A12_W912DR18B0003_Solicitation_Amendment.pdf

Knapps Narrow s Maintenance Dredging, Talbot County, Maryland

This Procurement is a 100% Total Small Business Set-Aside

NAICS CODE : 237110

Size Standard : $36.5 Million

X

ERIC L TAYLOR 410-962-3987

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

30-Nov-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________180 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See ____________________________52.211-10__

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________02 Jan 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______10 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USACE, BALTIMORE DISTRICT

10 S. HOWARD ST

ROOM 7000

BALTIMORE MD 21201

W912DR

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

11:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 410-962-2196 TEL: FAX:

W912DR18B0003 54

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912DR18B0003

Section 00 10 00 - Solicitation

PRICE SCHEDULE

PRICE SCHEDULE

Item No. Description Estimated Unit Price Amount __________________ ____________________Quantity___________________________________

0001 Reimbursement of Performance --- Job LS $_________ and Payment Bonds

0002 Mobilization and --- Job LS $_________ Demobilization

0003 Maintenance Dredging Knapps Narrows- Stations 25,637 CY $______ $__________ 1+300 to 3+900

0004 Maintenance Dredging Knapps Narrows-Station 1,207 CY $_______ $__________ 4+600 to 5+100

0005 Maintenance Dredging Knapps Narrows- Stations 75,125 CY $______ $__________ 5+700 to 9+400

TOTAL ESTIMATED BID AMOUNT $

NOTES TO BIDDERS

VARIATION IN ESTIMATED QUANTITIES. If the quantity of a unit-price item in this contract is an estimated quantity and the actual quantity of the unit-price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

IMPORTANT NOTES REGARDING THIS ACQUISITION:

A. BIDDING MATERIAL

Copies of the Solicitation, Specifications, and drawings forms are available by INTERNET ACCESS ONLY. All solicitation documents will be posted to the Federal Business Opportunity (FedBizOpps) website at:

https://www.fbo.gov. All inquiries should be emailed to the Contract Specialist, Eric.l.taylor@usace.army.mil BID DOCUMENTS: The following documents must be submitted with your bid package:

1. SF 1442, Solicitation, Offer and Award

2. Schedule of bids/prices

3. Representations and Certifications (Section 00600)

4. Standard Form LLL (Section 00600)

5. Certificate of Corporate Authority (Section 00600)

6. All amendments (if any) must be acknowledged

7. Bid Bond (Standard Form 24)

B. PROPOSAL CONDITIONS

1. Contractors must bid all items in the above bid schedule, with no exceptions. Should a contractor fail to fully complete the bid schedule, its BID will not be considered responsive to the solicitation and ineligible for the resultant contract award. Therefore, the bidder’s total price for the work must be based on the TOTAL of the Base Bid Items included in the Schedule and for each item bid, the Contractor must show the unit price and extended price for the quantity of the item.

2. Split awards or multiple award contracts will not result from this Solicitation.

3. Arithmetic Discrepancies:

a) For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the bidding schedule as submitted by bidder:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

b) For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends his bid to be evaluated on the basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

4. Caution to Bidders – Bid Errors: You are cautioned to exercise extreme care in preparation of your bid. Errors in bids are costly and could result in substantial loss to you as well as delayed award of contracts. Actions you can take to avoid errors are:

a) Make sure your bid takes into consideration all amendments to the IFB.

b) If you feel bidding requirements are unclear, contact the Baltimore District Office in writing for an explanation before preparing and submitting your bid.

c) Verify all quantities and prices, especially quotations from subcontractors. Make sure no line items have been overlooked in recapitulating. Have your bid reviewed by qualified personnel other than those preparing the bid.

d) Retain all original notes, subcontractor quotations, estimates, and summary worksheets from which your bid was prepared. If you have made a mistake in bid, you will need these papers to determine the nature and amount of an error and to support any request you may make for special relief.

C. COMPETITION: Competition for this acquisition Small Business Set Aside

D. SUBMISSION OF BIDS

1. All bids must be submitted in accordance with the procedures set forth in Block 13 of Page 1 of this Solicitation document. BIDS OR MODIFICATIONS TO BIDS THAT ARE RECEIVED BY FACSIMILE WILL

NOT BE CONSIDERED.

2. SF 1442 BACK (Page 2 of the Solicitation): Bidders are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in Block 19. Bidders shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C).

3. Section 00600 (Representation and Certifications): The bidders must fully complete Section 00600 of this Solicitation and submit it along with all other documents required by this Solicitation. Bidders received without this Section fully completed may be rejected, considered non-responsive and ineligible for award.

4. BID GUARANTEE: The bidders are required to submit a Bid Guarantee for this procurement. Any bidders failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award. The Bid Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

5. BONDS AND INSURANCE: The Contractor will be required to furnish proof of insurance, including copies of the required endorsements, and performance and payment bonds within 10 calendar days following the Contractor’s receipt of the contract award.

E. DELIVERY OF BIDS

1. Sealed Bids: Regardless of the method of delivery (mailed or hand-carried), bids and all other documents called out in the Solicitation shall be enclosed and sealed in an envelope that is clearly marked “Bid” and shall include the assigned Solicitation Number, and the Bid Opening Date and Time.

2. Hand Carried and Mailed Bids: It is the responsibility of each bidder to ensure that its Sealed Bid is received by the Baltimore District’s – Contracting Branch at the following location:

Contracting Division, Baltimore District, Corps of Engineers

Room 7000 ATTN: Eric L. Taylor City Crescent Building 10th South Howard Street

Baltimore, Maryland 21201

Sealed bids must be received prior to the date and time set for the opening of the bids – See Block 13A of Page 1 of the Solicitation.

F. EVIDENCE OF AUTHORITY TO SIGN BIDS/PROPOSALS

Evidence of the authority of individuals signing bids/proposals to submit firm bids/proposals on behalf of the bidder/offeror is required except where the bid/offer is signed, and shows that it is so signed, by: The President, Vice-President, or Secretary of Incorporated bidders; a partner in case of partnership; the owner in the case of sole proprietorships. Failure to submit with the bid satisfactory evidence of authority of all other persons may be cause for rejection of bid as an invalid or non-responsive bid.

G. BID OPENING ROOM:

1. Each visitor is required to check-in at the USACE Main Office, Room 7000, where they will be asked to sign-in and will then be directed to the Bid Opening Room. All individuals intending to attend the Bid Opening must allow enough time to go through security and check in at the USACE office before being escorted to the Bid Opening room.

2. In order to gain access, all interested participants must check in at the Security Desk in the lobby with a valid photo ID.

Offers will NOT be publicly opened. Information concerning the status of the evaluation and/or award will NOT be available after receipt of proposals.

PLEASE NOTE: THE LAST DAY FOR INTERESTED BIDDERS TO SUBMIT THEIR CONTRACTING

AND TECHNICAL REQUESTS FOR INFORMATION IS 14 DECEMBER 2017 AT 11:00 AM (EST) . NO

OTHER REQUEST FOR INFORMATION WILL BE ACCEPTED AFTER 11:00 AM (EST).

SCOPE OF WORK

The scope of the work consists of hydraulically dredging and pumping material via pipeline from the Knapps Narrows channel to an upland disposal site. The proposed work consists of dredging the entire channel length of 1.7 miles to the authorized depth of 9 feet mean lower low water (MLLW), plus 2 feet of allowable overdepth. The material will be placed at a previously used placement site. There is no earthwork/berm creation involved in this contract. Approximately 100,000 cubic yards of material consisting primarily of sand, silt, mud, shell and combinations thereof, are to be dredged. The maximum pumping distance is approximately 2.5 miles.

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

Section 00 21 13 - Instructions to Bidders

REQUESTS FOR INFORMATION

RFI

Contractors are encouraged to submit Requests for Information (RFI) regarding the solicitation documents.

Prospective offerors may submit RFIs at any time; however, the cutoff date for RFIs is December 14, 2017 at 11:00 A.M. EST, unless the Contracting Officer determines an extension is necessary, to be performed by amendment.

RFIs received after the cutoff date stated above may or may not be answered by the Government.

1. Prospective bidders/offerors must submit RFI inquiries relating to this solicitation only by to Contract Specialist, Eric L Taylor: Email: eric.l.taylor@usace.army.mil

IMPORTANT NOTE***When submitting your RFIs, please provide the project name, location and solicitation number in the subject line of the email. ALL INQUIRIES MUST BE IN WRITING. Please submit RFIs as email body text or as an attached word document. RFIs received as other file formats may be not considered.

Offerors are encouraged to submit RFIs as soon as they become available and not to wait until the cutoff dated to submit all at once

CLAUSES INCORPORATED BY REFERENCE

52.209-7 Information Regarding Responsibility Matters JUL 2013 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.217-5 Evaluation Of Options JUL 1990 52.232-38 Submission of Electronic Funds Transfer Information with

Offer

JUL 2013

52.251-1 Government Supply Sources APR 2012 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

Bidders must provide full, accurate, and complete information as required by this solicitation and its attachments.

The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001.

(End of provision)

52.214-5 SUBMISSION OF BIDS (DEC 2016)

(a) Bids and bid modifications shall be submitted in sealed envelopes or packages (unless submitted by electronic means) (1) addressed to the office specified in the solicitation, and (2) showing the time and date specified for receipt, the solicitation number, and the name and address of the bidder.

(b) Bidders using commercial carrier services shall ensure that the bid is addressed and marked on the outermost envelope or wrapper as prescribed in subparagraphs (a)(1) and (2) of this provision when delivered to the office specified in the solicitation.

(c) Facsimile bids, modifications, or withdrawals, will not be considered unless authorized by the solicitation.

(d) Bids submitted by electronic commerce shall be considered only if the electronic commerce method was specifically stipulated or permitted by the solicitation.

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders before the submission of their bids. Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective bidder concerning a solicitation will be furnished promptly to all other prospective bidders as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective bidders.

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

(a) Bidders are responsible for submitting bids, and any modifications or withdrawals, so as to reach the Government office designated in the invitation for bids (IFB) by the time specified in the IFB. If no time is specified in the IFB, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that bids are due.

(b)(1) Any bid, modification, or withdrawal received at the Government office designated in the IFB after the exact time specified for receipt of bids is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late bid would not unduly delay the acquisition; and--

(i) If it was transmitted through an electronic commerce method authorized by the IFB, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of bids; or

(ii) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of bids and was under the Government's control prior to the time set for receipt of bids.

(2) However, a late modification of an otherwise successful bid that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(c) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the bid wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(d) If an emergency or unanticipated event interrupts normal Government processes so that bids cannot be received at the Government office designated for receipt of bids by the exact time specified in the IFB and urgent Government requirements preclude amendment of the IFB, the time specified for receipt of bids will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(e) Bids may be withdrawn by written notice received at any time before the exact time set for receipt of bids. If the IFB authorizes facsimile bids, bids may be withdrawn via facsimile received at any time before the exact time set for receipt of bids, subject to the conditions specified in the provision at 52.214-31, Facsimile Bids. A bid may be withdrawn in person by a bidder or its authorized representative if, before the exact time set for receipt of bids, the identity of the person requesting withdrawal is established and the person signs a receipt for the bid.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a firmed fixed price contract resulting from this solicitation.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20% percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) (a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from (for hand delivered and mailed protests):

USACE Baltimore District ATTN: Ashley Williams 10 S Howard St, Room 7000 Baltimore, MD 21201

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://acquisition.gov/far/index.html http://farsite.hill.af.mil/VFDFARA.HTM http://farsite.hill.af.mil/VFAFAR1.HTM

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

INFORMATIONAL TEXT

EVIDENCE OF AUTHORITY TO SIGN BIDS/PROPOSALS

Evidence of the authority of individuals signing bids/proposals to submit firm bids/proposals on behalf of the bidder/offeror is required except where the bid/offer is signed, and shows that it is so signed, by: The President, Vice-President, or Secretary of Incorporated bidders; a partner in case of partnership; the owner in the case of sole proprietorships. Failure to submit with the bid satisfactory evidence of authority of all other persons may be cause for rejection of bid as an invalid or non-responsive bid.

End of Text

PREAWARD SAFETY CONFERENCE

a. Where an apparent awardee, in performance of contracts during the previous three year period incurred one or more accidents, or where, in the opinion of the Contracting Officer, there is any question regarding his compliance with any safety or accident prevention requirement, the apparent awardee, on request of the Contracting Officer prior to any award under this solicitation, shall attend a conference with representatives of the Contracting Officer to discuss any such accidents or non-compliance, the reasons for their occurrence, and measures which will be taken to preclude any recurrence thereof.

b. Information elicited at this conference will be used by the Contracting Officer, in conjunction with other information obtained in the pre award survey, in determining the awardees’ responsibility.

c. The items discussed, the preventive measures considered, and any conclusions reached in this conference shall be recorded in minutes of the meeting, which shall be authenticated by the signatures of representatives of the awardee and the Contracting Officer, and any procedures noted therein as agreed upon shall become an obligation of the awardee, along with all other safety and accident prevention requirements of the contract, if award is made to him.

End of Text

MAGNITUDE OF CONSTRUCTION PROJECT

The estimated value of the proposed work is between $1,000,000.00 & $5,000,000.00

End of Text

SAFETY REQUIREMENTS

The Contractor is advised that he shall be expected to comply with the OSHA Standards as well as the most recent Corps of Engineers Safety and Health Requirements Manual (EM 385- 1-1). EM 385-1-1 with applicable addenda and the OSHA Standards are hereby incorporated by reference, as if fully set forth.

IMPORTANT NOTES REGARDING THIS ACQUISITION:

A. BIDDING MATERIAL

Copies of the Solicitation, Specifications, and drawings forms are available by INTERNET ACCESS ONLY. All solicitation documents will be posted to the Federal Business Opportunity (FedBizOpps) website at:

https://www.fbo.gov.

BID DOCUMENTS: The following documents must be submitted with your bid package:

1. SF 1442, Solicitation, Offer and Award

2. Schedule of bids/prices

3. Representations and Certifications (Section 00600)

5. Standard Form LLL (Section 00600)

6. Certificate of Corporate Authority (Section 00600)

7. All amendments (if any) must be acknowledged

8. Bid Bond (Standard Form 24)

9. One (1) compact disk (CD) with the above documents in individual PDF files.

B. PROPOSAL CONDITIONS

1. Contractors must bid all items in the above price schedule, with no exceptions. Should a contractor fail to fully complete the price schedule, its BID will not be considered responsive to the solicitation and ineligible for the resultant contract award. Therefore, the bidder’s total price for the work must be based on the TOTAL of the Base Bid Items included in the Schedule and for each item bid, the Contractor must show the unit price and extended price for the quantity of the item.

2. Split awards or multiple award contracts will not result from this Solicitation.

3. Arithmetic Discrepancies:

a) For the purpose of initial evaluation of bids, the following will be utilized in resolving arithmetic discrepancies found on the face of the price schedule as submitted by bidder:

(1) Obviously misplaced decimal points will be corrected;

(2) Discrepancy between unit price and extended price, the unit price will govern;

(3) Apparent errors in extension of unit prices will be corrected;

(4) Apparent errors in addition of lump-sum and extended prices will be corrected.

b) For the purpose of bid evaluation, the Government will proceed on the assumption that the bidder intends his bid to be evaluated on the basis of the unit prices, the totals arrived at by resolution of arithmetic discrepancies as provided above and the bid will be so reflected on the abstract of bids.

c) These correction procedures shall not be used to resolve any ambiguity concerning which bid is low.

4. Caution to Bidders – Bid Errors: You are cautioned to exercise extreme care in preparation of your bid.

Errors in bids are costly and could result in substantial loss to you as well as delayed award of contracts. Actions you can take to avoid errors are:

a) Make sure your bid takes into consideration all amendments to the IFB.

b) If you feel bidding requirements are unclear, contact the Baltimore District Office in writing for an explanation before preparing and submitting your bid.

c) Verify all quantities and prices, especially quotations from subcontractors. Make sure no line items have been overlooked in recapitulating. Have your bid reviewed by qualified personnel other than those preparing the bid.

d) Retain all original notes, subcontractor quotations, estimates, and summary worksheets from which your bid was prepared. If you have made a mistake in bid, you will need these papers to determine the nature and amount of an error and to support any request you may make for special relief.

C. COMPETITION: 100% Small Business Set Aside

D. SUBMISSION OF BIDS

1. All bids must be submitted in accordance with the procedures set forth in Block 13 of Page 1 of this Solicitation document. BIDS OR MODIFICATIONS TO BIDS THAT ARE RECEIVED BY FACSIMILE WILL

NOT BE CONSIDERED.

2. SF 1442 BACK (Page 2 of the Solicitation): Bidders are required to acknowledge the receipt of all amendments to the Solicitation on the Standard Form 1442 in Block 19. Bidders shall fully complete all the required areas located under the section designated as “OFFER” (refer to Items 14 through 20C).

3. Section 00600 (Representation and Certifications): The bidders must fully complete Section 00600 of this Solicitation and submit it along with all other documents required by this Solicitation. Bidders received without this Section fully completed may be rejected, considered non-responsive and ineligible for award.

4. BID GUARANTEE: The bidders are required to submit a Bid Guarantee for this procurement. Any bidders failing to submit an authentic Bid Guarantee will be considered non-responsive to the Solicitation and ineligible for award. The Bid

Guarantee shall be in the amount of 20% of the bidder’s price or $3,000,000.00, whichever is less.

5. BONDS AND INSURANCE: The Contractor will be required to furnish proof of insurance, including copies of the required endorsements, and performance and payment bonds within 10 calendar days following the Contractor’s receipt of the contract award.

E. DELIVERY OF BIDS

1. Sealed Bids: Regardless of the method of delivery (mailed or hand-carried), bids and all other documents called out in the Solicitation shall be enclosed and sealed in an envelope that is clearly marked “Bid” and shall include the assigned Solicitation Number, and the Bid Opening Date and Time.

2. Hand Carried and Mailed Bids: It is the responsibility of each bidder to ensure that its Sealed Bid is received by the Baltimore District’s – Contracting Branch at the following location:

Contracting Division, Baltimore District, Corps of Engineers Room 7000 ATTN: Robert Jackson City Crescent Building 10 South Howard Street Suite 7000 Baltimore, Maryland 21201

Sealed bids must be received prior to the date and time set for the opening of the bids – See Block 13A of Page 1 of the Solicitation.

F. EVIDENCE OF AUTHORITY TO SIGN BIDS/PROPOSALS

Evidence of the authority of individuals signing bids/proposals to submit firm bids/proposals on behalf of the bidder/offeror is required except where the bid/offer is signed, and shows that it is so signed, by: The President, Vice-President, or Secretary of Incorporated bidders; a partner in case of partnership; the owner in the case of sole proprietorships. Failure to submit with the bid satisfactory evidence of authority of all other persons may be cause for rejection of bid as an invalid or non-responsive bid.

G. BID OPENING ROOM:

1. Each visitor is required to check-in at the USACE Main Office, Room 7000, where they will be asked to sign-in and will then be directed to the Bid Opening Room. All individuals intending to attend the Bid Opening must allow enough time to go through security and check in at the USACE office before being escorted to the Bid Opening room.

2. In order to gain access, all interested participants must check in at the Security Desk in the lobby with a valid photo ID.

Section 00 45 00 - Representations and Certifications

52.204-8 Annual Representations and Certifications JAN 2017

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (JUL 2016)

(a) Definition. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall enter its CAGE code in its offer with its name and address or otherwise include it prominently in its proposal. The CAGE code entered must be for that name and address. Enter ``CAGE'' before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via--

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the offeror does not otherwise register in SAM, an offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE Code is required for the immediate owner and/or the highest-level owner by 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE Code from that entity to supply the CAGE Code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(End of Provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or…