Amendment__4___Summary_of_Changes____W912JB19Q8002.pdf

F6DLCE9044AW01 MBMV162006

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The Reason for this Amendment #4 is to extend the Due Date From: 21 May 2019 To: 8 August 2019 at 2:00PM ET and:

1) Update the Solicitation by adding an Option, and its associated provision (52.217-5 Evaluation of Options), to the Solicitation.

2) Issue RFI answ eres.

3) Issue Addendum #1

4) Issue updated SOW Dated 4June2019

5) Issue new Wage Determination: WD # MI20190001 19Jul2019 Prospective bidders are highly encouraged to attend a second Site Visit on 1 August, 2019 at 11:00am LOCAL TIME

1. CONTRACT ID CODE PAGE OF PAGES

J 1 48

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-Jul-2019

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912JB19Q8002

X 9B. DATED (SEE ITEM 11)

17-Apr-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Jul-2019

CODE

127 MSC - FA6221

43200 MAPLE ST

BLDG 105, RM 16

SELFRIDGE ANGB MI 48045-5213

W912JB 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912JB19Q8002

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 21-May-2019 03:00 PM to 08-Aug-

2019 02:00 PM.

The required performance has changed from Project: MBMV162006 - Bridge maintenanceLocation: Battle Cree ANBG, MINAICS: 237310 Size Standard $36.5 MillionSet aside: 100% small businessProject magnitude: Between $25,000 and $100,000Funds are currently available for this contract to Project Title: Bridge maintenanceProject#:

MBMV162006Solicitation #: W912JB-19-Q-8002Location: Battle Creek ANGB, MI (Battle Creek, MI)Period of Performance (POP): 30 Days1) Set-aside: This requirement will be 100% Set-Aside for Small Business.2) Small Business Size Standard: $36.5M3) NAICS Code: 237310

- Highway, Street, and Bridge Construction4) Project Magnitude: Between $25,000 and $100,0005) Submit Proposals no later than: 8 August, 2019, 2:00 PM ET6) Prospective bidders are highly encouraged to attend a second Site Visit on 1 August, 2019 at 11:00am LOCAL TIME7) Funds are currently available..

CLIN 0001

The CLIN description has changed from Bridge Maintenance to Bridge Maintenance - Deck.

The CLIN extended description has changed from:

Project MBMV162006 for bridge maintenance. All work shall be done IAW with project SOW dated 22 May 2018 , drawings, specfications and all applicable terms and conditions.

To:

Project MBMV162006 for bridge maintenance. All work shall be done IAW with SOW Dated 4 June 2019, and Addendum #001.

CLIN 0002

The CLIN extended description has changed from:

The contractor shall report ALL contactor labor hours (including subcontractor labor hours) required for performance of services provided under this contact for the Air Force via a secure data collection site. The contractor is required to completely fill in all required data fields using the following we address: http://www.ecmra.mil. The contractor shall provide a price for this manpower reporting via Line Item 2. If there is no additional charge, the contractor shall price the line item as $0.00.

To:

The contractor shall report ALL contactor labor hours (including subcontractor labor hours) required for performance of services provided under this contact for the Air Force via a secure data collection site. The contractor is required to completely fill in all required data fields using the following we address: http://www.ecmra.mil. The contractor shall provide a price for this manpower reporting via Line Item 2. If there is no additional charge, the contractor shall price the line item as $0.00. (This requirment also applies to any option.)

The manufacturer part number Null has been added.

CLIN 0003 is added as follows:

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0003 1 Job OPTION Bridge Maintenance - Beam Repairs

FFP

Project MBMV162006 for bridge maintenance. All work shall be done IAW with SOW Dated 4 June 2019, and Addendum #001.

FOB: Destination MFR PART NR: Null

PSC CD: Z1LB

NET AMT

DELIVERIES AND PERFORMANCE

The following Delivery Schedule for CLIN 0003 has been added:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

30 dys. ANP 1 110 CES

NATHAN FINFROCK

3585 MUSTANG AVENUE

BATTLE CREEK MI 49015-5512

269-969-3346 FOB: Destination

F6DLCE

INSPECTION AND ACCEPTANCE

The following Acceptance/Inspection Schedule was added for CLIN 0003:

INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

Destination N/A Destination Government

The following Technical Office was added for CLIN 0003:

110 CES

NATHAN FINFROCK

3585 MUSTANG AVENUE

BATTLE CREEK MI 49015-5512

SECTION 00100 - BIDDING SCHEDULE/INSTRUCTIONS TO BIDDERS

The following have been added by reference:

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

The following have been added by full text:

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- See SF-30 Block 10

The following have been modified:

RFQ INSTRUCTION

INSTRUCTIONS

INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

SCOPE Contractor provides for furnishing all labor, material, equipment, testing and appliances to perform construction work for bridge maintenance.

1.1. This solicitation is set-aside 100% for Small Business Participation, using Simplified Procedures utilizing the NAICS code 237310.

2. STATEMENT OF WORK

2.1. Statement of Work (SOW) for this solicitation is incorporated in the SF1442 as an attachment. Specifications and drawings will be attached separately.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS AND AMENDMENTS PRIOR TO

DATE SET FOR RECEIPT OF PROPOSALS

3.1. Submit all questions in the format shown below by email to the contracting office at the addresses shown below.

Do NOT contact A-E or Engineering personnel directly. Doing so will only delay your answer. All questions must come through the Contracting Office. Please be sure to CC our General Inbox at: usaf.mi.127-wg.mbx.msc-construction@mail.mil

Subject Line: Reference No. Solicitation W912JB-19-Q-8002 Email: steven.a.stocking3.mil@mail.mil and bradley.m.moehlig.mil@mail.mil

PRE-PROPOSAL INQUIRY FORMAT

Date of Inquiry:

From: Company Name: Address: Phone Number: Fax Number: Email address:

Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

3.2. Any explanation desired by offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach offeror before the submission of their offer.

3.3. Any interpretations made will be in the form of an amendment of the solicitation, drawings, specifications, etc., and will be furnished the offeror.

3.3.1. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of proposals. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding.

3.4. The right is reserved, as the interest of the Government may require, to revise or amend, the specifications or drawings or both prior to and/or after the date set for receipt of proposals as necessary. Such amendments, if any, will be announced by an amendment or amendments to this Request for Quote. All information relating to this RFQ, including pertinent changes/amendments and information prior to the date set for receipt of proposals will be provided via FBO.

4. WAGE DETERMINATION

4.1. Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are . MI20190001 07/19/2019

4.2. Applicable wage rates be found at: http://www.wdol.gov/wdol/ General Decision Number: DECISION No.

MI20190001 07/19/2019 In the event the current prevailing Wage Determination is changed by the Department of Labor prior to the closing date of this solicitation, it is the offeror’s responsibility to insure the most recent determination is used in preparing the proposal. An Amendment will not be issued prior to closing to change Wage

Determination dates and/or numbers. Should the wage rate change after closing, but prior to award, the updated Wage Determination will be incorporated by amendment and issued to all offerors. If applicable, offeror will be given a reasonable opportunity to provide revised proposals solely to amend proposals due to Wage Determination changes. If the wage determination modification does not change any affected wage rates, then the provisions of FAR 22.404-5(c)(4) will apply.

5. PROPOSAL SUBMISSION REQUIREMENTS:

5.1. Offeror shall provide all price/cost information necessary to provide a meaningful basis for Government's analysis and evaluation of price/cost for the project. Provide an introductory page to include CAGE Code, DUNS Number, Tax Identification Number (TIN), points of contact, authorized negotiators, contact phone, facsimile numbers, and email addresses.

5.2. Offer and Section 00010 – Complete in its entirety the “Offeror” portion of the Standard Form (SF) 1442. An official having the authority to contractually bind your company must sign the SF 1442 in accordance with FAR

4.102. One copy of the SF 1442 is required to have an original signature. Section 00010 – Insert the price/cost associated with the project in the line items. All line items (CLINs) must be priced.

5.3. Representations and Certifications- Section 00600 - insert the required certifications and representations and return only those shown in section 00600. Return the entire Section 00600 with your proposal. All other required representations and certifications are to be completed on line in the System for Award Management (SAM) at https://www.sam.gov/portal/public/SAM /.

5.3. Provide a construction schedule with a period of performance (PoP) not to exceed 30 days after Notice to Proceed letter, with all “Fast Tracking” are clearly identified if proposed. The schedule shall be task oriented, capturing all SOW requirements and indicate dates by which milestones are to be achieved. The offeror shall use either the AF Form 3064 or a critical path scheduling approach and the schedules shall be graphically represented. explaining how the schedule will be achieved. For additional information see Basis of Award Section found elsewhere in the document.

5.4. Email proposals to steven.a.stocking3.mil@mail.mil and Bradley.m.moehlig.mil@mail.mil and our General Inbox: usaf.mi.127-wg.mbx.msc-construction@mail.mil

6. SUBMISSION REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA: N/A

7. CERTIFICATION OF COST OR PRICING DATA: N/A

8. PROPOSAL EXPENSES AND PRE-CONTRACT COSTS

This RFQ does not commit the Government to pay costs incurred in preparation and submission of initial and subsequent proposals or for other costs incurred prior to award of a formal contract.

9. REMOVAL OF SECTIONS AT TIME OF AWARD

Sections 00010, 00100 and 00600 and all exhibits will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

10. DISPOSITION OF UNSUCCESSFUL PROPOSALS

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful proposals. The Government will destroy extra copies of unsuccessful proposals. No destruction certificate will be provided.

11. EXCEPTIONS

If the offeror takes exception to any of the requirements specified in this solicitation, the offeror shall clearly Identify each such exception and include a complete explanation of why the exception was taken and what benefit accrues to the Government. All exceptions to the solicitation requirements (Sections 00010 through 001000) and supporting rationale shall be included in an addendum to the proposal and clearly labeled "Exceptions". An Addendum is only required if the offeror takes exception to any requirement in the solicitation. (The Addendum does not have a page limitation, but shall only include information relevant to exceptions taken to the solicitation requirements.) The Government will assume an offeror takes no exceptions to any solicitation requirement if the offeror does not submit an Addendum identifying exceptions. Offeror is advised that solicitation requirements are not necessarily negotiable and such exceptions may render an offer OR’s proposal unacceptable and ineligible for award.

12. CLAUSES

12.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are Incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

12.2. Clauses and provisions in this document may not appear in consecutive order.

13. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

14. NOTICE OF PRE-PROPOSAL CONFERENCE:

14.1. A pre-proposal conference will be conducted on See SF-30 Block 10, local time for the purposes of briefing on the proposal requirements and answering questions regarding this solicitation. This conference will be held at the job site. Attendees will meet at the front gate of Battle Creek Air National Guard Base Interested Contractors are highly encouraged to attend the preproposal conference. The site visit will be held following the conference.

14.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to: steven.a.stocking3.mil@mail.mil and bradley.m.moehlig.mil@mail.mil

Visitor’s Name Driver’s License No., State Issued and Expiration Date Date of Birth Citizenship Cell Phone Number

14.3. This information must be provided in advance, not later than 1 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may resultin the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

14.4. You may be required to present the following information upon arrival: (1) Vehicle Registration, (2) ValidDriver’s License, (3) Proof of Insurance for Vehicle, and/or (4) Safety Inspection and Car Rental agreement ifapplicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

14.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitationis amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

14.6. A record of the conference shall be made and furnished to all prospective offerors via posting to:

www.fbo.gov. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

15. JOINT VENTURE REQUIREMENTS- Parties wishing to propose as a joint venture must submit, with the Pro Forma documents, an executed copy of the joint venture agreement. The joint venture agreement shall be executed in accordance with FAR 4.102(d). Each joint venture partner shall submit evidence satisfactory to the Contracting Officer that its Board of Directors has approved its participation in the joint venture or by an instrument of similarly binding character in the case of an unincorporated entity. Offerors are reminded that to obtain an award the awardee, to include a joint venture, must be registered in the System for Award Management (SAM) database.

Applicable to set-aside solicitations: Joint Ventures must meet applicable size standards (See FAR Subpart 19.1).

Submit with the proposal any size determination for the Joint Venture entity received from the Small Business Administration. A Joint Venture where-in one party is not a small business may be referred to the Small Business Administration ( IAW FAR 19.302 (b)) to determine eligibility. All questions regarding Joint Ventures must be directed to the Small Business Administration (SBA) and not the Contracting Officer.

End of Section 00100

SECTION 00110 SUBMISSION REQUIREMENTS AND INSTRUCTIONS

1. PROPOSAL PREPARATION INSTRUCTIONS

1.1. These instructions prescribe the format of proposals, and describe the approach for the development and presentation of the proposal data. They are designed to ensure the submission of necessary information to provide for the understanding and comprehensive evaluation of proposals. Carefully review this section prior to commencing proposal preparation. All solicitation amendments must be acknowledged in accordance with Section 00100, FAR Provision 52.215-1, Instruction to Offerors – Competitive Acquisition.

1.2. Offerors are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete proposal. Failure to furnish a complete proposal, at the time of proposal submission, may result in the proposal being unacceptable to the Government and eliminated from consideration for award.

2. PROPOSAL CONTENT

2.1 Offeror shall provide all price/cost information necessary to provide a meaningful basis for Government's analysis and evaluation of price/cost for the project. Provide an introductory page to include CAGE Code, DUNS Number, Tax Identification Number (TIN), points of contact, authorized negotiators, contact phone, facsimile numbers, and email addresses.

2.2 Offer and Section 00010 – Complete in its entirety the “Offeror” portion of the Standard Form (SF) 1442.

An official having the authority to contractually bind your company must sign the SF 1442 in accordance with FAR 4.102.

3. DISCUSSIONS

The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer, in his/her sole discretion, later determines them to be necessary or appropriate. Further, the Government reserves the right to create or not to create a competitive range. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

End of Section 00110

SECTION 00120

SECTION 00120 PROPOSAL EVALUATIONS AND BASIS FOR AWARD

1. GENERAL INFORMATION

1.1. This solicitation is for a Firm Fixed Price Contract. The Government intends to award a single contract to a qualified Small Business Offeror deemed responsible in accordance with the Federal Acquisition Regulation (FAR), whose proposal conforms to all the RFP's requirements and is judged to represent the Best Value to the Government in accordance with the evaluation scheme set out in this solicitation.. Best Value offer will be determined on the basis of the lowest priced proposal meeting the acceptability standards for non-priced evaluation factors.

1.2. To arrive at a Best Value decision this acquisition will utilize the lowest price, technically acceptable process.

1.3. The source selection process will be conducted in accordance with FAR 13 Simplified Acquisiton Procedures.

Offers will be evaluated using the criteria listed in “Evaluation Factors for Award.” Noncompliance with the RFP requirements may raise serious questions regarding an offeror’s technical ability, past performance and/or pricing and may be grounds to eliminate the proposal from consideration for contract award. Failure to include all information requested may adversely affect the evaluation. A proposal that merely reiterates or promises to accomplish the requirements of the RFP will be considered unacceptable. A proposal that is orderly and sufficiently documented will be easy for the Government to understand and will enable the Government to perform a thorough and fair evaluation.

1.4. The Contracting Officer will begin the evaluation process by conducting a proposal compliance review for all timely-received proposals for determination of basic proposal adequacy prior to providing the proposals to the evaluators. Failure to provide a complete proposal may result in the proposal being removed from further consideration for award. Failure to address any factor Technical, Past Performance and Price or any technical subfactor shall be grounds for elimination from evaluation and consideration for award.

1.5. Although the assessment of Past Performance as a specific evaluation factor is separate and distinct from the Determination of Responsibility required by FAR Part 9, Past Performance information obtained herein will be used during the Government’s responsibility determination. The Government also reserves the right to obtain additional information solely for the purpose of making a responsibility determination from all offerors after receipt of proposals. Requests for responsibility information do not constitute discussions.

1.6. The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). The Government reserves the right to conduct discussions if the Contracting Officer, in his/her sole discretion, later determines them to be necessary or appropriate. Further, the Government reserves the right to create or not to create a competitive range.

1.7. ENFORCEABILITY OF PROPOSAL: The proposal must set forth full, accurate and complete information as required by this solicitation. By submission of the offer, the Offeror agrees that all items proposed (if applicable e.g., key personnel, subcontractors, etc.) will be utilized for the duration of the contract and any substitutions shall require prior Contracting Officer's approval.

2. EVALUATION FACTORS FOR AWARD

Evaluation Factors, the Best Value offer will be determined on the basis of the lowest priced proposal meeting the acceptability standards for non-priced evaluation factors.

Non-Priced Evaluation Factors listed below were evaluated on an acceptable /unacceptable basis:

• Technical

• Past Performance

TECHNICAL

The Technical Evaluation consists of one factor: Construction Schedule.

Provide a construction schedule with a period of performance (POP) not to exceed 30 days after NTP, with all “Fast Tracking” areas clearly identified if proposed. The schedule shall be task oriented, capturing all Statement of Work (SOW) requirements and indicate dates by which milestones are to be achieved. The Offeror shall use either the AF Form 3064 or a critical path scheduling approach, and the schedules shall be graphically represented.

Acceptability will be based on the offeror’s demonstration of execution of the construction schedule outlining completion within the desired POP. The schedule shall capture all SOW requirements, execution timelines, and critical path items. The written rationale shall describe coordination of work activities, phasing if applicable, and demonstrate an overview of how the project will be completed on time.

RATING DESCRIPTION

Acceptable Proposal clearly meets the minimum requirements of the solicitation

Unacceptable Proposal does not clearly meets the minimum requirements of the solicitation

PAST PERFORMANCE

Submit no more than three (3) relevant references for projects with similar scope/magnitude completed within the last 5 years. The references are to assist the Contracting Officer in the evaluation of past performance.

Provide the following information requested in this format for each of the projects/contracts being submitted as a reference project. Projects may be on going and cannot have been completed any earlier than 5 years prior to the solicitation issue date.

Project/Contract Title: ________________________________________________________ Project Specifics:

• Description of Effort as ______Prime Contractor or _____Subcontractor

• Contract Number__________________________________________________________

• Original Contract $ Value _____________ Current/Final Contract $ Value ____________

• If amounts above are different, provide a brief description of the reason:

Completion Date:

• Original Scheduled Completion Date: ____________________________________

• Final Completion Date: _________________________________________

• If original completion date and final completion dates are different, provide a brief description of the reason:

Provide brief description of the work performed under the contract and describe why you believe the work is relevant to this solicited project.

Provide a Point of Contact for Owner/Government agency Contracting Officer and or inspector for each reference project; include a current phone number and Email address.

The Government will evaluate responses from submitted references and/or any other record available, for the quality, timeliness, and management of the offeror's past performance considering, relevancy, context, and trends on recent projects (within the last 5 years). If there is information which deems past performance as less than acceptable for ongoing projects, the offeror will either have been already afforded an opportunity to offer a rebuttal of this information or will be provided such an opportunity in order for the information to be evaluated. The government may contact an offeror for questions on past performance. In the case of an offeror without a record of relevant past performance or for whom information on past performance is not available, the offeror may not be evaluated favorably or unfavorably on past performance and their record will be considered unknown.

IAW FAR 13.106-2(b)(3)(ii), evaluation of past performance will be based on one or more of the following:

• The contracting officer’s knowledge;

• Customer surveys, and past performance questionnaire replies;

• The Government wide Past Performance Information Retrieval System (PPIRS) at www.ppirs.gov; or

• Any other reasonable basis

RELEVANT: Present/past performance effort involved similar scope and magnitude of effort and complexities this solicitation requires.

NOT RELEVANT: Present/past performance effort involved little or none of the scope and magnitude of effort and complexities this solicitation requires.

Past Performance Evaluation Ratings Rating Description Acceptable Based on the offeror’s performance record, the Government has a reasonable expectation that the offeror will successfully perform the required effort, or the offeror’s performance record is unknown.

Unacceptable Based on the offeror’s performance record, the Government has no reasonable expectation that the offeror will be able to successfully perform the required effort.

PRICE

Adequate price competition, per FAR 13.106-3(a)(1) is anticipated to determine price reasonableness. In order to ascertain adequate price competition, at least two or more acceptable offers must be received. In the event only one acceptable offers is received, a price fair and reasonable determination will be prepared IAW FAR 13.106-3(a)(2).

IAW FAR 4.102. One copy of the SF 1442 is required to have an original signature. Section 00010 – Insert the price/cost associated with the project in the line items. All line items (CLINs) must be priced.

4. AWARD and DEBRIEFINGS

4.1. Award: A written award or acceptance of offer mailed, or otherwise furnished to the successful offeror within the time for acceptance specified in the offer shall be deemed to result in a binding contract without further action by either party.

4.1.1. To establish its responsibility, the apparent low offeror may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources and plant available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

4.2. Debriefings

4.2.1. Offerors excluded from the competitive range or otherwise excluded from the competition before award may submit a written request for a debriefing to the Contracting Officer in accordance with FAR 15.505.

4.2.2. After award, unsuccessful offerors may submit a written request for a debriefing to the Contracting Officer in accordance with FAR 15.506.

End of Section 00120

The following have been deleted:

52.236-27 Site Visit (Construction) FEB 1995

SECTION 00600 - REPRESENTATIONS & CERTIFICATIONS

The following included by full text have been revised:

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JUN 2019)

Substitute the following paragraphs (b), (d) and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at FAR 52.204-7, System for Award Management, is included in this solicitation, paragraph

(e) of this provision applies.

(2) If the provision at FAR 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

__ (i) Paragraph (e) applies.

__ (ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services--Representations.

Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(viii) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

SECTION 00700 - CONTRACT CLAUSES

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Complete Drawings MBMV162006 Bridge MX dated 05/18/2018 – DLZ construction services.

SHEET INDEX

G-001 B-01 B-02 B-03

CS-01

CS-02

TITLE SHEET

DECK REPAIR SHEET

BEAM REPAIR SHEET

GUARDRAIL REFLECTORS SHEET

MAINTENANCE OF TRAFFIC - STAGE I

MAINTENANCE OF TRAFFIC - STAGE II

Statement of Work: -Updated 4 June 2019 Addendum #01

(End of clause)

The following included by reference have been revised:

52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2019-O0003).

JAN 2019

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

The following have been added by full text:

ADDENDUM #1

This addendum applies to the following documents:

(X) SOW Dated 17 April 2016

(X) Specifications Dated ( ) Plans Dated

Description of Addendum: The purpose of this addendum is to issue an updated SOW in its totality. Address RFI Questions, and explain the Option, or Item 003 within the Solicitation.

1. See updated SOW:

a. Updated SOW - 4June2019.

b. Updated SOW address’s Railroad Insurance / flagging / payment requirements of the General

Contractor.

2. Specifications:

a. RFI’s have been answered, and are attached within FBO.gov. See “RFI’s W912JB-19-Q-8002” on FBO.gov.

3. Option – Item 0003

a. Item 0003 “Bridge Maintenance – Beam Repairs”

i. This Option (Item 0003) includes the following repairs; Fascia Beam Repairs, Interior Beam Repairs, and Joint Repair. (Plans Sheet # B-02)

ii. Intention is to include the work under the bridge, and requiring railroad insurance, within this option.

b. If this option is to be exercised, it will be exercised No Later Than 30Sep2019.

END OF ADDENDUM NO. 001

STATEMENT OF WORK

See Statement of Work dated 22 May 2018 for project number MBMW162006 – posted with solicitation to FBO.gov -Updated 4 June 2019. Posted to FBO.gov

WAGE DETERMINATION

"General Decision Number: MI20190001 07/19/2019

Superseded General Decision Number: MI20180001

State: Michigan

Construction Types: Highway (Highway, Airport & Bridge xxxxx and Sewer/Incid. to Hwy.)

Counties: Michigan Statewide.

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.60 for calendar year 2019 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.60 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2019. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/04/2019 1 01/25/2019 2 03/08/2019 3 07/05/2019 4 07/19/2019

CARP0004-004 06/01/2018

REMAINDER OF STATE

Rates Fringes

CARPENTER ( Piledriver)..........$ 27.12 20.19

CARP0004-005 06/01/2018

LIVINGSTON (Townships of Brighton, Deerfield, Genoa, Hartland, Oceola & Tyrone), MACOMB, MONROE, OAKLAND, SANILAC, ST. CLAIR

AND WAYNE COUNTIES

CARPENTER (Piledriver)...........$ 30.50 27.28

ELEC0017-005 06/03/2019

STATEWIDE

Rates Fringes

Line Construction Groundman/Driver............$ 28.58 15.27 Journeyman Signal Tech, Communications Tech, Tower Tech & Fiber Optic Splicers.$ 40.35 18.80 Journeyman Specialist.......$ 46.40 20.62 Operator A..................$ 34.10 16.93 Operator B..................$ 31.84 16.25

Classifications

Journeyman Specialist: Refers to a crew of only one person working alone.

Operator A: Shall be proficient in operating all power equipment including: Backhoe, Excavator, Directional Bore and Boom/Digger truck.

Operator B: Shall be proficient in operating any 2 of the above mentioned pieces of equipment listed under Operator A.

ENGI0324-003 06/01/2019

ALCONA, ALPENA, ARENAC, BAY, CHEBOYGAN, CLARE, CLINTON,

CRAWFORD, GENESEE, GLADWIN, GRATIOT, HURON, INGHAM, IOSCO,

ISABELLA, JACKSON, LAPEER, LENAWEE, LIVINGSTON, MACOMB,

MIDLAND, MONROE, MONTMORENCY, OAKLAND, OGEMAW, OSCODA, OTSEGO,

PRESQUE ISLE, ROSCOMMON, SAGINAW, ST. CLAIR, SANILAC,

SHIAWASSEE, TUSCOLA, WASHTENAW AND WAYNE COUNTIES:

OPERATOR: Power Equipment

(Steel Erection)

GROUP 1....................$ 46.52 24.35

GROUP 2....................$ 47.52 24.35

GROUP 3....................$ 45.02 24.35

GROUP 4....................$ 46.02 24.35

GROUP 5....................$ 43.52 24.35

GROUP 6....................$ 44.52 24.35

GROUP 7....................$ 43.25 24.35

GROUP 8....................$ 44.25 24.35

GROUP 9....................$ 42.80 24.35

GROUP 10....................$ 43.80 24.35

GROUP 11....................$ 42.07 24.35

GROUP 12....................$ 43.07 24.35

GROUP 13....................$ 41.71 24.35

GROUP 14....................$ 42.71 24.35

GROUP 15....................$ 41.07 24.35

GROUP 16....................$ 38.37 24.35

GROUP 17....................$ 23.89 11.50

GROUP 18....................$ 27.38 11.50

FOOTNOTE:

Paid Holidays: New Year's Day, Memorial Day, Fourth of July, Labor Day, Thanksgiving Day and Christmas Day.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Engineer when operating combination of boom and jib 400' or longer

GROUP 2: Engineer when operating combination of boom and jib 400' or longer on a crane that requires an oiler

GROUP 3: Engineer when operating combination of boom and jib 300' or longer

GROUP 4: Engineer when operating combination of boom and jib 300' or longer on a crane that requires an oiler

GROUP 5: Engineer when operating combination of boom and jib 220' or longer

GROUP 6: Engineer when operating combination of boom and jib 220' or longer on a crane that requires an oiler

GROUP 7: Engineer when operating combination of boom and jib 140' or longer

GROUP 8: Engineer when operating combination of boom and jib 140' or longer on a crane that requires an oiler

GROUP 9: Tower crane & derrick operator (where operator's work station is 50 ft. or more above first sub-level)

GROUP 10: Tower crane & derrick operator (where operator's work station is 50 ft. or more above first sub-level) on a crane that requires an oiler

GROUP 11: Engineer when operating combination of boom and jib 120' or longer

GROUP 12: Engineer when operating combination of boom and jib 120' or longer on a crane that requires an oiler

GROUP 13: Crane operator; job mechanic and 3 drum hoist and excavator

GROUP 14: Crane operator on a crane that requires an oiler

GROUP 15: Hoisting operator; 2 drum hoist and rubber tired backhoe

GROUP 16: Forklift and 1 drum hoist

GROUP 17: Compressor or welder operator

GROUP 18: Oiler

ENGI0324-004 06/01/2018

AREA 1: ALLEGAN, BARRY, BERRIEN, BRANCH, CALHOUN, CASS, EATON,

HILLSDALE, IONIA, KALAMAZOO, KENT, LAKE, MANISTEE, MASON,

MECOSTA, MONTCALM, MUSKEGON, NEWAYGO, OCEANA, OSCEOLA, OTTAWA,

ST. JOSEPH, VAN BUREN

AREA 2: ANTRIM, BENZIE, CHARLEVOIX, EMMET, GRAND TRAVERSE,

KALKASKA, LEELANAU, MISSAUKEE AND WEXFORD COUNTIES:

(Steel Erection)

AREA 1

GROUP 1....................$ 45.37 23.85

GROUP 2....................$ 42.10 23.85

GROUP 3....................$ 40.56 23.85

GROUP 4....................$ 37.82 23.85

GROUP 5....................$ 23.64 11.00

GROUP 6....................$ 27.08 11.00

AREA 2

GROUP 1....................$ 45.37 23.85

GROUP 2....................$ 42.10 23.85

GROUP 3....................$ 40.56 23.85

GROUP 4....................$ 37.82 23.85

GROUP 5....................$ 23.64 11.00

GROUP 6....................$ 27.08 11.00

FOOTNOTES:

Crane operator with main boom and jib 300' or longer: $1.50 additional to the group 1 rate. Crane operator with main boom and jib 400' or longer: $3.00 additional to the group 1 rate.

PAID HOLIDAYS: New Year's Day, Memorial Day, Fourth of July, Labor Day, Thanksgiving Day and Christmas Day.

POWER EQUIPMENT OPERATOR CLASSIFICATIONS:

GROUP 1: Crane Operator with main boom & jib 400', 300', or 220' or longer.

GROUP 2: Crane Operator with main boom & jib 140' or longer, Tower Crane; Gantry Crane; Whirley Derrick.

GROUP 3: Regular Equipment Operator, Crane, Dozer, Loader, Hoist, Straddle Wagon, Mechanic, Grader and Hydro Excavator.

GROUP 4: Air Tugger (single drum), Material Hoist Pump 6"" or over, Elevators, Brokk Concrete Breaker.

GROUP 5: Air Compressor, Welder, Generators, Conveyors

GROUP 6: Oiler and fire tender

ENGI0324-005 09/01/2018

AREA 1: GENESEE, LAPEER, LIVINGSTON, MACOMB, MONROE, OAKLAND,

ST. CLAIR, WASHTENAW AND WAYNE COUNTIES

AREA 2: ALCONA, ALLEGAN, ALGER, ALPENA, ANTRIM, ARENAC, BARAGA,

BARRY, BAY, BENZIE, BERRIEN, BRANCH, CALHOUN, CASS,

CHARLEVOIX, CHEBOYGAN, CHIPPEWA, CLARE, CLINTON, CRAWFORD,

DELTA, DICKINSON, EATON, EMMET, GLADWIN, GOGEBIC, GRAND

TRAVERSE, GRATIOT, HILLSDALE, HOUGHTON, HURON, INGHAM, IONIA,

IOSCO, IRON, ISABELLA, JACKSON, KALAMAZOO, KALKASKA, KENT,

KWEENAW, LAKE, LEELANAU, LENAWEE, LUCE, MACKINAC, MANISTEE,

MARQUETTE, MASON, MECOSTA, MENOMINEE, MIDLAND, MISSAUKEE,

MONTCALM, MONTMORENCY, MUSKEGON, NEWAYGO, OCEANA, OGEMAW,

ONTONAGON, OSCEOLA, OSCODA, OTSEGO, OTTAWA, PRESQUE ISLE,

ROSCOMMON, SAGINAW, SANILAC, SCHOOLCRAFT, SHIAWASSEE, ST.

JOSEPH, TUSCOLA, VAN BUREN AND WEXFORD COUNTIES

(Underground construction (including sewer))

AREA 1:

GROUP 1....................$ 32.53 23.85

GROUP 2....................$ 27.80 23.85

GROUP 3....................$ 27.07 23.85

GROUP 4....................$ 26.50 23.85

AREA 2:

GROUP 1....................$ 30.82 23.85

GROUP 2....................$ 25.93 23.85

GROUP 3....................$ 25.43 23.85

GROUP 4....................$ 25.15 23.85

POWER EQUIPMENT OPERATOR CLASSIFICATIONS

GROUP 1: Backfiller tamper; Backhoe; Batch plant operator (concrete); Clamshell; Concrete paver (2 drums or larger);

Conveyor loader (Euclid type); Crane (crawler, truck type or pile driving); Dozer; Dragline; Elevating grader;

Endloader; Gradall (and similar type machine); Grader;

Mechanic; Power shovel; Roller (asphalt); Scraper (self-propelled or tractor drawn); Side boom tractor (type D-4 or equivalent and larger); Slip form paver; Slope paver; Trencher (over 8 ft. digging capacity); Well drilling rig; Concrete pump with boom operator; Hydro Excavator

GROUP 2: Boom truck (power swing type boom); Crusher; Hoist;

Pump (1 or more - 6-in. discharge or larger - gas or diesel- powered or powered by generator of 300 amperes or more - inclusive of generator); Side boom tractor (smaller than type D-4 or equivalent); Tractor (pneu-tired, other than backhoe or front end loader); Trencher (8-ft. digging capacity and smaller);Vac Truck

GROUP 3: Air compressors (600 cfm or larger); Air compressors (2 or more-less than 600 cfm); Boom truck (non-swinging, non- powered type boom); Concrete breaker (self-propelled or truck mounted -…