W91236-16-B-0004-0004.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Subject Action W91236-16-B-0004, Maintenance Dredging, Quinby Creek, Viriginia is hereby Amended as follow s:

A. Section 00 21 00 INSTRUCTIONS, CONDITIONS, NOTICES TO OFFERORS has been updated to include "Notice to Bidders".

B. Proposal due date is unchanged, and remains 20 September 2016 at 2:00 PM EST.

C. Acknow ledge ALL Amendments in your proposal.

Contracting POC: Stormie Wicks, Stormie.B.Wicks@usace.army.mil, (757) 201.7215

1. CONTRACT ID CODE PAGE OF PAGES

J 1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 08-Sep-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W91236-16-B-0004

X 9B. DATED (SEE ITEM 11)

18-Aug-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

08-Sep-2016

CODE

USA ENGINEER DISTRICT, NORFOLK

803 FRONT STREET

NORFOLK VA 23510-1096

W91236 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W91236-16-B-0004

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SECTION 00 11 00 - SF 1442 AND CLIN SCHEDULE

SUMMARY OF CHANGES

SECTION 00 01 10 - TABLE OF CONTENTS

The Table of Contents has changed from:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 06-SEP-2016 to:

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

SECTION 00 21 00 - INSTRUCTIONS, CONDITIONS & NOTICES TO OFFERORS

The following have been added by full text:

NOTICE TO BIDDER

_1 . AWARD TO RESPONSIBLE BIDDER

Responsibility will be determined, prior to award, by the Contracting Officer, either by performing a pre-award survey or conclusions based on a previous pre-award survey and/or any performance data available. A pre-award survey will be performed in determining contractor’s responsibility in accordance with FAR 9.104 and 9.106. The bidder will be required to show that he has the necessary capital, experience, and owns or can procure the necessary plant or other resources to commence the work at the time prescribed in the specifications and thereafter to prosecute and complete the work safely and satisfactorily within the time specified.

_2 . EVIDENCE OF AUTHORITY TO SIGN BIDDERS

Evidence of the authority of individuals signing offers to submit firm offers on behalf of the bidder is required except where the offer is signed, and shows that it is so signed, by: the President, Vice- President, or Secretary of an incorporated Offeror; a partner in the case of a partnership; or the owner in the case of a sole proprietorship. Failure to submit with the bidder satisfactory evidence of the authority of all other persons may be cause for rejection of the bidder as invalid or nonresponsive.

_3 . PREAWARD SAFETY CONFERENCE

Where an apparent low bidder, in performance of contracts during the previous three-year period, incurred one or more accidents, or where, in the opinion of the Contracting Officer, there is any question regarding this compliance with any safety or accident prevention requirement, such bidder, on request of the Contracting Officer prior to any award under this solicitation, shall attend a conference with representatives of the Contracting Officer to discuss any such accidents or non-compliance, the reason for their occurrence, and measures which will be taken to preclude any recurrence thereof.

Information elicited at this conference will be used by the Contracting Officer, in conjunction with other information obtained in a pre-award survey, in determining the bidder's responsibility.

The items discussed, the preventive measures considered, and any conclusions reached in this conference shall be recorded in minutes of the meeting, which shall be authenticated by the signatures of representatives of the bidder and the Contracting Officer, and any procedures noted therein as agreed upon shall become an obligation of the bidder, along with all other safety and accident prevention requirements of the contract, if award is made to him.

_4 . BASIS OF AWARD

All blanks must be filled in by the bidder. A single award will be made to the lowest responsible, responsive bidder on the basis of the total price bid. Prior to making an award, a pre-award survey will be made and the low bidder will be required to show that he has the necessary capital, experience, and owns or can procure the necessary plant to commence the work at the time prescribed in the specifications and thereafter to prosecute and complete the work safely and satisfactorily within the time specified.

In order to minimize delays in conducting the pre-award survey and awarding the contract, the following information will be required:

- Financial Institution information/Address:

- Your Banking Point-of-Contact:

- Telephone Number, Fax Number & Email Address:

THREE (3) CURRENT OR COMPLETED PROJECTS OF SIMILAR SCOPE AND SIZE. (MUST BE

CURRENT WITHIN THE PAST FIVE (5) YEARS from the date of this solicitation).

Project Title/Contract Number

Customer

Point-of-Contact

Telephone Number, Fax Number & Email Address

Dollar Value

Percent Complete

Scheduled Completion Date

_5 . INCURRING COSTS

The Government is not liable for any costs incurred by the bidder submitting a bid in response to this solicitation.

_6 . AGENTS

Bids signed by an Agent must be made in the name of the Principal and must be accompanied by evidence of said Agent’s authority to act on behalf of its Principal.

_7 . UNBALANCED BIDS

Any bid which is materially unbalanced as to prices for the Base Items and the Optional Items may be rejected as non-responsive or otherwise not considered for award. An unbalanced bid is one which is based on prices significantly less than cost for some work and prices which are significantly overstated for other work.

_8 . UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

The contractor shall not accept instructions issued by any person, employed by the U.S. Government or otherwise, other than the Contracting Officer or the Authorized Representative of the Contracting Officer acting within the limits of his/her authority as defined in the Designation of Authority letter. A copy of the Designation of Authority letter will be furnished to the contractor at time of contract award.

_9 . MAGNITUDE OF CONSTRUCTION

The magnitude of construction is between $1,000,000.00 and $5,000,000.00

_10__. BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c )The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.

(d)If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e)In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount its bid, and the bid guarantee is available to offset the difference.

(End of provision)

(End of Summary of Changes)