Sol_L15PS00238.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040196733

BLM NM-STATE OFC-ALBUQUERQUE(NM916)

435 MONTANO RD NE

ALBUQUERQUE NM 87107

LXT

Clarisa Gallegos 505-761-8917

1x 03/16/2015

L15PS00238

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Paving specifications/statement of work

Bid schedule

BLM paving drawings

Boat parking curb and gutter plan

Day use curb and gutter plan

Evaluation criteria

Santa Cruz Lake Project Site map

Wage Determination rates NM048

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

0 45 calendar days and complete it within ________________ ________________ calendar days after receiving

04/20/2015

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

BLM NM-STATE OFC-ALBUQUERQUE(NM916)

435 MONTANO RD NE

ALBUQUERQUE NM 87107

LXT

Hermie (Reb) Conn

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 29

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

L15PS00238

The Bureau of Land Management (BLM), Taos Field

Office (TAFO), is seeking to pave and construct concrete curb and gutter at the Boat Ramp Parking

Lot, Day Use Parking Lot and sections of the site road at Santa Cruz Lake Recreation Area in accordance with the attached paving specifications/statement of work.

The Government intends to award one firm-fixed price contract in response to this solicitation to the contractor who represents the best value to the Government in accordance with the best value procedures as outlined in Section M of the solicitation and FAR 15.101-2 - Lowest Price

Technically Acceptable (LPTA) source selection process. See Section M of this solicitation for details on offeror submission requirements to respond to LPTA evaluation factors. All responsive offerors will be considered by the agency.

The prospective contractor must fully demonstrate their abilities, as well as specific expertise in concurrently managing a variety of construction projects, in a manner that complies with Federal, State, and local regulations and laws and within the time frame required.

The government will evaluate all firms using source selection procedures (See Section M of this solicitation for details on offeror submission requirements to respond to LPTA evaluation factors), in order to determine the firms experience in providing the type of work, experience of key personnel, past performance, and project schedule.

All firms or individuals responding must be registered with the System for Award Management

(SAM) at https://www.sam.gov/portal/public/SAM.

SAM registrations must indicate that their Online

Representations and Certifications Application

(ORCA) are service-disabled veteran-owned small business(SDVOSB)under NAICS 237310. This acquisition is 100 percent set-aside for SDVOSBs under this NAICS. To complete ORCA registrations, Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

4 29

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

L15PS00238

go to https://www.sam.gov/portal/public/SAM

In accordance with FAR 36.206, liquidated damages will be assessed for each calendar day required to complete the construction work on this project past the schedule completion date. The contractor has complete control of the pace of work.

Liquidated damages shall be in the amount of:

$1263 per calendar day

Offers must be submitted electronically via email per the following instructions:

Offerors shall submit two electronic files with separate volumes as their proposal.

Volume one: All pricing in accordance with the

RFP bid schedule.

Volume two: Past performance and technical information based on the attached evaluation factors which shall be evaluated on a LPTA basis by the Bureau of Land Management technical evaluation panel. All technical factors and past performance are equal in importance.

When responding, please include the solicitation number in the subject line of the e-mail. Submit offers to the Contracting Officer at the following email address: hconn@blm.gov by the solicitation closing date and time.

An electronic copy of the offerors bid guarantee is acceptable if the original bid guarantee is received at the BLM office location in BLOCK 7.

The Contracting Officers non-receipt of an original bid guarantee by no later than April 21, 2015 will result in that offer being determined to be non-responsive and rejected as such.

There will be a pre-bid conference and site visit on April 6, 2015 at 2:00 p.m. at the Santa Cruz

Lake Recreation Area project site which is located in Cundiyo, NM. Site is located approximately 90 miles northeast of Albuquerque, NM (see attached map for directions).

Any questions or clarification requests regarding

Continued ...

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

5 29

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

L15PS00238

any aspect of this solicitation are due no later than April 13, 2015 at 4:00 PM Mountain Standard

Time (MST) and must be submitted via email to hconn@blm.gov.

Suggested COR: CMARTIN3

FOB: Destination

Period of Performance: 05/22/2015 to 07/15/2015

00010 Paving Project at Santa Cruz Lake

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Solicitation L15PS00238

Section I…………………………………………………………………………………………… Page 2

Section J…………………………………………………………………………………………… Page 12

Section K…………………………………………………………………………………………... Page 12

Section L…………………………………………………………………………………………… Page 19

Section M…………………………………………………………………………………………... Page 23

Section I - Contract Clauses

52.202-1 Definitions. (NOV 2013)

52.203-3 Gratuities. (APR 1984)

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-6 Restrictions on Subcontractor Sales to the Government. (SEP 2006)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. (MAY 2014)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (OCT 2010)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights. (APR 2014)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards (JUL 2013)

52.204-13 System for Award Management Maintenance (JUL 2013)

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment. (AUG 2013)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. (JUL 2013)

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 45 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 7/15/2015. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 6/1/2015. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-12 Liquidated Damages - Construction. (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1263.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.215-2 Audit and Records - Negotiation. (OCT 2010)

52.219-8 Utilization of Small Business Concerns. (OCT 2014)

52.219-14 Limitations on Subcontracting. (NOV 2011)

52.219-27 Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (NOV 2011)

52.222-1 Notice to the Government of Labor Disputes. (FEB 1997)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation. (MAY 2014)

52.222-6 Construction Wage Rate Requirements. (MAY 2014)

52.222-7 Withholding of Funds. (MAY 2014)

52.222-8 Payrolls and Basic Records. (MAY 2014)

52.222-9 Apprentices and Trainees. (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements. (FEB 1988)

52.222-11 Subcontracts (Labor Standards). (MAY 2014)

52.222-12 Contract Termination - Debarment. (MAY 2014)

52.222-13 Compliance With Construction Wage Rate Requirements and Related Regulations. (MAY 2014)

52.222-14 Disputes Concerning Labor Standards. (FEB 1988)

52.222-15 Certification of Eligibility. (MAY 2014)

52.222-21 Prohibition of Segregated Facilities. (FEB 1999)

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999)

52.222-26 Equal Opportunity. (MAR 2007)

52.222-27 Affirmative Action Compliance Requirements for Construction. (FEB 1999)

52.222-35 Equal Opportunity for Veterans. (JUL 2014)

52.222-36 Equal Opportunity for Workers with Disabilities. (JUL 2014)

52.222-37 Employment Reports on Veterans. (JUL 2014)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (DEC 2010)

52.222-50 Combating Trafficking in Persons. (FEB 2009)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(SEP 2013)

52.223-6 Drug-Free Workplace. (MAY 2001)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. (AUG 2011)

52.225-9 Buy American - Construction Materials. (MAY 2014)

(a) Definitions. As used in this clause-

Commercially available off-the-shelf (COTS) item- (1) Means any item of supply (including construction material) that is-

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

Cost of components means-

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph

(1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means-

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if-

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference. (1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that-

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including-

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph

(d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute or Balance of Payments Program.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison

Construction material description Unit of Quantity Price

Measure (dollars)*

Item 1:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

Item 2:

Foreign construction material ________ ________ ________

Domestic construction material ________ ________ ________

* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

(End of clause)

52.225-13 Restrictions on Certain Foreign Purchases. (JUN 2008)

52.228-2 Additional Bond Security. (OCT 1997)

52.228-5 Insurance - Work on a Government Installation. (JAN 1997)

52.228-11 Pledges of Assets. (JAN 2012)

52.228-14 Irrevocable Letter of Credit. (NOV 2014)

52.228-15 Performance and Payment Bonds - Construction. (OCT 2010)

52.229-3 Federal, State, and Local Taxes. (FEB 2013)

52.232-5 Payments Under Fixed-Price Construction Contracts. (MAY 2014)

52.232-17 Interest. (MAY 2014)

52.232-23 Assignment of Claims. (MAY 2014)

52.232-27 Prompt payment for construction contracts. (MAY 2014)

52.232-33 Payment by Electronic Funds Transfer - System for Award Management. (JUL 2013)

52.232-39 Unenforceability of Unauthorized Obligations. (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors. (DEC 2013)

52.233-1 Disputes. (MAY 2014)

52.233-3 Protest after Award. (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim. (OCT 2004)

52.236-2 Differing Site Conditions. (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work. (APR 1984)

52.236-5 Material and Workmanship. (APR 1984)

52.236-6 Superintendence by the Contractor. (APR 1984)

52.236-7 Permits and Responsibilities. (NOV 1991)

52.236-8 Other Contracts. (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

(APR 1984)

52.236-10 Operations and Storage Areas. (APR 1984)

52.236-11 Use and Possession Prior to Completion. (APR 1984)

52.236-12 Cleaning Up. (APR 1984)

52.236-13 Accident Prevention. (NOV 1991)

52.236-17 Layout of Work. (APR 1984)

52.236-21 Specifications and Drawings for Construction. (FEB 1997)

52.236-26 Preconstruction Conference. (FEB 1995)

If the Contracting Officer decides to conduct a preconstruction conference, the successful offeror will be notified and will be required to attend. The Contracting Officer's notification will include specific details regarding the date, time, and location of the conference, any need for attendance by subcontractors, and information regarding the items to be discussed.

(End of clause)

52.242-13 Bankruptcy. (JUL 1995)

52.242-14 Suspension of Work. (APR 1984)

52.243-4 Changes. (JUN 2007)

52.244-6 Subcontracts for Commercial Items. (OCT 2014)

52.246-12 Inspection of Construction. (APR 1996)

52.246-21 Warranty of Construction. (MAR 1994)

52.249-2 Termination for Convenience of the Government (Fixed-Price). (APR 2012) - Alternate I

(SEP 1996)

52.249-10 Default (Fixed-Price Construction). (APR 1984)

52.252-2 Clauses Incorporated by Reference. (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

http://www.acquisition.gov/far/index.html (FAR), (End of clause)

52.253-1 Computer Generated Forms. (JAN 1991)

1452.204-70 Release of Claims (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-

137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

1452.228-70 Liability Insurance (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

$[] each person*

$[] each occurrence*

$[] property damage*

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed.

The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

*These amounts to be set by the Contracting Officer.

(End of clause)

1452.233-2 Service of Protest

As prescribed in 1433.106, the provision at FAR 52.233-2, Service of Protest, shall be modified before insertion into solicitations and contracts by changing the title of the provision to read:

"SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (JUL 1996) (DEVIATION)";

and adding the following sentence to the end of the provision:

(c) A copy of the protest served on the Contracting Officer shall be simultaneously furnished by the protester to the Department of the Interior Assistant Solicitor for Procurement and Patents, 1849 C Street, NW, Room 6511, Washington, D.C. 20240."

DOI ELECTRONIC INVOICING Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [CO to edit and include the documentation required under this contract]:

The Contractor must use the IPP website to register, access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Template)

DOI AUTHORITIES AND DELEGATIONS AUTHORITIES AND DELEGATIONS (MAY 2010)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award.

The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The

COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor.

Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment. The COR for this contract will be:

Herbert Chavez 226 Cruz Alta Road Taos, NM 87571 575-751-4730

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR¿s appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor¿s risk.

(End of notice)

DOI TEXT MESSAGING Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009)

Prohibition on Text Messaging and Using Electronic Equipment Supplied by the Government while Driving (October 2009)

Executive Order 13513 , Federal Leadership On Reducing Text Messaging While Driving , was signed by President Barack Obama on October 1, 2009 (Ref: http://edocket.access.gpo.gov/2009/pdf/E9-24203.pdf).

This Executive Order introduces a Federal Government-wide prohibition on the use of text messaging while driving on official business or while using Government-supplied equipment. Additional guidance enforcing the ban will be issued at a later date. In the meantime, please adopt and enforce policies that immediately bans text messaging while driving company-owned or rented vehicles, government owned or leased vehicles, or while driving privately owned vehicles while on official government business or when performing any work for or on behalf of the government.

End of Clause

Section J - List of Documents, Exhibits and Other Attachments

List of Documents, Exhibits, and Other Attachments

Attachment Number Title

1 Paving Specifications/ Statement of Work 2 Evaluation Criteria 3 BLM paving Drawings 4 Boat Parking Curb and Gutter Plan 5 Day use Parking and Gutter Plan 6 Santa Cruz Locational Map 7 SCL Bid Schedule 8 Wage Determination Rates

Section K - Representations, Certifications, and Other Statements of Bidders

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. (SEP 2007)

52.204-8 Annual Representations and Certifications. (DEC 2014)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237310.

(2) The small business size standard is $36.5M.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in the System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

[X] (i) Paragraph (d) applies.

[ ] (ii) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless-

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include provision at 52.204-7, System for Award Management.

(iv) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(v) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations- Representation.

(vi) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(vii) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(viii) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(ix) 52.219-1, Small Business Program Representations (Basic & Alternate I).

This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(x) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xi) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xii) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xiii) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xiv) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

(xv) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xvi) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xvii) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates I, II, and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $79,507, the provision with its Alternate II applies.

(D) If the acquisition value is $79,507 or more but is less than $100,000, the provision with its Alternate III applies.

(xviii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xix) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xx) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications.

This provision applies to all solicitations.

(xxi) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following certifications are applicable as indicated by the Contracting Officer:

(Contracting Officer check as appropriate.)

[ ] (i) 52.204-17, Ownership or Control of Offeror.

[ ] (ii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[ ] (iii) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Certification.

[ ] (iv) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

[ ] (v) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-Designated Products (Alternate I only).

[ ] (vi) 52.227-6, Royalty Information.

[ ] (A) Basic.

[ ] (B) Alternate I.

[ ] (vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM Web site accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph

(c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below (offeror to insert changes, identifying change by clause number, title, date). These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause No. Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-5 Certification Regarding Responsibility Matters. (APR 2010)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are [] are not X presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have [] have not X, within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for:

commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks "have", the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are [] are not X presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision; and

(D) Have [], have not X, within a three-year period preceding this offer, been notified of any delinquent Federal taxes in an amount that exceeds $3,000 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection.

The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has [] has not X, within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) "Principal," for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

52.209-7 Information Regarding Responsibility Matters. (JUL 2013)

(a) Definitions. As used in this provision-

"Administrative proceeding" means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

"Federal contracts and grants with total value greater than $10,000,000" means-

(1) The total value of all current, active contracts and grants, including all priced options;

and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

"Principal" means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror [] has [] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of…