W911S6-16-B-0002.pdf

0010850479

PROJECT TITLE: Modifications to Labs 53 and 55, Bldg. 4156 PROJECT LOCATION: Dugw ay Utah, Ditto Area DESCRIPTION: A firm f ixed price contract for the Modif ications to Labs 53 and 55, Bldg. 4156, Dugw ay, Utah. The successful contractor shall furnish all the equipment, materials, labor, and supervision necessary to perform the w ork for this project in accordance w ith the draw ings and specifications; the contract terms and conditions are incorporated by full text and reference.

SETASIDE: HUBZone NAICS CODE: 236220 Commercial and Institutional Building Construction SIZE STANDARD: $36,500,000.00 MAGNITUDE OF CONSTRUCTION PROJECT: The estimated value of the proposed w ork is betw een $25,000 and $100,000 PREBID MEETING/SITE VISIT: See FAR 52.236-27, Alt I for date, time and meeting location.

DUE DATE FOR ALL QUESTIONS: 18 October 2016 1:00 PM MTN. All questions shall be emailed to John Kurek AND Ricky Jaramillo at john.e.kurek.civ@mail.mil AND ricky.j.jaramillo2.civ@mail.mil BID OPENING: The bid opening w ill be held at Building 5330, MICC Conference Room 1201, Dugw ay, UT 84022. See Block 13A for date and time.

X

JOHN E KUREK 435-831-2369

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

22-Sep-2016

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________120 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________02 Nov 2016 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______120 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

US ARMY CONTRACTING AGENCY/DUGWAY

CCMI - DPG

5330 VALDEZ CIRCLE MS #1

DUGWAY PROVING GROUND UT 84022-5001

W911S6

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: 435-831-2102 TEL: FAX:

W911S6-16-B-0002 30

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W911S6-16-B-0002

Section 00 00 00 - Procurement and Contracting Requirements

TABLE OF CONTENTS

SOLICITATION, OFFER AND AWARD SF 1442 and SF 1442 BACK

SECTION 00010- NOTES

SECTION 00100- INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS (remove in award)

SECTION 00600- REPRESENTATIONS AND CERTIFICATIONS (remove in award)

SECTION 00700 - CONTRACT CLAUSES

SECTION 00800 - SPECIAL CONTRACT REQUIREMENTS

ATTACHMENT 1- PLANS AND SPECIFICATIONS: PWS_PRS - Modifications to Rms 53 and 55, Bldg 4156 rev 1, dtd 22 August 2016.pdf

ATTACHMENT 2- DRAWINGS

ATTACHMENT 3- GENERAL DECISION NUMBER: UT160107 07/29/2016 UT107 dtd 29 July 16.pdf

ATTACHMENT 4- CLIN PRICING SUMMARY AND DETAIL SHEETS.pdf

ATTACHMENT 5- SITE VISITOR INFORMATION SHEET.elsx

ATTACHMENT 6- IWATCH TRAINING FOR CONTRACTOR.pptx

ATTACHMENT 7- SOLICITATION QUESTIONS AND ANSWERS DOCUMENT to be inserted at award.

SECTION 00010- NOTES

1. Offeror’s attention is invited to the insurance requirement contained in this solicitation (Contract Clause FAR 52.228-5). Certification of the required coverage for the prime contractor shall be furnished prior to beginning work on this contract.

2. The term “Bidding Schedule” shall also be construed to mean “Offer Schedule” or “Schedule”. The terms

“bid” and “offer”, and “bidder” and “offeror” shall be construed as having the same meaning in this solicitation and resulting contract.

3. Facsimile transmission of bid is not authorized.

4. All information relating to this IFB, including pertinent changes/amendments and information will be posted on web site: http://www.fbo.gov. For security reasons, all potential offerors, plan rooms and printing companies are required to be registered in the GSA System for Award Management (SAM) database.

SECTION 00010- INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

INSTRUCTIONS TO BIDDERS

1. SCOPE:

1.1. You are invited to submit a bid in response to our Invitation for Bids (IFB) entitled W911S6-16-B-0002, Project: Modifications to Labs 53 and 55, Bldg. 4156, at Dugway, Utah.

1.2. As a result of this solicitation, the Government intends to award a Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible bidder whose bid, conforming to the invitation for bids, will be most advantageous to the Government, considering only price. The Magnitude of this Project is between $25,000 and $100,000.

1.3. This solicitation is set-aside 100% for small businesses HUBZONE qualified contractors.

2. BID PREPARATION INSTRUCTIONS:

Bid submissions shall be sent via shipper, ie. Fed-Ex, UPS, etc. or delivered in person to the contracting office Building 5330 Valdez Circle, Room 1402 A. If delivering in person, contractor shall provide Contract Specialist Mr. John. Kurek with person(s) information to be added to the access roster with security. Process is the same as the site visit instructions included herein. Bids must be submitted in a sealed envelope or package.

Questions: The Contracting Officer (KO) and Contracting Specialist are the sole points of contact for this acquisition. Address all questions or concerns you may have to the KO and Contract Specialist. All questions regarding this solicitation shall be submitted in writing via email (email is the preferred method) to: Mr.

Rick J. Jaramillo via email [ricky.j.jaramillo2.civ@mail.mil] (435) 831-2105 and Mr. John Kurek [john.e.kurek.civ@mail.mil] (435) 831-2369. Offerors shall submit their questions in writing by no later 5:00 PM [local prevailing time at U.S. Army Dugway Proving Ground, Utah] on Tuesday, October 18, 2016. Questions received after that time will not receive a response.

Bid Documents: Failure to follow the below return documents will cause your bid to be deemed nonresponsive by the Government:

Return Documents:

TAB 1 - SF 1442: The SF 1442 shall be submitted fully completed. The bidder is cautioned that the SF1442 must contain an original signature in block 20 of the form. The bidder shall acknowledge any amendments to the IFB in accordance with the instructions. The bid shall provide the name, title and telephone number of the company/division point of contact regarding decisions made with respect to your bid and who can obligate your company contractually.

TAB 2 – Contract Line Items Numbers (CLINs). CLIN 0001 shall be submitted fully completed and error free. It shall contain the bidder’s price for the established CLIN 0001 and 0002. CLIN 0002 Payment Bonds (not evaulated) – use your bonding rate – if bond comes in at lower rate the excess will be deobligated. (Intent bond price will be verified prior to award with successful offeror).

TAB 3 – Pricing Summary Spreadsheets – Division Bid Supporting Documents: Example supporting documentation for bid justification. (also these support your progress payment and facialitae DD Form 1354 submission) Issued Worksheets have no formulas – contractor ensure support documentation is correct. Supplied Excel (Attachment 4) worksheets contain the minimum construction divisions identified for project (government uses RS Means), contractor may add other supporting documentation (sub bid, etc.). With the documents submitted above, the Offeror shall also submit 1 copy of their bid electronically (CD).

3. EVALUATION FOR AWARD:

3.1. The Contracting Officer will award a single contract to the successful bidder. Bidders must submit the information requested in this section with its bid in order to be responsive to the requirements of this solicitation;

failure to omit any portion of this information when submitting a bid will render the bidder non-responsive and cause elimination from the competition.

3.2.. Contractor shall provide written verification, supported by documented work history, of being in the normal business of construction as a prime contractor for a minimum of 3 years performing Commercial and Institutional Construction, , as classified and described in the NAICS 236220.

3.3. Offers the lowest aggregate amount for the ; Modifications to Labs 53 and 55, Bldg. 4156.

4. NOTICE OF PRE-BID CONFERENCE AND SITE VISIT:

4.1. A pre-bid conference will be conducted on Wednesday, October 12, 2016 @ 09:00 AM for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at Dugway, Utah. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

4.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email information for all attendees to Mr. Rick J. Jaramillo and Mr. John Kurek at the following addresses:

ricky.j.jaramillo2.civ@mail.mil; john.e.kurek.civ@mail.mil. This information must be provided in advance, not later than 3 business days prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. SEE SOLICITATION CLAUSE FAR 52.236-27 FOR

DETAILS.

4.3. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

4.4 A record of the conference shall be made and furnished to all prospective bidders via posting at http://www.fbo.gov. The record will include minutes of the meeting, including any questions.

5. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS:

5.1. Submit all questions in the format shown below by email to the contracting office at the addresses show below.

All questions must come through the Contracting Office.

Subject Line: SOLICITATION W911S6-16-B-00002 Question Email:ricky.j.jaramillo2.civ@mail.mil; john.e.kurek.civ@mail.mil

PRE-BID INQUIRY FORMAT

Company Name:

Phone Number:

Email address: Bid Inquiry: (Please clearly state your question) (If sent via an attachment word docs are preferred to facilitate posting of answers to the master Q&A document.)

5.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach bidders before the submission of their bid.

5.3. Any interpretations made will be in the form of an amendment of the solicitation, drawings, specifications, etc., and will be furnished to all prospective offerors via posting at: http://www.fbo.gov.

5.4. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of bids. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding. Questions (on a non-attribution basis) and answers shall be furnished to all prospective bidders via the web site.

5.5. For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (fbo.gov) system. FedBizOpps is a web based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system. FedBizOpps registration requires the following information: All potential offerors, must be registered System for Award Management (SAM) database. Firms can register via the SAM internet site at https://www.sam.gov/portal/public/SAM/.

6. AMENDMENTS PRIOR TO DATE SET FOR OPENING OF BIDS:

The right is reserved, as the interest of the Government may require, to revise or amend the solicitation, specifications and/or drawings, prior to the date set for opening of bids, as necessary. Such changes, if any, will be announced by an amendment or amendments to this Invitation for Bids. All information relating to this IFB, including pertinent changes/amendments and other information applicable prior to the date set for receipt of bids will be posted at: http://www.fbo.gov. Offerors are strongly cautioned to check this site frequently and to “refresh” their web page to ensure they have the latest information.

7. BID OPENING

7.1. Follow the same instruction for obtaining entry to hand carry bid. Late receipt of bids due to entry delays may not be deemed excusable and the Contracting Officer may declare the bid “late” in accordance with FAR 14.304.

7.2. The bid opening will occur at the time and date specified in Block 13 of the SF1442 Wednesday, 2

November 2016, at 1:00 PM local prevailing time. All interested offerors and their major subcontractors are encouraged to attend the bid opening located at Valdez Street, Building 5330, Room 1201(MICC Conference Room) Dugway, Utah 84074. All interested offerors and their major subcontractors are encouraged to attend the bid opening.

8. WAGE DETERMINATION:

Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are. General Decision Number: UT160107 07/29/2016 UT107 dtd 29 July 16.pdf.

Applicable wage rates can be found at Applicable wage rates can be found at http://www.wdol.gov/dba.aspx

9. BID PREPARATION EXPENSES AND PRE-CONTRACT COSTS:

This IFB does not commit the Government to pay costs incurred in preparation and submission of bids or for other costs incurred prior to award of a formal contract.

10. DISPOSITION OF UNSUCCESSFUL BIDS:

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful bids. These are uploaded to MICC Paperless Contracting File (PCF) system. Government will destroy extra copies of unsuccessful bids. No destruction certificate will be provided.

11. OFFERORS QUALIFICATIONS:

To establish its responsibility, the apparent low bidder may be requested by the Government prior to award, to submit a statement regarding his previous experience in performing comparable work, his business and technical organization, financial and bonding resources available to be used in performing the work. This action may be requested to determine if the contractor is responsible.

Section 00 10 00 - Solicitation

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Modification to Rms 53 and 55, Bldg 4156

FFP

Construction to combine rooms 53 and 55 in Bldg 4156, Ditto Area, Dugway, Utah. The contractor shall furnish all the equipment, materials, labor, and supervision necessary to perform the work for this project in accordance with the drawings and specifications; the contract terms and conditions incorporated by full text and reference.

FOB: Destination

PURCHASE REQUEST NUMBER: 0010850479

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Job Payment Bond

FFP

Bond premium for the monetary value of construction work in CLIN 0001.

Contractor reimbursement cost will not exceed actual cost of Bond. Per FAR 28.102-2, the Contracting Officer may determine a lesser amount is adequate for the protection of the government.

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

0001 120 dys. ADC 1 COMMANDER

PETERSON, LES (DBO-DIS-E-CS)

US ARMY DUGWAY PROVING GROUND

DUGWAY UT 84022-5000

(435)831-2342

W911S6

0002 10 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

W911S6

CLAUSES INCORPORATED BY REFERENCE

52.204-7 System for Award Management JUL 2013 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids MAR 1997 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.219-2 Equal Low Bids OCT 1995 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-22 Previous Contracts And Compliance Reports FEB 1999 52.232-38 Submission of Electronic Funds Transfer Information with

Offer

JUL 2013

252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

CLAUSES INCORPORATED BY FULL TEXT

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

6% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Dugway Proving Ground, Dugway, Utah.

NOTICE OF WAGE DETERMINATION

Any contract awarded as a result of this solicitation will be subject to Wage Determination UT160107 07/29/2016 UT107. The current wage determination(s) are attached to this order/contract.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from:

Mr. Ricky J. Jaramillo, Contracting Officer 5330 Valdez Circle, MS #1

CCMI-CHD-DP

Dugway, Utah 84022 ricky.j.jaramillo2.civ@mail.mil

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) – ALTERNATE I (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for Wednesday, October 12, 2016 at 09:00 AM.

(c) Participants will meet at Ditto Diner, Building 4090, Ditto Area, Dugway, Ut.

(d) Bidders interested in attending the site visit shall contact Mr. John Kurek, Contract Specialist via email [john.e.kurek..civ@mail.mil] by no later 2:00 PM [local prevailing time at U.S. Army Dugway Proving Ground, Utah] on Wednesday, October 5, 2016. To request admittance to DPG/Site Visit, contractor shall provide the following information:

IMPORTANT - SEE Solicitation Attachment 5 - Site Visitor Information Sheet.elsx

All visitors will have a NACI III background check run before access is granted. If there are any adverse items on the report, they may not be allowed access to the installation. If a background check conducted upon arrival - this can typically take up to 20 minutes, up to an hour on weekends. Any personnel identified with a negative background check will be turned away.

Contractors driving onto post shall bring current vehicle registration and proof of insurance.

MAGNITUDE OF CONSTRUCTION PROJECT

The magnitude of this construction project is estimated between $ 25,000 and $ 100,000.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): http://farsite.hill.af.mil

Section 00 60 00 - Project Forms

52.219-1 SMALL BUSINESS PROGRAM REPRESENTATIONS (OCT 2014)

(a) Definitions. As used in this provision--

Economically disadvantaged women-owned small business (EDWOSB) concern means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

Service-disabled veteran-owned small business concern--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (b) of this provision.

Small disadvantaged business concern, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

Veteran-owned small business concern means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

Women-owned small business concern means a small business concern--

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition 236620.

(2) The small business size standard is 36.5 milion.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(c) Representations. (1) The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern. (2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ --.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (c)(4) of this provision.] The offeror represents as part of its offer that--

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ --.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ --.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm's status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall—

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government 0002 N/A N/A N/A Government

CLAUSES INCORPORATED BY REFERENCE

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2015

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.211-13 Time Extensions SEP 2000 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.219-3 Notice of HUBZone Set-Aside or Sole Source Award NOV 2011 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.222-26 Equal Opportunity APR 2015 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-50 Combating Trafficking in Persons MAR 2015 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

JUN 2016

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-9 Buy American--Construction Materials MAY 2014 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-1 Bid Guarantee SEP 1996 52.228-2 Additional Bond Security OCT 1997 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts MAY 2014 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-4 Physical Data APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-1 Alt I Termination for Convenience of the Government (Fixed-price) (Short Form) (Apr 1984) - Alternate I

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7004 Alt A System for Award Management Alternate A FEB 2014 252.223-7001 Hazard Warning Labels DEC 1991

252.223-7004 Drug Free Work Force SEP 1988 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.227-7033 Rights in Shop Drawings APR 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.247-7023 Transportation of Supplies by Sea APR 2014

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120 days to include all punch lists and final invoice* The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $196.37 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JULY 2013)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is ``not dominant in its field of operation'' when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it…