Terms_and_Conditions.doc

L15PS00520 – Road Beaver Culvert

Table of Contents

2Section 1

2Information to Offeror

39.1510.300—Signature Extension Page (Aug 1999)

4Section B—Supplies or Services and Prices

4Section C—Description and Specifications

4Section D—Packaging and Marking

5Section E—Inspection and Acceptance

6Section F—Deliveries or Performance

7Section G—Contract Administration Data

7Electronic Invoicing and Payment Requirements - Internet Payment Platform (IPP) APRIL 2011

9Section H—Special Contract Requirements

11Section I—Contract Clauses

19Section J—List of Documents, Exhibits and Other Attachments

19Section K—Representations, Certifications, and Other Statement of Offerors

29Section L—Instructions, Conditions and Notices to Bidders

32Section M—Evaluation Factors for Award

Section 1

Information to Offeror SITE VISIT – (a) The clauses at 52.236-2, Differing Site Conditions and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, you are urged and expected to inspect the site where the work will be performed.

An organized site visit has been scheduled for:

a. Date:

June 19, 2015

b. Time:

10 AM local time c.

Place:

Meet at the intersection of State Highway 149 and Gunnison County Road 27, as shown on the Vicinity Map, N38°17’34.14”, W107°06’41.45”.

Contractors shall provide their own transportation. Government transportation shall not be provided to contractors.

9.1510.300—Signature Extension Page (Aug 1999)

All persons participating in a "joint venture" shall sign as contractors, when submitting a quote. Spaces are provided below for additional signatures. A written acceptance is required; all signatures on the quote will be required on the written acceptance.

By: _______________________________________ By: ______________________________________

Name & Title: ______________________________ Name & Title: ______________________________

Address: __________________________________ Address: _________________________________

By: _______________________________________ By: ______________________________________

Name & Title: ______________________________ Name & Title: ______________________________

Address: __________________________________ Address: _________________________________

By: _______________________________________ By: ______________________________________

Name & Title: ______________________________ Name & Title: ______________________________

Address: __________________________________ Address: __________________________________

For persons involved in a "partnership" this quote must be signed in the partnership name. The contractor shall be prepared to furnish the Government, upon demand, a list of all partners, and proof that they have authority to sign for the partnership.

Section B—Supplies or Services and Prices B.1—Schedule of Items

TOTAL PROPOSAL FOR ITEMS 1-4 (ALL OR NONE) = $ ________________________

B.2—Evaluation for Award

Award will be made on a Schedule basis based on the available funds in accordance with Section L, Instructions, Conditions and Notices to Offeror, Clause 52.215-1, Instructions to Offerors – Competitive Acquisition and Section M, Evaluation and Award Factors.

Section C—Description and Specifications

C.1—Statement of Work Please see attached SOW Section D—Packaging and Marking

D.1—This section is not used.

Section E—Inspection and Acceptance

E.1—Clauses By Reference

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address (es):

www.acquisition.gov http://farsite.hill.af.mil/vffara.htm

E.2—Inspection

9.1510.301

INSPECTION

AUG 1999

(a) Work will be subject to periodic inspections by the Government to assure satisfactory progress, to determine quantities or work performed for progress payment purposes, to be certain that work is being performed in accordance with contract specifications, and to determine if work corrections are necessary.

(b) Inspection in the form of a review of all required reports will be performed by the Contracting Officer's Representative (COR). Accordingly, all reports, data, and documentation required by the contract will be submitted to the COR who will recommend approval/disapproval for acceptance purposes to the Contracting Officer.

(c) The Contractor shall notify the COR or the Project Inspector (PI) at least 3 days before the scheduled completion date, so the Government can schedule final inspection. The Contractor will not be granted a time extension to perform a work correction required as a result of a periodic or final inspection if such correction is necessary because of improper work by the Contractor. The Contractor or his authorized representative must be at the worksite at time of final inspection.

E.3—Acceptance

9.1510.302

ACCEPTANCE

Final inspection and acceptance of all items/services to be delivered under this contract shall be the responsibility of the Contracting Officer. Quality of work is subject to verification by the COR, with final payment to be withheld pending completion of any necessary rework by the Contractor.

Section F—Deliveries or Performance

F.1—Clauses By Reference

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

F.2—Commencement, Prosecution, and Completion of Work

52.211-10

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 49 days after receipt of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

*The Government recognizes that seasonal climatic conditions may occur that restrict or prohibit normal construction activities. The anticipated length of the seasonal delay for this project is 5 days. This number of days has been included in calculating the stated period of performance. Therefore, the contract period of performance will not be extended due to normal seasonal weather delays.

F.3—Charges for Actual Damages-Delayed Performance

9.1510.303

CHARGES FOR ACTUAL DAMAGES-DELAYED PERFORMANCE

AUG 199

Should the Contractor fail to complete the work within the performance time allowed or any extension there or, and his right to proceed is not terminated, he shall, in the absence of a liquidated damages provision, be charged actual dames suffered by the Government which can be directly attributable to the Contractor’s delayed performance. Such damages shall include, but not necessarily be limited to, the Project Inspector’s hourly salary, per-diem, travel or other expenses as well as losses of Government-Furnished property which can be accurately determined.

Section G—Contract Administration Data G.1—Procurement Office Representative

The Procurement Office Representative for this requirement is:

Contracting Officer Chau Nguyen Bureau of Land Management

Colorado State Office

2850 Youngfield Street

Lakewood, Colorado 80215

303-239-3678 cnguyen@blm.gov G.2—Contracting Officer’s Representative (COR)

Gordon Gardunio

Bureau of Land Management

Colorado State Office

2815 H Road

Grand Junction, CO 81506

970-244-3186 ggordunio@blm.gov G.3—Designated Government Office for Submitting Proper Invoice

9.1510.047

DESIGNATED GOVERNMENT OFFICE FOR SUBMITTING

PROPER INVOICE

(APR 1998)

Electronic Invoicing and Payment Requirements - Internet Payment Platform (IPP) APRIL 2011

Beginning May 1, 2011, payment requests for all new awards must be submitted electronically through the U. S. Department of the Treasury's Internet Payment Platform System (IPP). Payment terms for existing contracts and orders awarded prior to May 1 remain the same. The Contractor must use IPP for contracts and orders awarded May 1 and later, and must use the non-IPP invoicing process for those contracts and orders awarded prior to May 1.

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in FAR 32.905(b), "Payment documentation and process" and the applicable Prompt Payment clause included in this contract. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

Copy of contractor’s vendor commercial invoice

Payroll documents

Certification for progress payments under Fixed Price Construction Contracts The Contractor must use the IPP website to enroll, access and use IPP for submitting requests for payment. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the contracting officer.

(End of Template) G.4—Authorities and Delegations

AUTHORITIES AND DELEGATIONS

(MAY 2010)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR’s appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor’s risk.

Section H—Special Contract Requirements

H.1—Work Hours

9.1510.015

WORK HOURS

Work hours under this contract shall be limited to the hours of 7:00 am to4:00 pm, local time. If you require extended hours, you must put in a written request with the Contract rating Officer. No work will be done on Saturday, Sunday, or legal National Holidays or Federal Holidays unless authorized by the COR.

National and Federal Holidays to be observed are:

New Year Day

Independence Day

Labor Day

Memorial Day

Martin Luther King’s Birthday

Columbus Day

President’s Day

Veteran’s Day

Thanksgiving Day

Christmas Day

The Contractor shall observe any other day designated by Federal statute, Executive Order or the Presidential proclamation.

When any such day falls on a Saturday, the preceding Friday is observed; when any such day falls on a Sunday, the following Monday is observed. All personnel assigned to perform under this contract shall limit their observation of holidays to those set forth above.

H.2—Fire Danger Season

9.1510-016

FIRE DANGER SEASON

If the COR allows the Contractor to continue work during periods of declared fire danger or season, the Contractor shall comply with all applicable state laws relating to fire prevention and with all special conditions of work as directed by the COR.

H.3—Preservation of Historical and Archeological Data

9.1510-018

PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA (APR 1998)

(a) Public Law 93-291, May 24, 1974, provides for the preservation of scientific, prehistorical, and archeological data (including relics and specimens) which might otherwise be lost due to alteration of the terrain as a result of any Federal construction project.

(b) The Contractor agrees that should he or any of his employees in the performance of this contract discover evidence of possible scientific, prehistorical, historical, or archeological data he will notify the Contracting Officer immediately in writing giving the location and nature of the findings.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the applicable clauses in the Contract Clauses Section of this contract.

(d) The Contractor agrees to insert this paragraph in all subcontracts which involve the performance of work on the terrain of the site.

H.4—Pre-work Conference

9-1510-304

PRE-WORK CONFERENCE

(AUG 1999)

After award a pre-work conference shall be held between the Contractor and COR. The date and time of the meeting shall be determined by the COR and the Contractor in consultation. Discussions relative to contract requirements and the specific responsibilities of each party will be conducted at this time.

H.5—Notice to Proceed

9.1510-305

NOTICE TO PROCEED

(AUG 1999)

After award of contract, the COR will issue a written notice to proceed to the Contractor. Issuance of such notice may be delayed for a reasonable time if adverse soil, vegetative, or climatologically conditions exist.

H..6—Drawings

9-1510-017

DRAWINGS

(a) Typical Drawings. Any drawings titled typical are general only and dimensions of each structure will be fixed by the Contracting Officer to adapt the design to existing conditions at the structure location.

(b) Reduced Size Drawings. Any drawings identified as "REDUCED SIZE DRAWINGS" appearing in the solicitation are photographically reduced in size. Accordingly, measurements and dimensions should not be taken or be based on any numerical scales shown. Prospective bidders desiring to review a copy of the full size drawings may contact the Contracting Officer identified in the solicitation.

Section I—Contract Clauses

I.1—Clauses Incorporated by Reference

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/vffara.htm

52.204-07

Central Contractors Registration December 2012

I.2—Buy American Act-Construction Materials

(a) Definitions. As used in this clause--

“Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements the 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: ______ [Contracting Officer to list applicable excepted materials or indicate “none”]

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Item 1

Foreign construction material

Domestic construction material

Item 2

Foreign construction material

Domestic construction material

[List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.]

[Include other applicable supporting information.]

[*Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).] I.3—Subcontracts for Commercial Items

(a) Definitions. As used in this clause—

“Commercial item” has the meaning contained Federal Acquisition Regulation 2.101, Definitions.

“Subcontract” includes a transfer of commercial items between divisions, subsidiaries, or affiliates of the Contractor or subcontractor at any tier.

(b) To the maximum extent practicable, the Contractor shall incorporate, and require its subcontractors at all tiers to incorporate, commercial items or nondevelopmental items as components of items to be supplied under this contract.

(c)

(1) The Contractor shall insert the following clauses in subcontracts for commercial items:

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Apr 2010) (41 U.S.C. 3509), if the subcontract exceeds $5,000,000 and has a performance period of more than 120 days. In altering this clause to identify the appropriate parties, all disclosures of violation of the civil False Claims Act or of Federal criminal law shall be directed to the agency Office of the Inspector General, with a copy to the Contracting Officer.

(ii) 52.203-15, Whistleblower Protections Under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5), if the subcontract is funded under the Recovery Act.

(iii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), if the subcontract offers further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $650,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

(vi) 52.222-35, Equal Opportunity for Veterans (Jul 2014) (38 U.S.C. 4212(a));

(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(viii) 52.222-37, Employments Reports on Veterans (Jul 2014) (38 U.S.C. 4212).

(ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496), if flow down is required in accordance with paragraph (f) of FAR clause 52.222-40.

(x)

(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

(xi) 52.222-55, Establishing a Minimum Wage for Contractors (E.O. 13658) (Dec 2014).

(xii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xiii) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Dec 2013), if flow down is required in accordance with paragraph (c) of FAR clause 52.232-40.

(xiv) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. App. 1241 and 10 U.S.C. 2631), if flow down is required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may flow down to subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(d) The Contractor shall include the terms of this clause, including this paragraph (d), in subcontracts awarded under this contract.

I.4—Computer Generated Forms 52.253-1

COMPUTER GENERATED FORMS

(JAN 1991)

(a) Any data required to be submitted on a Standard or Optional Form prescribed by the Federal Acquisition Regulation (FAR) may be submitted on a computer generated version of the form, provided there is no change to the name, content, or sequence of the data elements on the form, and provided the form carries the Standard or Optional Form number and edition date.

(b) Unless prohibited by agency regulations, any data required to be submitted on an agency unique form prescribed by an agency supplement to the FAR may be submitted on a computer generated version of the form provided there is no change to the name, content, or sequence of the data elements on the form and provided the form carries the agency form number and edition date.

(c) If the Contractor submits a computer generated version of a form that is different than the required form, then the rights and obligations of the parties will be determined based on the content of the required form.

I.5—Authorized Deviations in Clauses

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the clause.

(b) The use in this solicitation or contract of any Department of the Interior Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205-1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government, or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

I.7—Release of Claims-Department of the Interior

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

I.8—Liability Insurance-Department of the Interior

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

WORKERS’ COMPENSATION AND EMPLOYER’S LIABILITY - $100,000

GENERAL LIABILITY - $500,000 per occurrence

AUTOMOBILE LIABILITY:

· $200,000 per person

· $500,000 per occurrence for bodily injury

· $20,000 per occurrence for property damage

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

Section J—List of Documents, Exhibits and Other Attachments

J.1—Department of Labor Wage Determination

Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are included in this Section. In the event the current prevailing Wage Determination is changed by the Department of Labor prior to the closing date of this solicitation it is the offeror’s responsibility to insure the most recent determination is used in preparing the proposal. An amendment will not be issued prior to closing to change Wage Determination dates and/or numbers. Applicable wage rates can be found at http://www.wdol.gov/.

See attached Davis Bacon Wage Rate J.2—Drawings/Maps/Site Location

See attached drawings Section K—Representations, Certifications, and Other Statement of Offerors

K.1 Solicitation Provisions Incorporated By Reference

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil/vffara.htm

K.2—Taxpayer Identification

52.204-03 Taxpayer Identification

October 1998

(a) Definitions.

"Common parent," as used in this provision, means that corporate entity that owns or controls an affiliated group of corporations that files its Federal income tax returns on a consolidated basis, and of which the offeror is a member.

"Taxpayer Identification Number (TIN)," as used in this provision, means the number required by the Internal Revenue Service (IRS) to be used by the offeror in reporting income tax and other returns. The TIN may be either a Social Security Number or an Employer Identification Number.

(b) All offerors must submit the information required in paragraphs (d) through (f) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the IRS. If the resulting contract is subject to the payment reporting requirements described in Federal Acquisition Regulation (FAR) 4.904, the failure or refusal by the offeror to furnish the information may result in a 31 percent reduction of payments otherwise due under the contract.

(c) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the

TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN.

(d) Taxpayer Identification Number (TIN).

[ ] TIN: _____________________.

[ ] TIN has been applied for.

[ ] TIN is not required because:

[ ] Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

[ ] Offeror is an agency or instrumentality of a foreign government;

[ ] Offeror is an agency or instrumentality of the Federal Government.

(e) Type of organization.

[ ] Sole proprietorship;

[ ] Partnership;

[ ] Corporate entity (not tax-exempt);

[ ] Corporate entity (tax-exempt);

[ ] Government entity (Federal, State, or local);

[ ] Foreign government;

[ ] International organization per 26 CFR 1.6049-4;

[ ] Other _________________________.

(f) Common parent.

[ ] Offeror is not owned or controlled by a common parent as defined in paragraph (a) of this provision.

[ ] Name and TIN of common parent:

Name _____________________________

TIN ______________________________

K.3—Small Business Program Representations

52.219-1 Small Business Program Representations.

As prescribed in 19.309(a)(1), insert the following provision:

Small Business Program Representations (Oct 2014)

(a) Definitions. As used in this provision-

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business concern eligible under the WOSB Program.

“Service-disabled veteran-owned small business concern”-

(1) Means a small business concern-

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) “Service-disabled veteran” means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and the size standard in paragraph (b) of this provision.

“Small disadvantaged business concern,” consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that-

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by-

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States, and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13 CFR 124.106) by individuals who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Veteran-owned small business concern” means a small business concern-

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Women-owned small business concern” means a small business concern-

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

(b)(1) The North American Industry Classification System (NAICS) code for this acquisition is– ________ [insert NAICS code].

(2) The small business size standard is _______ [insert size standard].

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(c) Representations.

(1) The offeror represents as part of its offer that it o is, o is not a small business concern.

(2) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents that it o is, o is not, a small disadvantaged business concern as defined in 13 CFR 124.1002.

(3) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it o is, o is not a women-owned small business concern.

(4) Women-owned small business (WOSB) concern eligible under the WOSB Program. [Complete only if the offeror represented itself as a women-owned small business concern in paragraph (c)(3) of this provision.] The offeror represents as part of its offer that-

(i) It o is, o is not a WOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It o is, o is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(4)(i) of this provision is accurate for each WOSB concern eligible under the WOSB Program participating in the joint venture. [The offeror shall enter the name or names of the WOSB concern eligible under the WOSB Program and other small businesses that are participating in the joint venture: ________.] Each WOSB concern eligible under the WOSB Program participating in the joint venture shall submit a separate signed copy of the WOSB representation.

(5) Economically disadvantaged women-owned small business (EDWOSB) concern. [Complete only if the offeror represented itself as a women-owned small business concern eligible under the WOSB Program in (c)(4) of this provision.] The offeror represents as part of its offer that-

(i) It o is, o is not an EDWOSB concern eligible under the WOSB Program, has provided all the required documents to the WOSB Repository, and no change in circumstances or adverse decisions have been issued that affects its eligibility; and

(ii) It o is, o is not a joint venture that complies with the requirements of 13 CFR part 127, and the representation in paragraph (c)(5)(i) of this provision is accurate for each EDWOSB concern participating in the joint venture. [The offeror shall enter the name or names of the EDWOSB concern and other small businesses that are participating in the joint venture: ________.] Each EDWOSB concern participating in the joint venture shall submit a separate signed copy of the EDWOSB representation.

(6) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents as part of its offer that it o is, o is not a veteran-owned small business concern.

(7) [Complete only if the offeror represented itself as a veteran-owned small business concern in paragraph (c)(6) of this provision.] The offeror represents as part of its offer that it o is, o is not a service-disabled veteran-owned small business concern.

(8) [Complete only if the offeror represented itself as a small business concern in paragraph (c)(1) of this provision.] The offeror represents, as part of its offer, that-

(i) It o is, o is not a HUBZone small business concern listed, on the date of this representation, on the List of Qualified HUBZone Small Business Concerns maintained by the Small Business Administration, and no material changes in ownership and control, principal office, or HUBZone employee percentage have occurred since it was certified in accordance with 13 CFR Part 126; and

(ii) It o is, o is not a HUBZone joint venture that complies with the requirements of 13 CFR Part 126, and the representation in paragraph (c)(8)(i) of this provision is accurate for each HUBZone small business concern participating in the HUBZone joint venture. [The offeror shall enter the names of each of the HUBZone small business concerns participating in the HUBZone joint venture: ________.] Each HUBZone small business concern participating in the HUBZone joint venture shall submit a separate signed copy of the HUBZone representation.

(d) Notice.

(1) If this solicitation is for supplies and has been set aside, in whole or in part, for small business concerns, then the clause in this solicitation providing notice of the set-aside contains restrictions on the source of the end items to be furnished.

(2) Under 15 U.S.C. 645(d), any person who misrepresents a firm’s status as a business concern that is small, HUBZone small, small disadvantaged, service-disabled veteran-owned small, economically disadvantaged women-owned small, or women-owned small eligible under the WOSB Program in order to obtain a contract to be awarded under the preference programs established pursuant to section 8, 9, 15, 31, and 36 of the Small Business Act or any other provision of Federal law that specifically references section 8(d) for a definition of program eligibility, shall-

(i) Be punished by imposition of fine, imprisonment, or both;

(ii) Be subject to administrative remedies, including suspension and debarment; and

(iii) Be ineligible for participation in programs conducted under the authority of the Act.

(End of provision)

K.3—Previous Contracts and Compliance Reports

52.222-22

PREVIOUS CONTRACTS AND COMPLICANE REPORTS

FEB 1999

The offeror represents that--

(a) It [ ] has, [ ] has not participated in a previous contract or subcontract subject to the Equal Opportunity clause of this solicitation;

(b) It [ ] has [ ] has not filed all required compliance reports; and

(c) Representations indicating submission of required compliance reports, signed by proposed subcontractors, will be obtained before subcontract awards.

K.4—Annual Representations and Certifications

52.204-8 -- Annual Representations and Certifications

As prescribed in 4.1202, insert the following provision:

Annual Representations and Certifications (Dec 2014)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238110.

(2) The small business size standard is $15.0 Mil

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of…