RFQ_Provisions.docx

Request for Quotation

Type of Contract: Construction, Firm Fixed Priced (FFP), Single Award Contract County: Elko County Type of Construction: Bldg Construction Projects

Magnitude:

Between $0 and $25,000.

NAICS:

238210 Electrical Contractors and Other Wiring Installation Contractors

SIZE STD:

$19M

SET-ASIDE:

Total Small Business

Quote Submittal Information:

Due Date: September 09, 2024 – 17:00 EST In accordance with this Solicitation Part IV – Representation and Instructions

Award Selection Process: Best-value, Trade-off process

Site Visit:

Lighting Panel Replacement Issuing Office: BLM Nevada State Office Location: BLM Nevada Elko District Office Solicitation Number: 140L3924Q0146 A formal site visit is not scheduled. Offerors or quoters are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award.

Table of Contents

SECTION 1 SPECIFICATIONS & GENERAL INFORMATION

Replace and program lighting panel RP1 from California Trail Center. Lighting panel shall be Greengate CKT48. ControlKeeper TouchScreen or approved equal. Only a single panel requires replacement (see attached drawing). See attached drawings & pictures for additional information on existing lighting panel. Replacement panel shall be wired and programmed to operate in same manner as existing panel. See attached drawings and pictures for further information. Panel shall be commissioned to ensure proper operation.

(a) The BLM intends to issue a single firm fixed price contract award in accordance with FAR Part 15. Award decision will be made on a best-value, trade-off process. This process permits tradeoffs among price and non-price factors and allows the Government to accept other than the lowest priced proposal. The Government may consider award to other than the lowest priced offeror or other than the highest technically rated offeror when it is in the best interest of the Government. The Government will not award any contract if the resulting contract would not represent a "best value" to the Government.

(c) To assure timely and equitable evaluation of quotations, respondents are cautioned to strictly comply with all instructions within this solicitation to ensure submission of a complete quotation. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to adhere to quotation requirements, at the time of submission, may result in the quotation being unacceptable to the Government and eliminated from consideration for award. It is the responsibility of offerors to ensure their quote is received by the recipient and by the due date and time.

(d) Offerors are cautioned to submit adequate information to enable the Government to fully ascertain each offeror’s capability to perform the requirements in accordance with the requirements of the request for quotation (RFQ).

(e) If a respondent believes that requirements in these instructions contain an error, omission, or are otherwise flawed, the respondent shall immediately notify the Contracting Officer in writing (email is the preferred method) with supporting rationale by the question deadline specified on the cover page of this document.

(f) This RFQ does not commit the Government to any costs incurred in the preparation and submission of a quote or for any other costs incurred by any firm submitting a quote in response to this solicitation. Note specifically that the Offeror will not be participating in a sealed bid procurement process under this acquisition method. Issuance of this RFQ does not constitute an award commitment on the part of the Government.

(g) Quotation must be valid for a minimum of 60 days.

(h) Respondents must complete the System for Award Management (SAM) at https://www.sam.gov/portal/public/SAM/ (previously ORCA and CCR). The Government will obtain respondent representations and certifications through this system.

(i) Award is subject to and based on the availability of funds. This project is currently funded based upon an independent cost estimate.

(j) In accordance with FAR 36.204 the Disclosure of the Magnitude of this construction project is between $0 and $25,000.

(k) Including all other factors, to qualify for award, a respondent must be determined responsible in accordance with Federal Acquisition Regulation Part 9.

(l) Respondents shall not contact any government personnel related to this requirement other than the Contracting Officer.

(m) All questions should be emailed directly to the Contracting Officer. Only written RFI’s will be considered and responded to by the Government. BLM responses to RFIs will be posted as an amendment to the solicitation.

(n) The successful Offeror shall submit appropriate Performance and Payment Bonds in accordance with clause 52.228-1 within 10 days of contract award.

QUOTATION SUBMITTAL

Failure to submit quotes according to the instructions provided within this solicitation may result in an offeror’s quote being deemed “non-responsive.” Quotes are due by the date and time specified on the cover page of this document to the Contracting Officer’s email address.

Required Documentation

Respondent shall submit the following information in response to this RFQ:

(1) Short Cover Letter:

(i) Offeror’s (company) name, address, SAM UEI, CAGE Code, and phone number

(ii) Point of contact for individuals within the company that may be contacted for this solicitation

(iii) A statement that the quote is valid for the time period set in item (g) above.

(iv) A response to the following questions:

· Judgments, Claims, and Lawsuits: Are there any judgments, claims, and/or lawsuits pending or outstanding against or involving entity or partners comprising your entity?

· No ___, Yes ___. If “Yes,” submit details of all judgments or claims against either parent office or division/branch that will be responsible for the accomplishment of this project on a separate sheet.

· Is your entity or partners comprising your entity under suspension or debarment by any Federal, state or local agency, or been terminated on any past projects (Federal or others)?

· No ___, Yes ___. If “Yes,” submit details on a separate sheet.

· IAW FAR 52.209-7(b), the offeror ___ has ___ does not have current active federal contracts and grants with a total value greater than $10,000,000.

· IAW FAR 52.204-24(d), the offeror represents that it ___ will ___ will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation

(2) Sign Standard Form (SF) 18, Request for Quotation. Please insert total price on the SF-1442 and complete and submit the attached Bid Schedule. An official having the authority to contractually bind the Offeror's company must sign the SF 18.

(3) Acknowledgement of Amendments: Acknowledge all amendments by signing and returning with your SF1442 any SF30s issued (if applicable).

(4) Complete and submit Attachment, Bid Schedule with your quote.

BASIS FOR CONTRACT AWARD

(a) This acquisition is a Small Business set-aside under the North American Industry Classification System (NAICS) Code 238220 Plumbing, Heating, and Air Conditioning Contractors with a small business size standard of $19M. An offeror determined to be other than a Small Business will be deemed ineligible for award.

(b) The Government intends to make ONE award based upon evaluation of quotes received. Award will be made to the responsible contractor whose quote conforms to all solicitation requirements, such as terms and conditions, representations and certifications, technical requirements, and provides the best value overall, with technical, past performance and price considered. The Government may consider award to other than the lowest priced offeror or other than the highest technically rated offeror when it is in the best interest of the Government.

SPECIAL CONTRACT REQUIREMENTS

Work Hours The performance period established for this contract is based upon all work being conducted during regular working hours between 7:00am and 4:00pm, Monday through Friday, excluding government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and government holidays, a request must be submitted to the Contracting Officer in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection. In addition to holidays declared by Executive Order, the following federal legal holidays are observed:

Fire Danger Season If the Contracting Officer Representative (COR) allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR. There may be some timeline constraints due to Fire Season in which the contractor shall work with The BLM for schedule coordination.

Drawings

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full-size drawings may contact the Contracting Officer identified in the solicitation.

Preservation Of Historical and Archeological Data

(a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the affected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

Progress Plan At the prework conference, the Contractor shall provide to the COR a written "work progress plan" that details it’s proposed work force and schedule to provide for orderly completion of the work within the contract performance time. This work schedule must be acceptable to the Government. At a minimum, the schedule must reflect a work progress rate equal to the available amount of contract performance time.

Pre-Work Conference After award a pre-work conference shall be held between the Contractor and the COR. The date and time of the meeting shall be determined by the COR and the Contractor in consultation. Discussions relative to contract requirements and the specific responsibilities of each party will be conducted at this time.

Environmental Interruption of Work

The Contracting Officer, by issuance of a suspend work order, may direct the Contractor to shut down any work that may be subject to damage due to weather conditions, fire danger, or because it is impracticable to work during the winter season. The Contractor will be given a resume work order which will document the date the work suspension ends. An allowance has been included in the contract time for all environmental delays. The count of contract time will therefore continue during all periods of suspension due to normal weather conditions, including fire danger. The Contractor will not be entitled to additional contract time for any suspensions except to the extent that they are due to unusually severe weather conditions. The Contractor will not be entitled to additional monetary compensation for such suspensions regardless of duration.

Environmental Impact All waste materials generated by any work under the contract performed on a Government installation shall at all times be handled, transported, stored, and disposed of by the contractor and by his subcontractors in accordance with all applicable Federal, state, and local laws, ordinances, regulations, court orders, and other types of rulings having the effect of the law, including, but not limited to Executive Order 12088, 13 October 1978, Federal Compliance with Pollution Control Standards; the Federal Water Pollution Control Act, as amended (33 U.S.C. 1251 ET SEQ); the Clean Air Act as amended (42 U.S.C. Sec 7401 ET SEQ); the Endangered Species Act, as amended (16 U.S.C. Sec 1531, ET SEQ); the Toxic Substances Control Act, as amended (15 U.S.C. Sec 2601, ET SEQ); the National Historic Preservation Act, as amended (16 U.S.C. Sec 470, ET SEQ); the Solid Waste Disposal Act, as amended (42 U.S.C. 6901 ET SEQ); and the Archaeological and Historic Preservation Act, as amended (16 U.S.C. Sec 469, ET SEQ). Should the United States Government be held liable for any neglect or improper actions by the contractor or any subcontractor regarding removal or disposal of any hazardous waste, the contractor shall reimburse the Government for all such liability.

Green Procurement Requirements

In the performance of this service or construction contract, the Contractor shall make maximum use of products identified on the mandatory environmental purchasing list at the following links, if applicable:

· U.S. EPA Comprehensive Procurement Guidelines published at https://www.epa.gov/smm/comprehensive-procurement-guideline-cpg-program

· USDA Biobased product listings published at www.biopreferred.gov.

· Energy Star® product listings published at www.energystar.gov/products.

· FEMP Low Standby Power product listings published at http://energy.gov/eere/femp/covered-product-categories

Contractor shall comply with all reporting requirements stated in the applicable clause(s):

· 52.223-1 Biobased Product Certification

· 52.223-2 Affirmative Procurement of Biobased Products under Service and Construction Contracts

· 52.223-4 Recovered Material Certification

· 52.223-9 Estimate of Percentage of Recovered Material Content for EPA Designated Items

· 52.223-15 Energy Efficiency in Energy-Consuming Products

· 52.223-17 Affirmative Procurement of EPA Designated Items in Service and Construction Contracts

SECTION 2 CONTRACT CLAUSES

Clauses Incorporated by Reference

Apr 2015

Contracts

Aug 2018

Dec 1991

Clauses Incorporated by Full Text 52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment Nov 2021

(a) Definitions. As used in this clause— Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People’s Republic of China.

Covered telecommunications equipment or services means–

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means–

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing—

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial products or commercial services.

Electronic Invoicing and Payment Requirements- Invoice Processing Platform (IPP)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

Format and Content:

Each invoice shall be submitted on the Contractor’s letterhead or invoice form with the following:

A Progress Report (may be included in Progress Meeting Notes) shall be submitted to support each invoice and shall include a summary of work performed during the period of performance identified on the invoice, which at a minimum must include:

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its quotation.

Local Internet Payment Platform (IPP) Hotline To check payment status, contact the Payment Hotline at 877-480-9724 or 303-236-2850. You will need to leave a message with the following information:

1. Company Name

2. Contract Number

3. Invoice Number

4. Invoice Amount

5. A brief description of why you are calling

6. Your contact information

If you do not receive a callback from the Payment Hotline within 72 hours, please contact the Contract Officer with the day and time you contacted the Payment Hotline.

52.211-10 Commencement, Prosecution, and Completion of Work Apr 1984, Alternate 1 Apr 1984 The Contractor shall be required to

(a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and

(c) complete the entire work ready for use not later than 90 calendar days. The time stated for completion shall include final cleanup of the premises.

52.225-9 Buy American - Construction Materials Oct 2022

(a) Definitions. As used in this clause— Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is–

(i) A commercial product (as defined in paragraph (1) of the definition of “commercial product” at Federal Acquisition Regulation (FAR) 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

"Construction material" means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Critical component means a component that is mined, produced, or manufactured in the United States and deemed critical to the U.S. supply chain. The list of critical components is at FAR 25.105.

Critical item means a domestic construction material or domestic end product that is deemed critical to U.S. supply chain resiliency. The list of critical items is at FAR 25.105.

Domestic construction material means—

(1) For construction material that does not consist wholly or predominantly of iron or steel or a combination of both-

(i) An unmanufactured construction material mined or produced in the United States; or

(ii) A construction material manufactured in the United States, if– (A)The cost of its components mined, produced, or manufactured in the United States exceeds 60 percent of the cost of all its components, except that the percentage will be 65 percent for items delivered in calendar years 2024 through 2028 and 75 percent for items delivered starting in calendar year 2029. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic. Components of unknown origin are treated as foreign; or

(B) The construction material is a COTS item; or

(2) For construction material that consists wholly or predominantly of iron or steel or a combination of both, a construction material manufactured in the United States if the cost of foreign iron and steel constitutes less than 5 percent of the cost of all components used in such construction material. The cost of foreign iron and steel includes but is not limited to the cost of foreign iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the construction material and a good faith estimate of the cost of all foreign iron or steel components excluding COTS fasteners. Iron or steel components of unknown origin are treated as foreign. If the construction material contains multiple components, the cost of all the materials used in such construction material is calculated in accordance with the definition of "cost of components".

Fastener means a hardware device that mechanically joins or affixes two or more objects together. Examples of fasteners are nuts, bolts, pins, rivets, nails, clips, and screws.

Foreign construction material means a construction material other than a domestic construction material.

Foreign iron and steel means iron or steel products not produced in the United States. Produced in the United States means that all manufacturing processes of the iron or steel must take place in the United States, from the initial melting stage through the application of coatings, except metallurgical processes involving refinement of steel additives. The origin of the elements of the iron or steel is not relevant to the determination of whether it is domestic or foreign.

Predominantly of iron or steel or a combination of both means that the cost of the iron and steel content exceeds 50 percent of the total cost of all its components. The cost of iron and steel is the cost of the iron or steel mill products (such as bar, billet, slab, wire, plate, or sheet), castings, or forgings utilized in the manufacture of the product and a good faith estimate of the cost of iron or steel components excluding COTS fasteners.

Steel means an alloy that includes at least 50 percent iron, between 0.02 and 2 percent carbon, and may include other elements.

"United States" means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C.chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the domestic content test of the Buy American statute is waived for construction material that is a COTS item, except that for construction material that consists wholly or predominantly of iron or steel or a combination of both, the domestic content test is applied only to the iron and steel content of the construction materials, excluding COTS fasteners. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial product or to the construction materials or components listed by the Government as follows:

________________________________________________[Contracting Officer to list applicable excepted materials or indicate "none"]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that- (i)The cost of domestic construction material would be unreasonable.

(A) For domestic construction material that is not a critical item or does not contain critical components.

(1)The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent;

(2)For construction material that is not a COTS item and does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that is manufactured in the United States and does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest offer of foreign construction material that exceeds 55 percent domestic content as a domestic offer and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(A)(1) of this clause.

(3)The procedures in paragraph (b)(3)(i)(A)(2) of this clause will no longer apply as of January 1, 2030.

(B) For domestic construction material that is a critical item or contains critical components.

(1)The cost of a particular domestic construction material that is a critical item or contains critical components, subject to the requirements of the Buy American statute, is unreasonable when the cost of such material exceeds the cost of foreign material by more than 20 percent plus the additional preference factor identified for the critical item or construction material containing critical components listed at FAR 25.105.

(2)For construction material that does not consist wholly or predominantly of iron or steel or a combination of both, if the cost of a particular domestic construction material is determined to be unreasonable or there is no domestic offer received, and the low offer is for foreign construction material that does not exceed 55 percent domestic content, the Contracting Officer will treat the lowest foreign offer of construction material that is manufactured in the United States and exceeds 55 percent domestic content as a domestic offer, and determine whether the cost of that offer is unreasonable by applying the evaluation factor listed in paragraph (b)(3)(i)(B)(1) of this clause.

(3)The procedures in paragraph (b)(3)(i)(B)(2) of this clause will no longer apply as of January 1, 2030.

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

[* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued)].

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.]

52.228-15 Performance and Payment Bonds-Construction. Jun 2020

(a) Definitions. As used in this clause- Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is valued at or below the threshold specified in Federal Acquisition Regulation 28.102-1(a) on the date of award of this contract, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds ( Standard Form 25). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment Bonds ( Standard Form 25A). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection.

(i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the:

U.S. Department of the Treasury, Financial Management, Service Surety Bond Branch, 3700 East West Highway, Room 6 F01, Hyattsville, MD 20782.

Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection ( 40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

(End of clause) 52.236-4 Physical Data Apr 1984 Data and…