W911PT-17-Q-0038.pdf

ARMY CONTRACTING COMMAND-WARREN (WVA)

SERVICES TEAM

ATTN: CCTA-HDW/BLDG 10

1 BUFFINGTON STREET

WATERVLIET NY 12189-4000

TEL: 518-266-4535 FAX:

W16H1F701102EX

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W911PT-17-Q-0038 27-Feb-2017 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

ARMY CONTRACTING COMMAND-WARREN (WVA)

ATTN: CCTA-HDW/BLDG 10

1 BUFFINGTON STREET

WATERVLIET NY 12189-4000

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

08-Mar-2017(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

(518) 266-4643RONALD ASCHER

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W911PT-17-Q-0038

Section A - Solicitation/Contract Form

CLAUSES INCORPORATED BY FULL TEXT

52.0000-4002 REQUEST FOR QUOTE RESPONSES (Oct 2016) (ACC-WRN (WVA))

ALL RESPONSES MUST BE ELECTRONIC. YOU MAY SUBMIT YOUR QUOTE RESPONSES USING ONE

OF THE FOLLOWING METHODS:

1) Email to ronald.a.ascher.civ@mail.mil

2) Federal Business Opportunities-FedBizOpps (FBO)

Requirements for the online FBO bid submission:

1. Vendors must login to the FBO System to be able to submit electronic responses for opportunities.

2. Vendors must also registered in the System for Award Management (SAM) at www.sam.gov (a Federal Government owned and operated free web site) and have a CAGE Code and CCR Marketing Partner Identification Number (MPIN).

3. Once logged into the FBO System, vendors will be asked to enter basic information and then will be directed to upload one or more files containing the offer and any additional information as outlined in the solicitation.

4. FBO will send an email to the email address on file for the user confirming the electronic submission.

5. For additional information on submitting electronic bid responses via the Federal Business Opportunities System reference the FBO Vendor Guide – Section 4.3.1 Submitting an Electronic Response Topic (https://www.fbo.gov/downloads/FBO_Vendor_Guide.pdf).

REQUEST FOR QUOTES MUST BE FILLED OUT COMPLETELY AND SENT IN ITS ENTIRETY TO BE

CONSIDERED RESPONSIVE.

(END OF NOTICE)

52.0000-4950 Disclosure of Unit Price Information (Jun 2004) (ACC-WRN (WVA))

This constitutes notification pursuant to Executive Order 12600, Pre-Disclosure Notification Procedures for Confidential Commercial Information (June 23, 1987), of our intention to release unit prices of the awardee in response to any request under the Freedom of Information Act, 5 USC 552. Unit price is defined as the contract price per unit or item purchased. We consider any objection to be waived unless the contracting officer is notified of your objection to such release prior to submission of initial proposals.

END OF CLAUSE

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Lot FSC: Z2EZ Replace Transformer B121

FFP

To provide all labor, material, parts and equipment to remove and replace a 300KVA transformer. All work will be performed in accordance with Statement of Work under project 7PW028 which is attached and incorporated.

Wage Determination General Decision Number NY170002 02/03/2017 NY2 applies and is incorporated.

Magnitude of this Project is between $25,000 and $100,000.

Technical Point of Contact is CPT Lee Stephens.

100% Payment Bond is required.

MID: 43694 M7955

AAS: 170040021

FOB: Destination

NSN: AASSVC701102EX

MILSTRIP: W16H1F701102EX

PURCHASE REQUEST NUMBER: W16H1F701102EX

NET AMT

STATEMENT OF WORK:

STATEMENT OF WORK (SOW)

FOR

Replace Existing 300KVA Transformer Building 121

AT

Watervliet Arsenal

Building 121 Project #: 7PW028

AAS: 170040021

Installation Management, Public Works Division Facilities Engineering (TAWV-IMP-F)

PART 1 GENERAL

1.1 SUMMARY OF WORK

1.1.1 Project Description

a. This Statement of Work (SOW) defines the effort required for removing & replacing Existing 300KVA oil filled Transformer Bldg. 121. The oil in the unit will be evacuated by the Arsenal on the day of removal. Accordance to the nameplate, transformer has 200 GAL Liquid in its tank and total WT IS 5775LB. Disconnect the high and low sides of the existing transformer, along with any conduits physically attached. Disconnect 480V feeder from the existing transformer to the existing 480V Disconnect switch in according to the electrical drawing E102. Install a new 300KVA Transformer on new concrete box pad. Reconnect the primary and secondary feeder. Replace 208V secondary feeder if it is necessary to meet NEC. Replace 480Volts feeder from a new transformer to the existing 480V Disconnect Switch in according to the electrical drawing E102. Test the secondary voltage and the phasing of a new transformer. Verify the grounding system and modify to meet NEC.

1.1.2 Location of Work

a. The work is located at Bldg 121, approximately as indicated. The exact location will be shown by the Contracting Officer.

1.1.3 Period of Performance

a. The contractor shall be required to (i) commence work under this contract within 7 calendar days after the date the contractor receives notice to proceed, (ii) prosecute the work diligently, and (iii) complete the entire work ready for use not later than 60 calendar days after notice to proceed was given. The time stated for completion shall include final cleanup of the premises.

1.1.4 Hours of Operation

a. Normal duty hours are 7:00 AM through 4:00 PM, Monday through Thursday, and 7:00 AM through 3:00 PM on select Fridays (the arsenal is closed every-other Friday). Federal holidays are non-work days. If a federal holiday falls on a Saturday or Sunday, the preceding Friday or following Monday is a work holiday.

1.2 SUBMITTALS

1.2.1 General Submittal Requirements

a. The contractor shall provide submittal documents via e-mail to the Contracting Officer for review and approval. Provide all physical (non-document) submittals (including but not limited to material swatches, samples, etc.) directly to the Contracting Officer for review and approval. All submittals require government approval unless otherwise explicitly stated.

b. The contractor shall reference APPENDIX A “Consolidated List of Submittals” for the complete list of required submittals.

1.2.2 Contractor Safety Plan

a. The contractor shall submit a safety plan which is specific to the work activity being performed under the scope of this project for Government review and approval.

1.2.3 Lockout / Tagout (LOTO) Acknowledgement

a. The Contractor shall sign and submit a “Lockout/Tagout (LOTO) Notification Acknowledgement Record” prior to working on or de-energizing any electrical equipment.

1.2.4 Project Schedule

a. The contractor shall create a project schedule and submit for Government review and approval.

b. The project schedule shall detail the phases of work and the overall timeline for the execution of the work. The contractor shall include delivery dates, appropriate milestones, and shall clearly detail any requirements for work performed outside of regular hours of operation.

1.2.5 Specs and Tests

a. Watervliet Arsenal Public Works Division will ensure proper oil sampling will be performed prior to any shutdown or work being performed on this transformer, to determine current PCB level.

b. Prior to replacement, WVA shall have all oil removed from the current transformer and properly disposed of, off-site.

1.3 GENERAL REQUIREMENTS

1.3.1 Watervliet Arsenal Information for Contractors (WAIC)

a. The contractor shall perform all work in strict conformance with Watervliet Arsenal Instructions for Contractors (WAIC). The contractor shall read and understand this document prior to submitting a proposal. The WAIC is publically available at:

<http://www.wva.army.mil/Documents/Contracting/WAIC.pdf>

1.3.2 Utility Outage Requests and Utility Connection Requests

a. Schedule work to minimize outages. For utility outages and connections required during the execution of work that affect existing systems, coordinate schedule with COR. Schedule utility outages and connections to minimize disruptions to the Government. No additional payment will be provided for utility outages and connections required to be performed outside the regular work hours.

b. The contractor shall notify the Contracting Specialist a minimum of two (2) business days before the contractor starts work. The contractor shall notify the COR a minimum of seven (7) business days before the shut-down of a utility or building service.

1.3.3 Safety Requirements

a. The contractor is required to provide the proper control of hazardous energy (lockout/tagout) per

OSHA 29 CFR 1910.147.

b. The contractor shall inspect the project work site prior to starting work, and shall request a copy of the asbestos building inspection records to verify the location and description of known asbestos-containing materials.

1.4 ON-SITE PERMITS

1.4.1 Excavation (Dig Permit)

a. The clearance of buried utilities will be performed by the Government in advance of the Contractor performing subsurface work, unless otherwise explicitly stated.

b. The Contractor shall obtain a copy of the completed Utility Clearance Permit (WVA Form 420-2-E) from the COR prior to performing subsurface work. Verify existing utility locations indicated on contract drawings, within area of work.

1.4.2 Hot Work and Confined Space

a. Obtain permit for welding, burning, use of flame, or entry into confined space from WVA Fire

Department by calling (518)266-5990 each day the permit is to be used.

1.5 APPLICABLE DOCUMENTS

1.5.1 Drawings

The following drawings accompany this Statement of Work and are a part thereof.

a. G001 - Cover Sheet

b. E101 – General Electrical Notes & Legends

c. E102 – Demo & Reno Plans

1.5.2 Specifications

The following specifications accompany this Statement of Work and are a part thereof.

DIVISION 01 – PROCUREMENT AND CONTRACTING REQUIREMENTS

01 01 15 LIST OF DRAWINGS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 SUMMARY OF WORK

01 33 00 SUBMITTAL PROCEDURES

01 78 00 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 – EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 26 - ELECTRICAL

26 12 19.10 THREE PHASE PAD MOUNTED TRANSFORMER

26 20 00 INTERIOR DISTRIBUTION SYSTEM

1.5.3 References

The following references accompany this Statement of Work and are a part thereof.

a. Watervliet Arsenal Instructions for Contractors (WAIC).

b. NFPA 70 – National Electric Code (NEC).

c. IEEE C2 National Electrical Safety Code.

1.6 CONTRACTOR EQUIPMENT

1.6.1 Equipment Identification

a. The contractor shall create and affix a label to all large equipment, dumpsters, and other mobilized property, which is weather-resistant (laminated, or within a see-thru label hanger), securely affixed to the equipment or visible through a window, and which clearly displays the General Contractor’s:

i. Company Name, POC Name (first, last), POC phone number, Project Number.

1.6.2 Waste Dumpster

a. The contractor shall place any waste dumpsters in a manner that does not interfere with thru-traffic.

b. Place waste dumpsters with a minimum of 33’ clearance from any building. The final location shall be coordinated with, and approved by the COR before any dumpsters are mobilized.

c. Cover all waste dumpsters when not in use, and before the end of each work shift. The cover shall be weather-tight.

d. Note: The Contractor shall be required to retain and submit copies of all Bills of Lading and Weight

Slips associated with the disposal of construction and demolition C&D) debris.

PART 2 PRODUCTS

2.1 GENERAL

All work shall be in strict accordance with product manufacturer’s instructions and specifications, including but not limited to manufacturer guidance for storage, staging, application, installation, and disposal of the product.

2.1.1 Hazardous Materials

a. The contractor shall submit Safety Data Sheets (SDS) for all hazardous materials to be used.

2.1.2 Asbestos, Mercury, Lead, PCB

a. Unless otherwise stated, all materials for this project shall be new. All products shall not contain any asbestos, mercury, chromium/lead paint, Class I Freon, and Polychlorinated Biphenyls (PCB), and shall state such on the manufacturer’s original packaging.

2.1.3 DoD Green Procurement Program

a. All construction materials shall meet the applicable requirements of the DoD Green Procurement

Program, specifically recycled content products, environmentally preferable products and services, biobased products, energy-and water-efficient products, alternate fuel vehicles and alternative fuels, products using renewable energy, and alternatives to hazardous or toxic chemicals as found at <http://www.acq.osd.mil/dpap/cpic/cp/docs/USA001967-08-DPAP.pdf>.

2.2 PRODUCTS

2.2.1 Product

a. Product requirement Three Phase Pad Mounted Transformer Two winding, 60 hertz, 65 degrees C rise above a 30 degree C average ambient, self-cooled type.

Transformer shall be rated 300KVA. Transformer voltage ratings: 480 V / 208V.

b. Concrete Box Pad

PART 3 EXECUTION

3.1 ITEMS OF WORK

a. The Contractor shall complete the items of Work in accordance with the Project Drawings and Specifications.

b. Electrical Power.

1. The contractor shall identify and isolate power to existing 300KVA Transformer from input and output circuits and verify power has been disconnect prior to working on electrical service.

a. The contractor will provide a minimum of 48 hour notice for needed coordination with

Watervliet Arsenal Public Works assistance

3.1.2 New Works

a. Prepare the transformer for removal. Disconnect the high and low sides of the transformer, along with any conduits physically attached.

b. Dismantle the surrounding fence, if required.

c. Pull out the transformer and set it on an Arsenal flatbed for our disposal.

d. Set the new transformer in place.

e. Tie in the low and high sides.

f. Test the secondary voltage of the transformer and adjust if necessary to obtain 208Volts.

g. Test the phasing and change primary connections if necessary.

h. Submit transformer specs, tests.

3.1.3 Installation

a. Electrical installation shall conform to IEEE C2, NFPA 70, and to the requirements specified herein.

Provide new equipment and materials unless indicated or specified otherwise.

b. Grounding NFPA 70 and IEEE C2, except that grounding systems shall have a resistance to solid earth not exceeding 5 ohms.

c. Warning Sign mounting provide the number required to be readable from each accessible side.

d. Sealing when the installation is complete, the contractor shall seal all entries into the equipment enclosure with an approved sealing method.

3.2 CLOSEOUT REQUIREMENTS

3.2.1 Construction and Demolition Debris

a. The Contractor shall submit copies of all Bills of Lading and Weight Slips associated with the disposal of construction and demolition (C&D) debris under this scope of work. Submit documentation to project COR.

3.2.2 Cleanup of Work Site

a. The contactor shall clean all work areas and remove all tools, equipment, debris, materials, and all waste from the premises.

b. The contractor shall remove all debris from any remote holding locations, to include any excavation and concrete equipment chute cleanout debris.

c. The contractor shall remove their equipment from Watervliet Arsenal premises within five (5) working days after completion of project work.

3.2.3 Restoration of Work Site

a. The contractor shall repair any items, building surfaces, equipment or miscellaneous items which were damaged during the execution of this SOW. Items that cannot be repaired to restore original function or aesthetics shall be replaced in kind by the Contractor at no additional charge to the Government.

b. Grass, trees, and other vegetation affected by project work shall be restored to same or better condition as existed prior to the start of project work. The Contractor shall prepare the affected areas to eliminate uneven areas and low spots. Remove foreign materials, weeds, and damaged soil. The Contractor shall scratch the area to a depth of three (3) inches where topsoil is to be placed. Spread topsoil to a uniform, compacted depth of less than five (5) inches over areas to be reseeded. Rake until smooth. The Contractor shall seed, fertilizer, and water the area to establish grass.

3.2.4 Warranty

a. The contractor shall provide a [1] year warranty on the following equipment/systems.

i. 300KVA Transformer

3.2.5 As-Built Drawings

a. The contractor shall provide as-built drawings for the following.

i. Pad Mounted Transformer drawings

ii. Test Reports

iii. Certificates

iv. Manufacture’s Field Reports

v. Operation and Maintenance Data

3.2.6 Operation and Maintenance Manuals

a. The contractor shall provide four (4) hard copies of full operations and maintenance manuals, as well as digital files, to the project COR for the following equipment/systems.

i. 300KVA Transformer 480/ 208V.

3.2.7 Training

a. If required, the contractor shall provide #6 hours of on-site training for up to ten (10) government employees for the following equipment/systems.

i. 300KVA Transformer 480/ 208V.

PART 4 APPENDICES

a. Consolidated List of Submittals

b. Quality Assurance Surveillance Plan (QASP)

APPENDIX A: Consolidated List of Submittals Line Item Submitted Submittal Needed By Submittal Reviewed By (Office)

1 Safety Data Sheets for Hazardous Materials

(SDS)

NLT 7 Calendar Days After Award

Safety Office

2 Signed Lockout/Tag out (LOTO) Notification Acknowledgement Record

NLT 7 Calendar Days After Award

Safety Office

3 Project Schedule NLT 7 Calendar Days After Award

COR (CPT Stephens)

4 Contractor Safety Plan NLT 7 Calendar Days After Award

COR (CPT Stephens)

5 Material Safety Sheets NLT 7 Calendar Days After Award

COR (CPT Stephens)

6 Specs and tests NLT 7 Calendar Days After Award

COR (CPT Stephens)

APPENDIX B: Quality Assurance Surveillance Plan (QASP)

PURPOSE

This Quality Assurance Surveillance Plan (QASP) will be used as a guide to Government Quality Assurance Personnel (QAP). It provides a systematic method to evaluate the services the contractor is required to furnish.

SURVEILLANCE PROCEDURES

Timeliness: Progress is maintained to assure compliance with completion time.

Quality: Conformance with statement of work and industry standards.

Tasks: Performed according to statement of work requirements.

Problem Resolution: Contractor submits deliverables in accordance with the contract and resolves any deficiencies identified by the government in the final submission. Following final submission, contractor resolves any additional deficiencies identified by the government and resubmits and or corrects within one week.

Delivery: Contractor submits each deliverable in accordance with the statement of work and terms of the contract.

PERFORMANCE AREAS

Management Responsiveness: Evaluate the adequacy of the contractor’s responsiveness and their ability to keep the government informed of work progress and provides for early problem identification and effective corrective action plans.

Schedule Control: Evaluate the contractor’s adherence to completion schedule.

Performance: The contractor will be evaluated as to the workmanship and adherence to the statement of work.

EVALUATION CRITERIA

(Outstanding). Indicates performance clearly exceeds contractual requirements. The area of evaluation contains few minor problems for which corrective actions appear highly effective.

(Satisfactory). Indicates performance clearly meets contractual requirements. The area of evaluation contains some minor problems for which the corrective actions appear satisfactory.

(Unsatisfactory). Indicates the contractor failed to satisfy contractual requirements and recovery is not likely in a timely manner. The area of evaluation contains serious problems for which the corrective actions were ineffective.

DOCUMENTATION

Documentation used to perform surveillance will consist of random government inspections and inspection records, as well as the evaluation of final work product delivery by the project COR/COTR.

RATING

Contractor will be given an overall rating of Outstanding, Satisfactory, or Unsatisfactory by the Government Technical point of contact or Contracting Specialist Representative, if appointed, 3 using the above evaluation criteria.

52.0000-4200 NOTICE OF WATERVLIET ARSENAL INFORMATION/REQUIREMENTS (Dec 2014) (ACC-

WRN(WVA)):

IMPORTANT DELIVERY/QUALITY REQUIREMENTS:

ALL OFFERORS MUST CAREFULLY REVIEW THE DELIVERY REQUIREMENT IN THE REQUEST

FOR QUOTE OR SOLICITATION. WHEN SUBMITTING AN OFFER/BID, PLEASE ENSURE THAT

YOU CAN MEET THE DELIVERY SCHEDULE.

ON TIME DELIVERY IS VERY CRITICAL. THEREFORE, YOU MUST ADHERE TO THE DELIVERY

REQUIREMENTS INDICATED IN ANY RESULTANT AWARD. FAILURE TO COMPLY WITH THE

CONTRACTUAL DELIVERY SCHEDULE, MAY RESULT IN TERMINATION OF THE ORDER OR

REQUIRE CONSIDERATION IF THE GOVERNMENT ELECTS TO EXTEND DELIVERY. (NOTE:

Non-availability of raw materials, subcontractor issues, scheduling conflicts, should be considered at the time you are submitting your offer/bid. They are not acceptable excuses for failing to meet the delivery after award).

PROVIDING QUALITY PRODUCTS THAT CONFORM TO THE CONTRACT ARE JUST AS

IMPORTANT AS MEETING THE REQUIRED DELIVERY. DELIVERY OF NON-CONFORMING

PRODUCTS RESULTS IN DELIVERY DELAYS AND INCREASED COSTS TO THE ARSENAL.

PAST PERFORMANCE FOR QUALITY AND DELIVERY MAY BE A MAJOR CONSIDERATION IN

MAKING DETERMINATIONS FOR FUTURE CONTRACT AWARDS.

NOTICE: Throughout this document we may use the terms “we” and “you”, the term “we” means the government of the United States of America, and the term “you” means the contractor.

WATERVLIET ARSENAL INFORMATION FOR CONTRACTORS:

“Watervliet Arsenal Information for Contractors” document is incorporated by reference in all solicitations and contracts. The full text version of the instructions is available at Internet address:

http://www.wva.army.mil/Documents/Contracting/WAIC.pdf Upon request, the contracting officer will make its full text available.”

POC - CONTRACT SPECIALIST/BUYER: Ron Ascher

TELEPHONE NUMBER: 518-266-4643

E-MAIL ADDRESS: ronald.a.ascher.civ@mail.mil

CONTRACTOR DUNS NUMBER/CAGE CODE/FAX NUMBER:

Please provide the following information for your company.

VENDOR NAME: _________________________

VENDOR POC: __________________________

POC PHONE: ____________________________

E-MAIL ADDRESS (see note below): __________________________

DUNS NUMBER _______________________

CAGE CODE (if known) __________________

TAX ID NUMBER ________________________

VENDOR FAX NUMBER ________________

NOTE: Your e-mail address is required so that in the event you receive the resultant award, we can e-mail it to you.

If we experience difficulties with e-mail, it will be datafaxed.

AWCF BULK FUND X DOES ____ DOES NOT APPLY

POSTERS:

Walsh-Healey Act/Service Contract Act. Orders subject to these Acts require contractors to post WH Publication 1313, “Employee Rights on Government Contracts”.

Construction Orders. Orders for construction require contractors to post WH Publication 1321, “Employee Rights under the Davis Bacon Act” and the Office of Federal Contract Compliance poster on “Equal Employment Opportunity is the Law.”

These posters can be accessed electronically at http://www.dol.gov .

Hard copies of the posters will be made available upon request to the contracting officer.

PAYMENTS:

Any vendor that receives an award (except those paid by credit card or accommodation check) can view invoice payments made by DFAS at https://wawf.eb.mil/ using the “my invoice” system. You will be required to register in order to view payments. Payment information is maintained for 120 days from invoice payment. Vendors can find out when invoices have been paid by Electronic Funds Transfer (EFT), etc. This website can save valuable time and frustration over billing questions and it is a free service.

RELEASE OF INFORMATION:

The contractor shall not release or authorize release of DoD specifications; acceptance test results; information involving critical military technology; or any other information in which the DoD maintains proprietary rights, or is otherwise confidential or classified. This restriction includes any endorsement by the Department of Army of a contractor. Release of information under the circumstances referenced above requires the prior written approval of the Contracting Officer responsible for this contract. It is the contractor’s responsibility to be familiar with, and comply with the requirements of Chapter 5, page 22, paragraph 5-48, of AR 360-1 may be found at http://www.apd.army.mil/pdffiles/r360_1.pdf

(END OF CLAUSE)

52.0000-4201 SERVICES/CONSTRUCTION REQUIREMENTS (Jan 2017) (ACC-WRN(WVA)):

SCHEDULE UNIT OF MEASURE NOTE: When "LOT" is stated as a unit of measure it is the equivalent to

"JOB".

WORK PERFORMED ON-SITE AT WATERVLIET ARSENAL:

The contractor agrees that each employee working at Watervliet Arsenal will sign the “Contractor Personnel Agreement on Non-Disclosure of Watervliet Arsenal Technology below. Signatures must be received by the Contract Administrator before work may begin and any resultant delay won’t be considered an excusable delay to contract performance as defined in the contract clause “Default”. Additional copies of this Non-Disclosure Statement can be found on the Internet at http://www.wva.army.mil/Documents/Contracting/nondis.pdf

CONTRACTOR PERSONNEL AGREEMENT ON NON-DISCLOSURE

OF WATERVLIET ARSENAL TECHNOLOGY

1. The Undersigned, as an employee of _________________________ (Name of Firm) agrees to the following terms and conditions.

2. Any knowledge gained, as a result of my being permitted on Watervliet Arsenal’s premises, concerning cannon production technology (as defined below) or other technology on any defense item being manufactured or developed at Watervliet Arsenal, will not be released outside of _________________________ (Name of firm) and/or the United States of America (this prohibition includes, but is not limited to, the company’s domestic and foreign subsidiaries, affiliates, etc.), nor will such technology be used to manufacture or assist another in the manufacture of cannon (as described below) or other defense items being manufactured or developed at Watervliet Arsenal, without the written prior approval of Watervliet Arsenal.

3. Definitions:

a. CANNON: is defined as any and all components/parts of a complete assembly consisting of a tube, breech mechanism, tube attachments, muzzle appendages, firing mechanisms, and all integral components. It may also be a component of a weapons system of 40mm Bore or over such as tank guns, towed and self-propelled howitzers, naval guns, mortars and recoilless guns.

b. CANNON PRODUCTION TECHNOLOGY: is defined as the technical data package and manufacturing technology.

(1) TECHNICAL DATA PACKAGE: cannon engineering drawings, specifications and standards.

(2) MANUFACTURING TECHNOLOGY: technical knowledge, documentation, assistance and equipment and machines used an/or useful in the manufacturing of cannon.

(a) TECHNICAL KNOWLEDGE: the know how collected, trade secrets, production experience and special skills necessary for the production of cannon and the technical information and inventions necessary for the manufacture of cannon and relating to the manufacture of cannon.

(b) TECHNICAL DOCUMENTATION: manufacturing technical data comprised of drawings, specifications, schemes, composition, descriptions, methods of calculations, instructions and other information necessary for the manufacture of cannon.

(c) TECHNICAL ASSISTANCE: all assistance required to make practical and economical use of the technology required to manufacture cannon, such as delivery of documentation, training of personnel, instructions, consultations and acquainting of specialists with the most economical method of using this technology in the manufacture of cannon.

(d) EQUIPMENT AND MACHINES: production machines, machine accessories, apparatuses, spare parts and tooling used for cannon manufacture.

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

TYPED OR PRINTED NAME, SIGNATURE DATE

JOB SITE AVAILABILITY:

The work site will be available for performance during normal business hours:

Monday through Thursday Business Hours: 7:00 a.m. EST to 4:00 p.m. EST

Friday Business Hours: Every other Friday from 7:00 a.m. EST to 3:00 p.m. EST

Fridays will be staggered with every other Friday being a closed business day. The first Friday of 2017 to be closed is January 6, 2017.

Based on the above, service contractors should call contract/purchase order administrator in advance if service is scheduled for a Friday to determine if the Arsenal will be open for business.

When a federal holiday is normally observed on Friday, the Arsenal may be closed on the preceding Thursday. In this case, contact the contract/purchase order administrator in advance if scheduling service to determine if the Arsenal will be open for business.

Work at other than the above hours won’t be allowed unless the contractor makes an application at least 48 hours in advance and gets written contracting officer approval. No guarantee is made that the job site will be made available other than as stated above.

CONTROL OF FOREIGN VISITORS TO WATERVLIET ARSENAL:

Offerors are advised that any employee or representative of their company who is not a U.S. citizen, (or is representing a foreign company) and is a U.S. citizen), planning on visiting the Watervliet Arsenal for the purpose of attending: bid conferences, bid openings, site visits, engineering services, or any other visit related to this solicitation will be escorted at all times by an arsenal representative while on the installation grounds.

Therefore, offerors must notify the Contracting Officer in advance (a minimum of two [2] weeks) of any proposed visit by a non-U.S. citizen or U.S. citizen representing a foreign firm, to assure proper clearance for entry into the arsenal. Failure to comply, or disclose a foreign national visitor, may subject the Contractor to the penalties set forth in 18 U.S.C.A. Section 1001, Chapter 14.

Due to manpower constraints, Watervliet Arsenal is often unable to provide escort services during contract performance. Therefore, if the resulting contract requires performance on Watervliet Arsenal property, employees, individuals or subcontractors representing the successful offeror who are not U.S. citizens may not, depending on staffing levels and the availability of escorts, be allowed access to the Arsenal for purpose of contract performance.

Be further advised that the inability of the Arsenal to provide escorts resulting in denial of access to Watervliet Arsenal of the aforementioned personnel will not be considered an excusable delay to contract performance as defined in the contract clause “Default” contained in the contract. Therefore, offerors should consider the above contingencies during offer preparation.

CONTRACTOR IDENTIFICATION:

Contractor employees shall identify themselves as contractor personnel by introducing themselves or being introduced as contractor personnel and displaying distinguishing badges or other visible identification for meetings with Government personnel. In addition, contractor personnel shall appropriately identify themselves as contractor employees in telephone conversations and in formal and informal written correspondence, and when working in situations where their actions could be construed as official government acts.

(END OF NOTICE)

Section C - Descriptions and Specifications

52.0000-4020 ACCESS AND GENERAL PROTECTION/SECURITY POLICY AND PROCEDURES (MAR

2015) (ACC-WRN)

a. The contractor and all associated subcontractors’ employees shall comply with applicable installation, facility, and area commander installation and facility access and local security policies and procedures (provided by the Government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by the installation Provost Marshal Office, Director of Emergency Services, or Security Office. The contractor workforce must comply with all personal identity verification requirements (FAR clause 52.204-9 “Personal Identity Verification of Contractor Personnel”) as directed by DoD, HQDA, and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

b. For contractors requiring Common Access Card (CAC). Before CAC issuance, the contractor employee requires, at a minimum, a favorably adjudicated National Agency Check with Inquiries (NACI) or an equivalent or higher investigation in accordance with Army Directive 2014-05, The contractor employee will be issued a CAC only if duties involve one of the following: (1) Both physical access to a DoD facility and access, via logon, to DoD networks on-site or remotely; (2) Remote access, via logon, to a DoD network using DoD-approved remote access procedures; or (3) Physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of six (6) months or more. At the discretion of the sponsoring activity, an initial CAC may be issued on a favorable review of the FBI fingerprint check and a successfully scheduled NACI at the Office of Personal Management (see clause 52.204-4959 “Trusted Associate Sponsorship System (TASS) Program” (Local ACC-WRN (WVA)).

c. For contractors that do not require CAC, but require access to a DoD facility or installation. Contractor and all associated sub-contractors employees shall comply with adjudication standards, and procedures using the National Crime Information Center Interstate Identification Index (NCIC-III) and Terrorist Screening Database (TSDB) (Army Directive 2014-05/AR 190-13), applicable installation, facility and area commander installation/facility access and local security policies and procedures (see “Watervliet Arsenal (WVA) Information For Contractors” incorporated by reference in ACC-WRN (WVA) notice 52.0000-4200, “Notice of Watervliet Arsenal Information/Requirements” and available at: http://www.wva.army.mil/Documents/Contracting/WAIC.pdf ) or at OCONUS locations, in accordance with Status of Forces Agreement and other theater regulations.

(End of Clause)

52.0000-4970 Scope of Work/Submission of Recordable Injuries and Illness Cases (Dec 2012) (ACC-WRN

(WVA))

Watervliet Arsenal is pursuing OSHA Voluntary Protection Program (VPP) recognition. The VPP impacts all contractors whose employees cummulatively work more than 1000 hours per quarter within a calendar year at Watervliet Arsenal (herein referred to as “applicable contractors”).

It is the contractor’s responsibility to ensure its employees and managers are in full compliance with OSHA requirements and have a general understanding of VPP. Detailed information on VPP is available on the OSHA website at http://www.osha.gov/dcsp/vpp/index.html . All contractors, whether regularly involved in routine site operations or engaged in temporary projects such as construction or repair, must follow the safety and health rules of Watervliet Arsenal.

Applicable contractors are required to annually submit to Watervliet Arsenal, ATTN: TAWV-XO-S/Safety Office, Bldg. 10, 1 Buffington Street, Watervliet, NY 12189-4000 or email: usarmy.watervliet.tacom.list.wate-safety@mail.mil the following documents (covering the previous calendar year quarters) by 15 January:

‐ Total Case Incidence Rate (TCIR) - the number of recordable injuries and illness cases per 100 full-time employees that a site has experienced in a given time frame.

‐ Days Away, Restricted, and/or Transfer Case Incident Rate (DART) - Number of recordable injuries and illness cases per 100 full-time employees resulting in days away from work, restricted work activity, and/or job transfer that a site has experienced in a given time frame.

‐ OSHA Form 300A

Applicable contractors may submit the above immediately following the completion of a quarter, if desired.

(End of Scope of Work)

Section G - Contract Administration Data

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Payment Invoice

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

Not Applicable

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0303 Issue By DoDAAC W911PT Admin DoDAAC W911PT Inspect By DoDAAC N/A Ship To Code N/A Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) N/A Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s)

CONTRACTING OFFICER W911PT

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

N/A

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

N/A

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

Section H - Special Contract Requirements

H2 INSURANCE (Fixed Price Contract)

Pursuant to the requirements of the contract clause titled “Insurance-Work on a Government installation,” the contractor shall obtain and maintain at least the following kinds of insurance and minimum liability coverage during any period of contract performance.

a. Workmen’s Compensation and occupational disease coverage as required by law except that, if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workmen’s Compensation Insurance shall extend to cover employers’ liability for accidental bodily injury or death and for occupational disease with a minimum liability limit of $100,000.

b. Comprehensive General Liability Insurance in the minimum limit of $500,000 per occurrence for bodily injury liability.

c. Comphrensive Automotive Liability Insurance with minimum limits of $200,000 per person and $500,000 per occurrence for bodily injury, and a minimum limit of $20,000 per occurrence for property damage.

(end of clause)

FAR 52.228-5, INSURANCE- WORK ON A GOVERNMENT INSTALLATION (JAN 1997) is hereby incorporated by reference as a result of inclusion of H2 INSURANCE.

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016 52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-9 Buy American--Construction Materials MAY 2014 52.225-10 Notice of Buy American Requirement--Construction

Materials

MAY 2014

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-1 Contractor Inspection Requirements APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7008 Compliance With Safeguarding Covered Defense Information Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.223-7006 Alt I Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials - Alternate I

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7002 Qualifying Country Sources As Subcontractors DEC 2016 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

52.0000-4210 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS FAR 52.232-27 NOTICE (SEP

2005) (ACC-WRN(WVA))

As authorized by FAR 32.908(b) para. (a)(1)(i)(A) and (a)(4)(i) the timeframes in clause 52.232-27 are changed as follows:

(a)(1)(i)(A), ....the due date for making payments shall be 21 days after the designated billing office receives a proper payment request. If the designated billing office fails to annotate the payment request with the actual date of receipt at the time of receipt, the payment due date shall be the 21st day after the date of the contractor's payment request, provided the designated billing office receives a proper payment request is received and there is no disagreement over quantity, quality, or contractor compliance with contract requirements.

(a)(4)(i), ....government acceptance or approval is deemed to occur constructively on the 30th day after the contractor has completed the work or services in accordance with the terms and conditions of the contract.

END OF NOTICE

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC

2014)

The Contractor's representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within seven (7) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 60 calendar days. The time stated for completion shall include final cleanup of the premises.

52.213-4 TERMS AND CONDITIONS--SIMPLIFIED ACQUISITIONS (OTHER THAN COMMERCIAL

ITEMS) (JAN 2017).

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses that are ncorporated by reference:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L.

113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(ii) 52.222-3, Convict Labor (JUN 2003) (E.O. 11755).

(iii) 52.222-21, Prohibition of Segregated Facilities (APR 2015).

(iv) 52.222-26, Equal Opportunity (SEPT 2016) (E.O. 11246).

(v) 52.225-13, Restrictions on Certain Foreign Purchases (JUN 2008) (E.O.s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(vi) 52.233-3, Protest After Award (AUG 1996) (31 U.S.C. 3553).

(vii) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Pub. L. 108-77, 108-78 (19 U.S.C. 3805 note).

(2) Listed below are additional clauses that apply:

(i) 52.232-1, Payments (APR 1984).

(ii) 52.232-8, Discounts for Prompt Payment (FEB 2002).

(iii) 52.232-11, Extras (APR 1984).

(iv) 52.232-25, Prompt Payment (JAN 2017).

(v) 52.232-39, Unenforceability of Unauthorized Obligations (JUN 2013).

(vi) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (DEC 2013).

(vii) 52.233-1, Disputes (MAY 2014).

(viii) 52.244-6, Subcontracts for Commercial Items (JAN 2017).

(ix) 52.222-55, Minimum Wages Under Executive Order 13658 (MAR 2016) (Applies when 52.222-6 or 52.222-41 are in the contract and performance in whole or in part is in the United States (the 50 States and the District of Columbia)).

(b) The Contractor shall comply with the following FAR clauses, incorporated by reference, unless the circumstances do not apply:

(1) The clauses listed below implement provisions of law or Executive order:

(i) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016) (Pub. L. 109-282) (31 U.S.C. 6101 note) (Applies to contracts valued at $30,000 or more).

(ii) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016) (E.O. 13126). (Applies to contracts for supplies exceeding the micro-purchase threshold).

(iii) 52.222-20, Contracts for Materials, Supplies, Articles, and Equipment Exceeding $15,000 (MAY 2014) (41 U.S.C. chapter 65) (Applies to supply contracts over $15,000 in the United States, Puerto Rico, or the U.S. Virgin Islands).

(iv) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212) (applies to contracts of $150,000 or more).

(v) 52.222-36, Equal Employment for Workers with Disabilities (JUL 2014) (29 U.S.C. 793) (Applies to contracts over $15,000, unless the work is to be performed outside the United…