Sol_140L2623Q0067.pdf

140L2623Q0067

1. REQUEST NO.

5a. ISSUED BY

NAME

a. NAME

c. STREET ADDRESS

d. CITY

10. PLEASE FURNISH QUOTATIONS TO

THE ISSUING OFFICE IN BLOCK 5a ON

OR BEFORE CLOSE OF BUSINESS (Date)

2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NO. 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG.1

RATING

6. DELIVERY BY (Date)

7. DELIVERY

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

PAGE OF PAGES

5b. FOR INFORMATION CALL: (No collect calls)

TELEPHONE NUMBER

AREA CODE NUMBER

8. TO:

b. COMPANY

e. STATE f. ZIP CODE

c. CITY

d. STATE e. ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

THIS RFQ

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

IS IS NOT A SMALL BUSINESS SET ASIDEX

08/18/2023 0040610830

1 47

1387 S. VINNELL WAY

BOISE ID 83709

BLM ID-STATE OFC HR&ADM SVC (ID953)

12/19/2023

BLM-ID POCATELLO FIELD OFFICE

4350 CLIFFS DRIVE

POCATELLO

ID 83204

208 373-3910Patricia Fort

09/05/2023 1000 MD

FOB DESTINATION

OTHER

(See Schedule)X

ITEM NO.

(a)

SUPPLIES/SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

00010 CURLEW & PLEASANTVIEW ROAD GRADING

Product/Service Code: Y1LB Product/Service Description: CONSTRUCTION OF

HIGHWAYS, ROADS, STREETS, BRIDGES, AND RAILWAYS

Delivery: 12/19/2023 Period of Performance: 09/11/2023 to 12/19/2023

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations

13. NAME AND ADDRESS OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

a. NAME OF QUOTER

AREA CODE

NUMBER

15. DATE OF QUOTATION

b. TELEPHONE are are not attached

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

STANDARD FORM 18 (REV. 6-95)

Prescribed by GSA - FAR (48 CFR) 53.215-1(a)

SOLICITATION NO: 140L2623Q0067

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 2

Type of Contract: Construction, Firm-Fixed Price (FFP) County: Oneida County, Idaho Type of Construction: Highway

Magnitude: Between $100,000 and $250,000 NAICS: 237310 Size Standard: $45.0 Million Set-Aside: Total Small Business

Bureau of Land Management Contracting Officer’s Representative (COR) Contracting Officer

Name: Jerry Burrows Patricia A. Fort

Email: jburrows@blm.gov pfort@blm.gov

Site Visit: See Section L.7

Proposal Due Date: Tuesday, September 5, 2023 at 10:00 am MT

Award Selection Process: Lowest Price mailto:jburrows@blm.gov mailto:pfort@blm.gov

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 3

SUBMIT ONLY REQUESTED ITEMS NOT THE ENTIRE SOLICITATION

GENERAL

(a) The Bureau of Land Management (BLM) is seeking quotations for construction services as attached in the accompanying statement of work. The BLM intends to conduct this acquisition by use of simplified acquisition procedures in accordance with FAR Part 13. A single contract award will be made to the Offeror that submits a quotation that has been determined to be the lowest price reasonable offeror.

(b) The Government will not award any contract if the resulting contract would not represent a "best value" to the Government.

(c) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award. It is the responsibility of offerors to ensure their quote is received by the recipient and by the due date and time.

(d) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer in writing (email is the preferred method) with supporting rationale by the question deadline specified on the cover page of this document.

(e) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government.

(f) Quotation must be valid for a minimum of 60 days.

(g) Respondents must complete the System for Award Management (SAM) at https://sam.gov (previously ORCA and CCR). The Government will obtain respondent representations and certifications through this system.

(h) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate.

(i) Including all other factors, to qualify for award, a respondent must be determined responsible in accordance with Federal Acquisition Regulation Part 9.

(j) Respondents shall not contact any government personnel related to this requirement other than the Contracting Officer.

(k) All questions should be emailed directly to the Contracting Officer. Only written RFI’s will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation.

(l) The successful Offeror shall submit appropriate Performance and Payment Bonds in accordance with clause 52.228-1 or Alternative Payment Protection in accordance with clause 52.228-13 within 10 days of contract award.

https://sam.gov/

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 4

TABLE OF CONTENTS

Part I - The Schedule

Section A - Solicitation/Contract Form See Standard Form 18

Section B - Bid Schedule 5

Section C - Specifications/Drawings 6

Section D - Packaging and Marking 6

Section E - Inspection and Acceptance 6

Section F - Deliveries or Performance 6

Section G - Contract Administration Data 8

Section H - Special Contract Requirements 10

Part II - Contract Clauses

Section I - Contract Clauses 13

Part III - List of Documents, Exhibits, and Other Attachments

Section J - List of Attachments 31

Part IV - Representations and Instructions

Section K - Representations, Certifications, and Other Statements of Offerors 36

Section L - Instructions, Conditions and Notices to Offerors 43

Section M - Evaluation Factors for Award 47

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 5

PART I - THE SCHEUDLE

SECTION B: BID SCHEDULE

Offerors are to complete Blocks 13 - 16 of the SF-18.

Pocatello Road Grading 2023

PAY

ITEM ESTIMATED UNIT TOTAL

NO. DESCRIPTION QUANTITY UNIT COST COST

01 FP-14 151 - Mobilization 1 LS -------- $____________

02 FP-14 602 - Road Culvert Replacement 1 EA $_________ $____________

03 FP-14 201 - Clearing and Grubbing 1 LS -------- $____________

04 FP-14 109 - Surface Course Haul 500 LCY $_________ $____________

05 FP-14 301 - Surface Course Spread 500 LCY $_________ $____________ & Compact

06 Provide Crushed Aggregate: B (Subbase)* 500 LCY $_________ $____________

07 FP-14 303 - Road Reconditioning - 25 MI $_________ $____________ Curlew

08 FP-14 303 - Road Reconditioning - 5.3 MI $_________ $____________ Pleasantview

TOTAL $____________

*According to Standard Specifications for Construction of Roads and Bridges on Federal Highway Projects, FP- 14, Table 703-2

LS = Lump Sum LCY = Loose Cubic Yard EA = Each MI = Mile

Period of Performance: 90 Calendar Days from Issuance of Notice to Proceed

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 6

SECTION C: SPECIFICATIONS/DRAWINGS

See Section J for additional attachments to include project specifications and drawings.

SECTION D: PACKAGING AND MARKING

Packaging and marking of deliverables shall be IAW the Contractor’s standard commercial practices.

SECTION E: INSPECTION AND ACCEPTANCE

E.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.246-12 Inspection of Construction August 1996

E.2 Final Inspection and Acceptance

Final completion of the punch list items, submission of all required submittals, and final cleanup of the project site shall be completed before the contract’s required completion date. The Contracting Officer or his/her designated representative will perform final inspection. Acceptance of the work will occur only upon written notice of acceptance by the ordering Contracting Officer or any other Warranted Contracting Officer employed by the Bureau of Land Management (BLM) and performing authorized duties in conjunction with this contract.

SECTION F: DELIVERIES OR PERFORMANCE

F.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.211-13 Time Extensions September 2000 52.211-18 Variation in Estimated Quantity April 1984 52.236-11 Use and Possession Prior to Completion April 1984

F.2 52.211-10 Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 days after receipt of Notice to Procced. *The time stated for completion shall include final cleanup of the premises.

https://www.acquisition.gov/browse/index/far#

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 7

*The Government recognizes that seasonal climatic conditions may occur that restrict or prohibit normal construction activities. The anticipated length of the seasonal delay for this project is 0 days. This number of days has been included in calculating the stated period of performance. Therefore, the contract period of performance will not be extended due to normal seasonal weather delays.

F.3 52.211-12 Liquidated Damages--Construction (Apr 1984)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $600.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.4 52.236-15 Schedules for Construction Contracts (Apr 1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

F.5 Simultaneous Performance

If a Contractor receives award of more than one contract, simultaneous performance will be required. All work must be completed within the timeframe allowed for each contract.

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 8

SECTION G: CONTRACT ADMINISTRATION DATA

G.1 Authorities and Delegations (Sep 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor.

Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.

The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

G.2 Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (Apr 2013)

Payment requests must be submitted electronically through the U.S. Department of the Treasury's Internet Payment Platform System (IPP).

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 9

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions- Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

(a) Copy of Company Generated Invoice.

(b) Substantiation Forms are to be submitted with progress payments only.

(c) Release of Claims shall be submitted with the final payment only.

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

G.3 Local Internet Payment Platform (IPP) Hotline

To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contracting Officer with the day and time you contacted the Payment Hotline.

G.4 Government Point of Contact

Patricia A. Fort pfort@blm.gov Bureau of Land Management 1387 S Vinnell Way Boise, ID 83709 Telephone (208) 373-3910 http://www.ipp.gov./ mailto:ippgroup@bos.frb.org

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 10

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 Work Hours

The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00 am and 5:00 pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.

In addition to any holidays declared by Executive Orders, the following Federal Legal Holidays are observed:

New Year’s Day, Martin Luther King Jr. Day, President’s Day, Memorial Day, Juneteenth, Independence Day, Labor Day, Columbus Day, Veterans Day, Thanksgiving Day, Christmas Day

H.2 Communications

“Time” for communications received after 3:00 pm, after 12:00 pm locally on Fridays, or after 12:00 pm locally prior to a holiday will not start until the next business day. All times are local Mountain time.

H.3 Fire Danger Season

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

H.4 Drawings

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full-size drawings may contact the Contracting Officer identified in the solicitation.

H.5 Preservation of Historical and Archeological Data

(a) The Historic and Archeological Data Preservation Act of 1974 provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings.

No objects of cultural resource value may be removed.

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 11

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the effected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

(e) The Contractor agrees to insert this paragraph in all subcontracts that involve the performance of work on the terrain of the site.

H.6 Safety and Quality Control Plan

Following contract award, the contractor must provide effective quality assurance and safety plans for acceptance by the Government.

H.7 Environmental Impact

All waste materials generated by any work under the contract performed on a Government installation shall at all times be handled, transported, stored, and disposed of by the contractor and by his subcontractors in accordance with all applicable Federal, state, and local laws, ordinances, regulations, court orders, and other types of rulings having the effect of the law, including, but not limited to Executive Order 12088, 13 October 1978, Federal Compliance with Pollution Control Standards; the Federal Water Pollution Control Act, as amended (33 U.S.C.

1251 ET SEQ); the Clean Air Act as amended (42 U.S.C. Sec 7401 ET SEQ); the Endangered Species Act, as amended (16 U.S.C. Sec 1531, ET SEQ); the Toxic Substances Control Act, as amended (15 U.S.C. Sec 2601, ET SEQ); the National Historic Preservation Act, as amended (16 U.S.C. Sec 470, ET SEQ); the Solid Waste Disposal Act, as amended (42 U.S.C. 6901 ET SEQ); and the Archaeological and Historic Preservation Act, as amended (16 U.S.C. Sec 469, ET SEQ). Should the United States Government be held liable for any neglect or improper actions by the contractor or any subcontractor regarding removal or disposal of any hazardous waste, the contractor shall reimburse the Government for all such liability.

H.8 Hazardous Materials

Any material suspected of being hazardous that is encountered during performance of a project shall immediately be brought to the attention of the Contracting Officer, at which time a determination will be made as to whether hazardous material testing shall be performed. If the Contracting Officer directs the contractor to perform tests, and/or the material is found to be of a hazardous nature requiring additional protective measures, a contract modification may be required, subject to equitable adjustment under the terms of the contract. The contractor is advised that friable and/or non-friable asbestos-containing material may be encountered in project areas.

Friable asbestos-containing material is any material that contains more than one percent asbestos by weight, and that hand pressure can crumble, pulverize or reduce to powder when dry. Non-friable asbestos containing materials are materials in which asbestos fibers are bound by a matrix material, saturation, impregnation or coating.

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 12

Non-friable asbestos-containing materials do not normally release airborne asbestos fiber during routine handling and end-use. However, excessive fiber concentrations may be produced during uncontrolled abrading, sanding, drilling, cutting, machining, removal, demolition, or other similar activities. 29 CFR 1910.1001 shall be referenced in the event asbestos-containing materials are encountered. Friable asbestos-containing materials are not authorized for use in new construction or maintenance projects.

H.9 Unauthorized Personnel

The contractor shall inform all personnel working under his jurisdiction (including subcontractor and visiting supplier personnel) that access to areas outside of the immediate work area; excluding direct haul and access routes, contracting and Civil Engineering offices and points of supply and storage; is prohibited. Circulation of said personnel will be limited to official business only. Persons in violation of the above will be apprehended and appropriately disciplined.

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 13

PART II - CONTRACT CLAUSES

SECTION I: CONTRACT CLAUSES

I.1 52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/browse/index/far#

Clause Title Date 52.203-12 Limitation on Payments to Influence Certain Federal Transactions June 2020 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements January 2017

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

June 2020

52.204-13 System for Award Management Maintenance October 2018 52.204-18 Commercial and Government Entity Code Maintenance August 2020 52.204-19 Incorporation by Reference of Representations and Certifications December 2014 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities November 2021

52.209-6 Protecting the Government's Interest when Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment

November 2021

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations November 2015 52.213-4 Terms and Conditions--Simplified Acquisitions (Other Than

Commercial Products And Commercial Services) June 2023

52.215-8 Order of Precedence-Uniform Contract Format October 1997 52.219-6 Notice of Total Small Business Set Aside November 2020 52.219-28 Post-Award Small Business Program Rerepresentation September 2021 52.222-3 Convict Labor June 2003 52.222-4 Contract Work Hours and Safety Standards Act - Overtime

Compensation May 2018

52.222-9 Apprentices and Trainees July 2005 52.222-10 Compliance with Copeland Act Requirements February 1988 52.222-11 Subcontracts (Labor Standards) May 2014 52.222-12 Contract Termination-Debarment May 2014 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations May 2014

52.222-14 Disputes Concerning Labor Standards February 1988 52.222-15 Certification of Eligibility May 2014 52.222-26 Equal Opportunity September 2016 52.222-27 Affirmative Action Compliance Requirements for Construction April 2015 52.222-36 Equal Opportunity for Workers with Disabilities June 2020 52.222-37 Employment Reports on Veterans June 2020 52.222-50 Combating Trafficking in Persons October 2020 52.222-54 Employment Eligibility Verification May 2022 52.222-55 Minimum Wages For Contractor Workers Under Executive Order

14026 January 2022

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 14

52.222-62 Paid Sick Leave under Executive Order 13706 January 2022 52.223-2 Affirmative Procurement of Biobased Products under Service and

Construction Contracts September 2013

52.223-3 Alt I Hazardous Material Identification and Material Safety Data - Alternate I

July 1995

52.223-6 Drug Free Workplace May 2001 52.225-13 Restrictions on Certain Foreign Purchases February 2021 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-Representation and Certifications

June 2020

52.228-11 Individual Surety--Pledge of Assets February 2021 52.228-12 Prospective Subcontractor Requests for Bonds December 2022 52.228-14 Irrevocable Letter of Credit November 2014 52.232-5 Payments under Fixed-Price Construction Contracts May 2014 52.232-16 Progress Payments - Alternate I November 2021 52.232-23 Assignment of Claims May 2014 52.232-27 Prompt Payment for Construction Contracts January 2017 52.232-39 Unenforceability of Unauthorized Obligations June 2013 52.232-40 Providing Accelerated Payments to Small Business Subcontractors March 2023 52.233-1 Alt I Disputes - Alternate I December 1991 52.233-3 Protest After Award August 1996 52.233-4 Applicable Law for Breach of Contract Claim October 2004 52.236-5 Material and Workmanship April 1984 52.236-6 Superintendence by the Contractor April 1984 52.236-8 Other Contracts April 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements April 1984

52.236-10 Operations and Storage Areas April 1984 52.236-11 Use and Possession Prior to Completion April 1984 52.236-12 Cleaning Up April 1984 52.236-13 Accident Prevention November 1991 52.236-14 Availability and Use of Utility Services April 1984 52.236-17 Layout of Work April 1984 52.243-5 Changes and Changed Conditions April 1984 52.244-6 Subcontracts for Commercial Products and Commercial Services June 2023 52.249-1 Termination for Convenience of the Government (Fixed-Price)

(Short Form) April 1984

52.249-10 Default (Fixed-Price Construction) April 1984

I.2 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Nov 2021)

(a) Definitions. As used in this clause— Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet). Covered foreign country means The People’s Republic of China. Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 15

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or (4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 16

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L.115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement. (1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

I.3 52.222-6 Construction Wage Rate Requirements (Aug 2018)

(a) Definition.—“Site of the work”— (1) Means—

(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed; and

(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is—

(A) Located in the United States; and

(B) Established specifically for the performance of the contract or project;

(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided—

(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and

(ii) They are adjacent or virtually adjacent to the “primary site of the work” as defined in paragraph (a)(1)(i), or the “secondary site of the work” as defined in paragraph (a)(1)(ii) of this definition;

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 17

(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the “site of the work.” Such permanent, previously established facilities are not a part of the “site of the work” even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.

(b)(1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work shall be effective from the first day on which work under the contract was performed at that site and shall be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work shall be paid in accordance with the wage determination applicable to the primary site of the work.

(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.

(3) Such laborers and mechanics shall be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill, except as provided in the clause entitled Apprentices and Trainees. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein; provided that the employer’s payroll records accurately set forth the time spent in each classification in which work is performed.

(4) The wage determination (including any additional classifications and wage rates conformed under paragraph

(c) of this clause) and the Construction Wage Rate Requirements (Davis-Bacon Act) poster (WH-1321) shall be posted at all times by the Contractor and its subcontractors at the primary site of the work and the secondary site of the work, if any, in a prominent and accessible place where it can be easily seen by the workers.

(c)(1) The Contracting Officer shall require that any class of laborers or mechanics which is not listed in the wage determination and which is to be employed under the contract shall be classified in conformance with the wage determination. The Contracting Officer shall approve an additional classification and wage rate and fringe benefits therefor only when all the following criteria have been met:

(i) The work to be performed by the classification requested is not performed by a classification in the wage determination.

(ii) The classification is utilized in the area by the construction industry.

(iii) The proposed wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates contained in the wage determination

(2) If the Contractor and the laborers and mechanics to be employed in the classification (if known), or their representatives, and the Contracting Officer agree on the classification and wage rate (including the amount designated for fringe benefits, where appropriate), a report of the action taken shall be sent by the Contracting Officer to the Administrator of the:

PROJECT DESCRIPTION: Pocatello Road Grading 2023 Page 18

Wage and Hour Division U.S. Department of Labor Washington, DC 20210

The Administrator or an authorized representative will approve, modify, or disapprove every additional classification action within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.

(3) In the event the Contractor, the laborers or mechanics to be employed in the classification, or their representatives, and the Contracting Officer do not agree on the proposed classification and wage rate (including the amount designated for fringe benefits, where appropriate), the Contracting Officer shall refer the questions, including the views of all interested parties and the recommendation of the Contracting Officer, to the Administrator of the Wage and Hour Division for determination. The Administrator, or an authorized representative, will issue a determination within 30 days of receipt and so advise the Contracting Officer or will notify the Contracting Officer within the 30-day period that additional time is necessary.

(4) The wage rate (including fringe benefits, where appropriate) determined pursuant to paragraphs (c)(2) and (c)(3) of this clause shall be paid to all workers performing work in the classification under this contract from the first day on which work is performed in the classification.

(d) Whenever the minimum wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit which is not expressed as an hourly rate, the Contractor shall either pay the benefit as stated in the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent thereof.

(e) If the Contractor does not make payments to a trustee or other third person, the Contractor may consider as part of the wages of any laborer or mechanic the amount of any costs reasonably anticipated in providing bona fide fringe benefits under a plan or program; provided, That the Secretary of Labor has found, upon the written request of the Contractor, that the applicable standards of the Construction Wage Rate Requirements statute have been met. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program.

I.4 52.222-7 Withholding of Funds (May 2014)

The Contracting Officer shall, upon his or her own action or upon written request of an authorized representative of the Department of Labor, withhold or cause to be withheld from the Contractor under this contract or any other Federal contract with the same Prime Contractor, or any other federally assisted contract subject to prevailing wage requirements, which is held by the same Prime Contractor, so much of the accrued payments or advances as may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and helpers, employed by the Contractor or any subcontractor the full amount of wages required by the contract. In the event of failure to pay any laborer or mechanic, including any apprentice, trainee, or helper, employed or working on the site of the work, all or part of the wages required by the contract, the Contracting Officer may, after written notice to the Contractor, take such action as may be necessary to cause the suspension of any further payment, advance, or guarantee of funds until such violations have ceased.

I.5 52.222-8 Payrolls and Basic Records (Jul 2021)

(a) Payrolls and basic records relating thereto shall be maintained by the Contractor during the course of the work and preserved for a period of 3 years thereafter for all laborers and mechanics working at the site of the work.

Such records shall contain the name, address, and social security number of each such worker, his or her correct…