RFQ 1333ND23QNB190204.pdf

REQUEST FOR QUOTATION

(THIS IS NOT AN ORDER)

THIS RFQ IS IS NOT A SMALL BUSINESS SET-ASIDE

15. DATE OF QUOTATION

16. SIGNER

a. NAME (Type or print)

c. TITLE (Type or print)

b. TELEPHONE

AREA CODE

NUMBER

STANDARD FORM 18 (REV. 6-95) Prescribed by GSA-FAR (48 CFR) 53.215-1(a)

AUTHORIZED FOR LOCAL REPRODUCTION

Previous edition not usable

8. TO:

b. COMPANYa. NAME

c. STREET ADDRESS

d. CITY e. STATE f. ZIP CODE

9. DESTINATION

a. NAME OF CONSIGNEE

b. STREET ADDRESS

c. CITY

d. STATE e. ZIP CODE

7. DELIVERY

FOB DESTINATION

OTHER

(See Schedule)

10. PLEASE FURNISH QUOTATIONS TO THE

ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS (Date)

IMPORTANT: This is a request for information and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or service. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this Request for Quotation must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State and local taxes)

ITEM NUMBER

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e)

AMOUNT

(f)

12. DISCOUNT FOR PROMPT PAYMENT

a. 10 CALENDAR DAYS (%) b. 20 CALENDAR DAYS (%) c. 30 CALENDAR DAYS (%) d. CALENDAR DAYS

NUMBER PERCENTAGE

NOTE: Additional provisions and representations are are not attached.

13. NAME AND ADDRESS OF QUOTER

a. NAME OF QUOTER

b. STREET ADDRESS

c. COUNTY

d. CITY e. STATE f. ZIP CODE

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

PAGE OF PAGES

1. REQUEST NUMBER 2. DATE ISSUED 3. REQUISITION/PURCHASE REQUEST NUMBER 4. CERT. FOR NAT. DEF.

UNDER BDSA REG. 2

AND/OR DMS REG. 1

RATING

5a. ISSUED BY 6. DELIVER BY (Date)

5b. FOR INFORMATION CALL (NO COLLECT CALLS)

NAME TELEPHONE NUMBER

AREA CODE NUMBER

SCHEDULE Continued

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

Base year of contract

0001 Passenger and freight traction elevators annual maintenance inspection (no load tests)

PR NUMBER: NB193000-23-01439

DELIVERY DATE: 04/30/2024

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination Period of Performance: 05/01/2023 to 04/30/2024

24.00 EA

Base year

0002 Passenger and freight hydraulic elevators annual maintenance inspection (no load tests)

PR NUMBER: NB193000-23-01439

DELIVERY DATE: 04/30/2024

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

18.00 EA

0003 Material and incline Lifts / Dumb waiters annual maintenance inspections

PR NUMBER: NB193000-23-01439

DELIVERY DATE: 04/30/2024

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

5.00 EA

0004 Unscheduled elevator maintenance inspection (no load test)

PR NUMBER: NB193000-23-01439

DELIVERY DATE: 04/30/2024

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

0005 Unscheduled elevator maintenance inspection (with load test)

PR NUMBER: NB193000-23-01439

PAGE 2 OF 293 1333ND23QNB190204

DELIVERY DATE: 04/30/2024

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

OPTION 1

OPT

1001 Passenger and freight traction elevators annual maintenance inspection (with load tests)

DELIVERY DATE: 04/30/2025

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination Period of Performance: 05/01/2024 to 04/30/2025

1002 Passenger and freight hydraulic elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2025

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

1003 Material and incline Lifts / Dumb waiters annual maintenance inspections

DELIVERY DATE: 04/30/2025

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

1004 Unscheduled elevator maintenance inspection (no load test)

DELIVERY DATE: 04/30/2025

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

PAGE 3 OF 293 1333ND23QNB190204

1005 Unscheduled elevator maintenance inspection (with load test)

DELIVERY DATE: 04/30/2025

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

OPTION 2

2001 Passenger and freight traction elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2026

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination Period of Performance: 05/01/2025 to 04/30/2026

2002 Passenger and freight hydraulic elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2026

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

2003 Material and incline Lifts / Dumb waiters annual maintenance inspections

DELIVERY DATE: 04/30/2026

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

2004 Unscheduled elevator maintenance inspection (no load test)

PAGE 4 OF 293 1333ND23QNB190204

DELIVERY DATE: 04/30/2026

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

2005 Unscheduled elevator maintenance inspection (with load test)

DELIVERY DATE: 04/30/2026

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

OPTION 3

3001 Passenger and freight traction elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2027

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination Period of Performance: 05/01/2026 to 04/30/2027

3002 Passenger and freight hydraulic elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2027

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

3003 Material and incline Lifts / Dumb waiters annual maintenance inspections

DELIVERY DATE: 04/30/2027

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

PAGE 5 OF 293 1333ND23QNB190204

GAITHERSBURG MD 20899-0001

3004 Unscheduled elevator maintenance inspection (no load test)

DELIVERY DATE: 04/30/2027

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

3005 Unscheduled elevator maintenance inspection (with load test)

DELIVERY DATE: 04/30/2027

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

OPTION 4

4001 Passenger and freight traction elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2028

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination Period of Performance: 05/01/2027 to 04/30/2028

4002 Passenger and freight hydraulic elevators annual maintenance inspection (no load tests)

DELIVERY DATE: 04/30/2028

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

4003 5.00 EA

PAGE 6 OF 293 1333ND23QNB190204

Material and incline Lifts / Dumb waiters annual maintenance inspections

DELIVERY DATE: 04/30/2028

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

4004 Unscheduled elevator maintenance inspection (no load test)

DELIVERY DATE: 04/30/2028

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

4005 Unscheduled elevator maintenance inspection (with load test)

DELIVERY DATE: 04/30/2028

SHIP TO:

NATIONAL INST OF STDS AND TECHNOLOGY

BUILDING 301 SHIPPING AND RECEIVING

100 BUREAU DRIVE

GAITHERSBURG MD 20899-0001

FOB : Destination

PAGE 7 OF 293 1333ND23QNB190204

Table of Contents

Statement of Work

Attachment A

Elevator data log (inventory)

Guidelines for Contractors and A&E Firms

NIST Suborders, Policies, and Notices

Outline of a Safety and Health Plan

52.202-1DEFINITIONS (JUN 2020)

52.203-7ANTI-KICKBACK PROCEDURES (JUN 2020)

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.204-12 UNIQUE ENTITY IDENTIFIER MAINTENANCE (OCT 2016)

52.204-13SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014)

52.212-4CONTRACT TERMS AND CONDITIONS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (DEC 2022)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUNE 2013)

52.232-40PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (MAR 2023)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.244-6SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (MAR 2023)

52.204-24REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR EQUIPMENT

(NOV 2021)

52.204-25PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE SERVICES OR

EQUIPMENT (NOV 2021)

52.204-26COVERED TELECOMMUNICATIONS EQUIPMENT OR SERVICES--REPRESENTATION (OCT 2020)

52.212-3OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (DEC

2022)

52.212-5CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS--COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES (MAR 2023)

52.216-24 LIMITATION OF GOVERNMENT LIABILITY (APR 1984)

52.219-1SMALL BUSINESS PROGRAM REPRESENTATIONS (MAR 2023)

52.225-25PROHIBITION ON CONTRACTING WITH ENTITIES ENGAGING IN CERTAIN ACTIVITIES OR TRANSACTIONS RELATING

TO IRAN--REPRESENTATION AND CERTIFICATIONS (JUN 2020)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

1352.201-72 CONTRACTING OFFICER`S REPRESENTATIVE (COR) (APR 2010)

NIST LOCAL-53CONTRACT PERFORMANCE DURING CHANGES IN NIST OPERATING STATUS

NIST LOCAL-54ELECTRONIC BILLING INSTRUCTIONS

NIST LOCAL-56INVOICING PROCESSING PLATFORM-ALTERNATE I (DEC 2022)

Instructions to Quoters

Evaluation-Basis for Award

PAGE 8 OF 293 1333ND23QNB190204

CLAUSES

Statement of Work

PAGE 9 OF 293 1333ND23QNB190204

GAITHERSBURG CAMPUS WIDE ELEVATOR ANNUAL CERTIFICATION INSPECTION

Statement of Work (SOW)

Background

NIST has multiple elevators in multiple buildings across Gaithersburg campus. These elevators, and man lifts, and stairwell lifts all require OSHA required annual inspections. The different types of elevators and their respective weight limits are listed individually in a separate attachment. (see attachment A). We require each one of these items to be inspected for OSHA safety requirements.

These inspections are required IAW Standards-29 CFRR, para 1917.116(e) and ASME A17.2

Objectives The contractor shall arrange to have an inspector onsite to observe work being performed on our elevators ensuring all work meets or exceeds standards IAW Standards-29-CFRR, para 1917.116(e) and ASME A17.2. These inspections will be performed once annually, or as needed in the event of an unplanned outage of service.

Scope The contractor shall provide an inspector to oversee the NIST elevator maintenance staff perform the required annual maintenance as per ASME A17.2 and attest to the safe operability and status of the same elevator, in the form of a required certificate of compliance.

The machines are either Hollister-Whitney for traction or Cemco for hydraulic type.

The controls there are MCE, IMCAC, Motion 2000, 4000, I-box for traction type, and Virginia controls, relay logic, and PLC for hydraulic type.

Tasks The following is a list of tasks necessary to complete the annual inspections:

1. Contact COR at a minimum of one month in advance to schedule annual inspection visit.

2. Work alongside NIST elevator maintenance personnel for the duration of the inspection.

3. Document all inspections, and issue a “Certification of Inspection,” IAW CFR 29, para

1917.116(e). Supply such inspection reports in digital format to the COR NLT 14 days after completion of inspection.

4. Perform full load test of all traction elevators at least once every five years, or prior to putting elevator back into service following a major outage of 30 days or more.

5. Inspection will include all the items outlined in the checklist provided in ASME A17.2.

Requirements

1. The contractor shall provide verification of employment and individual’s GSA inspection certifications, as well as a “current” QEI credential.

2. Contractor shall submit a sample inspection checklist.

3. Contractor shall submit a sample certification of inspection for official review.

PAGE 10 OF 293 1333ND23QNB190204

Deliverables The Contractor shall submit all deliverables to:

National Institute of Standards and Technology 100 Bureau Drive Building 301, Room A100 Gaithersburg, MD 20899 Attn: Kenneth Bishop, Contract Officer’s Representative, COR kenneth.bishop@nist.gov extn 6952

(1) Health and safety plan – shall be submitted within seven (7) calendar days after award of contract.

(2) Insurance Certificate – shall be submitted within ten (10) calendar days after award of contract.

(3) Payment Bonds – shall be submitted within ten (10) calendar days after award of contract.

(4) Certified Payroll – Shall be submitted with every invoice.

(5) Release of Claims – Shall be submitted with the final invoice.

Place of Performance The National Institute of Standards and Technology at its main campus located at 100 Bureau Drive, Gaithersburg, Maryland.

Security NIST is a Federal facility and access is controlled at all entrances to the campus. Only Government employees may grant access to non-Government employees. All non-Government employees must be registered with security prior to site access. Contractor shall notify COR a minimum of 72 hours prior to site access. Contractor shall provide COR with first and last names, country of citizenship, and whether the individual has a permanent resident card, (a.k.a. Green Card), of all personnel requiring site access. If any individuals are here on a work visa, they will need to complete a NIST 1260 form and return to the COR. Please refer to the following web site for additional Visitor Information http://www.nist.gov/public_affairs/visitor/

Automobile & Personnel Access:

Contractor personnel arriving in cars on their first day must check in at the visitor center to receive a temporary paper badge prior to proceeding to the project site. Hours of operation of the visitor center are 0600-1700. Once in possession of a valid NIST badge, workers may enter via the Main Gate (on W Diamond Ave and Bureau Dr) or Gate “C” (on Quince Orchard Rd and Sound Rd) and proceed to the project site. Note that all automobiles are subject to a random inspection.

Trucks: All Trucks are to enter NIST via “C” Gate along Quince Orchard Rd. between 6:00 am and 3:30 pm daily, and at the main gate off of W. Diamond Ave. between 3:30 pm and 4:30 pm. No deliveries will be allowed after 4:30 pm. “Trucks” include such vehicles as pick-ups with storage compartments, delivery trucks, delivery vans, and tractor center. Trucks arriving through Gate C will be directed to the Building 301 Truck Inspection Station. At Building 301, trucks will be registered, inspected, and the drivers will be granted access. Any truck which exits the installation will have to be re-inspected upon re-entry at Building 301. A vehicle dashboard placard will be placed within the truck. Placards change daily.

PAGE 11 OF 293 1333ND23QNB190204

All work expected to take place during business hours. Monday through Friday 6:00 a.m. to 6:00 p.m.

Work schedule outside business hours must be approved by the Contracting Officer Representative and the Contracting Officer.

Work will not take place during federal holidays. Fed holidays are.

Christmas, Thanksgiving, Independence Day, Presidents Day, Memorial Day, Labor Day, New Year’s, Veterans Day, Columbus Day, MLK, & Juneteenth

NIST Truck Inspection Stations hours are:

6:00am -3:30pm at Building 301 3:30 pm – 4:30pm at “A” Gate – (Main gate)

Attachment A

PAGE 12 OF 293 1333ND23QNB190204

Annual Elevator Inspection Data Number Bldg Type Car Name Hydraulic Traction Wt limit (Lbs) Status

1 101 Passenger Car #1 X 3,000

2 101 Passenger Car #2 X 3,000

3 101 Passenger Car #3 X 3,000

4 101 Passenger Car #4 X 3,000

5 101 Passenger Car #5 X 3,000

6 101 Passenger Car #6 X 2,000

7 101 Passenger Car #7 X 3,000

8 101 Passenger Car #8 X 3,000

9 101 Incline Lift #1 450

10 101 Incline Lift #2 450

11 202 Passenger/Freight #1 X 10,000

12 202 Material Lift (Drum Wound) 1,000

13 205 Passenger #1 X 3,500

14 208 Incline Lift #1 600

15 215 Passenger/Freight #1 X 10,000

16 215 Freight #2 X 10,000

17 217 Passenger #3 X 3,500

18 217 Passenger #4 X 3,500

19 217-219 Freight #5 X 30,000

20 216-218 Passenger #6 X 3,500

21 216 Passenger #8 X 3,500

22 217-219 Material Lift #1 X 10,000

23 215 Dumb Waiter #1 (Drum Wound) 500

24 220 Passenger #1 X 6,000

25 220 Passenger #2 X 3,500

26 221 Passenger #1 X 6,000

27 221 Passenger #2 X 3,500

PAGE 13 OF 293 1333ND23QNB190204

28 222 Passenger #1 X 6,000

29 222 Passenger #2 X 3,500

Annual Elevator Inspection Data Number Bldg Type Car Name Hydraulic Traction Wt limit Status

30 223 Passenger #1 X 6,000

31 223 Passenger #2 X 3,500

32 224 Passenger #1 X 6,000

33 224 Passenger #2 X 3,500

34 225 Passenger #1 X 6,000

35 225 Passenger #2 X 3,500

36 226 Passenger #1 X 6,000

37 226 Passenger #2 X 3,500

38 227 Passenger #1 X 3,000

39 227 Passenger #2 X 3,000

40 227 Freight #3 X 10,000

41 231 Freight #1 X 5,000

42 235 Freight #1 X 8,000

43 235 Passenger #2 X 3,000

44 235 Passenger #3 X 2,500

45 235 Passenger #4 X 2,500

46 235 Freight #5 X 3,500

47 304 Freight #1 X 20,000

48 245 Freight #1 X 40,000 a,b,c

49 245 Freight #2 X 40,000 a,b,c

50 245 Passenger #3 X 3,500 a,b,c

51 245 Passenger #4 X 3,500 a,b,c

52 245 Freight #5 X 40,000 a,b,c

53 245 Passenger #6 X 3,500 a,b,c

Elevator data log (inventory)

Guidelines for Contractors and A&E Firms

PAGE 14 OF 293 1333ND23QNB190204

Facilities Engineering, OFPM/ Design and Construction Division

GUIDELINES FOR OFPM CONTRACTORS

AND

A/E FIRMS

PERFORMING SITE INVESTIGATIONS

AND

FIELDWORK (including construction)

AT THE

NATIONAL INSTITUTE OF STANDARDS AND

TECHNOLOGY

GAITHERSBURG, MD

Revised date: April 13, 2022

PAGE 15 OF 293 1333ND23QNB190204

TABLE OF CONTENTS

Title Page

1. Emergencies

2. Safety Equipment

3. Investigation Equipment

4. Mechanical/Electrical Rooms

5. Confined Space Entry

6. Utility Outages, Road Blockages

7. Hazards

8. Corridors

9. Operating Equipment

10. Fire Protection

11. Internal Combustion Equipment

12. Asbestos

13. Safety and Health Compliance

14. Work Safety

15. Site Access and Working Hours

16. Excavation and Trenching Activities

17. Environmental Management

18. Scrap Building Materials Disposal

19. Electrical Safety

20. Daily Reports

21. Adverse Weather

22. Grass within Contractor Area

23. Building 101 Restricted Activities

24. Exterior Construction Sites and Storage

25. Restoration of Exterior Construction Site

26. Tours of Construction Site

27. Ground Penetrating Radar in Existing Structures

28. As-Built and/or Red Line Drawings

29. Operations and Maintenance Equipment Manuals ……………………………………….11

30. Roof Access ……………………………………………………….………………………………..………. 11

31. Security Badges

32. Designer – Historical Requirements

33. Temporary Exterior Power

34. Security Plan 16

35. FAR Clause 48 CFR 1352.237-71 Security Processing Requirements –

Low Risk Contracts (APR 2010) 17

PAGE 16 OF 293 1333ND23QNB190204

1. Emergencies:

In case of emergency, call x2222 from a campus phone. State your name, building location, room number, and a description of the emergency. The NIST Fire Protection Group provides fire and ambulance service on site. If a phone other than NIST (975 exchange) is used, "911" should be used for emergency calls. The contractor shall state that he/she is located at NIST and give the details as described above. Contractors should become familiar with the NIST Gaithersburg Occupant Emergency Plan, issued September 2012.

2. Safety Equipment:

Personal Protective Equipment (PPE) such as head, eye, foot, respiratory, and ear protection shall be worn in identified areas. Hard hats, for example, shall be worn in mechanical rooms. Contractors and A/E firms to provide necessary PPE of the approved type to protect themselves against exposures encountered. NIST provided dosimeters (radiation exposure measurement) may be required to be worn when working in or around specific sections of Building 235 and Building 245.

Unique safety awareness training is mandatory for working in Buildings 235 and 245.

Contractor shall plan on 2 hours of training for each employee to complete this training.

3. Investigation Equipment:

Site investigations and field work may require the use of a stepladder and/or other investigative equipment (measuring tapes, flashlights, screwdrivers, etc.). Contractors and A/E firms shall provide their own stepladders and/or investigative equipment. The stepladders shall be Type I (industrial) or Type II (commercial).

4. Mechanical/Electrical Rooms:

Obtain authorization from the Contracting Officer’s Representative (COR) prior to working in electrical and/or mechanical rooms. Lock rooms after use. For work in high-voltage rooms, a NIST high-voltage electrician must be present the entire time. Do not operate any valves, switches, or breakers without prior approval from the COR.

5. Confined Space Entry:

If a contractor or A/E must enter a confined space on the NIST site, they shall follow the applicable provisions of the OSHA Permit-Required Confined Space Regulation (29CFR1910.146). The contractor or A/E shall be responsible for implementing and documenting an entry permit system as necessary, giving full consideration to personnel training, atmospheric testing, ventilation, PPE, and emergency procedures and equipment. Should the contractor or A/E have questions regarding any confined space

PAGE 17 OF 293 1333ND23QNB190204

to be entered on the NIST site, they are to contact the COR or the Plant Division's Safety Coordinator (x6999, Bldg. 428). Copies of the contractor entry permit system shall be submitted to the COR for approval in advance.

6. Utility Outages, Road Blockages:

Do not close or partially block any roads or cause utility outages (electrical, steam, chilled water, water, compressed air, gas, sewer, telephone, fire alarm, signal systems, etc.) without prior authorization from the COR. Provide a minimum of 21 days’ written notice for all utility systems outages. Complete building outages require a 50 days writing notice. Outages to more than one building require 190 days’ notice. All outages and road closures shall be on Saturdays unless noted otherwise within the specifications or statement of work.

Site Coordination Procedures:

All construction or investigation activities that require closure of sidewalks, roads, or other transportation ways, require the contractor to submit a request for closure 21 days in advance.

7. Hazards:

Storing, positioning, and use of equipment, tools, and materials, in a manner likely to present a hazard to the public or building occupants by its accidental shifting, ignition, or other hazardous qualities is prohibited.

8. Corridors:

No corridor, aisle, stairway, door, or exit shall be obstructed or used in such a manner as to encroach upon routes of ingress or egress utilized by the public or building occupants, or to present unsafe or unhealthy conditions to the public or building occupants.

9. Operating Equipment:

Do not turn off, on, or adjust any NIST operating equipment without prior authorization from the COR. Work carefully around rotating equipment. Loosely fitting clothing (neck ties, dangling jewelry, etc.) shall not be worn when working near rotating equipment.

Long hair shall be secured. Some equipment may start automatically. (Note: It may become necessary to implement appropriate lock-out, tag-out procedures to control hazardous energy sources to ensure that personnel do not activate equipment during investigation, servicing, or maintenance.) Provisions of NFPA 70E shall be followed when an arc flash hazard exists.

PAGE 18 OF 293 1333ND23QNB190204

10. Fire Protection:

The Contractor or A/E shall comply with all applicable fire protection/prevention requirements of the National Fire Protection Association (NFPA) and the NIST Fire Protection Group. Should any operations capable of providing a source of ignition (for example welding, cutting, burning, or heating) be performed within or adjacent to NIST buildings/structures/equipment, a hot work permit must be obtained from the NIST Fire Protection Group (301-975-6190) prior to such work. Covering of room smoke, heat, or other NFPA 72 defined initiating devices or notification devices is only allowed with advance written approval from the COR.

11. Internal Combustion Equipment:

Such equipment will not be allowed within any building without prior written approval.

Gasoline or diesel powered equipment (such as fork lifts, loaders, tractors, cutting saws, etc.) will not be authorized for use within any building in any circumstance.

12. Asbestos:

Some ductwork and piping may be insulated with asbestos containing materials (ACM).

Contact the Plant Division Safety Coordinator (x6999) prior to disturbing suspected ACM. ACM may also be present in floor tile, bench tops, and/or plaster ceilings.

1) If more than three (3) ceiling tiles must be removed at one time in a single location, the Plant Division Safety Coordinator must be notified beforehand so she can review the task to be performed and ensure all safety requirements are adhered to. Contractors shall provide 7 calendar days’ notice.

2) Whenever a ceiling tile of any kind is removed, it must be removed slowly and as level as possible. Workers need to check as soon as they can see on top of the tile if there is any debris laying on top, such as a piece of pipe insulation or other bldg materials in general. If there is debris, the worker should re-install the tile and notify his supervisor and COR so the proper measure can be taken to remove whatever debris is found.

3) All contractors at a minimum must wear the following Personnel Protective Equipment while working on/in/above the ceiling and/or removing ceiling tiles:

* Safety glasses with side shields or goggles

* Leather gloves or the Mechanics Red Gloves

4) It is strictly prohibited to perform any type of "aggressive activity" that could break the encapsulate seal or agitate the air above the hallway or concourse ceilings. Examples of "aggressive activity" include - dragging conduit or pipes over ceiling tiles; hammer drilling into the columns; removing numerous ceiling tiles at one

PAGE 19 OF 293 1333ND23QNB190204

time; striking against pipes or pipe insulation; dropping items on top of ceiling tiles; and numerous workers above the ceiling at one time performing various tasks.

13. Safety and Health Compliance:

Contractors and A/E firms shall adhere to all applicable OSHA, NFPA, NEC and NIST safety and occupational health regulations while on site. Federal OSHA (Baltimore area office) has safety jurisdiction at federal facilities in the State of Maryland. The NIST local contact is the OFPM Safety Coordinator (Bldg. 428 301-975-6999).

All contractors are required to wear safety glasses. All contractors working at Buildings 235 and/or 245 are subject to a 2 hour radiation awareness training session.

If any chemicals, hazardous materials, equipment or materials are found in a lab or other contract space, the contractor shall notify the COR so arrangement can be made to have the items removed. Work shall not continue until the items have been cleared by others; Contractors are not to move any chemicals, materials or equipment in any lab.

Contractors are required to submit health and safety plans within 15 days of solicitation award. Health and safety plans are to be specific to the solicitation requirements.

Safety plan shall be contract specific and follow activity hazard analysis (AHA) format.

All roof construction shall be in accordance with U.S. Army Corps USACE EM-385-1-1 “Safety and Health Requirements Manual“ (current edition).

14. Work Safety:

The contractor shall take all necessary precautions to prevent injury to personnel, the public, building occupants, and damage to property of others. If unsafe work practices are observed, unsafe work may be stopped by the NIST OFPM Safety Officer and/or COR until corrections are made.

15. Site Access and Working Hours:

NIST is a Federal facility and access is controlled at all entrances to the campus. Only Government employees may grant access to non-Government employees.

Vehicles Access:

Automobiles: Contractor personnel arriving in cars on their first day must check in at the visitor center to receive a temporary badge prior to proceeding to the project site to obtain permanent badge. Hours of operation of the visitor center are 0600-1700. Once in possession of a valid NIST badge, workers may enter via the Main Gate or Gate “C”

PAGE 20 OF 293 1333ND23QNB190204

and proceed to the project site. Note that all automobiles are subject to a random inspection.

Trucks: All Trucks are to enter NIST via “C” Gate along Quince Orchard Rd. between 6:00 am and 3:30 pm daily, and at the main gate off of W. Diamond Ave. between 3:30 pm and 4:30 pm. No deliveries will be allowed after 4:30 pm. “Trucks” include such vehicles as pick-ups with storage compartments, delivery trucks, delivery vans, and tractor trailers. Trucks arriving through Gate C will be directed to the Building 301 Truck Inspection Station. At Building 301, trucks will be registered, inspected, and the drivers will be granted access. Any truck which exits the installation will have to be re-inspected upon re-entry at Building 301. A vehicle dashboard placard will be placed within the truck. Placards change daily.

NIST Truck Inspection Stations hours are:

6:00am -3:30pm at Building 301 3:30 pm – 4:30pm at “A” Gate – (Main gate)

Parking: Loading docks are for loading and unloading equipment and materials. Do not park at or near loading docks or the space between buildings. All Contractors vehicles and personal vehicles are to use the building parking lots or parking lots designated by the Contracting Officer for construction contractors.

Speeding: NIST speed limit is posted on the campus. If a speeding ticket is issued, the offender may be required to appear in Federal Court.

Responsibility: When deliveries are made, the Contractor is responsible providing information and directions to the driver to proceed to the work area and for unloading.

NIST will not be responsible for delivering contractor materials to the project site or for unloading materials.

Hours of Operation: NIST opens at 6:00 am (sharp) until 6: 00 pm for Contractors who do not have 24-hour access privileges.

Normal work hours defined in the contract are 7:30 AM to 5:30 PM.

All work over 80 dBA measured at 15 feet shall occur after normal work hours.

Contractor shall have a meter on hand to measure dBA.

Painting Hours: All painting shall be per the SOW and/or specifications. If not stated, all painting shall be done from 5:30 PM to 11:00 PM Monday to Friday. Painting on weekends from 6 AM to 4 PM shall be scheduled through the COR, with at least seven days’ notice.

PAGE 21 OF 293 1333ND23QNB190204

16. Excavation and Trenching Activities:

Excavation and trenching activities are not permitted without prior written authorization from the COR. Contractor is responsible for locating and identifying all utilities via contract personnel with utility locating devices. Contractor shall turn over a utility marking report plotted on the appropriate construction drawings to the COR within 7 days.

17. Environmental Management:

NIST will conduct its operations in an environmentally sound manner. NIST’s Environmental Management System (EMS) has been established based on the requirements of the International Organization of Standards (ISO14001). All firms contracted by NIST shall review and be familiar with the NIST Environmental Policy and significant aspects of the NIST EMS, which may be accessed at http://www.nist.gov/public_affairs/envpolicy.cfm

All contractors who provide products and services to NIST shall comply with all applicable environmental regulations, conduct their work using environmentally sound practices, and assess options that will result in the least environmental impacts. The Maryland Department of Environment (MDE) will inspect and enforce sediment control and storm water management regulations and practices for projects at NIST.

18. Scrap Building Materials Disposal

In order to reduce disposal volumes of clean scrap wood based building materials taken to landfill dump, segregate such materials and dispose of the materials and dispose of the materials using one or a combination of the following methods.:

Arrange for recycling of materials or provide to companies that receive wood for disposal in biomass to energy facilities.

It is NIST Policy to recycle construction demolition materials and debris to the greatest extent practicable. All NIST contractors shall strive to meet the goal of recycling 50% of construction demolition materials and debris as specified in Executive Order 13514.

Contractor shall store recyclable waste in separate clearly marked containers.

Recyclable items include, wood, glass, aluminum, steel, gypsum, paper, cardboard, and plastics.

PAGE 22 OF 293 1333ND23QNB190204

19. Electrical Safety:

All contractors shall comply with current edition of NFPA 70E “Standard for Electrical Safety in the Workplace.” If the Contractor selects to work on energized equipment, Contractor shall have a documented permit system for working on energized electrical equipment.

20. Daily Reports

Contractor shall provide to COR a daily report of all major activities, personnel on site (includes all subcontractors), major deliveries, and major tools and equipment on site.

Contractor shall inform the COR in writing ten days in advance when painting, new carpet installation, glue applications, using a cleaning solvent, large amount of grinding or core drilling is planned.

21. Adverse Weather

To request an adverse weather time extension, the weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month. The Request must be made no more than 30 days after the event.

The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) at Ronald Reagan Airport and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Jan Feb Mar Apr May June July Aug Sept Oct Nov Dec 8 6 8 6 8 7 7 6 6 6 6 7

For roofing projects, contractors will be permitted to work on Saturdays (if the contractor elects to do so) providing they provide the COR four days’ notice. Rain on Saturdays and Sundays are not factored into adverse weather delays for any contract, PAGE 23 OF 293 1333ND23QNB190204 unless that contract explicitly required all work to be completed on Saturdays and/or Sundays.

22. Grass within Contractor Area

Grass within the contractor’s area of control (i.e. – lay down area, construction site, etc.)

shall be maintained to a height of no more than 18 inches.

23. Building 101 Restricted Activities

For two days (total of four (4)) in the months of October and April the contractor will be prevented from completing any work in the courtyards, streets, sidewalks in and around Building 101. In addition, service/construction or other related activities will be prevented from occurring. COR will provide the contractor two days’ notice of the implementation of this restriction.

24. Exterior Construction Sites and Storage

Exterior construction sites and storage areas shall have woven galvanized steel fabric fencing with steel posts installed during the construction period. Fencing shall surround the entire construction site the contractor is working within. Fencing shall be at a minimum 8 feet tall. Provide opaque fence slats. Slat color shall be dark green/forest green. Fencing sections shall be bound together with mechanical fasteners. Posts shall be suitable for setting in concrete footings, driving into ground, anchoring with base plates, or inserting in precast concrete blocks. Provide a minimum of 3 ft spacing around fire hydrants and/or hose connections. Provide a minimum 20 foot gate for emergency vehicle access.

25. Restoration of Exterior Construction Site

The contractor shall restore the entire construction site(s) at the completion of all contract work. This shall include removing all debris and stones of 2 inches or from the subsoil to a depth of 8 inches regardless of the condition the site was turned over to the contractor. Seeding shall be completed by the contractor once all debris and noted stones are removed from the topsoil.

26. Tours of Construction Site

Any tours or presentations related to a contract by the contractor shall be submitted at a minimum of 30 days in advance to the COR. The contractor shall provide the following the information for review:

a) Purpose of the Tour/Presentation

b) Time of tour/presentation

PAGE 24 OF 293 1333ND23QNB190204

c) Number of attendees

d) Names of each attendee

e) Name of each attendee’s employer

f) Address of each attendee’s employer

g) Indicate if US Citizen, US Permanent Resident Alien, or foreign national

27. Ground Penetrating Radar in Existing Structures

Prior to core boring, drilling, or otherwise penetrating existing floors or walls within facilities the contractor shall clear the area with ground penetrating radar. COR shall observe the test report and/or the identification prior to penetrating the floor, wall, or proposed penetration location.

28. As-Builts and/or Red Line Drawings

Contract specified as-builts and/or red line drawings shall be provided in the following form:

• hard copies on Arch D (24”x36”) format, electronic copies on CD disk (adobe PDF, AutoCAD).

29. Operation and Maintenance Equipment Manuals

Contract operation and maintenance equipment manuals must be provided in the following form:

• hard copies in bound or spiral binders. Any drawings supplied in the binders shall not be larger than 11” x 17” and shall be folded to fit inside the binders.

• electronic copies on CD disk (adobe PDF).

30. Roof Access

Roof access permits must be obtained in order to access any roof on a NIST campus, for work or investigation purposes. Request roof access permits from the COR or the construction representative five (5) days before roof access is required.

• Requires Fall Protection training documentation.

• May require the completion of a Health and Safety Plan if work is to be performed on the roof.

31. Security Badges

United States Department of Commerce Office of Security issues badges for contractor access to NIST.

PAGE 25 OF 293 1333ND23QNB190204

All foreign nationals shall comply with United States Department of Commerce DAO 2017-12 - http://www.osec.doc.gov/opog/dmp/daos/dao207_12.html

For US Citizens and Resident Aliens, the following badging applies

(Yellow) Limited Access PCards are issued for construction/service areas that meet the following criteria –

• Purely exterior construction with no requirement to enter Department of Commerce/NIST facilities

• Locations where work areas are partitioned and/or fully separated from occupied areas, with isolated entrances and exits for construction/maintenance contractors.

• COMPLETE Limited Access PCard badge application are approved/disapproved within 7 calendar days of submission to COR.

(Yellow) Limited Access Cards are available for contract personnel for 180 days every two years (24 months) commencing with the issuance of the Card. If a contract employee was issued a Limited Access Card and exceeds the 180 days access within 24 months, he/she would be denied a Limited Access Card until the next 24-month period.

Turnaround time for a (Yellow) Limited Access Card is 7 days from an accepted badge application.

(Green Badge) Site Card (Site Access Badge)/ Personal Identification (PIV) Card for those contract site that do not qualify for a (Yellow) Limited Access Card

• Site Cards will be issued to contract employees who will be on site for less than 30 days. These site cards maybe extended. The total “life” of this badge cannot exceed 179 days. After 179 days, the contractor has to apply for a PIV badge.

• PIV Cards or equivalent will be issued to contract employees who are expected to be on site for more than 30 days. PIV Cards maybe extended.

• A Site Card/PIV Card processing is broken into distinctive time periods once the COMPLETE badge application is submitted to the COR o Badge application is entered/processed into the “system” within 8 days of submission to COR o Contract employee is invited/emailed to complete the on-line security check application https://www.opm.gov/investigations/e-qip-application/ Contract employee must monitor his/her email for the invitation E-QIP invitation expires 14 days after it is emailed ** E-QIP invitation will be sent to the applicant within 16 days of submission to COR

PAGE 26 OF 293 1333ND23QNB190204

o Once the contract employee completes E-QIP application, Department of Commerce personnel will review the application within 8 days of EQIP being submitted. The contract employee will be notified if corrections are required.

o Once the application is accepted, the COR will notify the contractor that the individual is ready for fingerprints. A trip to Gaithersburg is needed to be fingerprinted.

o The COR will notify the contractor that employee is ready to be issued a badge at NIST.

Summarizing the Site Card/PIV Timeline (Error free badge applications)

COR submits badge application after award to contractor (NIST Action) Within 7 days Contractor submits badge application and OF306 to COR for each and all contract employees *

Within 14 days

Application is entered into the security system (NIST Action) Within 8 days Applicant is emailed E-QIP invitation (DoC/NIST Action) Within 8 days Applicant completes E-QIP prior to email link expiration ** Within 14 days E-QIP application is reviewed and approved for fingerprints at NIST (DoC/NIST Action)

Within 8 days

Applicant arranges with COR for visitor center access to obtain fingerprints Within 8 days Applicant’s fingerprints are reviewed; Applicant is approved for NIST badge (NIST Action)

Within 8 days

Applicant schedules a badge appointment and arrives for badge Within 7 days Total (Maximum) 82 days

* If contractor does not submit all badge applications at one time, the last badge application submission date will drive how long the badge process will take.

** If the applicant doesn’t complete E-QIP within the 14 days, contractor needs to notify COR to request another E-QIP invitation. Resent E-QIP invitation may take up to 4 days to be sent.

COR notifications are via a weekly report on badge status applications. In this report, it will indicate if the applicant is:

• Pending E-QIP

• Ready for Fingerprints

• Ready for Badge

(White – Paper) Visitor Paper Badge are issued to contractor employees who

PAGE 27 OF 293 1333ND23QNB190204

• Visiting NIST to complete aspects of the badging process to include badge issuance

• Delivery drivers (material, equipment, etc.)

• Concrete trucks

32. Designer Historical Requirements

The NIST Campus in its entirety has been determined eligible for and is in the process of being nominated to the National Register of Historic Places. As such, all campus projects (buildings, structures and grounds) other than routine maintenance and repair must conform to the Secretary of the Interior’s (SOI) Standards for the Treatment of Historic Properties.

Most changes to building exteriors and landscapes as well as Changes to certain building interiors and most landscape features are reviewed and approved at various stages by the NIST Architectural Design Review Board (ADRB), and, ultimately by the NIST federal preservation officer.

All designs for proposed additions and changes to facades, rooflines and building silhouettes other than in-kind repairs, must be reviewed and approved by the NIST Architectural Design Review Board (ADRB) and the Maryland Historical Trust (MHT). Project related communications with the MHT are only conducted by the NIST Federal Preservation Officer who may require technical information and graphic support from the design professional The design professional shall coordinate with the NIST COR to schedule any needed presentations to the ADRB and/or the MHT. The Design professional shall provide sufficient time in the project schedule to allow for these design reviews.

Because many of NISTs natural and landscape features have been determined to be character defining features and/or contributory resources to the NIST historic district, the design professional shall coordinate with the NIST NEPA coordinator and the FPO.

Any proposed laydown areas, staging areas and or enclosures related to proposed work need to be reviewed and approved with the NIST Site Selection panel. The design professional shall work through the NIST COR to assure review and approval of any such proposed enclosure or site usage prior to issuing construction documents.

Certain campus locations around the central core because of high traffic and high visibility may require enclosed fencing, such as painted plywood panels on structural framing. The Design Professional shall coordinate with the COR to incorporate the design specifications for such enclosure based upon recommendations from the NIST ADRB.

Building 101 Some ceiling tiles may be considered character defining features of buildings that are contributory to the NIST historic district and as such cannot be removed without first consulting

PAGE 28 OF 293 1333ND23QNB190204

the NIST Federal Preservation Officer (FPO). It is the contractor’s responsibility to verify with the FPO if concealed spline ceiling tiles are character defining

33. Temporary Exterior Power:

If the contractor requests exterior power for construction purposes, the contractor shall follow the requirements noted below. In addition, the contractor shall follow requirements identified in paragraph #6 (outages).

Contractor shall furnish the following to the COR

A) Requested tie-in point – identify the voltage, overcurrent protection, and existing equipment (switchboard, panel board, load center, etc) location

B) Provide a one-line diagram for the proposed system

a. Cable sizes

b. Overcurrent protection size(s) and type(s) (all devices)

c. Length of cabling and type of conduit

d. Transformer sizing to include ground rods and grounding electrode conductors

e. If any component is aerial, the contractor shall provide construction details on

i. Height of cables

ii. How the cables are supported

C) NIST will review the request. Within 17 days if the request is complete, COR via a NIST engineer will provide:

a. Arc flash labels which the contract shall affix to the one-line devices per NFPA 70E.

b. Date the outage is approved for the work

34. Security Plan, SP:

Contractor shall provide a security plan to the COR. If not specified in the SOW or specifications, a security plan must be submitted within 21 days of award.

Elements of a security plan must address (if applicable):

• Security of contract trailer/on-site office

• Security of the contract site to unauthorized personnel.

o For instance, physical barriers restricting access to unauthorized personnel;

construction area warning signs; locked construction access points, etc.

• Access control o Background checks for contractors and subcontractors, o Clearances (if identified in the contract documents as needed), o Alien status - https://www.e-verify.gov/employers/federal-contractors ).

PAGE 29 OF 293 1333ND23QNB190204

• Badging o Ensuring contractor employees display NIST badges while on campus o Processing badge applications to ensure contract employees submit complete and accurate badge applications, o Complying with NIST badge policy that contractors are not permitted to escort non-Green badged employees o Lost NIST badge procedures & investigation o Retrieving NIST badges from contractors who do not need to come on campus any longer

• Vehicular access o Contract employees parking in NIST marked parking spots/places o Vehicle loading and unloading.

o Limiting parking times at loading docks

• Internal security o Vehicle key control when vehicles are not in use o Securing equipment and tools to prevent theft o Securing Government equipment so it is not stolen o Control of Government keys if furnished to the contractor

• Movement of contract employees o Identify how the contractor will ensure contract employees remain on their work sites especially in occupied buildings with other Federal employees.

• Security of procurement drawings/plans (hard copy and electronic) if not posted on

Internet for bidding

• Maintaining security during…