Solicitation - FA820122R0008.pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER PAGE 1 OF

2. CONTRACT NO. 3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER 5. SOLICITATION NUMBER 6. SOLICITATION ISSUE

DATE

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME b. TELEPHONE NUMBER (No collect calls)

8. OFFER DUE DATE/

LOCAL TIME

9. ISSUED BY

13b. RATING

14. METHOD OF SOLICITATION

CODE

15. DELIVER TO 16. ADMINISTERED BY CODE

18a. PAYMENT WILL BE MADE BY CODE17a. CONTRACTOR/

OFFEROR

CODE

FACILITY

CODE

CODE

TELEPHONE NO.

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK

BELOW IS CHECKED

RFQ IFB RFP

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

(Use Reverse and/or Attach Additional Sheets as Necessary)

25. ACCOUNTING AND APPROPRIATION DATA 26. TOTAL AWARD AMOUNT (For Govt. Use Only)

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

29. AWARD OF CONTRACT: REF. OFFER

DATED . . YOUR OFFER ON SOLICITATION

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR

30b. NAME AND TITLE OF SIGNER (Type or print) 30c. DATE SIGNED

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

10. THIS ACQUISITION IS UNRESTRICTED OR

NAICS:

SIZE STANDARD:

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

SET ASIDE: % FOR:

11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

ARE ARE NOT ATTACHED

ARE ARE NOT ATTACHED

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

8 (A)

EDWOSB

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SMALL BUSINESS

Solicitation/Contract Form

FY22 Aircraft Fire Training Facility Service

Proposal Identifier: FA820122R0008 Date: 11 Jan 2022

Supplies or Services & Prices or Costs

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April Product Service Code: J042 Firm Fixed Price

1 Each

Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April Product Service Code: J042 Firm Fixed Price

1 Each

Option Line Item

Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

Product Service Code: J042 Firm Fixed Price

1 Each

Description/Specifications/Statement of Work

Requirements Winterizing, de-Winterizing, and inspection of the Aircraft Fire Training Facility at Hill AFB, UT.

Packaging and Marking

Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-4 Inspection of Services-Fixed-Price. Aug 1996

Overall Contract Inspection/Acceptance Locations

0001 Inspection and Acceptance Location

Both Destination Instructions: De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: daniel.gallegos.2@us.af.mil Telephone: 801-775-3225

0002 Inspection and Acceptance Location

Both Destination Instructions: Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

0003 Inspection and Acceptance Location

Both Destination Instructions: Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: De-winterization/Inspection. De-winterization/Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Summer Inspection. Summer Inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

UNITED STATES

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Option Line Item

Inspection and Acceptance Location

Both Destination Instructions: Winterization/Inspection. Winterization and inspection of the Aircraft Fire Training Facility at Hill AFB IAW the attached SOW Dated April 2021.

DoDAAC: F2D0AA CountryCode: USA

775 CES

AF BPN NO MILSBILLS PROCESSES

7304 WARDLEIGH RD

HILL AFB, UT 84056-5129

Daniel S. Gallegos Email: Daniel.Gallegos.2@us.af.mil Telephone: 801-775-3225

Deliveries or Performance

Overall Contract Delivery Period

Contractor Destination

Line Item Delivery Schedule QTY Address and POC

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2022 To 31 Mar 2023

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2022 To 31 Mar 2023

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2022 To 31 Mar 2023

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Delivery Requested By Delivery Date 05 Feb 2022

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item 1001 Period of

Performance From 01 Apr 2023 To 31 Mar 2024

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2023 To 31 Mar 2024

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2023 To 31 Mar 2024

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2024 To 31 Mar 2025

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

01 Apr 2024 To 31 Mar 2025

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2024 To 31 Mar 2025

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2025 To 31 Mar 2026

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2025 To 31 Mar 2026

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2025 To 31 Mar 2026

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2026 To 31 Mar 2027

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2026 To 31 Mar 2027

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

Option Line Item

Delivery Requested By Delivery Date 05 Feb 2022

Period of Performance From 01 Apr 2026 To 31 Mar 2027

1 Each Ship To DoDAAC: F2D0AA

USAF:775TH CES

775 CES AF BPN NO MILSBILLS PROCESSES 7304 WARDLEIGH RD HILL

AFB UT 84056-5129

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-15 Stop-Work Order. Aug 1989 52.242-17 Government Delay of Work. Apr 1984

Contract Administration Data

Number Title Effective Date 52.213-2 Invoices. Apr 1984

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative. Dec 1991 252.204-7006 Billing Instructions. Oct 2005 252.217-7007 Payments. Dec 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. Dec 2018

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. Dec 2018

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports WAWF payment instructions.

in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer.

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in Document routing.

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700

Issue By DoDAAC FA8201

Admin DoDAAC F2D0AA

Inspect By DoDAAC F2D0AA

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

FA8201

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

(End of clause)

252.232-7007 Limitation of Government's Obligation. Apr 2014

As prescribed in 232.705-70, use the following clause:

LIMITATION OF GOVERNMENT'S OBLIGATION (APR 2014)

(a) Contract line item(s) is/are incrementally funded. For this/these item(s), the sum of $ [Contracting Officer insert after negotiations] of the total price is presently available for payment and allotted to this contract. An allotment schedule [Contracting Officer insert after negotiations] is set forth in paragraph (j) of this clause.

(b) For item(s) identified in paragraph (a) of this clause, the Contractor agrees to perform up to the point at which the total amount payable by the Government, including reimbursement in the event of termination of those item(s) for the Government's convenience, approximates the total amount currently allotted to the contract. The Contractor is not authorized to continue work on those item(s) beyond that point. The Government will not be obligated in any event to reimburse the Contractor in excess of the amount allotted to the contract for those item(s) regardless of anything to the contrary in the clause entitled "Termination for Convenience of the Government." As used in this clause, the total amount payable by the Government in the event of termination of applicable contract line item(s) for convenience includes costs, profit, and estimated termination settlement costs for those item(s).

(c) Notwithstanding the dates specified in the allotment schedule in paragraph (j) of this clause, the Contractor will notify the Contracting Officer in writing at least ninety days prior to the date when, in the Contractor's best judgment, the work will reach the point at which the total amount payable by the Government, including any cost for termination for convenience, will approximate 85 percent of the total amount then allotted to the contract for performance of the applicable item(s). The notification will state (1) the estimated date when that point will be reached and (2) an estimate of additional funding, if any, needed to continue performance of applicable line items up to the next scheduled date for allotment of funds identified in paragraph (j) of this clause, or to a mutually agreed upon substitute date. The notification will also advise the Contracting Officer of the estimated amount of additional funds that will be required for the timely performance of the item(s) funded pursuant to this clause, for a subsequent period as may be specified in the allotment schedule in paragraph (j) of this clause or otherwise agreed to by the parties. If after such notification additional funds are not allotted by the date identified in the Contractor's notification, or by an agreed substitute date, the Contracting Officer will terminate any item(s) for which additional funds have not been allotted, pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(d) When additional funds are allotted for continued performance of the contract line item(s) identified in paragraph (a) of this clause, the parties will agree as to the period of contract performance which will be covered by the funds. The provisions of paragraphs (b) through (d) of this clause will apply in like manner to the additional allotted funds and agreed substitute date, and the contract will be modified accordingly.

(e) If, solely by reason of failure of the Government to allot additional funds, by the dates indicated below, in amounts sufficient for timely performance of the contract line item(s) identified in paragraph (a) of this clause, the Contractor incurs additional costs or is delayed in the performance of the work under this contract and if additional funds are allotted, an equitable adjustment will be made in the price or prices (including appropriate target, billing, and ceiling prices where applicable) of the item(s), or in the time of delivery, or both. Failure to agree to any such equitable adjustment hereunder will be a dispute concerning a question of fact within the meaning of the clause entitled "Disputes."

(f) The Government may at any time prior to termination allot additional funds for the performance of the contract line item(s) identified in paragraph (a) of this clause.

(g) The termination provisions of this clause do not limit the rights of the Government under the clause entitled "Default." The provisions of this clause are limited to the work and allotment of funds for the contract line item(s) set forth in paragraph (a) of this clause. This clause no longer applies once the contract is fully funded except with regard to the rights or obligations of the parties concerning equitable adjustments negotiated under paragraphs (d) and (e) of this clause.

(h) Nothing in this clause affects the right of the Government to terminate this contract pursuant to the clause of this contract entitled "Termination for Convenience of the Government."

(i) Nothing in this clause shall be construed as authorization of voluntary services whose acceptance is otherwise prohibited under 31 U.S.C.

1342.

(j) The parties contemplate that the Government will allot funds to this contract in accordance with the following schedule:

On execution of contract $ ____

(month) (day), (year) $ ____

(month) (day), (year) $ ____

(month) (day), (year) $ ____

(End of clause)

Special Contract Requirements

Contract Clauses

Number Title Effective Date 52.202-1 Definitions. Jun 2020 52.203-3 Gratuities. Apr 1984 52.203-7 Anti-Kickback Procedures. Jun 2020 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-13 Contractor Code of Business Ethics and Conduct. Jun 2020

52.203-15 Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009.

Jun 2010

52.203-16 Preventing Personal Conflicts of Interest. Jun 2020

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights.

Jun 2020

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. May 2011 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-14 Service Contract Reporting Requirements. Oct 2016 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014 52.210-1 Market Research. Jun 2020 52.211-13 Time Extensions. Sep 2000 52.212-4 Contract Terms and Conditions-Commercial Items. Oct 2018 52.213-1 Fast Payment Procedure. May 2006 52.215-8 Order of Precedence-Uniform Contract Format. Oct 1997 52.216-8 Fixed Fee. Jun 2011 52.217-2 Cancellation Under Multi-year Contracts. Oct 1997 52.219-6 Notice of Total Small Business Set-Aside. Nov 2020 52.222-3 Convict Labor. Jun 2003 52.222-4 Contract Work Hours and Safety Standards -Overtime Compensation. May 2018 52.222-9 Apprentices and Trainees. Jul 2005 52.222-12 Contract Termination-Debarment. May 2014 52.222-14 Disputes Concerning Labor Standards. Feb 1988 52.222-15 Certification of Eligibility. May 2014 52.222-16 Approval of Wage Rates. May 2014 52.222-26 Equal Opportunity. Sep 2016 52.222-35 Equal Opportunity for Veterans. Jun 2020 52.222-36 Equal Opportunity for Workers with Disabilities. Jun 2020 52.222-37 Employment Reports on Veterans. Jun 2020 52.222-41 Service Contract Labor Standards. Aug 2018

52.222-43 Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts).

Aug 2018

52.222-50 Combating Trafficking in Persons. Oct 2020 52.222-54 Employment Eligibility Verification. Oct 2015 52.222-55 Minimum Wages Under Executive Order 13658. Nov 2020 52.222-62 Paid Sick Leave Under Executive Order 13706. Jan 2017 52.223-5 Pollution Prevention and Right-to-Know Information. May 2011 52.223-6 Drug-Free Workplace. May 2001 52.223-10 Waste Reduction Program. May 2011 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. Jun 2020 52.223-19 Compliance with Environmental Management Systems. May 2011 52.224-1 Privacy Act Notification. Apr 1984 52.224-2 Privacy Act. Apr 1984 52.224-3 Privacy Training. Jan 2017 52.228-3 Workers### Compensation Insurance (Defense Base Act). Jul 2014 52.228-5 Insurance-Work on a Government Installation. Jan 1997 52.228-7 Insurance-Liability to Third Persons. Mar 1996 52.229-1 State and Local Taxes. Apr 1984 52.229-3 Federal, State, and Local Taxes. Feb 2013 52.232-23 Assignment of Claims. May 2014 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. Oct 2018 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. Dec 2013 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.236-12 Cleaning Up. Apr 1984 52.236-13 Accident Prevention. Nov 1991 52.236-14 Availability and Use of Utility Services. Apr 1984 52.236-17 Layout of Work. Apr 1984 52.237-2 Protection of Government Buildings, Equipment, and Vegetation. Apr 1984

52.242-13 Bankruptcy. Jul 1995 52.242-14 Suspension of Work. Apr 1984 52.243-1 Changes-Fixed-Price. Aug 1987 52.243-4 Changes. Jun 2007 52.243-5 Changes and Changed Conditions. Apr 1984 52.245-1 Government Property. Sep 2021 52.246-23 Limitation of Liability. Feb 1997

52.249-1 Alternate I Termination for Convenience of the Government (Fixed-Price) (Short Form). - (Alternate I)

Apr 1984

52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). Apr 1984 52.249-2 Termination for Convenience of the Government (Fixed-Price). Apr 2012 52.249-4 Termination for Convenience of the Government (Services) (Short Form). Apr 1984 52.249-8 Default (Fixed-Price Supply and Service). Apr 1984 52.249-14 Excusable Delays. Apr 1984 52.253-1 Computer Generated Forms. Jan 1991

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials. Sep 2011

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

Dec 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. Sep 2013 252.203-7004 Display of Hotline Posters. Aug 2019 252.204-7000 Disclosure of Information. Oct 2016 252.204-7003 Control of Government Personnel Work Product. Apr 1992 252.204-7004 Antiterrorism Awareness Training for Contractors. Feb 2019 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. Dec 2019 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. May 2016

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

May 2019

252.217-7003 Changes. Dec 1991 252.217-7009 Default. Dec 1991 252.217-7010 Performance. Jul 2009 252.217-7012 Liability and Insurance. Aug 2003 252.217-7015 Safety and Health. Dec 1991 252.217-7028 Over and Above Work. Dec 1991 252.219-7003 Small Business Subcontracting Plan (DoD Contracts). Dec 2019 252.219-7011 Notification to Delay Performance. Jun 1998 252.223-7004 Drug-Free Work Force. Sep 1988 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials. Sep 2014 252.223-7008 Prohibition of Hexavalent Chromium. Jun 2013 252.225-7001 Buy American and Balance of Payments Program. Dec 2017 252.225-7002 Qualifying Country Sources as Subcontractors. Dec 2017 252.225-7041 Correspondence in English. Jun 1997 252.227-7003 Termination. Aug 1984 252.227-7016 Rights in Bid or Proposal Information. Jan 2011 252.227-7022 Government Rights (Unlimited). Mar 1979 252.232-7010 Levies on Contract Payments. Dec 2006

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

Apr 2020

252.236-7005 Airfield Safety Precautions. Dec 1991 252.237-7005 Performance and Delivery. Dec 1991 252.237-7006 Subcontracting. Dec 1991 252.237-7007 Termination for Default. Dec 1991 252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. Jun 2013 252.239-7013 Term of Agreement and Continuation of Services. Oct 2019 252.243-7001 Pricing of Contract Modifications. Dec 1991 252.244-7000 Subcontracts for Commercial Items. Oct 2020 252.247-7007 Liability and Insurance. Dec 1991

FAR Clauses Incorporated by Full Text

52.203-14 Display of Hotline Poster(s). Jun 2020

As prescribed in , insert the following clause:3.1004(b)

DISPLAY OF HOTLINE POSTER(S) (JUN 2020)

(a) Definition.

, as used in this clause, means the 50 States, the District of Columbia, and outlying areas.United States

Except as provided in paragraph (c)-(b) Display of fraud hotline poster(s).

During contract performance in the United States, the Contractor shall prominently display in common work areas within business (1) segments performing work under this contract and at contract work sites-

Any agency fraud hotline poster or Department of Homeland Security (DHS) fraud hotline poster identified in paragraph (b)(3) of this (i) clause; and

Any DHS fraud hotline poster subsequently identified by the Contracting Officer.(ii)

Additionally, if the Contractor maintains a company website as a method of providing information to employees, the Contractor shall (2) display an electronic version of the poster(s) at the website.

Any required posters may be obtained as follows:(3)

Poster(s) Obtain from

(Contracting Officer shall insert-

Appropriate agency name(s) and/or title of applicable Department of Homeland Security fraud hotline poster); and(i)

The website(s) or other contact information for obtaining the poster(s).)(ii)

If the Contractor has implemented a business ethics and conduct awareness program, including a reporting mechanism, such as a hotline (c) poster, then the Contractor need not display any agency fraud hotline posters as required in paragraph (b) of this clause, other than any required DHS posters.

The Contractor shall include the substance of this clause, including this paragraph (d), in all subcontracts that exceed the (d) Subcontracts.

threshold specified in Federal Acquisition Regulation 3.1004(b)(1) on the date of subcontract award, except when the subcontract-

Is for the acquisition of a commercial item; or(1)

Is performed entirely outside the United States.(2)

(End of clause)

52.204-1 Approval of Contract. Dec 1989

As prescribed in , insert the following clause:4.103

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of [identify title of designated agency official here] and shall not be binding until so approved.____

52.204-2 Security Requirements. Mar 2021

As prescribed in , insert the following clause:4.404(a)

SECURITY REQUIREMENTS (MAR 2021)

This clause applies to the extent that this contract involves access to information classified "Confidential," "Secret," or "Top Secret."(a)

The Contractor shall comply with-(b)

The Security Agreement DD Form441), including the and(1) National Industrial Security Program Operating Manual (32 CFR part 117);

Any revisions to that manual, notice of which has been furnished to the Contractor.(2)

If, subsequent to the date of this contract, the security classification or security requirements under this contract are changed by the (c) Government and if the changes cause an increase or decrease in security costs or otherwise affect any other term or condition of this contract, the contract shall be subject to an equitable adjustment as if the changes were directed under the Changes clause of this contract.

The Contractor agrees to insert terms that conform substantially to the language of this clause, including this paragraph (d) but excluding (d) any reference to the Changes clause of this contract, in all subcontracts under this contract that involve access to classified information.

(End of clause)

52.209-1 Qualification Requirements. Feb 1995

As prescribed in , insert the following clause:9.206-2

QUALIFICATION REQUIREMENTS (FEB 1995)

. "Qualification requirement," as used in this clause, means a Government requirement for testing or other quality assurance (a) Definition demonstration that must be completed before award.

One or more qualification requirements apply to the supplies or services covered by this contract. For those supplies or services requiring (b) qualification, whether the covered product or service is an end item under this contract or simply a component of an end item, the product, manufacturer, or source must have demonstrated that it meets the standards prescribed for qualification before award of this contract. The product, manufacturer, or source must be qualified at the time of award whether or not the name of the product, manufacturer, or source is actually included on a qualified products list, qualified manufacturers list, or qualified bidders list. Offerors should contact the agency activity designated below to obtain all requirements that they or their products or services, or their subcontractors or their products or services, must satisfy to become qualified and to arrange for an opportunity to demonstrate their abilities to meet the standards specified for qualification.

(Name) ____

(Address) ____

If an offeror, manufacturer, source, product or service covered by a qualification requirement has already met the standards specified, the (c) relevant information noted below should be provided.

Offeror's Name ____

Manufacturer's Name ____ ____

Source's Name ____

Item Name ____

Service Identification ____

Test Number (to the extent known)____

Even though a product or service subject to a qualification requirement is not itself an end item under this contract, the product, (d) manufacturer, or source must nevertheless be qualified at the time of award of this contract. This is necessary whether the Contractor or a subcontractor will ultimately provide the product or service in question. If, after award, the Contracting Officer discovers that an applicable qualification requirement was not in fact met at the time of award, the Contracting Officer may either terminate this contract for default or allow performance to continue if adequate consideration is offered and the action is determined to be otherwise in the Government's best interests.

If an offeror, manufacturer, source, product or service has met the qualification requirement but is not yet on a qualified products list, (e) qualified manufacturers list, or qualified bidders list, the offeror must submit evidence of qualification prior to award of this contract. Unless determined to be in the Government's interest, award of this contract shall not be delayed to permit an offeror to submit evidence of qualification.

Any change in location or ownership of the plant where a previously qualified product or service was manufactured or performed requires (f) reevaluation of the qualification. Similarly, any change in location or ownership of a previously qualified manufacturer or source requires reevaluation of the qualification. The reevaluation must be accomplished before the date of award.

(End of provision)

52.211-10 Commencement, Prosecution, and Completion of Work. Apr 1984

As prescribed in , insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The 11.404(b) clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the ____ date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than .____

* The time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. Sep 2000

As prescribed in , insert the following clause in solicitations and contracts:11.503(a)

LIQUIDATED DAMAGES-SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEPT 2000)

If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place (a) of actual damages, pay to the Government liquidated damages of $ per calendar day of delay [ ].280.90 Contracting Officer insert amount

If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is (b) liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without (c) the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract.

(End of clause)

52.211-12 Liquidated Damages-Construction. Sep 2000

As prescribed in , insert the following clause in solicitations and contracts:11.503(b)

LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the (a) Government in the amount of [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.____

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. (b) These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders-Commercial Items. Sep

As prescribed in , insert the following clause:12.301(b)(4)

CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS-COMMERCIAL ITEMS.

(SEP 2021)

The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by (a) reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (section 743 of Division E, (1) (JAN 2017) Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other (2) Covered Entities (Section 1634 of Pub. L. 115-91).(JUL 2018)

52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (3) (AUG 2020) (Section 889(a)(1)(A) of Pub. L. 115-232).

52.209-10, Prohibition on Contracting with Inverted Domestic Corporations .(4) (NOV 2015)

52.233-3, Protest After Award (31 U.S.C. 3553).(5) (AUG 1996)

52.233-4, Applicable Law for Breach of Contract Claim (Public Laws 108-77 and 108-78 ( 19 U.S.C. 3805 note)).(6) (OCT 2004)

The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in (b) this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[ .]Contracting Officer check as appropriate

52.203-6, Restrictions on Subcontractor Sales to the Government , with (41 U.S.C. 4704 and 10 U.S.(1) (JUNE 2020) Alternate I (OCT 1995)

C. 2402).

52.203-13, Contractor Code of Business Ethics and Conduct (41 U.S.C. 3509)).(2) (JUN 2020)

52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Section 1553 of Pub. L. 111-5). (3) (JUN 2010)

(Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Pub. L. 109-282) ( 31 U.S.C. 6101 note).(4) (JUN 2020)

[Reserved].(5)

52.204-14, Service Contract Reporting Requirements (Pub. L. 111-117, section 743 of Div. C).(6) (OCT 2016)

52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Pub. L. 111-117, section 743 of Div. C).(7) (OCT 2016)

52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (8) (JUN

(31 U.S.C. 6101 note).2020)

52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (41 U.S.C. 2313).(9) (OCT 2018)

[Reserved].(10)

(11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (15 U.S.C. 657a).(SEP 2021)

(12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (if the offeror elects to waive the (SEP 2021) preference, it shall so indicate in its offer) (15 U.S.C. 657a).

[Reserved](13)

52.219-6, Notice of Total Small Business Set-Aside (15 U.S.C. 644).(14)(i) (NOV 2020)

Alternate I of 52.219-6.(ii) (MAR 2020)

52.219-7, Notice of Partial Small Business Set-Aside (15 U.S.C. 644).(15)(i) (NOV 2020)

Alternate I of 52.219-7.(ii) (MAR 2020)

52.219-8, Utilization of Small Business Concerns (15 U.S.C. 637(d)(2) and (3)).(16) (OCT 2018)

52.219-9, (17)(i) Small Business Subcontracting Plan (15 U.S.C. 637(d)(4)).(SEP 2021)

Alternate I of 52.219-9.(ii) (NOV 2016)

Alternate II of 52.219-9.(iii) (NOV 2016)

Alternate III of 52.219-9.(iv) (JUN 2020)

(v) Alternate IV of 52.219-9.(SEP 2021)

52.219-13, Notice of Set-Aside of Orders (15 U.S.C. 644(r)).(18)(i) (MAR 2020)

Alternate I of 52.219-13.(ii) (MAR 2020)

(19) 52.219-14, Limitations on Subcontracting (15 U.S.C. 637s).(SEP 2021)

(20) 52.219-16, Liquidated Damages-Subcontracting Plan (15 U.S.C. 637(d)(4)(F)(i)).(SEP 2021)

(21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (15 U.S.C. 657f).(SEP 2021)

(22)(i) 52.219-28, Post Award Small Business Program Rerepresentation (15 U.S.C. 632(a)(2)).(SEP 2021)

Alternate I of 52.219-28.(ii) (MAR 2020)

(23) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (SEP

(15 U.S.C. 637(m)).2021)

(24) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned

Small Business Program (15 U.S.C. 637(m)).(SEP 2021)

52.219-32, Orders Issued Directly Under Small Business Reserves (15 U.S.C. 644(r)).(25) (MAR 2020)

(26) 52.219-33, Nonmanufacturer Rule (15U.S.C. 637(a)(17)).(SEP 2021)

52.222-3, Convict Labor (E.O.11755).(27) (JUN 2003)

52.222-19, Child Labor-Cooperation with Authorities and Remedies (E.O.13126).(28) (JAN2020)

52.222-21, Prohibition of Segregated Facilities .(29) (APR 2015)

52.222-26, Equal Opportunity (E.O.11246).(30)(i) (SEP 2016)

Alternate I of 52.222-26.(ii) (FEB 1999)

52.222-35, Equal Opportunity for Veterans (38 U.S.C. 4212).(31)(i) (JUN 2020)

Alternate I of 52.222-35.(ii) (JUL 2014)

52.222-36, Equal Opportunity for Workers with Disabilities (29 U.S.C. 793).(32)(i) (JUN 2020)

Alternate I of 52.222-36.(ii) (JUL 2014)

52.222-37, Employment Reports on Veterans ( ) (38 U.S.C. 4212).(33) JUN 2020

52.222-40, Notification of Employee Rights Under the National Labor Relations Act (E.O. 13496).(34) (DEC 2010)

52.222-50, Combating Trafficking in Persons (22 U.S.C. chapter 78 and E.O. 13627).(35)(i) (OCT 2020)

Alternate I of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).(ii) (MAR 2015)

52.222-54, Employment Eligibility Verification ( ). (Executive Order 12989). (Not applicable to the acquisition of commercially (36) OCT 2015 available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not (37)(i) applicable to the acquisition of commercially available off-the-shelf items.)

Alternate I of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)(ii) (MAY 2008)

52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).(38)

52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (E.O. 13693).(39) (JUN 2016)

52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (E.O.s 13423 and 13514).(40)(i) (JUN 2014)

Alternate I of 52.223-13.(ii) (OCT 2015)

52.223-14, Acquisition of EPEAT®-Registered Televisions (E.O.s 13423 and 13514).(41)(i) (JUN 2014)

Alternate I (Jun2014) of 52.223-14.(ii)

52.223-15,…