Solicitation - FA557520R0002.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA557520R0002

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

QUUG 15-1010 Rpr by Replacement the existing Fire Alarm Reporting System Product Service Code: N063

CIN: 00000000000005527042

1.0 Lot

QUUG 15-1010 Install Mass Notification system Product Service Code: N063

CIN: 00000000000005527043

1.0 Lot

QUUG 15-1010 Rpr Giant Voice Product Service Code: N063

CIN: 00000000000005527044

1.0 Lot

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.229-7005 Tax Exemptions (Spain). 2012-03

DFARS Clauses Incorporated by Full Text

252.229-7004 Status of Contractor as a Direct Contractor (Spain). 1997-06

As prescribed in 229.402-70(d), use the following clause:

STATUS OF CONTRACTOR AS A DIRECT CONTRACTOR ( SPAIN ) (JUN 1997)

(a) "Direct Contractor," as used in this clause, means an individual, company, or entity with whom an agency of the United States Department of Defense has executed a written agreement that allows duty-free import of equipment, materials, and supplies into Spain for the construction, development, maintenance, and operation of Spanish-American installations and facilities.

(b) The Contractor is hereby designated as a Direct Contractor under the provisions of Complementary Agreement 5, articles 11, 14, 15, 17, and 18 of the Agreement on Friendship, Defense and Cooperation between the United States Government and the Kingdom of Spain , dated July 2, 1982 . The Agreement relates to contracts to be performed in whole or part in Spain , the provisions of which are hereby incorporated into and made a part of this contract by reference.

(c) The Contractor shall apply to the appropriate Spanish authorities for approval of status as a Direct Contractor in order to complete duty-free import of non-Spanish equipment, materials, and supplies represented as necessary for contract performance by the Contracting Officer. Orders for equipment, materials, and supplies placed prior to official notification of such approval shall be at the Contractor's own risk. The Contractor must submit its documentation in sufficient time to permit processing by the appropriate United States and Spanish Government agencies prior to the arrival of the equipment, materials, or supplies in Spain . Seasonal variations in processing times are common, and the Contractor should program its projects accordingly. Any delay or expense arising directly or indirectly from this process shall not excuse untimely performance (except as expressly allowed in other provisions of this contract), constitute a direct or constructive change, or otherwise provide a basis for additional compensation or adjustment of any kind.

(d) To ensure that all duty-free imports are properly accounted for, exported, or disposed of, in accordance with Spanish law, the Contractor shall obtain a written bank letter of guaranty payable to the Treasurer of the United States, or such other authority as may be designated by the Contracting Officer, in the amount set forth in paragraph (g) of this clause, prior to effecting any duty-free imports for the performance of this contract.

(e) If the Contractor fails to obtain the required guaranty, the Contractor agrees that the Contracting Officer may withhold a portion of the contract payments in order to establish a fund in the amount set forth in paragraph (g) of this clause. The fund shall be used for the payment of import taxes in the event that the Contractor fails to properly account for, export, or dispose of equipment, materials, or supplies imported on a duty-free basis.

(f) The amount of the bank letter of guaranty or size of the fund required under paragraph (d) or (e) of this clause normally shall be 5 percent of the contract value. However, if the Contractor demonstrates to the Contracting Officer's satisfaction that the amount retained by the United States Government or guaranteed by the bank is excessive, the amount shall be reduced to an amount commensurate with contingent import tax and duty-free liability. This bank guaranty or fund shall not be released to the Contractor until the Spanish General Directorate of Customs verifies the accounting, export, or disposition of the equipment, material, or supplies imported on a duty-free basis.

(g) The amount required under paragraph (d), (e), or (f) of this clause is 10%(Contracting Officer insert amount at time of contract award) .

(h) The Contractor agrees to insert the provisions of this clause, including this paragraph (h), in all subcontracts.

(End of clause)

Section C - Description/Specifications/Statement of Work

See Section J for list of Attachments.

Requirements QUUG 15-1010 Rpr/Add F. Alarm Reporting Sys Mass Notification Sys

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08

0001 Inspection and Acceptance Location Both Destination Instructions: Construction Management Office will perform daily inspections of the work site.

DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Chief of Engineering Telephone: 722-8317 Email:

0002 Inspection and Acceptance Location Both Destination Instructions: Construction Management Office will perform daily inspections of the work site.

DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Chief of Engineering Telephone: 722-8317 Email:

0003 Inspection and Acceptance Location Both Destination Instructions: Construction Management Office will perform daily inspections of the work site.

DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Chief of Engineering Telephone: 722-8317 Email:

Section F - Deliveries or Performance

Delivery Schedule Ship To Address

Delivery Requested By

31 AUG 2021

1.0 Lot

Ship To DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Chief of Enginerring Telephone: 722-8317 Email:

Delivery Schedule Ship To Address

Delivery Requested By

31 AUG 2021

1.0 Lot

Ship To DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Chief of Enginerring Telephone: 722-8317 Email:

Delivery Schedule Ship To Address

Delivery Requested By

31 AUG 2021

1.0 Lot

Ship To DoDAAC: F3N7A0 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

712 CES CER

AF BPN NO MILSBILLS PROCESSES

UNIT 6585 BLDG 202 MORON AB

, APO AE 09643 6585

United States

OfficeCode:

496 ABS Civil Engineering Email:

Telephone: 722-8317

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.247-34 F.o.b. Destination. 1991-11

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.204-7006 Billing Instructions. 2005-10 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.232-7008 Assignment of Claims (Overseas). 1997-06 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12

As prescribed in 232.7004(b), use the following clause:

WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) As used in this clause- Definitions.

"Department of Defense Activity Address Code (DoDAAC)" is a six position code that uniquely identifies a unit, activity, or organization.

"Document type" means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

"Local processing office (LPO)" is the office responsible for payment certification when payment certification is done external to the entitlement system.

"Payment request" and "receiving report" are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(b) The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as Electronic invoicing.

authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) To access WAWF, the Contractor shall- WAWF access.

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site.

(d) The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice WAWF training.

Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the "Web Based Training" link on the WAWF home page at https://wawf.eb.mil/

(e) Document submissions may be via web entry, Electronic Data Interchange, or File Transfer WAWF methods of document submission.

Protocol.

(f) The Contractor shall use the following information when submitting payment requests and receiving reports WAWF payment instructions.

in WAWF for this contract or task or delivery order:

(1) The Contractor shall submit payment requests using the following document type(s): Document type.

(i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items-

(A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer.

(Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.)

(B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer. Construction Invoice

(Contracting Officer: Insert either "Invoice 2in1" or the applicable invoice and receiving report document type(s) for fixed price line items for services.)

(iii) For customary progress payments based on costs incurred, submit a progress payment request.

(iv) For performance based payments, submit a performance based payment request.

(v) For commercial item financing, submit a commercial item financing request.

(2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract.

(f) [Note: The Contractor may use a WAWF "combo" document type to create some combinations of invoice and receiving report in one step.]

(3) The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in Document routing.

WAWF when creating payment requests and receiving reports in the system.

Routing Data Table*

Field Name in WAWF Data to be entered in WAWF

Pay Official DoDAAC F87700

Issue By DoDAAC FA5575

Admin DoDAAC FA5575

Inspect By DoDAAC FA5575

Ship To Code ____

Ship From Code ____

Mark For Code ____

Service Approver (DoDAAC) ____

Service Acceptor (DoDAAC) ____

Accept at Other DoDAAC ____

LPO DoDAAC ____

DCAA Auditor DoDAAC ____

Other DoDAAC(s) ____

(*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert "See Schedule" or "Not applicable.")

(**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).)

(4) The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in Payment request.

accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable.

(5) The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. Receiving report.

(g) WAWF point of contact.

(1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

(Contracting Officer: Insert applicable information or "Not applicable.")

(2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed.

Section H - Special Contract Requirements

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

As prescribed in 4.2105(a), insert the following provision:

REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT (AUG 2020)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Items.

(a) Definitions. As used in this provision- Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition. (1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [] will, [] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that-- It [] does, [] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)

(2) of this section.

(e) Disclosures. (1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

As prescribed in 4.2105(b), insert the following clause:

Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment (Aug 2020)

(a) Definitions. As used in this clause--

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means-

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means-

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled-

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub.

L. 115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or redirect user data traffic or permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(d) Reporting requirement.

(1) In the event the Contractor identifies covered telecommunications equipment or services used as a substantial or essential component of any system, or as critical technology as part of any system, during contract performance, or the Contractor is notified of such by a subcontractor at any tier or by any other source, the Contractor shall report the information in paragraph (d)(2) of this clause to the Contracting Officer, unless elsewhere in this contract are established procedures for reporting the information; in the case of the Department of Defense, the Contractor shall report to the website at https://dibnet.dod.mil. For indefinite delivery contracts, the Contractor shall report to the Contracting Officer for the indefinite delivery contract and the Contracting Officer(s) for any affected order or, in the case of the Department of Defense, identify both the indefinite delivery contract and any affected orders in the report provided at https://dibnet.dod.mil.

(2) The Contractor shall report the following information pursuant to paragraph (d)(1) of this clause

(i) Within one business day from the date of such identification or notification: the contract number; the order number(s), if applicable; supplier name; supplier unique entity identifier (if known); supplier Commercial and Government Entity (CAGE) code (if known); brand; model number (original equipment manufacturer number, manufacturer part number, or wholesaler number); item description; and any readily available information about mitigation actions undertaken or recommended.

(ii) Within 10 business days of submitting the information in paragraph (d)(2)(i) of this clause: any further available information about mitigation actions undertaken or recommended. In addition, the Contractor shall describe the efforts it undertook to prevent use or submission of covered telecommunications equipment or services, and any additional efforts that will be incorporated to prevent future use or submission of covered telecommunications equipment or services.

(e) Subcontracts. The Contractor shall insert the substance of this clause, including this paragraph (e) and excluding paragraph (b)(2), in all subcontracts and other contractual instruments, including subcontracts for the acquisition of commercial items.

(End of clause)

FAR Clauses Incorporated by Full Text

52.236-1 Performance of Work by the Contractor. 1984-04

As prescribed in , insert the following clause: [36.501(b) Complete the clause by inserting the appropriate percentage consistent with the complexity ]and magnitude of the work and customary or necessary specialty subcontracting (see 36.501(a)).

PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least [10% insert the appropriate number in words percent of the total amount of work to be performed under the contract. This percentage may be reduced by a ]followed by numerals in parentheses supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.202-1 Definitions. 2013-11 52.203-5 Covenant Against Contingent Fees. 2014-05 52.203-6 Restrictions on Subcontractor Sales to the Government. 2006-09 52.203-7 Anti-Kickback Procedures. 2014-05 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. 2014-05 52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

2007-09

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights.

2014-04

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements. 2017-01 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. 2011-05 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment.

2015-10

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. 2018-10 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-50 Combating Trafficking in Persons. 2019-01 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.228-11 Pledges of Assets. 2018-08 52.228-14 Irrevocable Letter of Credit. 2014-11 52.229-6 Taxes-Foreign Fixed-Price Contracts. 2013-02 52.232-8 Discounts for Prompt Payment. 2002-02 52.232-11 Extras. 1984-04 52.232-17 Interest. 2014-05 52.232-27 Prompt Payment for Construction Contracts. 2017-01 52.232-33 Payment by Electronic Funds Transfer-System for Award Management. 2018-10 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-15 Schedules for Construction Contracts. 1984-04 52.236-21 Specifications and Drawings for Construction. 1997-02 52.236-26 Preconstruction Conference. 1995-02 52.242-13 Bankruptcy. 1995-07 52.242-14 Suspension of Work. 1984-04 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1987-08 52.243-4 Changes. 2007-06 52.244-6 Subcontracts for Commercial Items. 2019-08 52.246-21 Warranty of Construction. 1994-03 52.249-2 Termination for Convenience of the Government (Fixed-Price). 2012-04 52.249-10 Default (Fixed-Price Construction). 1984-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-Related Felonies.

2008-12

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting. 2019-12 252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05 252.205-7000 Provision of Information to Cooperative Agreement Holders 1991-12

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is a State Sponsor of Terrorism.

2019-05

252.222-7002 Compliance with Local Labor Laws (Overseas). 1997-06 252.222-7004 Compliance with Spanish Social Security Laws and Regulations. 1997-06 252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements. 2010-12 252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7012 Preference for Certain Domestic Commodities. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7041 Correspondence in English. 1997-06 252.225-7043 Antiterrorism/Force Protection for Defense Contractors Outside the United States. 2015-06 252.225-7048 Export-Controlled Items. 2013-06 252.232-7010 Levies on Contract Payments. 2006-12

252.232-7017 Accelerating Payments to Small Business Subcontractors-Prohibition on Fees and Consideration.

2020-04

252.233-7001 Choice of Law (Overseas). 1997-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.243-7002 Requests for Equitable Adjustment. 2012-12

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. 1989-12

As prescribed in , insert the following clause:4.103

APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of and shall not be binding [ ]A Contracting Officer identify title of designated agency official here until so approved.

(End of clause)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. 2016-02

As prescribed in , insert the following provision:9.104-7(d)

REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A FELONY CONVICTION UNDER ANY

FEDERAL LAW (FEB 2016)

As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), (a) and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-

Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or (1) have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware (2) of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

The Offeror represents that-(b)

It is is not a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and (1) ____ ____ administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

It is is not a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.(2) ____ ____

(End of provision)

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04

As prescribed in , insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The 11.404(b) clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction.

COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within calendar days after the [ ]10 Contracting Officer insert number date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365

.* The time stated for completion shall include final cleanup of the premises.days after NTP

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 Liquidated Damages-Construction. 2000-09

As prescribed in , insert the following clause in solicitations and contracts:11.503(b)

LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the (a) Government in the amount of for each calendar day of delay [ ]752.64 EUROS for the first day and 628.52 EUROS Contracting Officer insert amount until the work is completed or accepted.

If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. (b) These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.232-5 Payments under Fixed-Price Construction Contracts. 2014-05

As prescribed in , insert the following clause:32.111(a)(5)

PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

. The Government shall pay the Contractor the contract price as provided in this contract.(a) Payment of price

. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as (b) Progress payments determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

The Contractor's request for progress payments shall include the following substantiation:(1)

An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment (i) requested.

A listing of the amount included for work performed by each subcontractor under the contract.(ii)

A listing of the total amount of each subcontract under the contract.(iii)

A listing of the amounts previously paid to each such subcontractor under the contract.(iv)

Additional supporting data in a form and detail required by the Contracting Officer.(v)

In the preparation of estimates, the Contracting Officer may authorize material delivered on the site and preparatory work done to be (2) taken into consideration. Material delivered to the Contractor at locations other than the site also may be taken into consideration if-

Consideration is specifically authorized by this contract; and(i)

The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform (ii) this contract.

. Along with each request for progress payments, the Contractor shall furnish the following certification, or payment (c) Contractor certification shall not be made: (However, if the Contractor elects to delete paragraph (c)(4) from the certification, the certification is still acceptable.)

I hereby certify, to the best of my knowledge and belief, that-

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of Chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract; and

(4) This certification is not to be construed as final acceptance of a subcontractor's performance.

____ ( )Name

____ ( )Title

____ ( )Date

. If the Contractor, after making a certified request for progress payments, discovers that a portion or all of (d) Refund of unearned amounts such request constitutes a payment for performance by the Contractor that fails to conform to the specifications, terms, and conditions of this contract (hereinafter referred to as the "unearned amount"), the Contractor shall-

Notify the Contracting Officer of such performance deficiency; and(1)

Be obligated to pay the Government an amount (computed by the Contracting Officer in the manner provided in paragraph (j) of this (2) clause) equal to interest on the unearned amount from the 8 thday after the date of receipt of the unearned amount until-

The date the Contractor notifies the Contracting Officer that the performance deficiency has been corrected; or(i)

The date the Contractor reduces the amount of any subsequent certified request for progress payments by an amount equal to the (ii) unearned amount.

. If the Contracting Officer finds that satisfactory progress was achieved during any period for which a progress payment is to be (e) Retainage made, the Contracting Officer shall authorize payment to be made in full. However, if satisfactory progress has not been made, the Contracting Officer may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved. When the work is substantially complete, the Contracting Officer may retain from previously withheld funds and future progress payments that amount the Contracting Officer considers adequate for protection of the Government and shall release to the Contractor all the remaining withheld funds. Also, on completion and acceptance of each separate building, public work, or other division of the contract, for which the price is stated separately in the contract, payment shall be made for the completed work without retention of a percentage.

. All material and work covered by progress payments made shall, at the time of payment, become (f) Title, liability, and reservation of rights the sole property of the Government, but this shall not be construed as-

Relieving the Contractor from the sole responsibility for all material and work upon which payments have been made or the restoration (1) of any damaged work; or

Waiving the right of the Government to require the fulfillment of all of the terms of the contract.(2)

. In making these progress payments, the Government shall, upon request, reimburse the Contractor for (g) Reimbursement for bond premiums the amount of premiums paid for performance and payment bonds (including coinsurance and reinsurance agreements, when applicable) after the Contractor has furnished evidence of full payment to the surety. The retainage provisions in paragraph (e) of this clause shall not apply to that portion of progress payments attributable to bond premiums.

. The Government shall pay the amount due the Contractor under this contract after-(h) Final payment

Completion and acceptance of all work;(1)

Presentation of a properly executed voucher; and(2)

Presentation of release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that (3) the Contractor has specifically excepted from the operation of the release.