SOLICITATION_EMERGENCY_POWER_REPAIRa.pdf

15B11418Q00000029A Page 1 of 27

SOLICITATION,OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

15B11418Q00000029A

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFQ)

3. DATE ISSUED

05/17/2018

IMPORTANT -The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

0030-18

6. PROJECT NO.

1C1V

7. ISSUED BY CODE 15B114 8. ADDRESS OFFER TO

Federal Bureau of Prisons Mary A. Williams FCC Petersburg (O) 804-504-7200 1060 River Road Hopewell, VA 23860

Federal Bureau of Prisons FCC Petersburg 1060 River Road

9. FOR INFORMATION CALL: a. NAME

Mary A. Williams

b. TELEPHONE NO. (Include area code)(NO COLLECT CALLS)

804-504-7200 ex.1070

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" means "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

The contractor should provide quotes for EMERGENCY POWER SYSTEM REPAIRS, at FCC Petersburg, VA in accordance with the requirements of solicitation 15B11418Q00000029A.

*INCLUDE THE FOLLOWING INFORMATION*

DUNS NUMBER:

TIN NUMBER:

CAGE CODE:

EMAIL:

11. The Contractor shall begin performance 10 calendar days and complete it within 90 calendar days after receiving award, X notice to proceed. This performance period is X mandatory negotiable. (See 52.211-10.)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS? (If "YES," indicate within how many calendar days after award in Item 12b).

X YES NO

12b. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS

a. Sealed offers in original and copies to perform the work required are due at the place specified in item 8 by 2:00PM (hour) local time 0 6 / 0 7 / 2 0 1 8 (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee X is, is not required. (See FAO-0001 Bonds, on page 8 for bid bond applicability)

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference

d. Offers providing less than 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

15B11418Q00000029A Page 2 of 27

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

AMOUNTS TOTAL FIRM-FIXED-PRICE OFFER AMOUNT: $

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED

AWARD (To be completed by Government)

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

X3-FP011411-1C1V-2599 YREG: T C 1 3 0 0 0 1

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 27 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY BOXF 27. PAYMENT WILL BE MADE BY

Federal Bureau of Prisons FCC Petersburg 1060 River Road

Federal Bureau of Prisons FCC Petersburg 1060 River Road

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

Mary A. Williams

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 4-85)BACK

15B11418Q00000029A Page 3 of 27

Table of Contents

Section Description Page Number

1 Solicitation, Offer and Award 2 Commodity or Services Schedule 3 Special Contract Requirements 4 Contract Clauses 5 Attachments 6 Solicitation Provisions 7 Representations and Certifications

15B11418Q00000029A Page 4 of 27

Section 2 - Commodity or Services Schedule

SCHEDULE OF SUPPLIES/SERVICES

CONTINUATION SHEET

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Provide quote for EMERGENCY POWER SYSTEM REPAIR at FCC Petersburg for solicitation 15B11418Q00000029A.

NO ADDITIONAL LINE INFORMATION

1 JB $ $

The successful contractor shall be responsible for all applicable federal, state, and local taxes. THE TOTAL PRICE SHALL BE

WRITTEN IN BLOCK 17 OF THE STANDARD FORM 1442.

15B11418Q00000029A Page 5 of 27

Section 3 - Special Contract Requirements

Clauses by Full Text

2852.223-70 Unsafe Conditions Due to the Presence of Hazardous Material (June 1996)

(a) "Unsafe condition" as used in this clause means the actual or potential exposure of contractor or Government employees to a haz-ardous material as defined in Federal Standard No. 313, and any revisions thereto during the term of this contract, or any other materi-al or working condition designated by the Contracting Officer's Technical Representative (COTR) as potentially hazardous and requir-ing safety controls.

(b) The Occupational Safety and Health Administration (OSHA) is responsible for issuing and administering regulations that require contractors to apprise its employees of all hazards to which they may be exposed in the course of their employment; proper conditions and precautions for safe use and exposure; and related symptoms and emergency treatment in the event of exposure.

(c) Prior to commencement of work, contractors are required to inspect for and report to the contracting officer or designee the pres-ence of, or suspected presence of, any unsafe condition including asbestos or other hazardous materials or working conditions in areas in which they will be working.

(d) If during the performance of the work under this contract, the contractor or any of its employees, or subcontractor employees, dis-covers the existence of an unsafe condition, the contractor shall immediately notify the contracting officer, or designee, (with written notice provided not later than three (3) working days thereafter) of the existence of an unsafe condition. Such notice shall include the contractor's recommendations for the protection and the safety of Government, contractor and subcontractor personnel and property that may be exposed to the unsafe condition.

(e) When the Government receives notice of an unsafe condition from the contractor, the parties will agree on a course of action to mitigate the effects of that condition and, if necessary, the contract will be amended. Failure to agree on a course of action will consti-tute a dispute under the Disputes clause of this contract.

(f) Nothing contained in this clause shall relieve the contractor or subcontractors from complying with applicable Federal, State, and local laws, codes, ordinances and regulations (including the obtaining of licenses and permits) in connection with hazardous material including but not limited to the use, disturbance, or disposal of such material.

(End of Clause)

52.21-603-70 Contracting Officer's Representative (COR) (June 2012)

(a) John Tiller, Engineering Technician, FCC Petersburg,804-504-7200 ext. 4269, is hereby designated as the Contracting Officer's Representative (COR) under this contract.

(b) The COR is responsible, as applicable, for: receiving all deliverables, inspecting and accepting the supplies or services provide hereunder in accordance with the terms and conditions of this contract; providing direction to the contractor which clarifies the con-tractor effort, fills in details or otherwise serves to accomplish the contractual Scope of Work; evaluating performance; and certifying all invoices/vouchers for acceptance of the supplies or services furnished for payment.

(c) The COR does not have the authority to alter the contractor's obligations under the contract, and/or modify any of the expressed terms, conditions, specifications, or cost of the agreement. If as a result of technical discussions it is desirable to alter/change contrac-tual obligations or the Scope of Work, the Contracting Officer shall issue such changes.

52.218-000 CONTINUING CONTRACT PERFORMANCE DURING A PANDEMIC INFLUENZA OR OTHER NATIONAL EMERGENCY (May 2008)

During a Pandemic or other emergency we understand that our contractor workforce will experience the same high levels of absentee-ism as our federal employees. Although the Excusable Delays and Termination for Default clauses used in Government contracts list epidemics and quarantine restrictions among the reasons to excuse delays in contract performance, we expect our contractors to make a reasonable effort to keep performance at an acceptable level during emergency periods.

The Office of Personnel Management (OPM) has provided guidance to federal managers and employees on the kinds of actions to be taken to ensure the continuity of operations during emergency periods. This guidance is also applicable to our contract workforce.

Contractors are expected to have reasonable policies in place for continuing work performance, particularly those performing mission critical services, during a pandemic influenza or other emergency situation.

The types of actions a federal contractor should reasonably take to help ensure performance are:

• Encourage employees to get inoculations or follow other preventive measures as advised by the public health ser-vice.

• Cross-train workers as backup for all positions performing critical services. This is particularly important for work such as guard services where telework is not an option.

• Implement telework to the greatest extent possible in the workgroup so systems are in place to support successful re-mote work in an emergency.

• Communicate expectations to all employees regarding their roles and responsibilities in relation to remote work in the event of a pandemic health crisis or other emergency.

15B11418Q00000029A Page 6 of 27

• Establish communication processes to notify employees of activation of this plan.

• Integrate pandemic health crisis response expectations into telework agreements.

• With the employee, assess requirements for working at home (supplies and equipment needed for an extended tele-work period). Security concerns should be considered in making equipment choices; agencies or contractors may wish to avoid use of employees' personal computers and provide them with PCs or laptops as appropriate.

• Determine how all employees who may telework will communicate with one another and with management to accom-plish work.

• Practice telework regularly to ensure effectiveness.

• Make it clear that in emergency situations, employees must perform all duties assigned by management, even if they are outside usual or customary duties.

• Identify how time and attendance will be maintained.

It is the contractor's responsibility to advise the Government Contracting Officer if they anticipate not being able to perform and to work with the Department to fill gaps as necessary. This means direct communication with the Contracting Officer or in his/her ab-sence, another responsible person in the contracting office via telephone or email messages acknowledging the contractor's notifica-tion. The incumbent contractor is responsible for assisting the Department in estimating the adverse impacts of nonperformance and to work diligently with the Department to develop a strategy for maintaining the continuity of operations.

The Department does reserve the right in such emergency situations to use Federal employees, employees of other agencies, contract support from other existing contractors, or to enter into new contracts for critical support services. Any new contracting efforts would be acquired following the guidance in the Office of federal Procurement Policy issuance "Emergency Acquisitions", May, 2007 and Subpart 18.2. Emergency Acquisition Flexibilities, of the Federal Acquisition Regulations.

[End of Clause]

52.24-403-70 Notice of Contractor Personnel Security Requirements (OCT 2005)

Compliance with Homeland Security Presidential Directive-12 (HSPD-12) and Federal Information Processing Standard Publication 201 (FIPS 201) 1 entitled "Personal Identification Verification (PIV) for Federal Employees and Contractors," Phase I.

1. Long-Term Contractor Personnel:

In order to be compliant with HSPD-12/PIV I, the following investigative requirements must be met for each new long-term 2 con-tractor employee whose background investigation (BI) process begins on or after October 27, 2005:

a. Contractor Personnel must present two forms of identification in original form prior to badge issuance (acceptable documents are listed in Form I-9, OMB No. 1615-0047, "Employment Eligibility Verification," and at least one document must be a valid State or Federal government-issued picture ID);

b. Contractor Personnel must appear in person at least once before a DOJ official who is responsible for checking the identification documents. This identity proofing must be completed sometime during the clearance process but prior to badge issuance and must be documented by the DOJ official;

c. Contractor Personnel must undergo a BI commensurate with the designated risk level associated with the duties of each position.

Outlined below are the minimum BI requirements for each risk level:

• High Risk - Background Investigation (5 year scope)

• Moderate Risk - Limited Background Investigation (LBI) or Minimum Background Investigation (MBI)

• Low Risk - National Agency Check with Inquiries (NACI) investigation

d. The pre-appointment BI waiver requirements for all position sensitivity levels are a:

1) Favorable review of the security questionnaire form;

2) Favorable fingerprint results;

3) Favorable credit report, if required;3

4) Waiver request memorandum, including both the Office of Personnel Management schedule date and position sensitivity/risk level;

and

5) Favorable review of the National Agency Check (NAC) 4 portion of the applicable BI that is determined by position sensitivity/risk level.

A badge may be issued following approval of the above waiver requirements.

If the NAC is not received within five days of OPM's scheduling date, the badge can be issued based on a favorable review of the Se-curity Questionnaire and the Federal Bureau of Investigation Criminal History Check (i.e., fingerprint check results).

e. Badge re-validation will occur once the investigation is completed and favorably adjudicated. If the BI results so justify, badges is-sued under these procedures will be suspended or revoked.

2. Short-Term Contractor Personnel:

It is the policy of the DOJ that short-term contractors having access to DOJ information systems and/or DOJ facilities or space for six months or fewer are subject to the identity proofing requirements listed in items 1a. and 1b. above. The pre-appointment waiver re-quirements for short-term contractors are:

a. Favorable review of the security questionnaire form;

b. Favorable fingerprint results;

c. Favorable credit report, if required;5 and

15B11418Q00000029A Page 7 of 27

d. Waiver request memorandum indicating both the position sensitivity/risk level and the duration of the appointment. The commen-surate BI does not need to be initiated.

A badge may be issued following approval of the above waiver requirements and the badge will expire six months from the date of is-suance. This process can only be used once for a short-term contractor in a twelve month period. This will ensure that any consecutive short-term appointments are subject to the full PIV-I identity proofing process.

For example, if a contractor employee requires daily access for a three or four-week period, this contractor would be cleared according to the above short-term requirements. However, if a second request is submitted for the same contractor employee within a twelve-month period for the purpose of extending the initial contract or for employment under a totally different contract for another three or four-week period, this contractor would now be considered "long-term" and must be cleared according to the long-term requirements as stated in this interim policy.

3. Intermittent Contractors:

An exception to the above-mentioned short-term requirements would be intermittent contractors.

a. For purposes of this policy, "intermittent" is defined as those contractor employees needing access to DOJ information systems and/ or DOJ facilities or space for a maximum of one day per week, regardless of the duration of the required intermittent access. For ex-ample, the water delivery contractor that delivers water one time each week and is working on a one-year contract.

b. Contractors requiring intermittent access should follow the Department's escort policy. Please reference the August 11, 2004, and January 29, 2001, Department Security Officer policy memoranda that conveys the requirements for contractor facility escorted ac-cess.

c. Due to extenuating circumstances, if a component requests unescorted access or DOJ IT system access for an intermittent contract-or, the same pre-employment background investigation waiver requirements that apply to short-term contractors are required.

d. If an intermittent contractor is approved for unescorted access, the contractor will only be issued a daily badge. The daily badge will be issued upon entrance into a DOJ facility or space and must be returned upon exiting the same facility or space.

e. If an intermittent contractor is approved for unescorted access, the approval will not exceed one year. If the intermittent contractor requires unescorted access beyond one year, the contractor will need to be re-approved each year.

4. An individual transferring from another department or agency shall not be re-adjudicated provided the individual has a current (within the last five years), favorably adjudicated BI meeting HSPD-12 and DOJ's BI requirements.

5. The DOJ's current escorted contractor policy remains unchanged by this acquisition notice.

Notes:

1. FIPS 201 is available at: www.csrc.nist.gov/publications/fips/fips201/FIPS-201-022505.pdf

2. Under HSPD-12, long-term contractors are contractors having access to DOJ information systems and/or DOJ facilities or space for six months or longer. The PIV-I identity proofing process, including initiation and adjudication of the required background investiga-tion, is required for all new long-term contractors regardless of whether it is the current practice to issue a badge. The second phase of HSPD-12 implementation (PIV-II) requires badge issuance to all affected long-term contractors.

3. For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

4. In order to avoid a delay in the hiring process, components should request an Advance NAC Report when initiating investigations to OPM. Per OPM ' s instructions, to obtain an Advance NAC Report, a Code " 3" must be placed in block " B " of the " Agency Use Only " section of the investigative form. This report is available for all case types.

5.For contractors in position sensitivity/risk levels above level 1, a favorable review of a credit check is required as part of the pre-appointment waiver package.

[End of Clause]

52.27-103-72 DOJ CONTRACTOR RESIDENCY REQUIREMENT BUREAU OF PRISONS (JUNE 2004)

For three of the five years immediately prior to submission of an offer/bid/quote, or prior to performance under a contract or commit-ment, individuals or contractor employees providing services must have:

1. Legally resided in the United States (U.S.);

2. worked for the U.S. overseas in a Federal or military capacity; or

3. been a dependent of a Federal or military employee serving overseas.

If the individual is not a U.S. citizen, they must be from a country allied with the U.S. The following website provides current inform-ation regarding allied countries: http://www.opm.gov/employ/html/citizen.htm By signing this contract or commitment document, or by commencing performance, the contractor agrees to this restriction.

[End of Clause] http://www.csrc.nist.gov/publications/fips/fips201/FIPS-201-022505.pdf http://www.opm.gov/employ/html/citizen.htm http://www.opm.gov/employ/html/citizen.htm

15B11418Q00000029A Page 8 of 27

FAO-0001 Bonds

(a) Bid Guarantee. Each bidder shall submit with his bid a Bid Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government, or other security as provided in provision 52.228-1, in the form of twenty percent (20) of the bid price or not to exceed $3,000,000. The bid bond penalty may be expressed in terms of a percentage of the bid price or may be ex-pressed in dollars and cents. A bid bond is not required for bids of $150,000 or less. (FAR 28.102-1)

(b) Performance and Payment Bonds. Within 10 days after award the contractor shall execute and submit to the Contracting Of-ficer two bonds, each with good and sufficient surety or sureties acceptable to the Government, as follows; a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25A). The penal sums of such bonds will be as follows: (Not required for contracts of $150,000 or less)

(1) Performance Bond: The penal sum of performance bonds at the time of contract award shall be 100 percent of the ori-ginal contract price.

(2) Payment Bond: The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(c) For construction contracts greater than $35,000 but not greater than $150,000, the Contracting Officer shall select two or more of the following payment protections, giving particular consideration to inclusion of an irrevocable letter of credit as one of the selec-ted alternatives (FAR 28.102-1(b)(1)):

(1) A Payment Bond;

(2) An irrevocable letter of credit (ILC);

(3) A tripartite escrow agreement;

(4) A Certificate of Deposit; or

(5) A deposit of the types of security listed in 28.204-1 and 28.204-2.

(d) Individual Sureties.

(1) Bidders may elect to furnish individual surety bonds. If individual surety bonds are furnished for bid guarantees, pay-ment or performance bonds, the individual sureties must submit their bonds proof of ownership and value of the assets which they claim in their net worth at time of bid opening. The Government's preferred method of proof is to have a statement of net worth pre-pared by a Certified Public Accountant (CPA) in accordance with Generally Accepted Accounting Principles (GAAP). Statements from a CPA that contain disclaimers are not acceptable. The statement of net worth on the Standard Form 28, Affidavit of Individual Surety, is insufficient and will not be accepted without additional proof of value and ownership.

(2) Bidders are cautioned that individual sureties must provide complete and detailed information in Block 9 of Standard

Form 28 concerning other contracts on which they have provided bonds. This information shall include contract number, contract loc-ation, amount, and type of bond and telephone number of the involved contracting office. Failure to provide the proof and information required may result in rejection of the bid or termination of the contract for failure to provide adequate bonds.

FAO-0002 Magnitude

The magnitude of this project is between $25,000.00 and $100,000.00.

FAO-0003 Required Insurance

See FAR 52.228-5, Insurance - Work on a Government Installation.

The Contractor shall, at its own expense, provide and maintain during the entire performance period of this contract, at least the kinds and minimum amounts of insurance required in the

Schedule or elsewhere in the contract.

15B11418Q00000029A Page 9 of 27

TYPE AMOUNT

(1) WORKERS COMPENSATION & EMPLOYER'S LIABILITY $100,000

The required Workmen's Compensation Insurance shall extend to cover employee's liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.

(2) COMPREHENSIVE GENERAL LIABILITY with a minimum limit of:

PER ACCIDENT OR

OCCURRENCE FOR BODILY INJURY $500,000

This insurance shall include contractor's protective and contractual liability.

(3) COMPREHENSIVE AUTOMOBILE LIABILITY with the following minimum limits:

PER PERSON $200,000

PER OCCURRENCE FOR BODILY INJURY $500,000

PER OCCURRENCE FOR PROPERTY DAMAGE $ 20,000

FAO-0004 Pre-Construction Conference

(a) Prior to the start of construction, Contracting Officers shall call a conference with the contractor, subcontractor(s), Warden, Controller/Business Administrator, Safety Manager, Facilities Administrator, Project Representative, A&E firm, Captain and other in-terested personnel to discuss the statutory labor standards, prevailing wage requirements, submission of the contractor's payrolls, sub-contractor's responsibilities, institution work schedules, local policies, contraband, parking, storage of vehicles and equipment, etc.

Minutes of the conference shall be recorded, listing the names and titles of all attendees, and the subject matter of all items covered.

The minutes shall be signed by the contractor and the Contracting Officer, and a signed copy placed in the contract file.

(b) The Contractor shall familiarize himself/herself with all procedures involved in normal institution routines. Any requirements which may constitute a problem or result in conflict, will be brought to the attention of the Contracting Officer or his representative for determination.

FAO-0005 Submittals

Within 10 calendar days after commencement of work or as otherwise established by the Contracting Officer, all materials and articles requiring approval, as contemplated by the Materials and Workmanship clause, shall be submitted by the contractor.

The submittal process is in place to allow the Government the opportunity to determine whether materials or procedures used by the contractor are in accordance with contract requirements. It is ultimately the Contractor's responsibility via the quality control process to ensure submittal items installed under the contract and work performed on site are in accordance with industry standards and gener- al practices.

15B11418Q00000029A Page 10 of 27

(a) The types of submittal requirements specified in this contract may include, but is not limited to; shop drawings, product data, samples, certificates of conformance or compliance, certified test or inspection reports, equipment, materials, and miscellaneous work related submittals for construction. Individual submittal requirements are generally specified in applicable sections for each unit of work in the specifications and/or as a whole in one section in the statement of work.

(b) The Bureau of Prisons (BOP) Contracting Officer’s Representative (COR) shall act for the Contracting Officer in the review and acceptance of all submittals. The Contractor shall submit submittals as required by the contract/specifications to the COR for transmittal to the Contracting Officer. Fabrication of any work or purchase or use of any submittals (such as materials for which samples are required or equipment, etc.) shall not take place until written acceptance is given by the COR, except at the Contractor's own risk.

(c) The Contractor shall submit all shop drawings and submittals sufficiently in advance (unless otherwise specified in the spe- cifications) of the construction requirements to allow ample time for checking, re-submitting, and re-checking.

(d) Failure of any materials to pass their specified tests shall be sufficient cause for refusal to consider, under this contract, any fur- ther samples of the same brand or make of that material. The Government reserves the right to disapprove any material or equipment which has previously proven unsatisfactory in service.

(e) The Contracting Officer’s or designee’s approval or acceptance of submittals is not to be construed as a complete check. Ap-proval or acceptance will not relieve the Contractor of the responsibility for any error which may exist, as the Contractor is responsible for the satisfactory construction of all work. The Contractor is responsible for delivering a final product/system that is operational as intended by the contract requirements, regardless of any Government approvals or acceptance of submittals. The Government assumes no liability during the submittal approval/acceptance process. It is the sole responsibility of the Contractor to deliver a properly func- tioning product or system.

FAO-0006 Contractor Use of Premises

Work Hours The project schedule is based on a normal forty (40) hour work week, eight (8) hours per day, Monday through Friday, excluding Fed- eral holidays. The Contracting Officer’s Representative (COR) shall establish the work hour time frames for the duration of the project, subject to the approval of the Contracting Officer. Work hours and work days may be altered only with a 48 hour advance ap- proval of the Contracting Officer.

NOTE: Access to the site will be available during normal working hours except during emergencies. It shall be the responsibility of the Contractor to familiarize himself, his employees, and his subcontractors of the working hours and conditions in the correctional fa-cility, as working hours may not constitute a full eight hour day. The Government assumes no responsibility to the Contractor, nor to any of his subcontractors, for shorter hours due to institutional emergencies or entry and/or exit of workers necessitated by normal in-stitution routines. The procedures and institutional entrance/exit routines applicable to this project will be explained at both the pre-bid conference/site visit and the pre-construction meeting.

Contraband The Contractor shall inform his employees that intoxicating beverages, drugs, weapons, etc., will not be allowed on the site.

Introduc- tion of contraband shall be subject to the penalties prescribed by Title 18 USC-1791.

Explosives The use of explosives is absolutely forbidden without written authorization from the Contracting Officer.

Parking and Temporary Office Parking will be available at the site to the extent it does not interfere with construction activities. Otherwise, parking shall be provided for by the Contractor, at his expense, off the site for workmen employed on the project. Any temporary field office used by the Con- tractor shall be located in an area approved by the COR.

Safety and Accident Prevention In performing work under this contract the contractor shall:

(a) Conform to the specific safety requirements established by this contract;

(b) Comply with the safety rules of the Government institution that concern related activities not directly addressed in this con-tract;

(c) Take all reasonable steps and precautions to prevent accidents and preserve the life and health of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(d) Take such additional immediate precautions as the Contracting Officer and/or COR may reasonably require for safety and acci-dent prevention purposes.

15B11418Q00000029A Page 11 of 27

FAO-0007 Payment Services

(a) Original application for payment shall be prepared on AIA (American Institute of Architects) Form G-702 "Application and Certificate for Payment" and submitted to the Contracting Officer. The contractor may use another form; however, it shall contain similar information as the AIA Form G-702. The Contracting Officer will approve the amount of payment by signing and forwarding the application and certificate as follows: Original to Accounting; Copy for Contract Award File.

(b) All small business contractors are required to self-certify on all invoices their small business status.

FAO-0008 Request for Final Inspection

The Contractor shall give the Contracting Officer’s Representative (COR) a minimum of ten (10) working days advanced written no-tice of the date on which the work will be fully completed and ready for the Government’s final inspection.

FAO-0009 Contract Security (Program Statement 3000.03 Human Resource Management Manual)

The following security measures will be applied to all contract employees who will be working under the terms of the contract:

National Crime Information Center (NCIC) Check Name Check Fingerprint Check (FD-258) OF-306, Declaration for Federal Employment, and Appropriate Resume or Optional Application Contract Pre-employment Form Release of Information

FAO-0010 Assignment of Contract Administration Office and Functions

Pursuant to FAR 42.201 and 42.202, the assigned Contract Administration Office is listed in Block 26 of the Standard Form 1442 Back. This assignment carries with it the authority to perform all of the contract administration functions listed in FAR 42.302(a) and 42.302(b) to the extent that those functions apply to the contract.

FAO-0012 Progress Meetings

The Administrative Contracting Officer (ACO) shall conduct progress meetings at the project site on a monthly basis, or at intervals as determined by the ACO.

(a) At a minimum, the attendees shall include but is not limited to:

(1) FBOP: Administrative Contracting Officer, Contracting Officer’s Representative (COR), Facility Administrator/Man-ager, Architect/Engineer (if applicable), Other Personnel (Executive Staff, Captain, Safety Manager, etc.).

(2) Contractor: Project Manager, Superintendent, and technical support disciplines as appropriate (Subcontractors, Manu-facturers, Suppliers, etc.).

(b) The meeting should include, but is not limited to issues such as:

Administrative Contracting Officer:

(1) Old business from previous progress meeting(s);

(2) Status of modifications, certified payrolls, submittals, requests for information (RFI);

(3) Review of payments made to date and review/approve current payment request;

(4) Status of modification proposal requests;

(5) Discuss new business.

COR:

(1) Status of escort coverage;

15B11418Q00000029A Page 12 of 27

(2) Review gate or sallyport entrance/exit issues;

(3) Discuss other delays contractor may be experiencing;

(4) Discuss performance/quality issues.

Contractor:

(1) Review/discuss updated progress schedule;

(2) Provide 30 day outlook;

(3) Discuss other issues affecting performance.

FAO-0014 Contract Closeout Procedures (for construction contracts $150,000 or less)

Contract Closeout must be completed upon receipt of property and final payment.

Prior to payment of final invoice:

The Contractor shall submit the following documentation:

(1) Guarantees and warranties;

(2) All operation/maintenance manuals;

(3) Consent of Surety to Final Payment (AIA Document G707), if the contractor furnished a bond;

(4) Release of Claims (GSA Form 1142);

(5) Evidence of no pending labor disputes;

(6) As-built drawings/shop drawings, (if applicable);

(7) Contractor’s final invoice.

AIA forms can be obtained from The American Institute of Architects at www.aiabookstore.com.

GSA forms can be obtained from the General Services Administration at www.gsa.gov (click on the “Forms Library” link).

http://www.aiabookstore.com/ http://www.gsa.gov/

15B11418Q00000029A Page 13 of 27

Section 4 - Contract Clauses

Clauses by Reference

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text.

Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.acquisition.gov/far

Clause Title

52.246-12 Inspection of Construction (Aug 1996)

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017)

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II (Apr 1984)

52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016)

52.204-13 System for Award Management Maintenance (Oct 2016)

52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.209-6 Protecting The Government's Interest When Subcontracting With Contractors Debarred, Suspended, or

Proposed for Debarment (Oct 2015)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

52.219-6 Notice of Total Small Business Set-Aside (Nov 2011)

52.219-28 Post-Award Small Business Program Rerepresentation (Jul 2013)

52.222-1 Notice to the Government of Labor Disputes (Feb 1997)

52.222-3 Convict Labor (June 2003)

52.222-6 Construction Wage Rate Requirements (May 2014)

52.222-7 Withholding of Funds (May 2014)

52.222-8 Payrolls and Basic Records (May 2014)

52.222-9 Apprentices and Trainees (July 2005)

52.222-10 Compliance with Copeland Act Requirements (Feb 1988)

52.222-11 Subcontracts (Labor Standards) (May 2014)

52.222-12 Contract Termination - Debarment (May 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (May 2014)

52.222-14 Disputes Concerning Labor Standards (Feb 1988)

52.222-15 Certification of Eligibility (May 2014)

52.222-21 Prohibition of Segregated Facilities (Apr 2015)

52.222-26 Equal Opportunity (Sept 2016) http://www.acquisition.gov/far

15B11418Q00000029A Page 14 of 27

Clause Title

52.222-27 Affirmative Action Compliance Requirements for Construction (Apr 2015)

52.222-37 Employment Reports on Veterans (Feb 2016)

52.222-50 Combating Trafficking in Persons (Mar 2015)

52.222-55 Minimum Wages Under Executive Order 13658 (Dec 2015)

52.222-62 Paid Sick Leave Under Executive Order 13706 (Jan 2017)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts (Sep 2013)

52.223-5 Pollution Prevention and Right-to-Know Information (May 2011)

52.223-6 Drug Free Workplace (May 2001)

52.223-15 Energy Efficiency in Energy-Consuming Products (Dec 2007)

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts (May 2008)

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving (Aug 2011)

52.225-13 Restrictions on Certain Foreign Purchases (June 2008)

52.227-1 Authorization and Consent (Dec 2007)

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (Dec 2007)

52.227-4 Patent Indemnity - Construction Contracts (Dec 2007)

52.228-2 Additional Bond Security (Oct 1997)

52.228-5 Insurance - Work on a Government Installation (Jan 1997)

52.228-11 Pledges of Assets (Jan 2012)

52.229-3 Federal, State and Local Taxes (Feb 2013)

52.232-5 Payments under Fixed-Price Construction Contracts (May 2014)

52.232-17 Interest (May 2014)

52.232-23 Assignment of Claims (May 2014)

52.232-27 Prompt Payment for Construction Contracts (Jan 2017)

52.232-33 Payment by Electronic Funds Transfer - System for Award Management (Jul 2013)

52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (Dec 2013)

52.233-1 Alt I Disputes (May 2014) - Alternate I (Dec 1991)

52.233-3 Protest after Award (Aug 1996)

52.233-4 Applicable Law for Breach of Contract Claim (Oct 2004)

52.236-2 Differing Site Conditions (Apr 1984)

52.236-3 Site Investigation and Conditions Affecting the Work (Apr 1984)

52.236-5 Material and Workmanship (Apr 1984)

15B11418Q00000029A Page 15 of 27

52.236-6 Superintendence by the Contractor (Apr 1984)

52.236-7 Permits and Responsibilities (Nov 1991)

52.236-8 Other Contracts (Apr 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements (Apr 1984)

52.236-10 Operations and Storage Areas (Apr 1984)

52.236-11 Use and Possession Prior to Completion (Apr 1984)

52.236-12 Cleaning Up (Apr 1984)

52.236-13 Accident Prevention (Nov 1991)

52.236-14 Availability and Use of Utility Services (Apr 1984) [Available utilities are: water and electricity.]

52.236-17 Layout of Work (Apr 1984)

52.236-21 Alt II Specifications and Drawings for Construction (Feb 1997) - Alternate II (Apr 1984) [Insert "1" for clause fill-in.]

52.236-26 Preconstruction Conference (Feb 1995)

52.242-14 Suspension of Work (Apr 1984)

52.243-5 Changes and Changed Conditions (Apr 1984)

52.244-6 Subcontracts for Commercial Items (Nov 2017)

52.246-21 Warranty of Construction (Mar 1994)

52.248-3 Value Engineering - Construction (Oct 2015)

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form) (Apr 1984)

52.249-10 Default (Fixed-Price Construction) (Apr 1984)

52.253-1 Computer Generated Forms (Jan 1991)

52.204-18 Commercial and Government Entity Code Maintenance (Jul 2016)

Clauses by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor re-ceives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 calen-dar days.* The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages - Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $200.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is com-pleted. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

15B11418Q00000029A Page 16 of 27

52.215-21 Alt IV Requirements for Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data - Modifications (Oct 2010) - Alternate IV (Oct 2010)

(a) Submission of certified cost or pricing data is not required.

(b) Provide data described below:

Modification cost breakdown formatted as a listing of individual costs for labor, materials, equipment, overhead, profit, bond, and any additional information requested by the Contracting Officer.

52.222-35 Equal Opportunity for Veterans (Oct 2015)

(a) Definitions. As used in this clause—

“Active duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,” “disabled veteran,” “protected veteran,” “qualified disabled veteran,” and “recently separated veteran” have the meanings given at FAR 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

52.222-36 Equal Opportunity for Workers with Disabilities (Jul 2014)

(a) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

(b) Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

52.225-9 Buy American - Construction Materials (May 2014)

(a) Definitions. As used in this clause--

"Commercially available off-the-shelf (COTS) item"--

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Component" means an article, material, or supply incorporated directly into a construction material.

15B11418Q00000029A Page 17 of 27

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are dis-crete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and dis-tinct construction material regardless of when or how the individual parts or components of those systems are delivered to the con-struction site. Materials purchased directly by the Government are supplies, not construction material.

"Cost of components" means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transporta-tion costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

"Domestic construction material means"--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its compon-ents. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

"Foreign construction material" means a construction material other than a domestic construction material.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In ac-cordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or compon-ents listed by the Government as follows: NONE.

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that--

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or in-consistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)(i) Any Contractor request to use foreign construction material in accordance with…