Sol_140P4321Q0010.pdf

140P4321Q0010

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

02/24/2021 0040521444

1 50

Boston National Historical Park Charlestown Navy Yard Building I-1

NPS, NER - NE MABO

Boston MA 02129-4543

09/15/2021

NPS, Springfield Armory NHS

1 Armory Square Suite 2

Springfield

MA 01105-0299

617 242-5786David Barceleau

03/29/2021 1400 ED

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

a) This procurement is a TOTAL SMALL BUSINESS SET-ASIDE. Responsible small business sources may submit an offer that will be considered. The small business size standard for NAICS Code 238220, Plumbing, Heating, and Air-Conditioning Contractors, is $16.5 million.

b) Refer to "Instructions to Offerors" for what to submit with your quote.

c) Refer to provision 52.236-27 for site visit information.

d) Estimated Price Range: Between $25,000 and $100,000.

Continued ...

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

2 50

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

140P4321Q0010

e) Information and requirements stated in sections; Award Selection Process, General, Special Contract Requirements, Provisions, and

Contract Clauses including the List of

Attachments apply this solicitation and the subsequent contract.

f) Wage Determination MA20210003 applies to this solicitation and the subsequent contract.

g) Estimated Period of Performance: See clause

52.211-10, Commencement, Prosecution, and

Completion of Work.

h) Do NOT use beta.SAM's Interested Vendor List

(IVL). The IVL is not active in the U. S.

Department of the Interior at this time. The

National Park Service cannot receive or respond to the IVL. Offerors shall submit questions, proposals, and acknowledge solicitation amendments as stated in the Instructions to

Offerors and General sections of this solicitation.

00010 Firm-Fixed-Price Quarters One Boiler Replacement in accordance with the attached Scope of Work.

Delivery: 09/15/2021

Period of Performance: 04/05/2021 to 09/15/2021

Contracting Officer's Representative (COR):

Keenan Comer, (413) 391-6027, keenan_comer@nps.gov

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

RFQ 140P4321Q0010

Solicitation #140P4321Q0010 - Current as of 02/24/2021 Point of Contact: David Barceleau, (617) 242-5786, David_barceleau@nps.gov

Request for Quotation 140P4321Q0010

Quarters One Boiler Replacement Springfield Armory National Historic Site (SPAR), Springfield, MA

This is a request for quotations for construction prepared in accordance with the format in the Federal Acquisition Regulations (FAR) Part 13 and Part 36, as supplemented with additional information included in this notice. This announcement constitutes the only solicitation issued as Request for Quotation (RFQ) 140P4321Q0010, Quarters One Boiler Replacement Springfield Armory National Historic Site (SPAR), Springfield, MA. FAR clauses and provisions enclosed within this RFQ are those in effect through Federal Acquisition Circular (FAC) 2021-03 and are available in full text through Internet access at http:// www.acquisition.gov/far/.

Type of Contract: Construction, Firm Fixed Priced (FFP), Single Award Contract County: Hampden County, Massachusetts Type of Construction: Building

Magnitude:

Between $25,000 and $100,000.

NAICS:

238220, Plumbing, Heating, and Air- Conditioning Contractors

SIZE STD:

$16.5 million

SET-ASIDE:

Total Small Business

National Park Service Contract Specialist (CS) Contracting Officer (CO)

Name: David Barceleau Wendy DeLeon

Email: David_barceleau@nps.gov Wendy_deleon@nps.gov mailto:David_barceleau@nps.gov

AWARD SELECTION PROCESS:

Award will be made in accordance with FAR Part 13 to the offeror that provides the best value to the government based on price, technical, and prior experience. This solicitation is not stating, nor is required to state, the relative importance assigned to each evaluation factor and/or sub factor (FAR 13.106-1(a)(2)).

Price: The NPS shall analyze prices, in accordance with the FAR. Pricing must be determined to be fair and reasonable

Technical:

• Offeror must provide proof of the Prime Contractor possessing a current Commonwealth of Massachusetts’ Master Gas Fitter license. Other licensing authorities will not be recognized in evaluating this technical factor.

• Recent (within 5 years) and relevant experience providing similar services.

• Draft schedule and basic approach for conducting the project activities.

Past Performance: The quoter must receive a satisfactory confidence rating where, based on the offeror’s recent/relevant performance record, the Government has a reasonable expectation that the offeror will successfully perform the required effort. A satisfactory confidence rating is defined as demonstrated performance that meets/met contractual requirements. The contractual performance of the element or sub-element contains/contained some minor problems for which corrective actions taken by the contractor appear or were satisfactory. The NPS may evaluate Quoters' past performance based on contacting references provided by the quoter; the Government's knowledge of Quoter's past performance; and / or references obtained from any other source. The Government reserves the right to limit the number of references it ultimately contacts and to contact references or use sources other than those provided by Quoters to obtain information related to past performance. Other sources include, but are not limited to, the Past Performance Information Retrieval System; Federal, State or local governmental agencies; and private sector businesses.

GENERAL

(a) The National Park Service (NPS) is seeking quotations for construction services as attached in the accompanying scope of work. The NPS intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13.

(b) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Respondents are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award.

(c) Respondents are cautioned to submit adequate information to enable the Government to fully ascertain each respondent’s capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ).

(d) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer through the Contract Specialist (David_barceleau@nps.gov) in writing (email is the preferred method) with supporting rationale prior to the closing of this RFQ.

(e) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation.

Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government.

(f) Quotation must be valid for a minimum of 90 days.

(g) All interested parties should be registered in the System for Award Management or SAM at time an offer or quotation is submitted.

(h) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate.

(i) If total quote, inclusive of all options, is in an amount greater than $150,000.00 then clause 52.228-1, Bid Guarantee, applies.

(j) Respondents shall not contact any government personnel related to this requirement other than the Contracting Officer and Contract Specialist.

(k) All questions should be emailed directly to the Contract Specialist at david_barceleau@nps.gov.

Only written RFI’s will be considered and responded to by the Government. NPS responses to RFIs will be posted as an amendment to the solicitation.

SPECIAL CONTRACT REQUIREMENTS

WORK HOURS

The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00am and 3:30 pm, Monday through Friday, except for Federal Holidays and/ or Weather-related delays declared by Springfield Technical Community College Campus.. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, official ceremonies, and government holidays, a written request must be submitted to the Contracting Officer 48 hours in advance to allow sufficient time to review the request for acceptability and, if accepted by the Contracting Officer, to allow satisfactory arrangements to be made by the Government for access to the work site and inspection. The request shall include number of personnel, expected work hours, and nature of work to be conducted.

The following Federal Legal Holidays are observed:

Federal Holidays:

New Year’s Day Martin Luther King, Jr. Day President’s Day Memorial Day

Independence Day Labor Day Columbus Day Veterans Day

Thanksgiving Day Christmas

PERIOD OF PERFORMANCE

See clause 52.211-10, Commencement, Prosecution, and Completion of Work herein for period of performance dates.

Any administrative work can begin after receipt of the Notice of Award.

On-site work can begin after receipt of the Notice to Proceed (NTP).

NTP will be issued upon receipt of, and either acceptance or approval, of the following:

1. Letter designating Project Manager / Foreman / Superintendent [FAR clause 52.236-6];

2. Project Schedule. [FAR clause 52.236-15];

3. A comprehensive breakdown of the Schedule of Values. [FAR clause 52.232-5];

4. Accident Prevention Plan [FAR clause 52.236-13 Accident Prevention. -

Alternate I];

5. A list of Subcontractors for this project;

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses (SF 1413). [FAR clause 52.222-11];

7. Satisfactory evidence of liability insurance coverage and workman's compensation for the contractor and all Subcontractors. [See clause 1452.228-70 Liability Insurance (JUL 1996)];

8a. Alternative Payment Protection [FAR clause 52.228-13, Alternative Payment Protections – IF award value exceeds $35,000 but does not exceed $150,000]

OR

8b. Performance and Payment Bonds [FAR clause 52.228-15, Performance and Payment

Bonds-Construction - For awards that exceed $150,000.

Special Notice #1. Documents identified by the government as required to be submitted prior to the Preconstruction Conference/Meeting are required to be submitted within the dates specified by the contract documents. Government documents that are required prior to the Pre-construction not identified with a specific delivery date are due to the Contracting Officer within 5 business days of the date of the Contracting Officer’s Notice of Award. The requirements for the submittals are found in the Project Specifications, award clauses, and/or in the body of the Notice of Award.

Special Notice #2. For an award value that exceeds $35,000 but does not exceed $150,000, Federal Acquisition Regulation (FAR) clause 52.228-13, Alternative Payment Protections, is applicable to the award and is incorporated by full text herein.

Special Notice #3. For awards that to exceed $150,000, Federal Acquisition Regulation (FAR) clause 52.228-15, Performance and Payment Bonds-Construction, is applicable to the award and is incorporated by full text herein.

Special Notice #4. Tax Exempt Certificates will not be issued per FAR Subpart 29.303. Therefore, per FAR clause, 52.229-3, Federal, State, and Local Taxes (included by reference herein): The contract price shall include all applicable Federal, State, and local taxes and duties.

Special Clause #1: INFECTIOUS DISEASE PREPAREDNESS AND RESPONSE – CORONAVIRUS

PANDEMIC (COVID-19)

1. Contractors are responsible for their employees’ safety and the safety of job site visitors during the performance of this contract. We encourage contractors to follow guidance from the Department of Labor, Occupational Safety and Health Administration (OSHA), the Centers for Disease Control and Prevention (CDC), and all other applicable local, city, and state mandates. We encourage contractors to develop policies for infection prevention and an Infectious Disease Preparedness and Response Plan.

2. To the extent appropriate, Contractors should include the protective health and safety measures they intend to implement related to COVID-19 in any accident prevention or safety submittals required under this contract. These plans should contain preventive measures the contractor intends to follow while performing work on government property as well as responsive and corrective actions to be taken if an employee exhibits symptoms or tests positive for COVID-19.

3. Upon contract award, contractors should communicate with the Contracting Officer regarding contractor decisions and actions to protect the health and safety of workers for the duration of contract performance under which pandemic conditions exist.

4. The following websites provide additional guidance and information:

https://www.coronavirus.gov/ https://www.osha.gov/SLTC/covid-19/ https://www.cdc.gov/coronavirus/2019-ncov/index.html https://www.cdc.gov/coronavirus/2019-ncov/community/organizations/construction-workers.html https://www.fema.gov/coronavirus https://www.nps.gov/aboutus/news/public-health-update.htm

(End of Local Clause)

INSTRUCTIONS TO OFFERORS:

Quotes must be in accordance with and in the order detailed in this section. Failure to submit quotes according to the instructions provided within the solicitation may result in the respondent’s quote is being deemed “non-responsive.”

All interested parties should be registered in the System for Award Management or SAM at time an offer or quotation is submitted.

The offeror shall submit a quote to the Contract Specialist by email to David_barceleau@nps.gov.

Offers shall be submit the following information in its entirety:

a) Checklist for quote submittal:

● This page of the solicitation completed as the first page in the package. ☐

● Signed acknowledgement of Standard Form 18 (SF 18). ☐ Complete blocks 11 (f), Amount, and Blocks 12 through 16. An official having the authority to contractually bind the offeror's company must sign the SF 18 in accordance with the procedures prescribed in FAR 4.102.

● All Amendments Acknowledged (if applicable). ☐ See instructions in Block 11a of the amendment’s Standard Form 30 (SF 30).

● Proof of Prime Contractor possessing a current Commonwealth of Massachusetts’ ☐ Master Gas Fitter license. (Other licensing authorities will not be recognized.)

● Draft schedule and basic approach for conducting the project activities. ☐

● Demonstration of recent (within 5 years) and relevant experience providing ☐ similar services.

● Three to Five prior experiences of projects in similar size and similar scope within the past five years to include:

o Brief description of project ☐ o Contact name ☐ o Telephone number ☐ o Email address ☐ o Project description ☐ o Contract value ☐ o Completion date or status ☐

[CONTINUED ON NEXT PAGE]

● A response to the following questions:

Judgments, Claims, and Lawsuits:

o Are there any judgments, claims, and/or lawsuits pending or outstanding against or involving entity or partners comprising your entity?

No ___, Yes ___. If “Yes,” submit details of all judgments or claims against either parent office or division/branch that will be responsible for the accomplishment of this project on a separate sheet.

o Is your entity or partners comprising your entity under suspension or debarment by any Federal, state or local agency, or been terminated on any past projects (Federal or others)?

o No ___, Yes ___. If “Yes,” submit details on a separate sheet.

• Complete the paragraphs (c)(1) and (c)(2) of the flowing provision:

52.204-26 Covered Telecommunications Equipment or Services-Representation.

(Oct 2020)

(a) Definitions. As used in this provision, "covered telecommunications equipment or services" and "reasonable inquiry" have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services".

(c) (1) Representation. The Offeror represents that it □ does, □ does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it □ does, □ does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

(End of provision)

b) Contractor Core Data:

Offeror’s Name:___________________________________________________________________

Offeror’s DUNS:__________________________________________________________________

Offeror’s POC:____________________________________________________________________

Offeror’s Phone/Email:_____________________________________________________________

PROVISIONS SECTION:

52.252-1 Solicitation Provisions Incorporated by Reference FEB 1998

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es): https://www.acquisition.gov.

52.204-7 System for Award Management Oct 2018

52.204-16 Commercial and Government Entity Code Reporting Aug 2020

52.204-19 Incorporation by Reference of Representations and Certifications Dec 2014

52.204-22 Alternative Line Item Proposal Jan 2017

52.211-6 Brand Name or Equal Aug 1999

Provisions incorporated full text:

52.204-8 Annual Representations and Certifications Mar 2020

(a) (1) The North American Industry Classification System (NAICS) code for this acquisition is 238220, Plumbing, Heating, and Air-Conditioning Contractors.

(2) The small business size standard is _$16.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) □ Paragraph (d) applies.

(ii) □ Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

mailto:David_barceleau@nps.gov https://www.acquisition.gov/ https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless–

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation.

This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations- Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

mailto:David_barceleau@nps.gov https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063268 https://www.acquisition.gov/content/part-13-simplified-acquisition-procedures#i1112458 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063408 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i52_203-18 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063736 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063796 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#id19CAC0P0ESS https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1062479 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1062558 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#id165RA0UH01A

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I & II). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans’ Employment Reporting Requirements.

This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA–designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA–designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals- Representation. This provision applies to solicitations that include the clause at 52.204- 7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

mailto:David_barceleau@nps.gov https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1059991 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1059247 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1057235 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1057302 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055729 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055793 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055782 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1055793 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1056289 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1052963 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1052973 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053040 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#CDCHDCIFF4 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1063838 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053411 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053372

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate.

(Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $83,099, the provision with its Alternate II applies.

(D) If the acquisition value is $83,099 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan- Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

__X (i) 52.204-17, Ownership or Control of Offeror.

__X (ii) 52.204-20, Predecessor of Offeror.

__ (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

__ (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

__ (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

__ (vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA–Designated Products (Alternate I only).

mailto:David_barceleau@nps.gov https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053526 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053446 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053693 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1053648 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1054426 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1054876 https://www.acquisition.gov/content/part-52-solicitation-provisions-and-contract-clauses#i1054999

(vii) 52.227-6, Royalty Information.

__ (A) Basic.

__ (B) Alternate I.

__ (viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov. After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance

Services or Equipment Aug 2020

The Offeror shall not complete the representation in this provision if the Offeror has represented that it “does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument” in the provision at 52.204-26, Covered Telecommunications Equipment or Services- Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications-Commercial Items.

(a) Definitions. As used in this provision—

“Covered telecommunications equipment or services”, “critical technology”, and “substantial or essential component” have the meanings provided in clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

mailto:David_barceleau@nps.gov https://www.sam.gov/ https://www.acquisition.gov/content/part-4-administrative-and-information-matters#i1121876

(b) Prohibition. Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system.

Contractors are not prohibited from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award

Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

(d) Representation. The Offeror represents that it □ will, □ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation.

(e) Disclosures. If the Offeror has represented in paragraph (d) of this provision that it “will” provide covered telecommunications equipment or services”, the Offeror shall provide the following information as part of the offer—

(1) A description of all covered telecommunications equipment and services offered (include brand; model number, such as original equipment manufacturer (OEM) number, manufacturer part number, or wholesaler number; and item description, as applicable);

(2) Explanation of the proposed use of covered telecommunications equipment and services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b) of this provision;

(3) For services, the entity providing the covered telecommunications services (include entity name, unique entity identifier, and Commercial and Government Entity (CAGE) code, if known); and

(4) For equipment, the entity that produced the covered telecommunications equipment

(include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known).

52.204-26 Covered Telecommunications Equipment or Services - Representation Oct 2020

(a) Definitions. As used in this provision, “covered telecommunications equipment or services” and “reasonable inquiry” have the meaning provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for “covered telecommunications equipment or services”.

https://www.acquisition.gov/far/part-52#FAR_52_204_25 https://www.sam.gov/

(c) Representations. (1) The Offeror represents that it [ ] does, [ ] does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument.

(2) After conducting a reasonable inquiry for purposes of this representation, the offeror represents that it [ ] does, [ ] does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services.

52.222-5 Construction wage rate requirements- secondary site of work May 2017

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

(End of provision)

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal

Employment Opportunity for Construction Feb 1999

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade Goals for Female Participation for Each Trade

4.8% 6.9%

These goals are applicable to all of the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.

The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

http://acquisition.gov/far/current/html/52_222.html#wp1147505

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is the job site in the City of Springfield, Hampden County, Commonwealth of Massachusetts.

52.225-10 Notice of Buy American Requirement--Construction Material May 2014

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American—Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested—

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/52_223_226.html#wp1169273 http://acquisition.gov/far/current/html/FormsStandard62.html#wp1177057

52.228-1 Bid Guarantee [If quote is over $150,000.00] Sep 1996

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier’s check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $250,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.228-17 Individual Surety—Pledge of Assets (Bid Guarantee) [If 52.228-1, Bid Guarantee, required]

Feb 2021

(a)Offerors shall obtain from each person acting as an individual surety on a bid guarantee—

(1)A pledge of assets that meets the eligibility, valuation, and security requirements described in the Federal Acquisition Regulation (FAR) 28.203-1; and

(2)Standard Form 28, Affidavit of Individual Surety.

(b)The Offeror shall include with its offer the information required at paragraph (a) of this provision within the timeframe specified in the provision at FAR 52.228-1, Bid Guarantee, or as otherwise established by the Contracting Officer.

(c)The Contracting Officer may release the security interest on the individual surety's assets in support of a bid guarantee based upon evidence that the offer supported by the individual surety will not result in contract award.

(End of provision

52.236-27 Site Visit (Construction). (FEB 1995) Feb 1995

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Keenan Comer

Address: keenan_comer@nps.gov

Telephone: (413) 391-6027

(End of Provision)

SPECIAL NOTICE# 5: COVID-19 Site Visit Precautions: No more than two visitors from each prime vendor, to include subcontractors. All visitors will supply their own Personal Protective Equipment (PPE), to include, at a minimum, masks and gloves. The government will not supply PPE nor allow anyone not on the identified PPE to take part in the site visit. Prior to visiting the site, each employee will self-certify to their supervisor that they; • Have no signs of a fever or a measured temperature above 100.3 degrees or greater, a cough or trouble breathing within the past 24 hours. • Have not had "close contact" with an individual diagnosed with COVID-19. “Close contact” means living in the same household as a person who has tested positive for COVID-19, caring for a person who has tested positive for COVID-19, being within 6 feet of a person who has tested positive for COVID-19 for about 15 minutes, or coming in direct contact with secretions (e.g., sharing utensils, being coughed on) from a person who has tested positive for COVID-19, while that person was symptomatic. • Have not been asked to self-isolate or quarantine by their doctor or a local public health official. In the event of an exposure, the Contractor shall work with the local board of health to identify any potential job site exposures, including : • National Park Service COR Keenan Comer, (413) 391-6027, keenan_comer@nps.gov and other workers with close contact to the individual.

mailto:David_barceleau@nps.gov mailto:keenan_comer@nps.gov mailto:keenan_comer@nps.gov

CONTRACT CLAUSES SECTION:

52.252-2 Clauses Incorporated by Reference FEB 1998

This contract incorporates one or more clauses by reference, with the same force and effect as…