A) THIS IS A DESIGN BUILD MULTIPLE AWARD CONSTRUCTION CONTRACT (DB-MACC) PROJECT INTENDED TO STRUCTURALLY REPAIR FACILITY 779XRAY WHARF, APRA HARBOR NAVAL BASE, GUAM. B) THE CONTRACTOR SHALL PROVIDE ALL DESIGN, LABOR, MATERIAL, EQUIPMENT, PERMIT AND CLEARANCES, ENGINEERING DESIGN/APPROACH SERVICES AND OTHER INCIDENTAL WORK REQUIRED, IN ACCORDANCE WITH THE STATEMENT OF WORK (SOW), DATED 14 APRIL 2012 FOR WR 5446845, AND KEUM YANG CORPORATION S PROPOSAL DATED 15 JUNE 2012. C) LIQUIDATED DAMAGES IN THE AMOUNT OF $300.00 SHALL BE ASSESSED FOR EACH CALENDAR DAY OF DELAY UNTIL THE WORK IS COMPLETED OR ACCEPTED. D) THE SITE SAFETY AND HEALTH OFFICER FOR THIS PROJECT SHALL MEET THE REQUIREMENTS OF LEVEL 3. E) THE PERFORMANCE PERIOD IS 356 CALENDAR DAYS AFTER THE DATE OF AWARD UP TO AND INCLUDING 14 JUNE 2013. F) THE ASSIGNED CONTRACT SPECIALIST, CONSTRUCTION MANAGEMENT ENGINEER, AND ENGINEERING TECHNICIAN WILL BE PROVIDED BY THE CONTRACTING OFFICER PRIOR TO START OF WORK. THE REQUIREMENTS OF DFARS 252.247-7023, TRANSPORTATION OF SUPPLIES BY SEA, APPLY TO THIS CONTRACT. WITHIN 30 DAYS OF EACH SHIPMENT, THE CONTRACTOR IS REQUIRED TO PROVIDE AN ELECTRONIC COPY OF THE CARRIER'S BILL OF LADING TO THE CONTRACTING OFFICER AND TO MARAD VIA E-MAIL. MARAD EMAIL: MARGUERITE.SPEIGHTS@DOT.GOV. IN ADDITION, THE CONTRACTOR SHALL NOTIFY THE CONTRACTING OFFICER WHEN OCEANIC SHIPMENTS HAVE BEEN INITIATED WITHIN 3 WORKING DAYS OF SHIPMENT.