N68335-16-R-0269.docx
DOCX document 105 KB Posted
- Attached to
- Low Frequency Power Amplifier Federal contract opportunity
- Solicitation number
- N68335-16-R-0269
About this file
Solicitation
View the file
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
N68335-16-R-0269
Section B - Supplies or Services and Prices
| ITEM NO |
| SUPPLIES/SERVICES |
| QUANTITY |
| UNIT |
| UNIT PRICE |
| AMOUNT |
| 18 |
| Each |
AMPLIFIER,RADIO FRE
FFP
Electronics & Innovation Ltd.P/N 525 LA NOTE: The requirements in DFARS 252.211-7003, Item Identification and Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.
FOB: Destination
NSN: 5996012797011
PURCHASE REQUEST NUMBER: 1300575477
NET AMT
Section C - Descriptions and Specifications
ADDITIONAL INFORMATION
REQUIREMENTS:
1. Mfr. Std. three year warranty with sticker affixed to each unit plus a warranty certificate.
2. Calibration Certificate and calibration sticker, shall be affixed to each unit.
3. Units shall be serialized.
4. Units (over $5,000) shall have an IUID Label applied per DFAR 252.211-7003.
5. Operating and servicing manuals (CD version acceptable) shall be provided with each unit.
Section D - Packaging and Marking
ADDITIONAL INFORMATION
PACKING AND MARKING INSTRUCTIONS:
1. All items shall be packaged IAW best commercial practices.
2. Mark all packaging with the purchase order number.
Section E - Inspection and Acceptance
INSPECTION AND ACCEPTANCE TERMS
Supplies/services will be inspected/accepted at:
| CLIN |
| INSPECT AT |
| INSPECT BY |
| ACCEPT AT |
| ACCEPT BY |
| 0001 |
| Destination |
| Government |
| Destination |
| Government |
Section F - Deliveries or Performance
DELIVERY INFORMATION
| CLIN |
| DELIVERY DATE |
| QUANTITY |
| SHIP TO ADDRESS |
| DODAAC / CAGE |
| 0001 |
| 12 wks. ADC |
| 18 |
| COMMANDER |
LOU CERRILLO
NAVAIR CALIBRATIONS STANDARDS, BLDG 612,
BAY 9
BEAUFORT SC 29904-5002
843-524-1405 FOB: Destination N48535
CLAUSES INCORPORATED BY REFERENCE
| 52.247-34 |
| F.O.B. Destination |
| NOV 1991 |
Section G - Contract Administration Data
CLAUSES INCORPORATED BY FULL TEXT
| 252.204-0001 | LINE ITEM SPECIFIC: SINGLE FUNDING (SEP 2009) |
| The payment office shall make payment using the ACRN funding of the line item being billed. |
| 252.232-7006 | WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013) | |
| (a) Definitions, as used in this clause-- | ||
| "Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization. | ||
| "Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). | ||
| "Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system. | ||
| (b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. | ||
| (c) WAWF access. To access WAWF, the Contractor shall-- | ||
| (1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and | ||
| (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site. | ||
| (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/. | ||
| (e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol. | ||
| (f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order: | ||
| (1) Document type. The Contractor shall use the following document type(s). | ||
| __________________________________COMBO_________________________________________ | ||
| (Contracting Officer: Insert applicable document type(s). Note: If a "Combo" document type is identified but not supportable by the Contractor's business systems, an "Invoice" (stand-alone) and "Receiving Report" (stand-alone) document type may be used instead.) | ||
| (2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer. | ||
| __________________________________IAW Schedule_______________________________________ | ||
| (Contracting Officer: Insert inspection and acceptance locations or "Not applicable.") | ||
| (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. |
| Routing Data Table* | ||||
| Field Name in WAWF | Data to be entered in WAWF | |||
| Pay Official DoDAAC: | _________________________ | |||
| Issue By DoDAAC: | _______N68335____________ | |||
| Admin DoDAAC: | _________________________ | |||
| Inspect By DoDAAC: | _________________________ | |||
| Ship To Code: | _______N48535____________ | |||
| Ship From Code: | _________________________ | |||
| Mark For Code: | _________________________ | |||
| Service Approver (DoDAAC): | _________________________ | |||
| Service Acceptor (DoDAAC): | _________________________ | |||
| Accept at Other DoDAAC: | _________________________ | |||
| LPO DoDAAC: | _________________________ | |||
| DCAA Auditor DoDAAC: | _________________________ | |||
| Other DoDAAC(s): | _________________________ | |||
| (*Contracting Officer: Insert applicable DoDAAC information or "See schedule" if multiple ship to/acceptance locations apply, or "Not applicable.") | ||||
| (4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request. | ||||
| (5) WAWF email notifications. The Contractor shall enter the email address identified below in the "Send Additional Email Notifications" field of WAWF once a document is submitted in the system. |
_____patrick.brannick@navy.mil____or_______thomas.dastis@navy.mil__________________________ (Contracting Officer: Insert applicable email addresses or "Not applicable.")
| (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact. For Navy WAWF questions call DFAS Customer Care 1-800-756-4571 option 6 | |
| (2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988. |
Section I - Contract Clauses
| 52.204-7 |
| System for Award Management |
| OCT 2016 |
| 52.204-13 |
| System for Award Management Maintenance |
| OCT 2016 |
| 52.204-16 |
| Commercial and Government Entity Code Reporting |
| JUL 2016 |
| 52.204-17 |
| Ownership or Control of Offeror |
| JUL 2016 |
| 52.204-18 |
| Commercial and Government Entity Code Maintenance |
| JUL 2016 |
| 52.204-19 |
| Incorporation by Reference of Representations and Certifications. |
| DEC 2014 |
| 52.212-4 |
| Contract Terms and Conditions--Commercial Items |
| JAN 2017 |
| 52.225-25 |
| Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications. |
| OCT 2015 |
| 52.232-40 |
| Providing Accelerated Payments to Small Business Subcontractors |
| DEC 2013 |
| 52.247-34 |
| F.O.B. Destination |
| NOV 1991 |
| 252.203-7000 |
| Requirements Relating to Compensation of Former DoD Officials |
| SEP 2011 |
| 252.203-7003 |
| Agency Office of the Inspector General |
| DEC 2012 |
| 252.204-7004 Alt A |
| System for Award Management Alternate A |
| FEB 2014 |
| 252.204-7008 |
| Compliance With Safeguarding Covered Defense Information Controls |
| OCT 2016 |
| 252.204-7012 |
| Safeguarding Covered Defense Information and Cyber Incident Reporting |
| OCT 2016 |
| 252.204-7015 |
| Notice of Authorized Disclosure of Information for Litigation Support |
| MAY 2016 |
| 252.211-7003 |
| Item Unique Identification and Valuation |
| MAR 2016 |
| 252.225-7001 |
| Buy American And Balance Of Payments Program-- Basic (Dec 2016) |
| DEC 2016 |
| 252.225-7002 |
| Qualifying Country Sources As Subcontractors |
| DEC 2016 |
| 252.225-7012 |
| Preference For Certain Domestic Commodities |
| DEC 2016 |
| 252.225-7016 |
| Restriction On Acquisition Of Ball and Roller Bearings |
| JUN 2011 |
| 252.226-7001 |
| Utilization of Indian Organizations and Indian-Owned Economic Enterprises, and Native Hawaiian Small Business Concerns |
| SEP 2004 |
| 252.227-7015 |
| Technical Data--Commercial Items |
| FEB 2014 |
| 252.232-7003 |
| Electronic Submission of Payment Requests and Receiving Reports |
| JUN 2012 |
| 252.232-7010 |
| Levies on Contract Payments |
| DEC 2006 |
| 252.243-7002 |
| Requests for Equitable Adjustment |
| DEC 2012 |
| 252.244-7000 |
| Subcontracts for Commercial Items |
| JUN 2013 |
| 252.247-7023 |
| Transportation of Supplies by Sea |
| APR 2014 |
| 52.212-5 | CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR EXECUTIVE ORDERS - COMMERCIAL ITEMS (DEC 2016) | |
| (a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items: | ||
| (1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015). | ||
| (2) 52.233-3, Protest after Award (Aug 1996)(31 U.S.C. 3553). | ||
| (3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78(19 U.S.C.3805 note)). | ||
| (b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items: |
[Contracting Officer shall check as appropriate.]
| [_X_] (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sep 2006), with Alternate I (Oct 1995)(41 U.S.C. 4704 and 10 U.S.C. 2402). |
| [___] (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010)(41 U.S.C. 3509)). |
| [___] (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010)(Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.) |
| [_X_] (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2016)(Pub. L. 109-282) (31 U.S.C. 6101 note). |
| [___] (5) [Reserved]. |
| [___] (6) 52.204-14, Service Contract Reporting Requirements (Oct 2016)(Pub.L. 111-117, section 743 of Div. C). |
| [___] (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016)(Pub.L. 111-117, section 743 of Div. C). |
| [_X_] (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (Aug 2013) (31 U.S.C. 6101 note). |
| [_X_] (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013)(41 U.S.C. 2313). |
| [_X_] (10) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (May 2012)(section 738 of Division C of Public Law 112-74, section 740 of Division C of Pub. L. 111-117, section 743 of Division D of Pub. L. 111-8, and section 745 of Division D of Pub. L 110-161). |
| [___] (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011)(15 U.S.C. 657a). |
| [___] (ii) Alternate I (Nov 2011) of 52.219-3. |
| [___] (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer)(15 U.S.C. 657a). |
| [___] (ii) Alternate I (Jan 2011) of 52.219-4. |
| [___] (13) [Reserved]. |
| [___] (14)(i) 52.219-6, Notice of Total Small Business Aside (Nov 2011) (15 U.S.C. 644). |
| [___] (ii) Alternate I (Nov 2011) of 52.219-6. |
| [___] (iii) Alternate II (Nov 2011) of 52.219-6. |
| [___] (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (Jun 2003)(15 U.S.C. 644). |
| [___] (ii) Alternate I (Oct 1995) of 52.219-7. |
| [___] (iii) Alternate II (Mar 2004) of 52.219-7. |
| [_X_] (16) 52.219-8, Utilization of Small Business Concerns (Nov 2016) (15 U.S.C. 637(d)(2) and (3)). |
| [_X_] (17)(i) 52.219-9, Small Business Subcontracting Plan (Nov 2016) (15 U.S.C. 637(d)(4)). |
| [___] (ii) Alternate I (Nov 2016) of 52.219-9. |
| [___] (iii) Alternate II (Nov 2016) of 52.219-9. |
| [___] (iv) Alternate III (Nov 2016) of 52.219-9. |
| [___] (v) Alternate IV (Nov 2016) of 52.219-9. |
| [___] (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011)(15 U.S.C. 644(r)).) |
| [___] (19) 52.219-14, Limitations on Subcontracting (Nov 2011)(15 U.S.C. 637(a)(14)). |
| [___] (20) 52.219-16, Liquidated Damages - Subcontracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)). |
| [___] (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011)(15 U.S.C. 657f). |
| [_X_] (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)). |
| [___] (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business (EDWOSB) Concerns (Dec 2015)(15 U.S.C. 637(m)). |
| [___] (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business (WOSB) Concerns Eligible Under the WOSB Program (Dec 2015)(15 U.S.C. 637(m)). |
| [_X_] (25) 52.222-3, Convict Labor (Jun 2003)(E.O. 11755). |
| [_X_] (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Oct 2016)(E.O. 13126). |
| [_X_] (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). |
| [_X_] (28) 52.222-26, Equal Opportunity (Sept 2016)(E.O. 11246). |
| [_X_] (29) 52.222-35, Equal Opportunity for Veterans (July 2014)(38 U.S.C. 4212). |
| [_X_] (30) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014)(29 U.S.C. 793). |
| [_X_] (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212). |
| [_X_] (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010)(E.O. 13496). |
| [_X_] (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015)(22 U.S.C. chapter 78 and E.O. 13627). |
| [___] (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627). |
| [___] (34) 52.222-54, Employment Eligibility Verification (Aug 2013). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.) |
| [___] (35) 52.222-59, Compliance with Labor Laws (Executive Order 13673)(Oct 2016). (Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017. |
NOTE TO PARAGRAPH (b)(35): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.
| [___] (36) 52.222-60, Paycheck Transparency (Executive Order 13673)(Oct 2016). | |
| [___] (37)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (May 2008)(42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.) | |
| [___] (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.) | |
| [___] (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June 2016)(E.O. 13693). | |
| [___] (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June 2016)(E.O. 13693). | |
| [___] (40)(i) 52.223-13, Acquisition of EPEAT(R) Registered Imaging Equipment (Jun 2014)(E.O.s 13423 and 13514). | |
| [___] (ii) Alternate I (Oct 2015) of 52.223-13. | |
| [___] (41)(i) 52.223-14, Acquisition of EPEAT(R) Registered Televisions (Jun 2014)(E.O.s 13423 and 13514). | |
| [___] (ii) Alternate I (Jun 2014) of 52.223-14. | |
| [___] (42) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b) | |
| [___] (43)(i) 52.223-16, Acquisition of EPEAT(R) Registered Personal Computer Products (Oct 2015)(E.O.13423 and 13514). | |
| [___] (ii) Alternate I (Jun 2014) of 52.223-16. | |
| [_X_] (44) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging while Driving (Aug 2011)(E.O. 13513). | |
| [___] (45) 52.223-20, Aerosols (June 2016)(E.O. 13693) | |
| [___] (46) 52.223-21, Foams (June 2016)(E.O. 13693) | |
| [___] (47) 52.225-1, Buy American--Supplies (May 2014)(41 U.S.C. chapter 83). | |
| [___] (48)(i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42 and 112-43). | |
| [___] (ii) Alternate I (May 2014) of 52.225-3. | |
| [___] (iii) Alternate II (May 2014) of 52.225-3. | |
| [___] (iii) Alternate III (May 2014) of 52.225-3. | |
| [___] (49) 52.225-5, Trade Agreements (Oct 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note). | |
| [_X_] (50) 52.225-13, Restrictions on Certain Foreign Purchases (Jun 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury). | |
| [___] (51) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016)(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2303 Note). | |
| [___] (52) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007)(42 U.S.C. 5150). | |
| [___] (53) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150). | |
| [___] (54) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002)(41 U.S.C. 4504, 10 U.S.C. 2307(f)). | |
| [___] (55) 52.232-30, Installment Payments for Commercial Items (Oct 1995)(41 U.S.C. 4504, 10 U.S.C. 2307(f)). | |
| [_X_] (56) 52.232-33, Payment by Electronic Funds Transfer- System for Award Management (Jul 2013)(31 U.S.C. 3332). | |
| [___] (57) 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management (Jul 2013)(31 U.S.C. 3332). | |
| [___] (58) 52.232-36, Payment by Third Party (May 2014)(31 U.S.C. 3332). | |
| [___] (59) 52.239-1, Privacy or Security Safeguards (Aug 1996)(5 U.S.C. 552a). | |
| [___] (60)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006)(46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). | |
| [___] (ii) Alternate I (Apr 2003) of 52.247-64. | |
| (c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial items: |
[Contracting Officer check as appropriate.]
| [___] (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495) | ||
| [___] (2) 52.222-41, Service Contract Labor Standards (May 2014)(41 U.S.C. chapter 67). | ||
| [___] (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014)(29 U.S.C. 206 and 41 U.S.C. chapter 67). | ||
| [___] (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts)(May 2014)(29 U.S.C.206 and 41 U.S.C. chapter 67). | ||
| [___] (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014)(29 U.S.C. 206 and 41 U.S.C. chapter 67). | ||
| [___] (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014)(41 U.S.C. chapter 67). | ||
| [___] (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014)(41 U.S.C. chapter 67). | ||
| [___] (8) 52.222-55, Minimum Wages Under Executive Order 13658(Dec 2014)(Executive Order 13658). | ||
| [___] (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014)(42 U.S.C. 1792). | ||
| [___] (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sep 2008)(31 U.S.C. 5112(p)(1)). | ||
| (d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records -- Negotiation. | ||
| (1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transactions related to this contract. | ||
| (2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved. | ||
| (3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law. | ||
| (e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause-- | ||
| (i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509)). | ||
| (ii) 52.219-8, Utilization of Small Business Concerns (Nov 2016)(15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities. | ||
| (iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495). Flow down required in accordance with paragraph (1) of FAR clause 52.222-17. | ||
| (iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015). | ||
| (v) 52.222-26, Equal Opportunity (Sept 2016)(E.O. 11246). | ||
| (vi) 52.222-35, Equal Opportunity for Veterans (July 2014)(38 U.S.C. 4212). | ||
| (vii) 52.222-36, Equal Opportunity for Workers with Disabilities (July 2014)(29 U.S.C. 793). | ||
| (viii) 52.222-37, Employment Reports on Veterans (Feb 2016)(38 U.S.C. 4212). | ||
| (ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40. | ||
| (x) 52.222-41, Service Contract Labor Standards (May 2014)(41 U.S.C. chapter 67). | ||
| (xi)(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627). | ||
| (B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. 78 and E.O. 13627). | ||
| (xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014)(41 U.S.C. chapter 67). | ||
| (xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014)(41 U.S.C. chapter 67). | ||
| (xiv) 52.222-54, Employment Eligibility Verification (Aug 2013). | ||
| (xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2014)(Executive Order 13658). | ||
| (xvi) 52.222-59, Compliance with Labor Laws (Executive Order 13673)(Oct 2016)(Applies at $50 million for solicitations and resultant contracts issued from October 25, 2016 through April 24, 2017; applies at $500,000 for solicitations and resultant contracts issued after April 24, 2017). |
NOTE TO PARAGRAPH (e)(1)(xvi): By a court order issued on October 24, 2016, 52.222-59 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.
| (xvii) 52.222-60, Paycheck Transparency (Executive Order 13673)(Oct 2016). | |
| (xviii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016)(Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note). | |
| (xix) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (May 2014)(42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6. | |
| (xx) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Feb 2006)(46 U.S.C. Appx 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64. | |
| (2) While not required, the contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations. |
| 52.252-2 | CLAUSES INCORPORATED BY REFERENCE (FEB 1998) |
| This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): https://www.acquisition.gov/far/ or http://farsite.hill.af.mil. |
THIS PAGE WAS LEFT BLANK INTENTIONALLY
Section K - Representations, Certifications and Other Statements of Offerors
| 52.225-25 |
| Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications. |
| OCT 2015 |
| 252.203-7005 |
| Representation Relating to Compensation of Former DoD Officials |
| NOV 2011 |
| 252.204-7008 |
| Compliance With Safeguarding Covered Defense Information Controls |
| OCT 2016 |
| 252.222-7007 |
| Representation Regarding Combating Trafficking in Persons |
| JAN 2015 |
| 252.247-7022 |
| Representation Of Extent Of Transportation Of Supplies By Sea |
| AUG 1992 |
| 52.209-7 | INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013) | |||
| (a) Definitions. As used in this provision-- | ||||
| “Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables. | ||||
| “Federal contracts and grants with total value greater than $10,000,000” means-- | ||||
| (1) The total value of all current, active contracts and grants, including all priced options; and | ||||
| (2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules). | ||||
| “ Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions). | ||||
| (b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000. | ||||
| (c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information: | ||||
| (1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions: | ||||
| (i) In a criminal proceeding, a conviction. | ||||
| (ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more. | ||||
| (iii) In an administrative proceeding, a finding of fault and liability that results in-- | ||||
| (A) The payment of a monetary fine or penalty of $5,000 or more; or | ||||
| (B) The payment of a reimbursement, restitution, or damages in excess of $100,000. | ||||
| (iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision. | ||||
| (2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence. | ||||
| (d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database at http://www.acquisition.gov (see 52.204-7). |
| 52.209-11 | REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016) | |
| (a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub.L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that -- | ||
| (1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or | ||
| (2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government. | ||
| (b) The Offeror represents that -- | ||
| (1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and | ||
| (2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under any Federal law within the preceding 24 months, |
52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS - COMMERCIAL ITEMS (JAN 2017) - ALTERNATE I (OCT 2014) An offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certifications electronically via the System for Award Management (SAM) Web site located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the offeror shall complete only paragraphs (c) through (u) of this provision.
| (a) Definitions. As used in this provision: | |||||
| "Administrative merits determination" means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. | |||||
| "Arbitral award or decision" means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. | |||||
| "Civil judgment" means- | |||||
| (1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction. | |||||
| (2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance. | |||||
| "DOL Guidance" means the Department of Labor (DOL) Guidance entitled: "Guidance for Executive Order 13673, 'Fair Pay and Safe Workplaces'". The DOL Guidance, dated August 25, 2016, can be obtained from www.dol.gov/fairpayandsafeworkplaces. | |||||
| "Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program. | |||||
| "Enforcement agency" means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are-- | |||||
| (1) Department of Labor Wage and Hour Division (WHD) for -- | |||||
| (i) The Fair Labor Standards Act; | |||||
| (ii) The Migrant and Seasonal Agricultural Worker Protection Act; | |||||
| (iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act: | |||||
| (iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act; | |||||
| (v) The Family and Medical Leave Act; and | (vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors); | ||||
| (2) Department of Labor Occupational Safety and Health Administration (OSHA) for -- | |||||
| (i) The Occupational Safety and Health Act of 1970; and | |||||
| (ii) OSHA-approved State Plans; | |||||
| (3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for -- | |||||
| (i) Section 503 of the Rehabilitation Act of 1973; | |||||
| (ii) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974; and | |||||
| (iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity); | |||||
| (4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and | |||||
| (5) Equal Employment Opportunity Commission (EEOC) for -- | |||||
| (i) Title VII of the Civil Rights Act of 1964; | |||||
| (ii) The Americans with Disabilities Act of 1990; | |||||
| (iii) The Age Discrimination in Employment Act of 1967; and | |||||
| (iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act). | |||||
| "Forced or indentured child labor" means all work or service-- | |||||
| (1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or | |||||
| (2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties. | |||||
| "Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner. | |||||
| "Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees. | |||||
| "Inverted domestic corporation" means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c). | |||||
| "Labor compliance agreement" means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters. | |||||
| "Labor laws" means the following labor laws and E.O.s: | |||||
| (1) The Fair Labor Standards Act. | |||||
| (2) The Occupational Safety and Health Act (OSHA) of 1970. | |||||
| (3) The Migrant and Seasonal Agricultural Worker Protection Act. | |||||
| (4) The National Labor Relations Act. | |||||
| (5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act. | |||||
| (6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act. | |||||
| (7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity). | |||||
| (8) Section 503 of the Rehabilitation Act of 1973. | |||||
| (9) The Vietnam Era Veterans' Readjustment Assistance Act of 1972 and the Vietnam Era Veterans' Readjustment Assistance Act of 1974. | |||||
| (10) The Family and Medical Leave Act. | |||||
| (11) Title VII of the Civil Rights Act of 1964. | |||||
| (12) The Americans with Disabilities Act of 1990. | |||||
| (13) The Age Discrimination in Employment Act of 1967. | |||||
| (14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors). | |||||
| (15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html). | |||||
| "Labor law decision" means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of "labor laws". | |||||
| "Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except-- | |||||
| (1) PSC 5510, Lumber and Related Basic Wood Materials; | |||||
| (2) Product or Service Group (PSG) 87, Agricultural Supplies; | |||||
| (3) PSG 88, Live Animals; | |||||
| (4) PSG 89, Subsistence; | |||||
| (5) PSC 9410, Crude Grades of Plant Materials; | |||||
| (6) PSC 9430, Miscellaneous Crude Animal Products, Inedible; | |||||
| (7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products; | |||||
| (8) PSC 9610, Ores; | |||||
| (9) PSC 9620, Minerals, Natural and Synthetic; and | |||||
| (10) PSC 9630, Additive Metal Materials. | |||||
| "Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture. | |||||
| "Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor. | |||||
| "Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate-- | |||||
| (1) Are conducted under contract directly and exclusively with the regional government of southern Sudan; | |||||
| (2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization; | |||||
| (3) Consist of providing goods or services to marginalized populations of Sudan; | |||||
| (4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization; | |||||
| (5) Consist of providing goods or services that are used only to promote health or education; or | |||||
| (6) Have been voluntarily suspended. | |||||
| "Sensitive technology"-- | |||||
| (1) Means hardware, software, telecommunications equipment, or any other technology which is to be used specifically-- | |||||
| (i) To restrict the free flow of unbiased information in Iran; or | |||||
| (ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and | |||||
| (2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3). | |||||
| "Service-disabled veteran-owned small business concern"-- | |||||
| (1) Means a small business concern- | |||||
| (i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and | |||||
| (ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran. | |||||
| (2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16). | |||||
| "Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation. | |||||
| "Small disadvantaged business concern" consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that -- | |||||
| (1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by -- | |||||
| (i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and | |||||
| (ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); | |||||
| (2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition. | |||||
| "Subsidiary" means an entity in which more than 50 percent of the entity is owned-- | |||||
| (1) Directly by a parent corporation; or | |||||
| (2) Through another subsidiary of a parent corporation. | |||||
| "Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances. | |||||
| "Veteran-owned small business concern" means a small business concern- | |||||
| (1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and | |||||
| (2) The management and daily business operations of which are controlled by one or more veterans. | |||||
| "Women-owned business concern" means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women. | |||||
| "Women-owned small business concern" means a small business concern - | |||||
| (1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and | |||||
| (2) Whose management and daily business operations are controlled by one or more women. | |||||
| "Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127)" means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States. | |||||
| Note to paragraph (a); By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: "Administrative merits determination", "Arbitral award or decision", paragraph (2) of "Civil judgment", "DOL Guidance", "Enforcement agency", "Labor compliance agreement", "Labor laws", and "Labor law decision". The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in Federal Register advising the public of the termination of the injection. | (b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website. | ||||
| (2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications-Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs [_________].[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer. Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM. | |||||
| (c) Offerors must complete the following representations when the resulting contract will be performed in the United States or its outlying areas. Check all that apply. | |||||
| (1) Small business concern. The offeror represents as part of its offer that it [ ] is, [ ] is not a small business concern. | |||||
| (2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a veteran-owned small business concern. | |||||
| (3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ] is, [ ] is not a service-disabled veteran-owned small business concern. | |||||
| (4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, that it [ ] is, [ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002. |
This is the start of the file's text. The full file is on GovTribe.
File details come from the government source that posted it. Updated .