Administrative Contracting Officer, Contracting Officer’s Representative (COR), Facility Administrator/Man-ager, Architect/Engineer (if applicable), Other Personnel (Executive Staff, Captain, Safety Manager, etc.).

(2) Contractor: Project Manager, Superintendent, and technical support disciplines as appropriate (Subcontractors, Manu-facturers, Suppliers, etc.).

(b) The meeting should include, but is not limited to issues such as:

Administrative Contracting Officer:

(1) Old business from previous progress meeting(s);

(2) Status of modifications, certified payrolls, submittals, requests for information (RFI);

(3) Review of payments made to date and review/approve current payment request;

(4) Status of modification proposal requests;

(5) Discuss new business.

COR:

(1) Status of escort coverage;

(2) Review gate or sallyport entrance/exit issues;

(3) Discuss other delays contractor may be experiencing;

(4) Discuss performance/quality issues.

IFB2111900000001 Page 9 of 21

Contractor:

(1) Review/discuss updated progress schedule;

(2) Provide 30 day outlook;

(3) Discuss other issues affecting performance.

52.24-403-70 Notice of Contractor Personnel Security Requirements (OCT 2005)

Compliance with Homeland Security Presidential Directive-12 (HSPD-12) and Federal Information Processing Standard Publication 201 (FIPS 201) 1 entitled "Personal Identification Verification (PIV) for Federal Employees and Contractors," Phase I.

1. Long-Term Contractor Personnel:

In order to be compliant with HSPD-12/PIV I, the following investigative requirements must be met for each new long-term 2 con-tractor employee whose background investigation (BI) process begins on or after October 27, 2005:

a. Contractor Personnel must present two forms of identification in original form prior to badge issuance (acceptable documents are listed in Form I-9, OMB No. 1615-0047, "Employment Eligibility Verification," and at least one document must be a valid State or Federal government-issued picture ID);

b. Contractor Personnel must appear in person at least once before a DOJ official who is responsible for checking the identification documents. This identity proofing must be completed sometime during the clearance process but prior to badge issuance and must be documented by the DOJ official;

c. Contractor Personnel must undergo a BI commensurate with the designated risk level associated with the duties of each position.

Outlined below are the minimum BI requirements for each risk level:

• High Risk - Background Investigation (5 year scope)

• Moderate Risk - Limited Background Investigation (LBI) or Minimum Background Investigation (MBI)

• Low Risk - National Agency Check with Inquiries (NACI) investigation

d. The pre-appointment BI waiver requirements for all position sensitivity levels are a:

1) Favorable review of the security questionnaire form;

2) Favorable fingerprint results;

3) Favorable credit report, if required;3

4) Waiver request memorandum, including both the Office of Personnel Management schedule date and position sensitivity/risk level;

and

5) Favorable review of the National Agency Check (NAC) 4 portion of the applicable BI that is determined by position sensitivity/risk level.

A badge may be issued following approval of the above waiver requirements.

If the NAC is not received within five days of OPM's scheduling date, the badge can be issued based on a favorable review of the Se-curity Questionnaire and the Federal Bureau of Investigation Criminal History Check (i.e., fingerprint check results).

e. Badge re-validation will occur once the investigation is completed and favorably adjudicated. If the BI results so justify, badges is-sued under these procedures will be suspended or revoked.

2. Short-Term Contractor Personnel:

It is the policy of the DOJ that short-term contractors having access to DOJ information systems and/or DOJ facilities or space for six months or fewer are subject to the identity proofing requirements listed in items 1a. and 1b. above. The pre-appointment waiver re-quirements for short-term contractors are:

a. Favorable review of the security questionnaire form;

b. Favorable fingerprint results;

c. Favorable credit report, if required;5 and

d. Waiver request memorandum indicating both the position sensitivity/risk level and the duration of the appointment. The commen-surate BI does not need to be initiated.

A badge may be issued following approval of the above waiver requirements and the badge will expire six months from the date of is-suance. This process can only be used once for a short-term contractor in a twelve month period. This will ensure that any consecutive short-term appointments are subject to the full PIV-I identity proofing process.

For example, if a contractor employee requires daily access for a three or four-week period, this contractor would be cleared according to the above short-term requirements. However, if a second request is submitted for the same contractor employee within a twelve-month period for the purpose of extending the initial contract or for employment under a totally different contract for another three or four-week period, this contractor would now be considered "long-term" and must be cleared according to the long-term requirements as stated in this interim policy.

3. Intermittent Contractors:

An exception to the above-mentioned short-term requirements would be intermittent contractors.

a. For purposes of this policy, "intermittent" is defined as those contractor employees needing access to DOJ information systems and/ or DOJ facilities or space for a maximum of one day per week, regardless of the duration of the required intermittent access. For ex-ample, the water delivery contractor that delivers water one time each week and is working on a one-year contract.

b. Contractors requiring intermittent access should follow the Department's escort policy. Please reference the August 11, 2004, and January 29, 2001, Department Security Officer policy memoranda that conveys the requirements for contractor facility escorted ac-cess.

IFB2111900000001 Page 10 of 21

c. Due to extenuating circumstances, if a component requests unescorted access or DOJ IT system access for an intermittent contract-or, the same pre-employment background investigation waiver requirements that apply to short-term contractors are required.

d. If an intermittent contractor is approved for unescorted access, the contractor will only be issued a daily badge. The daily badge will be issued upon entrance into a DOJ facility or space and must be returned upon exiting the same facility or space.

e. If an intermittent contractor is approved for unescorted access, the approval will not exceed one year. If the intermittent contractor requires unescorted access beyond one year, the contractor will need to be re-approved each year.

4. An individual transferring from another department or agency shall not be re-adjudicated provided the individual has a current (within the last five years), favorably adjudicated BI meeting HSPD-12 and DOJ's BI requirements.

5. The DOJ's current escorted contractor policy remains unchanged by this acquisition notice.

Notes:

1. FIPS 201 is available at: www.csrc.nist.gov/publications/fips/fips201/FIPS-201-022505.pdf

2. Under HSPD-12, long-term contractors are contractors having access to DOJ information systems and/or DOJ facilities or space for six months or longer. The PIV-I identity proofing process, including initiation and adjudication of the required background investiga-tion, is required for all new long-term contractors regardless of whether it is the current practice to issue a badge. The second phase of HSPD-12 implementation (PIV-II) requires badge issuance to all affected long-term contractors.

3. For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

4. In order to avoid a delay in the hiring process, components should request an Advance NAC Report when initiating investigations to OPM. Per OPM ' s instructions, to obtain an Advance NAC Report, a Code " 3" must be placed in block " B " of the " Agency Use Only " section of the investigative form. This report is available for all case types.

5.For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

[End of Clause]

52.27-103-72 DOJ CONTRACTOR RESIDENCY REQUIREMENT BUREAU OF PRISONS (JUNE 2004)

For three of the five years immediately prior to submission of an offer/bid/quote, or prior to performance under a contract or commit-ment, individuals or contractor employees providing services must have:

1. Legally resided in the United States (U.S.);

2. worked for the U.S. overseas in a Federal or military capacity; or

3. been a dependent of a Federal or military employee serving overseas.

If the individual is not a U.S. citizen, they must be from a country allied with the U.S. The following website provides current inform-ation regarding allied countries: http://www.opm.gov/employ/html/citizen.htm By signing this contract or commitment document, or by commencing performance, the contractor agrees to this restriction.

[End of Clause]

52.218-000 CONTINUING CONTRACT PERFORMANCE DURING A PANDEMIC INFLUENZA OR OTHER NATIONAL EMERGENCY (May 2008)

During a Pandemic or other emergency we understand that our contractor workforce will experience the same high levels of absentee-ism as our federal employees. Although the Excusable Delays and Termination for Default clauses used in Government contracts list epidemics and quarantine restrictions among the reasons to excuse delays in contract performance, we expect our contractors to make a reasonable effort to keep performance at an acceptable level during emergency periods.

The Office of Personnel Management (OPM) has provided guidance to federal managers and employees on the kinds of actions to be taken to ensure the continuity of operations during emergency periods. This guidance is also applicable to our contract workforce.

Contractors are expected to have reasonable policies in place for continuing work performance, particularly those performing mission critical services, during a pandemic influenza or other emergency situation.

The types of actions a federal contractor should reasonably take to help ensure performance are:

• Encourage employees to get inoculations or follow other preventive measures as advised by the public health service.

• Cross-train workers as backup for all positions performing critical services. This is particularly important for work such as guard services where telework is not an option.

• Implement telework to the greatest extent possible in the workgroup so systems are in place to support suc-cessful remote work in an emergency.

• Communicate expectations to all employees regarding their roles and responsibilities in relation to remote work in the event of a pandemic health crisis or other emergency.

• Establish communication processes to notify employees of activation of this plan.

• Integrate pandemic health crisis response expectations into telework agreements.

• With the employee, assess requirements for working at home (supplies and equipment needed for an extended telework period). Security concerns should be considered in making equipment choices; agencies or contract-ors may wish to avoid use of employees' personal computers and provide them with PCs or laptops as appropri-ate.

IFB2111900000001 Page 11 of 21

• Determine how all employees who may telework will communicate with one another and with management to accomplish work.

• Practice telework regularly to ensure effectiveness.

• Make it clear that in emergency situations, employees must perform all duties assigned by management, even if they are outside usual or customary duties.

• Identify how time and attendance will be maintained.

It is the contractor's responsibility to advise the Government Contracting Officer if they anticipate not being able to perform and to work with the Department to fill gaps as necessary. This means direct communication with the Contracting Officer or in his/her ab-sence, another responsible person in the contracting office via telephone or email messages acknowledging the contractor's notifica-tion. The incumbent contractor is responsible for assisting the Department in estimating the adverse impacts of nonperformance and to work diligently with the Department to develop a strategy for maintaining the continuity of operations.

The Department does reserve the right in such emergency situations to use Federal employees, employees of other agencies, contract support from other existing contractors, or to enter into new contracts for critical support services. Any new contracting efforts would be acquired following the guidance in the Office of federal Procurement Policy issuance "Emergency Acquisitions", May, 2007 and Subpart 18.2. Emergency Acquisition Flexibilities, of the Federal Acquisition Regulations.

[End of Clause]

2852.223-70 Unsafe Conditions Due to the Presence of Hazardous Material (June 1996)

(a) "Unsafe condition" as used in this clause means the actual or potential exposure of contractor or Government employees to a haz-ardous material as defined in Federal Standard No. 313, and any revisions thereto during the term of this contract, or any other materi-al or working condition designated by the Contracting Officer's Technical Representative (COTR) as potentially hazardous and requir-ing safety controls.

(b) The Occupational Safety and Health Administration (OSHA) is responsible for issuing and administering regulations that require contractors to apprise its employees of all hazards to which they may be exposed in the course of their employment; proper conditions and precautions for safe use and exposure; and related symptoms and emergency treatment in the event of exposure.

(c) Prior to commencement of work, contractors are required to inspect for and report to the contracting officer or designee the pres-ence of, or suspected presence of, any unsafe condition including asbestos or other hazardous materials or working conditions in areas in which they will be working.

(d) If during the performance of the work under this contract, the contractor or any of its employees, or subcontractor employees, dis-covers the existence of an unsafe condition, the contractor shall immediately notify the contracting officer, or designee, (with written notice provided not later than three (3) working days thereafter) of the existence of an unsafe condition. Such notice shall include the contractor's recommendations for the protection and the safety of Government, contractor and subcontractor personnel and property that may be exposed to the unsafe condition.

(e) When the Government receives notice of an unsafe condition from the contractor, the parties will agree on a course of action to mitigate the effects of that condition and, if necessary, the contract will be amended. Failure to agree on a course of action will consti-tute a dispute under the Disputes clause of this contract.

(f) Nothing contained in this clause shall relieve the contractor or subcontractors from complying with applicable Federal, State, and local laws, codes, ordinances and regulations (including the obtaining of licenses and permits) in connection with hazardous material including but not limited to the use, disturbance, or disposal of such material.

(End of Clause)

FAO-0002 Magnitude

The magnitude of this project is between $25,000.00 and $100,000.00.

IFB2111900000001 Page 12 of 21

Section 4 - Contract Clauses

Clauses By Reference

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov

Clause Title Fill-ins (if applicable)

52.246-12 Inspection of Construction (Aug 1996)

52.243-4 Changes (June 2007)

52.219-6 Notice of Total Small Business Set-Aside (Nov 2011)

52.222-50 Combating Trafficking in Persons (Mar 2015)

52.222-6 Construction Wage Rate Requirements (Aug 2018)

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

(Aug 2011)

52.228-14 Irrevocable Letter of Credit (Nov 2014)

52.228-15 Performance and Payment Bonds - Construction (Oct 2010)

52.228-5 Insurance - Work on a Government Installation (Jan 1997)

52.232-33 Payment by Electronic Funds Transfer-System for Award Management

(Oct 2018)

52.249-2 Termination for Convenience of the Government (Fixed-Price) (Apr

2012)

52.253-1 Computer Generated Forms (Jan 1991)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements (Apr 1984)

52.236-7 Permits and Responsibilities (Nov 1991)

52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984)

52.236-26 Preconstruction Conference (Feb 1995)

52.236-2 Differing Site Conditions (Apr 1984)

52.236-15 Schedules for Construction Contracts (Apr 1984)

52.236-12 Cleaning Up (Apr 1984)

IFB2111900000001 Page 13 of 21

Clause Title Fill-ins (if applicable)

52.204-13 System for Award Management Maintenance (Oct 2018)

Clauses By Full Text

52.204-21 Basic Safeguarding of Covered Contractor Information Systems (June 2016)

(a) Definitions. As used in this clause--

Covered contractor information system means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

Federal contract information means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Govern-ment to the public (such as on public Web sites) or simple transactional information, such as necessary to process payments.

Information means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, in-cluding textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction

(CNSSI) 4009).

Information system means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

Safeguarding means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures. (1) The Contractor shall apply the following basic safeguarding requirements and pro-cedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other in-formation systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational informa-tion systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal net-works.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

IFB2111900000001 Page 14 of 21

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Fed-eral agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this con-tract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within ________ calendar days after the date the Contract-or receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than _______________.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calen-dar date.

FAO-0015 Changes

(a) Changes will be in accordance with the Changes clause 52.243-4 or Changes and Changed Conditions clause 52.243-5 whichever applies to this contract.

(b) When changes are made in the work that requires an equitable adjustment to the contract, the Contractor shall submit to the Contracting Officer, through the Contracting Officer’s Representative (COR), a written proposal for adjustment of the amount of in-crease or decrease. With the proposal, the Contractor shall submit an itemized breakdown in at least the following detail:

(1) Material quantities and unit cost

(2) Labor costs by material item

(3) Construction equipment cost

(4) Workmen's compensation and public liability insurance

(5) Overhead

(6) Profit or commission

(7) Employment taxes (FICA and FUTA)

(c) The maximum allowable overhead, profit and commission percentages are contained below. The percentages for overhead, profit and commission shall be negotiated and may vary according to the nature, extent and complexity of the work involved, but in no case shall exceed the following:

(1) To the Contractor, on work performed by other than his own forces. The commission is 10% in the first $20,000, 7 1/2% on the next $30,000, 5% on the balance over $50,000.

(2) To the Contractor, and/or the Subcontractors for that portion of the work performed with their respective forces. The commission is 10% overhead and 10% profit on the first $20,000, 7 1/2% overhead and 7 1/2% profit on the next $30,000, and 5% overhead and 5% profit on the balance over $50,000.

Not more than three (3) percentages, not to exceed the maximum percentage amounts shown above, will be allowed regardless of the number of Subcontractors (i.e., the mark up on work subcontracted by the Subcontractor will be limited to the overhead percentage and one profit percentage in addition to the prime Contractor's commission percentage). On proposals covering both increases and decreases in the amount of the contract, overhead, profit and commission will be allowed on the net in-crease only.

(d) When certified cost or pricing data are required under FAR 15.403-4 for proposals over $700,000, the cost or pricing data shall be submitted in accordance with FAR 15.408, Table 15-2. No itemized breakdown will be required for proposals amounting to less than $1,000.

IFB2111900000001 Page 15 of 21 bop45087 Typewritten Text bop45087

30 CD

(e) When the necessity to proceed with a change does not allow sufficient time to negotiate a modification or because of failure to reach an agreement, the Contracting Officer may issue a change order instructing the contractor to proceed on the basis of a tentative price based on the best estimate available at the time, with the firm price to be determined later. Furthermore, when the change order is issued, the contractor shall submit a proposal for cost of changes in work within 30 calendar days.

(f) The Contracting Officer will consider issuing a settlement by determination to the contract, if the contractor's proposal re-quired by paragraphs (a) and (b) of this clause is not received within 30 calendar days, or if agreement has not been reached.

(g) Where a change involves credit items only, a proper measure of the amount of downward adjustment in the contract price is the reasonable cost to the contractor if he/she had performed the deleted work. A reasonable allowance for overhead and profit are properly includable as part of the downward adjustment for a deductive change. The amount of such allowance is subject to negoti-ation.

(h) Overhead and contractor's fee percentages shall be considered to include insurance other than mentioned herein, field and of-fice supervisors and assistants, security police, use of small tools, incidental job burdens, and general home office expenses and no separate allowance will be made therefor. Assistants to office supervisors include all clerical, stenographic and general office help. In-cidental job burdens include, but are not necessarily limited to, office equipment and supplies, temporary toilets, telephone and con-formance to OSHA requirements. Items such as, but not necessarily limited to, review and coordination, estimating and expediting rel-ative to contract changes are associated with field and office supervision and are considered to be included in the contractor's overhead and/or fee percentage.

(i) The Contractor shall submit with his proposal a request for time extension, if applicable.

(j) The COR shall review the proposal and check estimates in detail, utilizing unit prices where specified or agreed upon. If they are in agreement, the COR shall forward the proposal to the Contracting Officer.