Amendment_0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of Amendment 0003 is as follow s:

1. Incorporate revisions to the plans and technical specif ications as listed in the Summary of Changes.

2. Revise the Bid Schedule.

3. Incorporate revisions to Clause 52.211-10 Commencement, Prosecution, and Completion of Work.

The bid opening date has been extended to June 19, 2018 at 01:00 PM.

1. CONTRACT ID CODE PAGE OF PAGES

1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 11-Jun-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EF18B0017

X 9B. DATED (SEE ITEM 11)

11-Apr-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

11-Jun-2018

CODE

USAED, WALLA WALLA - CONTRACTING DIV.

JULIE M. MORRIS

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

W912EF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EF18B0017

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

SUMMARY OF CHANGES

Summary of Changes for Amend - 0003 Heise-Roberts Levee Rehabilitation

1. Revised the Construction Start date

2. Revised the following Specifications:

a. SECTION 00 01 15.00 28, LIST OF DRAWINGS

• Updated the LIST OF DRAWINGS Section

b. SECTION 01 11 01.00 28, SUPPLEMENTARY REQUIREMENTS

• Revised the following paragraph:

o 1.10, FIRE CONTROL

c. SECTION 01 22 00.00 28, MEASUREMENT AND PAYMENT

• Revised the following paragraphs:

o 1.1, DELETED o 1.3, CLIN 0001AA – CLIN 0008AA REUSE AND PLACE EXISTING RIPRAP o 1.4, MEASUREMENT FOR PAYMENT o 1.5, CLIN 0001AB – CLIN 0008AB PLACE RIPRAP o 1.6, CLIN 0001AC – CLIN 0008AC PLACE QUARRY SPALLS o 1.7, CLIN LOCATIONS

d. SECTION 01 35 29.10 28, GOVERNMENT SAFETY REQUIREMENTS o 1.5, SITE QUALIFICATIONS, DUTIES AND MEETINGS

e. SECTION 35 41 10.61 28 o 2.3, QUARRY SPALLS o 2.4, RIPRAP AND QUARRY SPALL MATERIAL SOURCE

See revised specification for details.

3. Revised the following Drawings (See clouded areas).

a. G-002

b. C-101

c. C-102

d. C-103

e. C-104

f. C-105

g. C-106

h. C-301

i. C-302

j. C-303

k. C-902

4. Added the following Drawings

a. C-107

b. C-108

c. C-903

d. FIO-020

e. FIO-021

f. FIO-022

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 15-Jun-2018 01:00 PM to 19-Jun-2018 01:00 PM.

The following have been modified:

BID SCHEDULE

Walla Walla District Corps of Engineers Heise-Roberts Levee Rehabilitation

The magnitude of construction is estimated to be between $1,000,000 and $5,000,000

PROJECT IS 100% WOMAN-OWNED SMALL BUSINESS SET-ASIDE

ITEM

DESCRIPTION

QUANTITY

U/M

U/P

AMOUNT

Items

0001 Site 17-1 Nebeker Drain Pipe 0001AA Reuse and Place Existing Riprap N/A JOB XXXXX $________ 0001AB Place Riprap Est 565 CY $_______ $________ 0001AC Place Quarry Spalls Est 1197 CY $_______ $________

0002 Site 17-2 Bob Harrop East 0002AA Reuse and Place Existing Riprap 1 JOB XXXXX $________ 0002AB Place Riprap Est 651 CY $_______ $________ 0002AC Place Quarry Spalls Est 1588 CY $_______ $________

0003 Site 17-3 Randy Harmon Property 0003AA Reuse and Place Existing Riprap 1 JOB XXXXX $________ 0003AB Place Riprap Est 706 CY $_______ $________ 0003AC Place Quarry Spalls Est 2961 CY $_______ $________

0004 Site 17-4 Downstream Lorenzo Boat Ramp 0004AA Reuse and Place Existing Riprap 1 JOB XXXXX $________ 0004AB Place Riprap Est 3266 CY $_______ $________ 0004AC Place Quarry Spalls N/A CY $_______ $________

0005 Site 17-5 Downstream Gasline Crossing 0005AA Reuse and Place Existing Riprap N/A JOB XXXXX $________ 0005AB Place Riprap Est 795 CY $_______ $________ 0005AC Place Quarry Spalls N/A CY $_______ $________

0006 Site 17-7 Bannock Feeder 0006AA Reuse and Place Existing Riprap 1 JOB XXXXX $________ 0006AB Place Riprap Est 226 CY $_______ $________ 0006AC Place Quarry Spalls Est 239 CY $_______ $________

0007 Site 17-8 Pennock Location 0007AA Reuse and Place Existing Riprap 1 JOB XXXXX $________ 0007AB Place Riprap Est 1008 CY $_______ $________ 0007AC Place Quarry Spalls Est 2883 CY $_______ $________

0008 Site 18-1 Hall Dairy Site 0008AA Reuse and Place Existing Riprap N/A JOB XXXXX $________ 0008AB Place Riprap Est 4839 CY $_______ $________ 0008AC Place Quarry Spalls Est 111 CY $_______ $________

0009 Site 18-2 Roth Location 0009AA Reuse and Place Existing Riprap N/A JOB XXXXX $________ 0009AB Place Riprap Est 225 CY $_______ $________ 0009AC Place Quarry Spalls Est 100 CY $_______ $________

SCHEDULE TOTAL $__________

IMPORTANT See Section 01 22 00.00 28; MEASUREMENT AND PAYMENT; Paragraph; Retainage of Payment, for withholding of payment for final deliverables.

Est = Estimated

Quantities identified as Estimated (“Est”) in the bid schedule are subject to FAR Clause 52.211-18, VARIATION IN ESTIMATED QUANTITY, located in Section 00 70 00.

Funds are not presently available for this acquisition. No contract award will be made until funds are made available.

Environmental clearance has not yet been obtained for this project. No contract award will be made until all applicable environmental clearances are obtained.

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than the dates listed below.

(1) The Contractor shall complete all work for the Heise-Roberts Levee Rehabilitation by not later than October 31, 2018.

(2) The Contractor can begin stockpiling materials once the Notice to Proceed is issued.

(3) Material can be stockpiled on the levee. Coordinate other stockpile locations with the appropriate landowner.

(4) Other than to stockpile materials, the on-site work window is restricted to September 15, 2018 through October 31, 2018.

(5) The Contractor shall complete final cleanup and demobilization by not later than 15 calendar days after completion of work in (1) above.

(6) The Contractor shall complete, working “as-built” contract drawings and final approved versions of Contractor prepared drawings (see SECTION 01 78 00.00 28) by not later than 30 calendar days after completion of work in (1) above.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by August 1, 2018 The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of Clause)

(End of Summary of Changes)