SOLICITATION W912BV22Q0082.pdf

SEE ADDENDUM

(No Collect Calls)

W912BV22Q0082 26-Aug-2022

b. TELEPHONE NUMBER

918.669.4392

8. OFFER DUE DATE/LOCAL TIME

05:00 PM 23 Sep 2022

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

W912BV9. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

JEREME A KEMP

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

0 27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

CONTRACTING DIV

US ARMY CORPS OF ENGINEERS, TULSA DISTRICT

2488 E. 81ST STREET

TULSA OK 74137-4290

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

918-669-7436FAX:

TEL: SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

NAICS:

332312

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF57

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

W912BV22Q0082

Section A - Solicitation/Contract Form

INSTRUCTION TO OFFERORS

INSTRUCTIONS TO OFFERORS

STOP-LOG AND LIFTING BEAM PROCUREMENT

OOLOGAH DAM AND RESERVOIR

SOLICITATION NUMBER: W912BV22Q0082

Read the solicitation in its entirety and all amendments before submitting documents. Payments will be made after receipt of a proper invoice and receipt of acceptable supplies or services. Regular office hours: Monday to Friday, 8:00 a.m. to 4:30 p.m. CST

GENERAL INSTRUCTIONS

GOVERNMENT SECURITY REQUIREMENTS

The offeror must ensure that all mail sent to the Tulsa district, U.S. army corps of engineers, either precontract or post-contract award, has a return mailing address on the outside of the envelope, package, box, etc. Any mail addressed to the U.S. Army Corps of Engineers, including but not limited to bids, modifications to bids, proposals, revised proposals, bonds, correspondence, etc., will be rejected by the U.S. Army Corps of Engineers mail room facility located at 2488 E. 81st street, Tulsa, OK 74137-4290, if it does not contain a return mailing address. There will be no exceptions.

PROPOSAL SUBMITTALS

Request for Quote (RFQ) documents shall be submitted through the Solicitation Module of the Procurement Integrated Enterprise Environment (PIEE) suite at https://piee.eb.mil/ . quotes submitted by mail or hand carried will not be evaluated. Proposals sent through proprietary or third-party File Transfer Protocol (FTP) sites or DoD SAFE will not be retrieved. It is the responsibility of the Offeror to confirm receipt of Solicitation. All quotes received after the exact time specified for receipt shall be treated as late submissions and will not be considered except under facts and circumstances allowed by the Federal Acquisition Regulation (FAR).

There are 10 general steps a vendor must follow in order to use PIEE application modules. A complete list can be viewed at the following site:

https://piee.eb.mil/xhtml/unauth/web/homepage/vendorGettingStartedHelp.xhtml#step5

For instructions on how to post an offer, please refer to the Posting Offer demo:

https://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf.

It is the Offeror’s responsibility to obtain written confirmation of receipt of all electronic files of the full proposal by the Tulsa District Contracting office. In the event the Solicitation Module is down, the alternate method for proposal submission is via email to: Jereme.a.kemp@usace.army.mil and Wyman.W.Walker@usace.army.mil

ONLY.

The Offeror must obtain prior approval from the Contracting Officer to use the alternate submission method.

Offerors are responsible for ensuring electronic copies are virus-free and shall run an anti-virus scan before submission.

Electronic copies of RFQ documents shall be compatible with the following software products: Adobe Acrobat Reader 11 and Microsoft Office Suite 2016. Narrative portions of the proposal shall be in Adobe Acrobat portable document file (pdf) searchable text format. The Offeror shall not embed sound or video (e.g., MPEG) files into the files. Electronic files shall be clearly identified for each item submitted for Evaluation Criteria.

All offers shall be submitted to Mr. Jereme Kemp copying Mr. Wyman Walker via email. Offers shall not be submitted to any other Government Official. Proposals received after the due date/time shall be considered “late” and will be handled in accordance with FAR 52.212-1(f), Instructions to Offerors—Commercial Products and Commercial Services (NOV 2021). If an offeror wishes to receive a separate delivery receipt the request should be emailed to the Government Officials listed below.

Jereme A. Kemp contact information:

Jereme.a.kemp@usace.army.mil

Tel: 918-669-4392

Wyman W. Walker contact information:

Wyman.W.Walker@usace.army.mil

Tel: 918-669-7043

Solicitation Closing Date: Please referrence block 8 of the SF 1449

Offerors are responsible for including sufficient details to permit a complete and accurate evaluation of each Evaluation Criteria. Proprietary information shall be clearly marked.

This procurement is being conducted in accordance with Simplified Acquisition Procedures (SAP) of FAR Parts 12 and 13. Any reference to offers or bids or offerors or bidders should be substituted with quotations or quoters. All reference to discussions shall not be interpreted under FAR Part 15, but rather indicate that the Government may communicate with offerors/quoters as allowed under simplified acquisition procedures.

Submit the following documents:

1. Complete a signed copy of the first page of the solicitation and all amendments, including CAGE code/DUNS number.

2. Complete the pricing schedule provided in section C SECTION 00 11 00 PRICING SCHEDULE

3. The Offeror shall provide a summary project management plan that shows key milestones dates and demonstrates an understanding of the overall contract duration. Gantt charts are appropriate for this submission. 5 page maximum.

4. The Offeror shall provide a copy of the certificate demonstrating AISC (American Institute of Steel Construction) Quality Certification Program and current designation as an AISC Certified Plant, Category IBR (Intermediate Steel Bridge), or Category ABR (Advanced Steel Bridge), or Category HYD (Hydraulic Steel Structure), and a copy of the Fracture Control Endorsement (FCE).

5. The Offeror shall submit a resume for the CQC System Manager which demonstrates a minimum of 2-years' experience scheduling fabrication projects similar in size and nature to this project. 2 Page Maximum.

6. Offeror shall provide a minimum (3) three examples of previously developed, created, and maintained projects similar in nature and complexity to the project, detailing scope, name, contract amount, and location of projects with scheduling software that meets the requirements of this specification. Please utilize and submit Attachment L-1 PAST PERFORMANCE QUESTIONNAIRE for each project. 10 Page Maximum.

7. Offeror shall provide the country of origin.

8. Complete all FAR Clauses with applicable blanks filled in from SECTIONS I, K, L, and M (If responses are filled out in SAM then indicate by marking “SEE SAM”)

9. Contractor must respond to the representation in Section K: FAR 52.204-24 and 52.204-26. Failure to respond to these provisions will deem your offer non-responsive and unawardable.

INQUIRIES – OFFEROR’S QUESTIONS AND COMMENTS

USE OF BIDDER’S INQUIRY

Prospective offerors shall submit questions and inquiries related to this solicitation in accordance with the following (no other means of questions or inquiries will be answered except through Bidder Inquiry):

For information related to amendments, and the dates set for receipt of proposals, please check Solicitation Module of the Procurement Integrated Enterprise Environment (PIEE) suite at https://piee.eb.mil/ and/or https://sam.gov

Contractual and Technical inquiries and questions relating to proposal procedures are to be submitted via Bidder Inquiry in ProjNet at https://www.projnet.org/projnet

To submit and review bid inquiry items, offerors will need to be a current registered user or self‐register into the system. To self‐register go to the aforementioned web page and click on the BID tab. Select Bidder Inquiry, select agency USACE, and enter the Bidder Inquiry Key for this solicitation listed below, your e‐mail address, and then click login. Fill in all required information and click create user. Verify that information on next screen is correct and click continue.

From this page, you may view all bidder inquiries or add an inquiry.

Bidders will receive an acknowledgement of their question via e‐mail, followed by an answer to their question after it has been processed.

The Solicitation Number is: W912BV22Q0082

The Bidder Inquiry Key is: CCPYGP-GRJ478

The Bidder Inquiry System will be unavailable for new inquiries after 5:00 PM CST Friday, 16 September 2022 in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation, if necessary.

Offerors are requested to review the specification in its entirety, and review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry.

The call center operates weekdays from 8AM to 5PM U.S. Central Time Zone (Chicago). The telephone number for the Call Center is 800‐428‐HELP.

Offers will NOT be publicly opened. Information concerning the status of the evaluation and/or award will

NOT be available after receipt of proposals.

The point of contact for this solicitation is:

Contract Specialist: Jereme A. Kemp Telephone: 918‐669‐4392

E‐mail: Jereme.a.kemp@usace.army.mil

PREPROPOSAL/SITE VISIT CONFERENCE

A site visit will not be held.

ANTITERRORISM AND OPERATIONS SECURITY REQUIREMENTS

See section H.

As outlined in AFARS 5132.702(a)(ii)(B), “Funds are not presently available for this acquisition. No contract award will be made until appropriated funds are made available.”

Section B - Supplies or Services and Prices

PRICE SCHEDULING

PLEASE SEE ATTACHMENT C

SECTION 00 11 00 PRICING SCHEDULE

SECTION 01 20 00.00 47 PRICE AND PAYMENT PROCEDURES

Section C - Descriptions and Specifications

PERFORMANCE WORK STATEMENT

PLEASE REFERENCE ATTACHMENT: SECTION C

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE

PLEASE REFERRENCE STATEMENT OF WORK ATTACHMENT

SECTION 01 33 00.00 47 SUBMITTAL PROCEDURES

SECTION 01 45 00.00 47 QUALITY CONTROL

SECTION 05 05 23.13 10 ULTRASONIC INSPECTION OF WELDMENTS

SECTION 09 97 02 PAINTING: HYDRAULIC STRUCTURES

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996 52.246-16 Responsibility For Supplies APR 1984

Section F - Deliveries or Performance

DELIVERY LOCATION

Oologah Lake Project Office U.S. Army Corps of Engineers 8400 E. Hwy 88 Oologah, OK 74053

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

52.211-17 Delivery of Excess Quantities SEP 1989 52.242-15 Stop-Work Order AUG 1989 52.242-17 Government Delay Of Work APR 1984 52.247-34 F.O.B. Destination NOV 1991 52.247-48 F.O.B. Destination--Evidence Of Shipment FEB 1999 52.247-58 Loading, Blocking, And Bracing Of Freight Car Shipment APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.211-8 TIME OF DELIVERY (JUN 1997)

(a) The Government requires delivery to be made according to the following schedule:

REQUIRED DELIVERY SCHEDULE

275 DAYS AFTER RECIEPT OF AWARD NOTICE

Item No. Quantity of Contract

PLEASE SEE ATTACHED DELIVERY SCHEDULE

The Government will evaluate equally, as regards time of delivery, offers that propose delivery of each quantity within the applicable delivery period specified above. Offers that propose delivery that will not clearly fall within the applicable required delivery period specified above, will be considered nonresponsive and rejected. The Government reserves the right to award under either the required delivery schedule or the proposed delivery schedule, when an offeror offers an earlier delivery schedule than required above. If the offeror proposes no other delivery schedule, the required delivery schedule above will apply.

OFFEROR'S PROPOSED DELIVERY SCHEDULE

Within Days

After Date

Item No. Quantity of Contract

(b) Attention is directed to the Contract Award provision of the solicitation that provides that a written award or acceptance of offer mailed, or otherwise furnished to the successful offeror, results in a binding contract. The Government will mail or otherwise furnish to the offeror an award or notice of award not later than the day award is dated. Therefore, the offeror should compute the time available for performance beginning with the actual date of award, rather than the date the written notice of award is received from the Contracting Officer through the ordinary mails. However, the Government will evaluate an offer that proposes delivery based on the Contractor's date of receipt of the contract or notice of award by adding (1) five calendar days for delivery of the award through the ordinary mails, or (2) one working day if the solicitation states that the contract or notice of award will be transmitted electronically. (The term "working day" excludes weekends and U.S. Federal holidays.) If, as so computed, the offered delivery date is later than the required delivery date, the offer will be considered nonresponsive and rejected.

(End of clause)

Section G - Contract Administration Data

252.204-7006 Billing Instructions OCT 2005 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

(a) "Definition. Contracting officer's representative" means an individual designated in accordance with subsection 201.602-2 of the Defense Federal Acquisition Regulation Supplement and authorized in writing by the contracting officer to perform specific technical or administrative functions.

(b) If the Contracting Officer designates a contracting officer's representative (COR), the Contractor will receive a copy of the written designation. It will specify the extent of the COR's authority to act on behalf of the contracting officer. The COR is not authorized to make any commitments or changes that will affect price, quality, quantity, delivery, or any other term or condition of the contract.

Section H - Special Contract Requirements

ANTITERRORISM/OPERATIONS SECURITY REQUIREMENTS, MAY 2022

The Contractor shall comply with the following requirements marked with an “X”.

1. General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative (e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations. facilities and activities. and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract.

should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

X 2. Antiterrorism (AT) Level I training: All contract personnel requiring routine access to Army installations, facilities. and controlled access areas, or requiring network access shall complete initial and annual refresher AT Level I awareness training. Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

3. Physical security and access control requirements: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location.

Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as "NCIC-I11") and Terrorist Screening Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys. access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

4. Contract personnel requiring a common access card (CAC): Contract personnel will be issued a common access card (CAC) only if duties involve one of the following: (1) both physical access to a DoD facility and access to DoD information systems or networks; (2) remote access to a DoD information system or network using DoD-approved remote access procedures; or (3) physical access to multiple DoD facilities or multiple non-DoD federally controlled facilities on behalf of the DoD on a recurring basis for a period of 6 months or more. Before CAC issuance, contract personnel must have, at a minimum, a favorably adjudicated Tier 1 investigation or an equivalent or higher investigation in accordance with applicable Army regulations and Homeland Security Presidential Directive-12 (HSPD- 12). At the discretion of the RA, an initial CAC may be issued based on a favorable review of a fingerprint check and a successfully scheduled Tier 1 investigation with the National Background Investigations Bureau. The RA provides contract personnel with additional information and forms to initiate the CAC issuance process, and/or to initiate background investigations, when required. Contract personnel shall complete these processes within established timelines to avoid delays.

5. Security requirements for contract performance outside the U.S.: For contract performance requirements that involve services or delivery in a foreign country, the Contractor shall comply with the requirements of DFARS clause 252.225-7043. For performance requirements that involve contract personnel accompanying or supporting US Armed Forces deployed outside the US, the Contractor shall comply with the requirements of DFARS clause 252.225-7040. Contract personnel accessing DoD or other federal facilities outside the US shall comply with applicable Status of Forces Agreements and Geographic Combatant Command requirements. Prior to contract personnel traveling outside the US, the Contractor shall provide documentation of AT, OPSEC, and other required training to the Government representative. Additionally, contract personnel shall comply with requirements specified in the DoD Foreign Clearance Guide, including country and theater clearance processes.

6. Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something): All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

7. Contract personnel requiring access to Government information systems: All contract personnel with access to a government information system (including USACE business systems and CAC-enabled websites) shall comply with applicable DoD and Army regulations, and shall use the organization's User ID-Password Administration and Security System (U-PASS) at commencement of services to request network user accounts. Contract personnel shall complete DoD Information Assurance Awareness training prior to accessing information systems. and annually thereafter.

8. Contracts requiring a formal OPS EC program: The Contractor shall develop an OPSEC SOP/Plan within 90 days of contract award. The OPSEC SOP/Plan shall be reviewed and accepted by the RA OPSEC Officer. This plan will include a process to identify critical information, where it is located, who is responsible for it, how to protect it, and why it needs to be protected. In accordance with Army and DoD regulations, the contractor shall have a certified Level II OPSEC coordinator, who shall ensure OPSEC compliance during contract performance.

9. Training requirements for the protection of sensitive information: All contract personnel with access to critical information (as identified in the RA's OPS EC Program) shall complete initial and annual refresher OPS EC Level I Awareness training, which is available at the following websites:

https://www.iad.gov/ioss/, or http://www.cdse.edu/catalog/operations-security.html (websites subject to change). All contract personnel with access to Controlled Unclassified Information (CUI) shall complete initial and annual refresher CUI training in accordance with applicable Army policy.

10. Information Assurance (IA)/lnformation Technology (IT) requirements: All contract personnel performing IA/IT services must comply with DoD training and certification requirements specified in DoD 8570.01-M, Information Assurance Workforce Improvement Program, and maintain required background investigations specified in RA policy. Contract personnel shall provide the Government representative with documentation of certification(s) prior to performing on the contract. In accordance with applicable DoD. Army, and USACE regulations, the Contractor shall ensure that all information systems (IS) and platform information technology (PIT) systems developed and/or supported under this contract comply with cybersecurity and architectural requirements, including, but not limited to: security technical implementation guides (STIG)(e.g., the current version of the Application Security and Development STIG, and the internet access point (IAP) demilitarized zone (DMZ) STIG), and the use of security controls developed under the risk management framework documentation for the system or platform. The Contractor shall address questions regarding these provisions to the Government representative. who will coordinate between the Contractor and the USACE Chief Information Officer

(CIO).

11. Contracts requiring handling or access to classified information: The prime Contractor shall have a Facility Clearance (FCL) at the appropriate level prior to performance on the contract; the RA will sponsor the prime contract company in obtaining the FCL. All cleared contract personnel shall comply with the FCL requirements, as well as applicable laws and regulations regarding contractor access to national security information. For classified contracts, the RA will generate the DD Form 254, which will be attached to the contract.

12. Threat Awareness Reporting Program: All contract personnel who maintain an active security clearance shall receive initial and annual refresher training on the Threat Awareness and Reporting Program (commonly referred to as "TARP"), provided by a Counterintelligence Agent. As determined by the servicing Counterintelligence Agent for the RA, contract personnel may complete web-based TARP training.

13. Escorting in classified and/or sensitive areas: In accordance with applicable regulations. all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas.

14. Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1 (i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award.

When contracts are with individuals, the individuals will be required to complete a Form 1-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

15. Contracts requiring armed security guards: All contract personnel performing contract security guard duties shall comply with the Individual Reliability Program in accordance with AR 190-56 (The Army Civilian Police and Security Guard Program), as well as applicable installation, facility and area commander installation/facility policies and procedures regarding storing weapons and ammunition in accordance with AR 190-11 (Physical Security of Arms Ammunition, and Explosives).

16. Contracts requiring delivery of food and water: The supplies delivered under this contract shall be transported in delivery conveyances maintained to prevent tampering with and/or adulteration or contamination of the supplies, and if applicable, equipped to maintain a prescribed temperature. All delivery vehicles and storage locations are subject to inspection at any time by the COR, Post Veterinarian, law enforcement officers, or other RA representatives authorized to conduct such inspections. When the sanitary conditions of the delivery conveyance have led, or may lead to product contamination. adulteration, constitute a health hazard. the delivery conveyance is not equipped to maintain prescribed temperatures, or the transport results in product "unfit for intended purpose," supplies tendered for acceptance may be rejected without further inspection. As the holder of a contract with the DoD, the Contractor shall ensure that all products and/or packaging have not been tampered with or contaminated. The Contractor shall ensure all delivery conveyances are always locked or sealed, except when actively loading or unloading. Unsecured vehicles shall not be left unattended. All incoming truck drivers shall provide adequate identification upon request. In the event of an identified threat to a delivery location. or a heightened force protection/Homeland Security threat level, the Contractor may be required to adjust delivery routes to minimize vulnerability risks and enable direct delivery to DoD facilities.

(END)

Section I - Contract Clauses

52.203-3 Gratuities APR 1984 52.203-6 Alt I Restrictions On Subcontractor Sales To The Government

(JUN 2020) -- Alternate I

NOV 2021

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information Systems

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.219-6 Alt I Notice of Total Small Business Set-Aside (NOV 2020) Alternate I

MAR 2020

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

JUN 2020

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

NOV 2021

52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-21 Specifications and Drawings for Construction FEB 1997 52.242-2 Production Progress Reports APR 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

DEC 2019

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services

JAN 2021

252.204-7020 NIST SP 800-171 DoD Assessment Requirements MAR 2022 252.211-7003 Item Unique Identification and Valuation MAR 2022 252.211-7008 Use of Government-Assigned Serial Numbers SEP 2010 252.225-7001 Buy American And Balance Of Payments Program-- Basic JUN 2022 252.225-7010 Commercial Derivative Military Article--Specialty Metals

Compliance Certificate

JUL 2009

252.227-7013 Rights in Technical Data--Noncommercial Items FEB 2014 252.227-7015 Technical Data--Commercial Items FEB 2014 252.227-7016 Rights in Bid or Proposal Information JAN 2011 252.227-7030 Technical Data--Withholding Of Payment MAR 2000 252.227-7037 Validation of Restrictive Markings on Technical Data APR 2022 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012 252.244-7000 Subcontracts for Commercial Items JAN 2021 252.246-7001 Alt II Warranty Of Data (Mar 2014) - Alternate II MAR 2014 252.246-7003 Notification of Potential Safety Issues JUN 2013 252.246-7006 Warranty Tracking of Serialized Items MAR 2016

52.202-1 DEFINITIONS (JUN 2020)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless--

(a) The solicitation, or amended solicitation, provides a different definition;

(b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning;

(d) The word or term is defined in FAR part 31, for use in the cost principles and procedures; or

(e) The word or term defines an acquisition-related threshold, and if the threshold is adjusted for inflation as set forth in FAR 1.109(a), then the changed threshold applies throughout the remaining term of the contract, unless there is a subsequent threshold adjustment; see FAR 1.109(d).

52.211-11 LIQUIDATED DAMAGES--SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of 1,540.00 per calendar day of delay.

(b) If the Government terminates this contract in whole or in part under the Default--Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default--Fixed-Price Supply and Service clause in this contract.

52.212-4 CONTRACT TERMS AND CONDITIONS--COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES (NOV 2021)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at Federal Acquisition Regulation (FAR) 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include--

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer—System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer--Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act (31 U.S.C. 3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.--

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt payment. The Government will make payment in accordance with the Prompt Payment Act (31 U.S.C.

3903) and prompt payment regulations at 5 CFR part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall--

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the--

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C.

7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if--

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on--

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in FAR 32.608-2 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b.

destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government's convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor's records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C.

chapter 87, Kickbacks; 41 U.S.C. 4712 and 10 U.S.C. 2409 relating to whistleblower protections; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) Reserved.

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C.

1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to…