19Q0029_RELEASED.pdf

SEE ADDENDUM

(No Collect Calls)

M6700119Q0029 05-Aug-2019

b. TELEPHONE NUMBER

910-451-1847

8. OFFER DUE DATE/LOCAL TIME

03:00 PM 19 Aug 2019

5. SOLICITATION NUMBER 6. SOLICITATION ISSUE DATE

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA – FAR (48 CFR) 53.212

(TYPE OR PRINT)

(SIGNATURE OF CONTRACTING OFFICER)

ADDENDA X ARE

26. TOTAL AWARD AMOUNT (For Gov t. Use Only )

23.

CODE 10. THIS ACQUISITION IS

SUCH ADDRESS IN OFFER

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT

BELOW IS CHECKED

TELEPHONE NO.

M670019. ISSUED BY

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a. UNLESS BLOCK

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

KYLE GREENE

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER

(TYPE OR PRINT)

30b. NAME AND TITLE OF SIGNER 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a.UNITED STATES OF AMERICA

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1. 52.212-4. FAR 52.212-3. 52.212-5 ARE ATTACHED.X

25. ACCOUNTING AND APPROPRIATION DATA

1. REQUISITION NUMBER

20.

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, AND 30

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

SEE SCHEDULE

ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

(BLOCK 5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE

SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

. YOUR OFFER ON SOLICITATION

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

% FOR:SET ASIDE:UNRESTRICTED OR X

SMALL BUSINESSX

17a.CONTRACTOR/ CODE FACILITY

OFFEROR CODE

M67001

PO BOX 8368 BLDG 1116

CAMP LEJEUNE NC 28547

18a. PAYMENT WILL BE MADE BY CODE

RATED ORDER UNDER

DPAS (15 CFR 700)

13a. THIS CONTRACT IS A

13b. RATING

CODE15. DELIVER TO CODE 16. ADMINISTERED BY

SEE SCHEDULE

12. DISCOUNT TERMS11. DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

SEE SCHEDULE

14. METHOD OF SOLICITATION

RFQ IFB RFPX

843-228-7251FAX:

TEL: 843-228-7345

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8(A)

HUBZONE SMALL

BUSINESS

SIZE STANDARD:

1,000

NAICS:

337910

X

OFFER DATED

29. AWARD OF CONTRACT: REF.

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

EMAIL:

TEL:

31c. DATE SIGNED

SEE SCHEDULE

SCHEDULE OF SUPPLIES/ SERVICESITEM NO. QUANTITY UNIT UNIT PRICE AMOUNT

24.22.21.19.

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

(CONTINUED)

PAGE 2 OF40

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: ______________________________________________________

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

32b. SIGNATURE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f . TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

37. CHECK NUMBER

FINALPARTIALCOMPLETE

36. PAYMENT35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER

FINAL

33. SHIP NUMBER

PARTIAL

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42a. RECEIVED BY (Print)

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 2/2012) BACK

Prescribed by GSA – FAR (48 CFR) 53.212

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

SEE SCHEDULE

20.

SCHEDULE OF SUPPLIES/ SERVICES

21.

QUANTITY UNIT

22. 23.

UNIT PRICE

24.

AMOUNT

19.

ITEM NO.

M6700119Q0029

Section SF 1449 - CONTINUATION SHEET

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 524 Each

MATTRESSES

FFP

MINIMUM SPECIFICATIONS:

Width: 36 inches to 38 inches

Length: 78 inches to 80 inches

Thickness: 8 inches to 10 inches

Two sided twin XL mattress with mininum 364 double, heat tempered steel

Bonnell innerspring coils (12.75 gauge minimum) each coil with minimum one turn per inch.

Edge support with 6-gauge minimum border wire secured to the outer row of perimeter coils by helicals.

Wire border must be butt-welded at ends

All sides shall be completely enclosed with adequate padding.

Smooth, dark- colored, outer-cover of breathable, polyurethane-coated nylon fabric or similar Polybrominated Diphenyl Ether (PDBE) and Polyvinyl Chloride (PVC) material and shall have inverted seams.

Bonded, flame resistant and chemical-free insulation pad or fire retardant fiber

(laminated to the outer cover) on top and bottom as a fire barrier.

Beneath the fire barrier, a minimum of 1.5 thick High Resilience (HR) polyurethane high density foam with an unfilled density of at least 1.5 pounds per cubic foot and minimum Indentation Load Deflection (ILD) of 30 on both sides of mattress

Mattress must be fluid proof, hypoallergenic, bug resistant, antimicrobial, antistatic, crack resistant, and flame retardant. Flame retardant chemicals shall not be used to meet FR requirements Meet CPSC 16 CFR 1632 and 16 CFR 1633 -

Manufacturer

Manufacturer's warranty shall be a minimum of 10 years

FOB: Destination

MILSTRIP: MMP20019SUXQYF8

PURCHASE REQUEST NUMBER: MMP20019SUXQYF8

PSC CD: 7210

NET AMT

0002 1 Each

MOTOR FREIGHT

FFP

Freight to Camp Lejeune NC.

FOB: Destination

MILSTRIP: MMP20019SUXQYF8

PSC CD: V112

0003 1 Each

INSTALLATION OF EQ/HOUSEHOLD FURNISHINGS

FFP

INSTALLATION FOR CLIN 0001

BLDG: AS-4030

(66) ROOMS

TOTAL: 132 MATTRESSES

BLDG: AS-4212

(104) ROOMS

TOTAL: 208 MATTRESSES

BLDG: HP 550

(92) ROOMS

TOTAL: 184 MATTRESSES

FOB: Destination

MILSTRIP: MMP20019SUXQYF8

PSC CD: N072

0004 1,296 Each

HOUSEHOLD FURNISHINGS

MINIMUM SPECIFICATIONS:

Width: 36 inches to 38 inches

Length: 78 inches to 80 inches

Thickness: 8 inches to 10 inches

Two sided twin XL mattress with mininum 364 double, heat tempered steel

Bonnell innerspring coils (12.75 gauge minimum) each coil with minimum one turn per inch.

Edge support with 6-gauge minimum border wire secured to the outer row of perimeter coils by helicals.

Wire border must be butt-welded at ends

All sides shall be completely enclosed with adequate padding.

Smooth, dark- colored, outer-cover of breathable, polyurethane-coated nylon fabric or similar Polybrominated Diphenyl Ether (PDBE) and Polyvinyl Chloride (PVC) material and shall have inverted seams.

Bonded, flame resistant and chemical-free insulation pad or fire retardant fiber

(laminated to the outer cover) on top and bottom as a fire barrier.

Beneath the fire barrier, a minimum of 1.5 thick High Resilience (HR) polyurethane high density foam with an unfilled density of at least 1.5 pounds per cubic foot and minimum Indentation Load Deflection (ILD) of 30 on both sides of mattress

Mattress must be fluid proof, hypoallergenic, bug resistant, antimicrobial, antistatic, crack resistant, and flame retardant. Flame retardant chemicals shall not be used to meet FR requirements Meet CPSC 16 CFR 1632 and 16 CFR 1633 -

Manufacturer

Manufacturer's warranty shall be a minimum of 10 years

PURCHASE REQUEST NUMBER: MMP20019SUYT5RB

PSC CD: 7210

0005 1 Each

MOTOR FREIGHT

FFP

Freight to Camp Lejeune NC.

FOB: Destination

PSC CD: V112

0006 1 Each

INSTALLATION

INSTALLATION OF CLIN 0004

BLDG: FC - 478

(162) ROOMS

TOTAL: 324 MATTRESSES

BLDG: FC - 481

BLDG: FC - 504

BLDG: FC - 507

PSC CD: N072

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 90 dys. ADC 524 MMP200

ROBERT RADEL

BASE PROPERTY

AS-4212

DOUGLASS STREET

MCAS NEW RIVER NC 28542

910-451-9488

MMP200

0002 90 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0003 90 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

0004 90 dys. ADC 1,296 N/A

0005 90 dys. ADC 1 MMP200

ROBERT RADEL

BLDG 1212 ROOM 16

CAMP LEJEUNE NC 28542

910-451-9488

0006 90 dys. ADC 1 (SAME AS PREVIOUS LOCATION)

PERFORMANCE WORK STATEMENT

1. BACKGROUND

This is an acquisition of mattresses and associated delivery/ installation services for the above identified Bachelor

Enlisted Quarters (BEQ). The items listed on the order shall be delivered and installed in (3) buildings for a total of

(1820) mattresses. Similar to a motel style layout, the BEQs each have (4) floors, (2) exterior stair cases to left and right of the building, and (1) interior stair case located center of the building. All stair cases connect each floor and lead to exterior cat-walks. The buildings have NO elevators/lifts.

Currently, buildings are OCCUPIED. If building is to be OCCUPIED prior to/or during the installation of the items, a Base Property representative will provide notice to Contracting Office and the contractor and installation shall be conducted in such a manner to prevent displacement of occupants. The contractor will be required to deliver and install the items as well as remove and dispose of all packaging and installation debris.

2. SCOPE OF WORK

2.1 REQUIREMENT

Contractor shall provide the items as indicated in 2.2.3. Installation. Contractor shall perform per all specifications and contract requirements.

2.2 CONTRACTOR SPECIFICATIONS

Contractor Shall:

2.2.1 Arrange Pre-Installation meeting(s) with a Base Property (Government) representative within (3) business days of contractor award. Purpose of this meeting is to coordinate both conduct of and delivery/installation schedules.

Base Property Government points of contact will be provided at time of award.

OPERATING HOURS: Normal operating hours are 7:30 AM EST – 4:00 PM EST, Monday through Friday. Closed on weekends and federal holidays.

2.2.2 DELIVERY

Delivery shall be coordinated with Base Property (Government) representative. REQUEST DELIVERY

NOTIFICATION A MINIMUM OF ONE WEEK PRIOR TO DELIVERY/INSTALLATION. The successful offeror shall provide a Project Manager to be on site throughout the entire project. The Project Manager shall have authority to represent the company to coordinate all services and issues through the Contracting and Base Property

Offices. All work will be conducted during the normal operating hours listed above.

Deliver all mattresses directly to the required building at time of installation. Forklift(s), temporary storage containers, trailers, and/or vehicles may be set up in vicinity of buildings, with locations as directed by the government representative. Cost of forklift and above storage means to include properly locking is the full responsibility of the contractor. NO GOVERNMENT-OWNED FORKLIFTS, WAREHOUSING, OR

STORAGE FACILITIES WILL BE PROVIDED.

2.2.3 Installation

Installation of Mattresses shall be coordinated with Base Property (Government) representative. Buildings, ground-load following:

Building HP-550 located on N St (Cross St Julian C. Smith St) Camp Lejeune, NC

(92), 2-man room

Total (184) Mattresses

Building AS-4030 located on Schmidt Street, Marine Corps Air Station New River, NC

(66), 2-man room

Total (132) Mattresses

Building AS-4212 located on Douglass Street, Marine Corps Air Station New River, NC

(104), 2-man room

Total (208) Mattresses

Building FC-478 located on Gonzalez Blvd, Camp Lejeune, NC

(162), 2-man room

Total (324) Mattresses

Building FC-481

Building FC-504

Building FC-507

Hallways, door frames, and individual rooms shall be protected with some form of padding. Item(s) shall be installed and set-up as functional. Notify a Base Property Representative if any items are found damaged/inoperable; they must be replaced.

Deviations or modifications will be redirected to the attention of the Operations Branch Head, Supply Management

Division and may require approval by the Contracting Officer via a signed modification on a Standard Form 30

(SF30).

2.2.4 REMOVAL

Contractor is responsible for removal of all old mattresses to include packing materials and debris from delivery and installation to include dirt, sand, mud, grass, water, etc.

2.2.5 DISPOSAL

Contractor at own expense will dispose of old mattresses off Base, all plastics, tape, card board packaging, zip ties, and Styrofoam, etc.

Once a week (maximum), debris may be taken to the Materials Recycling Facility (MRF)/Landfill located on Piney

Green Road (materials must be sorted as cardboard, plastic, and wood). Driver must have a copy of the contract and placard provided by Base Property to enter the site.

2.2.6. FACILITY DAMAGE

Contractor shall be responsible for all damages to buildings or surrounding areas (including grass/lawns) when moving or installing mattresses. Damages shall be repaired by contractor at contractor’s expense before final invoicing.

2.2.7 PARKING/EQUIPMENT

Contractor must provide any containers if storage is necessary. Contractor shall be responsible for ensuring all storage containers maintained on the job site are locked. Parking of equipment and vehicles will be in designated areas or in authorized parking lots (normally not on the grass or lawn).

Contractor shall provide all necessary material handling equipment and tools required to support this requirement to include non-marking, rubber-wheeled hand trucks, dollies, and carts. Contractor shall be responsible for securing all material handling equipment. The Government will not be liable for any stolen or damaged property that is left unsecured by the Contractor.

2.2.8 BASE ACCESS INSTRUCTIONS

Marine Corps Installations across the region are transitioning to a new government-owned access control system called Defense Biometric Identification System (DBIDS). This new and enhanced system l replaces RAPIDGate and MCESS for contractors and other non-DoD-affiliated personnel requiring installation access. DBIDS is already installed at more than 320 sites with over 5 million registered personnel and unlike previous systems, this one is a free service.

Current RAPIDGate or MCESS credentials can easily be switched out for a DBIDS credential and new contractors can apply for a DBIDS credential using the same vetting requirements as previously required. RAPIDGate/MCESS credentials will be honored until September 30, 2018. After this date, all contractors will be required to have a

DBIDS credential in order to access MCB Camp Lejeune and MCAS New River. In order to reduce wait time when exchanging your RAPIDGate/MCESS credential, it is highly recommended each applicant pre-register at https://dbids-global.dmdc.mil/enroll#!/.

Here’s what you need to know:

CURRENT DOD ID CARD HOLDERS

-If you currently hold a valid Common Access Card (CAC), dependent ID card, reserve ID card, or retiree ID card, issued by the Defense Enrollment Eligibility Reporting System (DEERS), no further action is required.

-You will be automatically enrolled in DBIDS when your ID card is initially scanned at the gate. Expect a one-time delay of 3-6 seconds as the DBIDS system initially registers your information.

CURRENT CONTRACTORS

-Beginning June 5, 2018, RAPIDGate/MCESS card holders will be required to present a second form of government-issued identification to the gate sentry, along with the RAPIDGate/MCESS credential, in order to access MCB Camp Lejeune and MCAS New River.

-DBIDS credentials will be issued beginning June 25, 2018

-DBIDS credentials will be valid for the duration of your contract, not to exceed five years; however, re-vetting of individuals’ information will occur each year.

-Contractors can exchange their current RAPIDGate/MCESS credential for a DBIDS credential without re-vetting, however they will be required to bring the following items:

o Current RAPIDGate/MCESS credential o Second form of government-issued identification (driver license, passport, etc.)

o Company Contract/Letter of Authorization

- New DBIDS credentials will be valid for the remainder of the contract (not to exceed 5 years), but individuals will be re-vetted each year.

- All contractors (MCB Camp Lejeune and MCAS New River) will be able to exchange their current

RAPIDGate/MCESS credential at the Camp Lejeune Contractor Vetting Office, Building TT-13, next to the Wilson

Gate. NOTE: If a contractor requires flight line access, they must exchange their credential at Building AS-187 next to MCAS New River’s Main Gate entrance. Only contractors needing flight line access will be serviced at AS-187.

Flight line access will still be granted at AS-302 using the procedures already in place.

NEW CONTRACTORS

- DBIDS credentials will be issued beginning June 25, 2018

- New contractors requiring access for over 60 days will receive a credential valid for up to one year.

- New contractors requiring access for less than 60 days will receive a temporary paper pass.

REMINDER: Beginning June 5, 2018, all personnel in possession of a RAPIDGate/MCESS credential will also be required to provide a second valid U.S. government form of identification. Beginning June 25, 2018, DBIDS credentials will be issued or exchanged in place of a RAPIDGate/MCESS credential. The last day

RAPIDGate/MCESS credentials will be authorized for entry onto the installation is September 30, 2018.

More information on DBIDS can be accessed by current CAC holders at https://dbids.dmdc.mil/#!/resources.

If you have questions regarding the exchange of a current RAPIDGate/MCESS credential for DBIDS or you are a new contractor seeking enrollment into DBIDS, please contact the Contractor Vetting Office at 910-451-

0283/0284/0285.

CLAUSES INCORPORATED BY REFERENCE

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements--

Representation

JAN 2017

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-7 System for Award Management OCT 2018

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2018

52.204-13 System for Award Management Maintenance OCT 2018

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-18 Commercial and Government Entity Code Maintenance JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-21 Basic Safeguarding of Covered Contractor Information

Systems

JUN 2016

52.204-22 Alternative Line Item Proposal JAN 2017

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.211-5 Material Requirements AUG 2000

52.211-17 Delivery of Excess Quantities SEP 1989

52.212-1 Instructions to Offerors--Commercial Items OCT 2018

52.212-4 Contract Terms and Conditions--Commercial Items OCT 2018

52.219-6 (Dev) Notice of Total Small Business Set-Aside (DEVIATION

2019-O0003).

JAN 2019

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

AUG 2018

52.232-1 Payments APR 1984

52.232-8 Discounts For Prompt Payment FEB 2002

52.232-11 Extras APR 1984

52.232-23 Assignment Of Claims MAY 2014

52.232-25 Prompt Payment JAN 2017

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.242-17 Government Delay Of Work APR 1984

52.243-1 Changes--Fixed Price AUG 1987

52.244-6 Subcontracts for Commercial Items JAN 2019

52.247-34 F.O.B. Destination NOV 1991

52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7004 Antiterrorism Awareness Training for Contractors. FEB 2019

252.204-7007 Alternate A, Annual Representations and Certifications JUN 2019

252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.213-7000 Notice to Prospective Suppliers on Use of Supplier

Performance Risk System in Past Performance Evaluations

MAR 2018

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7048 Export-Controlled Items JUN 2013

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.247-7023 Transportation of Supplies by Sea FEB 2019

CLAUSES INCORPORATED BY FULL TEXT

52.204-17 OWNERSHIP OR CONTROL OF OFFEROR (JUL 2016)

(a) Definitions. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics

Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity;

or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA

Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

Highest-level owner means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

Immediate owner means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

(b) The Offeror represents that it [ ___ ] has or [ ___ ] does not have an immediate owner. If the Offeror has more than one immediate owner (such as a joint venture), then the Offeror shall respond to paragraph (c) and if applicable, paragraph (d) of this provision for each participant in the joint venture.

(c) If the Offeror indicates ``has'' in paragraph (b) of this provision, enter the following information:

Immediate owner CAGE code:

Immediate owner legal name: ___

(Do not use a ``doing business as'' name)

Is the immediate owner owned or controlled by another entity?:

[ ___ ] Yes or [ ___ ] No.

(d) If the Offeror indicates ``yes'' in paragraph (c) of this provision, indicating that the immediate owner is owned or controlled by another entity, then enter the following information:

Highest-level owner CAGE code:

Highest-level owner legal name:

(Do not use a ``doing business as'' name)

(End of provision)

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.212-2 EVALUATION--COMMERCIAL ITEMS (Oct 2014) “TAILORED”

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

BASIS FOR AWARD WILL BE LOWEST PRICE TECHNICALLY ACCEPTABLE (LPTA)

THIS IS A BRAND NAME OR EQUAL PROCUREMENT.

The proposed acquisition is for a 100% small business set-aside for NAICS code 337910 and the small business size standard is 1,000 employees. Offerors must be registered in the System for Award Management

(SAM) database. Information on registering in SAM may be obtained by calling (866) 606-8220 or via the internet at http://www.sam.gov. The provision at 52.212-1, Instructions to Offerors - Commercial Items applies to this acquisition.

The Government intends to award a single firm-fixed price contract on an “all or none” basis for all items. The

Government reserves the right to award without discussions, but reserves the right to engage in discussions if later determined to be in the best interest of the Government. This acquisition will be conducted in accordance with FAR

13.5 - Simplified Procedures for Certain Commercial Items.

Quotes will be evaluated and ranked according to price, from lowest to highest. The Government reserves the right to evaluate only the technical quote of the lowest price quote. Other technical quotes may not be evaluated unless the Government determines the lowest price quote to be unacceptable or non-responsive. In the event that

Government determines the lowest price quote to be unacceptable, the next lowest price quote will be evaluated.

This process will continue until a technically acceptable quote is found.

Technical acceptability will be based on the demonstrated ability to meet the technical requirements as stated below.

A mere statement that the vendor “will meet the Government’s requirements” is insufficient; the vendor must demonstrate how it will meet the requirement.

Quotes are to be submitted via email to kyle.greene@usmc.mil or by fax at 910-451-2193 by the response date annotated in the solicitation

Lowest Price Technically Acceptable (LPTA) will be evaluated based on: (1) price; (2) technical acceptability, and

(3) past performance.

TECHNICAL ACCEPTABILITY: To ensure technical acceptability, vendor quotes shall include the following information:

a. Item Information: Descriptive literature showing all required specifications of the items quoted to include drawings The manufacturer’s name and manufacturer’s complete part numbers of all items quoted shall be submitted in the quote. A mere statement that the quote will meet the Government’s requirement is NOT sufficient. Quotes shall clearly state all products specifications for all items quoted.

DELIVERY: Clearly state if the quoter can meet the requested delivery as stated in each line item. Vendors who cannot meet the requested delivery are to provide an alternate date(s) of delivery and proposed delivery schedule.

PAST PERFORMANCE EVALUATION OF PPIRS HISTORY: For this volume, The vendor shall identify minum two contracts, or those portions of a relevant contract, whose performance is within three years of the proposal due date and contains efforts similar to those efforts (e.g., service, type effort, contract tasks, contract type, contract dollar value, etc.), required by this solicitation. Vendors shall provide point of contact information for each past peformance reference. Offerors shall also identify relevant contracts within the past three years that had any show-cause notices, cure notices, corrective action reports or termination for default. The Government will also review vendor's record in the Past Performance Information Retrieval System (www.ppirs.gov).

Offerors are reminded that the Government reserves the right to use information to evaluate past performance obtained from sources other than those identified by The vendor. The Government may send additional questionnaires and/or obtain information from sources identified by the Government evaluation team.

Vendors lacking relevant past performance history will not be evaluated favorably or unfavorably on past performance and will receive a neutral rating.

VENDORS MUST SUBMIT PRICING USING SAME CLIN STRUCTURE PROVIDED IN THIS RFQ TO

BE CONSIDERED FOR AN AWARD.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer's specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

52.212-3 OFFEROR REPRESENTATIONS AND CERTIFICATIONS--COMMERCIAL ITEMS (OCT 2018)

ALTERNATE I (OCT 2014)

http://www.ppirs.gov/

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u)) of this provision.

(a) Definitions. As used in this provision--

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Forced or indentured child labor” means all work or service—

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: Ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation,” means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

https://www.sam.gov/

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act

(50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern—

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern, consistent with 13 CFR 124.1002,” means a small business concern under the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans(as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of the its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern --

(1) That is at least 51 percent owned by one or more women or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program (in accordance with 13 CFR part 127),” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the

United States.

(b)

(1) Annual Representations and Certifications. Any changes provided by the Offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications in SAM.

(2) The offeror has completed the annual representations and certifications electronically in SAM accessed through http://www.sam.gov. After reviewing SAM information, the Offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and

Certifications--Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), at the time this offer is submitted and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs __.

[Offeror to identify the applicable paragraphs at (c) through (u) of this provision that the offeror has completed for the purposes of this solicitation only, if any.

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted electronically on SAM.]

(c) Offerors must complete the following representations when the resulting contract is to be performed in the

United States or its outlying areas. Check all that apply.

(1) Small business concern. The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a small business concern.

(2) Veteran-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a veteran-owned small business concern.

(3) Service-disabled veteran-owned small business concern. [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(2) of this provision.] The offeror represents as part of its offer that it [ ___ ] is, [ ___ ] is not a service-disabled veteran-owned small business concern.

(4) Small disadvantaged business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(5) Women-owned small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.]The offeror represents that it [ ___ ] is, [ ___ ] is not a women-owned small business concern.

Note: Complete paragraphs (c)(8) and (c)(9) only if this solicitation is expected to exceed the simplified acquisition threshold.

http://www.sam.gov/

(6) WOSB concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(5) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(6)(i) of this provision is accurate for each WOSB concern eligible under the WOSB

Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ___ .] Each

WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(7) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a WOSB concern eligible under the WOSB Program in (c)(6) of this provision.] The offeror represents that—

(i) It [ ___ ] is, [ ___ ] is not an EDWOSB concern, has provided all the required documents to the WOSB

Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It [ ___ ] is, [ ___ ] is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(7)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ___ .] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(8) Women-owned business concern (other than small business concern). [Complete only if the offeror is a women-owned business concern and did not represent itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it [ ___ ] is, a women-owned business concern.

(9) Tie bid priority for labor surplus area concerns. If this is an invitation for bid, small business offerors may identify the labor surplus areas in which costs to be incurred on account of manufacturing or production (by offeror or first-tier subcontractors) amount to more than 50 percent of the contract price:

(10) HUBZone small business concern. [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that--

(i) It [ ___ ] is, [ ___ ] is not a HUBZone small business concern listed, on the date of this representation, on the

List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR part 126; and

(ii) It [ ___ ] is, [ ___ ] is not a HUBZone joint venture that complies with the requirements of 13 CFR part 126, and the representation in paragraph (c)(10)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ___ .] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(11) (Complete if the offeror has represented itself as disadvantaged in paragraph (c)(4) of this provision.)

[The offeror shall check the category in which its ownership falls]:

___ Black American.

___ Hispanic American.

___ Native American (American Indians, Eskimos, Aleuts, or Native Hawaiians).

___ Asian-Pacific American (persons with origins from Burma, Thailand, Malaysia, Indonesia, Singapore, Brunei, Japan, China, Taiwan, Laos, Cambodia (Kampuchea), Vietnam, Korea, The Philippines, Republic of Palau, Republic of the Marshall Islands, Federated States of Micronesia, the Commonwealth of the Northern Mariana

Islands, Guam, Samoa, Macao, Hong Kong, Fiji, Tonga, Kiribati, Tuvalu, or Nauru).

___ Subcontinent Asian (Asian-Indian) American (persons with origins from India, Pakistan, Bangladesh, Sri

Lanka, Bhutan, the Maldives Islands, or Nepal).

___ Individual/concern, other than one of the preceding.

(d) Representations required to implement provisions of Executive Order 11246 --

(1) Previous contracts and compliance. The offeror represents that --

(i) It [ ___ ] has, [ ___ ] has not, participated in a previous contract or subcontract subject to the Equal

Opportunity clause of this solicitation; and

(ii) It [ ___ ] has, [ ___ ] has not, filed all required compliance reports.

(2) Affirmative Action Compliance. The offeror represents that --

(i) It [ ___ ] has developed and has on file, [ ___ ] has not developed and does not have on file, at each establishment, affirmative action programs required by rules and regulations of the Secretary of Labor (41 CFR parts

60-1 and 60-2), or

(ii) It [ ___ ] has not previously had contracts subject to the written affirmative action programs requirement of the rules and regulations of the Secretary of Labor.

(e) Certification Regarding Payments to Influence Federal Transactions (31 U.S.C. 1352). (Applies only if the contract is expected to exceed $150,000.) By submission of its offer, the offeror certifies to the best of its knowledge and belief that no Federal appropriated funds have been paid or will be paid to any person for influencing or attempting to influence an officer or employee of any agency, a Member of Congress, an officer or employee of

Congress or an employee of a Member of Congress on his or her behalf in connection with the award of any resultant contract. If any registrants under the Lobbying Disclosure Act of 1995 have made a lobbying contact on behalf of the offeror with respect to this contract, the offeror shall complete and submit, with its offer, OMB

Standard Form LLL, Disclosure of Lobbying Activities, to provide the name of the registrants. The offeror need not report regularly employed officers or employees of the offeror to whom payments of reasonable compensation were made.

(f) Buy American Certificate. (Applies only if the clause at Federal Acquisition Regulation (FAR) 52.225-1, Buy

American – Supplies, is included in this solicitation.)

(1) The offeror certifies that each end product, except those listed in paragraph (f)(2) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The offeror shall list as foreign end products those end products manufactured in the United States that do not qualify as domestic end products, i.e., an end product that is not a COTS item and does not meet the component test in paragraph (2) of the definition of

“domestic end product.” The terms “commercially available off-the-shelf (COTS) item,” “component,” “domestic end product,” “end product,” “foreign end product,” and “United States” are defined in the clause of this solicitation entitled “Buy American—Supplies.”

(2) Foreign End Products:

LINE ITEM NO. COUNTRY OF ORIGIN

[List as necessary]

(3) The Government will evaluate offers in accordance with the policies and procedures of FAR Part 25.

(g)

(1) Buy American -- Free Trade Agreements -- Israeli Trade Act Certificate. (Applies only if the clause at FAR

52.225-3, Buy American -- Free Trade Agreements -- Israeli Trade Act, is included in this solicitation.)

(i) The offeror certifies that each end product, except those listed in paragraph (g)(1)(ii) or (g)(1)(iii) of this provision, is a domestic end product and that for other than COTS items, the offeror has considered components of unknown origin to have been mined, produced, or manufactured outside the United States. The terms “Bahrainian, Moroccan, Omani, Panamanian, or Peruvian end product,” “commercially available off-the-shelf (COTS) item,”

“component,” “domestic end product,” “end product,” “foreign end product,” “Free Trade Agreement country,”

“Free Trade Agreement country end product,” “Israeli end product,” and “United States” are defined in the…