FA4528-18-R-0003.pdf

1) This acquisition is 100% WOSB Set-Aside

2) Magnitude: $500,000.00 - $1,000,000.00.

NOTE 1: The US Government intends to evaluate proposals and aw ard a contract w ithout discussions w ith offerors (except clarif ications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint.

NOTE 2: Notice to Offerors: Funds are not presently available for this effort. Please see section L for more information.

NOTE 3: For either the site visit, submission of proposals, or base access all personnel requesting access to Minot Air Force Base must possess a valid State or Government picture identif ication card. Furthermore, individuals presenting identif ication cards from a state that is non-compliant w ith the REAL ID Act w ill require additional documentation to gain unescorted base access. Additional documentation includes a valid U.S. or foreign government issued passport, an employment authorization document that contains a photograph, or identif ication cards issued by federal state or local government agencies that include a photo and biographic information. Additional information can be found at https://w w w .dhs.gov/current-status-states-territories.

RYAN J. NICHOLS 701-723-6935

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

18-Dec-2017

(RFP)

(IFB)

X

CALL:

Construct Sump Pump

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________150 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________17 Jan 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______260 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

5 CONS

165 MISSILE AVENUE

MINOT AFB ND 58705-5027

FA4528

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

QJVF 1007885

8. ADDRESS OFFER TO (If Other Than Item 7)

701-723-4173FAX:TEL: 701-723-2261 TEL: FAX:

FA452818R0003 37

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued)

(Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA452818R0003

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 4 Each Sump Pump SP-104

FFP

SERVICES NON-PERSONAL: The contractor will provide all plant , labor, material, tools, parts, equipment, and transportation to and from job site necessary to accomplish project QJVF 1007885 in accordance with attached specifications and drawings for sites: B-9, B-10, K-5, L-10.

The Period of Performance is 150 days after Notice to Proceed with one winter exclusion from 15 November 2018 to 15 April 2019. In accordance with 10 U.S.C.

§ 2805, this unspecified minor military construction project (including the option) may not exceed $1,000,000.00 due to appropriation restrictions.

FOB: Destination

NET AMT

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0002 1 Each OPTION Sump Pump SP-104 Option Site K-9

FFP

SERVICES NON-PERSONAL: The contractor will provide all plant , labor, material, tools, parts, equipment, and transportation to and from job site necessary to accomplish project QJVF 1007885 for only site K-9 in accordance with attached specifications and drawings.

The Period of Performance is 150 days after Notice to Proceed with one winter exclusion from 15 November 2018 to 15 April 2019. In accordance with 10 U.S.C.

§ 2805, this unspecified minor military construction project (including the option) may not exceed $1,000,000.00 due to appropriation restrictions.

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.236-5 Material and Workmanship APR 1984

52.246-12 Inspection of Construction AUG 1996

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 150 dys. ANP 4 5 CONS

RYAN J. NICHOLS

165 MISSILE AVENUE

MINOT AFB ND 58705-5027

701-723-6935

FA4528

0002 150 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

FA4528

52.211-13 Time Extensions SEP 2000

52.242-14 Suspension of Work APR 1984

CLAUSES INCORPORATED BY FULL TEXT

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

Section I - Contract Clauses

52.202-1 Definitions NOV 2013

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-7 Anti-Kickback Procedures MAY 2014

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement

To Inform Employees of Whistleblower Rights

APR 2014

52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.204-13 System for Award Management Maintenance OCT 2016

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.215-2 Audit and Records--Negotiation OCT 2010

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.219-8 Utilization of Small Business Concerns NOV 2016

52.219-14 Limitations On Subcontracting JAN 2017

52.219-30 Notice of Set-Aside for, or Sole Source Award to, Women-

Owned Small Business Concerns Eligible Under the Women-

Owned Small Business Program

DEC 2015

52.222-3 Convict Labor JUN 2003

52.222-6 Construction Wage Rate Requirements MAY 2014

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records MAY 2014

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014

52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity SEP 2016

52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-35 Equal Opportunity for Veterans OCT 2015

52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014

52.222-37 Employment Reports on Veterans FEB 2016

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015

52.222-54 Employment Eligibility Verification OCT 2015

52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015

52.223-1 Biobased Product Certification MAY 2012

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-6 Drug-Free Workplace MAY 2001

52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

JUN 2016

52.223-12 Maintenance, Service, Repair, or Disposal of Refrigeration

Equipment and Air Conditioners.

JUN 2016

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007

52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.223-20 Aerosols JUN 2016

52.223-21 Foams JUN 2016

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008

52.227-1 Authorization and Consent DEC 2007

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 Pledges Of Assets JAN 2012

52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014

52.228-14 Irrevocable Letter of Credit NOV 2014

52.228-15 Performance and Payment Bonds--Construction OCT 2010

52.229-3 Federal, State And Local Taxes FEB 2013

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-17 Interest MAY 2014

52.232-18 Availability Of Funds APR 1984

52.232-23 Assignment Of Claims MAY 2014

52.232-27 Prompt Payment for Construction Contracts JAN 2017

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

DEC 2013

52.233-1 Disputes MAY 2014

52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984

52.236-12 Cleaning Up APR 1984

52.236-13 Accident Prevention NOV 1991

52.236-14 Availability and Use of Utility Services APR 1984

52.236-15 Schedules for Construction Contracts APR 1984

52.236-21 Specifications and Drawings for Construction FEB 1997

52.236-21 Alt I Specifications and Drawings for Construction (Feb 1997) -

Alternate I

APR 1984

52.236-26 Preconstruction Conference FEB 1995

52.242-13 Bankruptcy JUL 1995

52.243-4 Changes JUN 2007

52.244-6 Subcontracts for Commercial Items JAN 2017

52.246-21 Warranty of Construction MAR 1994

52.248-3 Value Engineering-Construction OCT 2015

52.249-2 Alt I Termination for Convenience of the Government (Fixed-

Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984

52.253-1 Computer Generated Forms JAN 1991

252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense-

Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013

252.204-7003 Control Of Government Personnel Work Product APR 1992

252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation

Support

MAY 2016

252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of

Terrorism

OCT 2015

252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013

252.225-7012 Preference For Certain Domestic Commodities DEC 2016

252.225-7048 Export-Controlled Items JUN 2013

252.226-7001 Utilization of Indian Organizations and Indian-Owned

Economic Enterprises, and Native Hawaiian Small Business

Concerns

SEP 2004

252.227-7033 Rights in Shop Drawings APR 1966

252.232-7010 Levies on Contract Payments DEC 2006

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

252.242-7006 Accounting System Administration FEB 2012

252.243-7001 Pricing Of Contract Modifications DEC 1991

252.243-7002 Requests for Equitable Adjustment DEC 2012

252.244-7000 Subcontracts for Commercial Items JUN 2013

252.246-7004 Safety of Facilities, Infrastructure, and Equipment for

Military Operations

OCT 2010

252.247-7023 Transportation of Supplies by Sea APR 2014

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address:

https://farsite.hill.af.mil

(End of clause)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

See Section J

252.236-7006 COST LIMITATION (JAN 1997)

(a)Certain items in this solicitation are subject to statutory cost limitations. The limitations are stated in the

Schedule.

(b)An offer which does not state separate prices for the items identified in the Schedule as subject to a cost limitation may be considered nonresponsive.

(c)Prices stated in offers for items subject to cost limitations shall include an appropriate apportionment of all costs, direct and indirect, overhead, and profit.

(d) Offers may be rejected which--

(1)Are materially unbalanced for the purpose of bringing items within cost limitations; or

(2)Exceed the cost limitations, unless the limitations have been waived by the Government prior to award.

5352.201-9101 OMBUDSMAN (JUN 2016)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, AFICA/KG, 841 Fairchild Avenue, Building 5541, Room 327, Barksdale AFB, LA 71110, phone number (318)

456-6336, email address igafica_kg.workflow@us.af.mil. Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS)

(Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs) (NOV 2012)

(a) Contractors shall not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS as part of this contract/order.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

http://www.whitehouse.gov/omb/circulars_a076_a76_incl_tech_correction/ mailto:igafica_kg.workflow@us.af.mil

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

5352.223-9001 HEALTH AND SAFETY ON GOVERNMENT INSTALLATIONS (NOV 2012)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(2) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH)

Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (Nov 2012)

(a) The contractor shall obtain base identification and vehicle passes, if required, for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or Security Forces for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, and valid vehicle insurance certificate to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-209, The Air Force Resource Protection Program and AFI 31-501, Personnel Security Program

Management citing the appropriate paragraphs as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

Section J - List of Documents, Exhibits and Other Attachments

ATTACHMENTS

No. Title/Description Pages Date

1 Specifications 63 April 2017

2 Drawings 7 14 July 2017

3 Davis Bacon Wage Rates ND170015 11/10/2017

ND15

6 11/10/2017

4 Past Performance Information Form 4 N/A

5 Financial Responsibility Questionnaire 1 N/A

Attachments 1 – 5 are available on the Federal Business Opportunities (FBO) website.

Section K - Representations, Certifications and Other Statements of Offerors

52.203-11 Certification And Disclosure Regarding Payments To

Influence Certain Federal Transactions

SEP 2007

52.204-16 Commercial and Government Entity Code Reporting JUL 2016

52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.222-38 Compliance With Veterans' Employment Reporting

Requirements

FEB 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.203-7005 Representation Relating to Compensation of Former DoD

Officials

NOV 2011

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

52.203-18 PROHIBITION ON CONTRACTING WITH ENTITIES THAT REQUIRE CERTAIN INTERNAL

CONFIDENTIALITY AGREEMENTS OR STATEMENTS--REPRESENTATION (JAN 2017)

(a) Definition. As used in this provision--

Internal confidentiality agreement or statement, subcontract, and subcontractor, are defined in the clause at 52.203-

19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

(b) In accordance with section 743 of Division E, Title VII, of the Consolidated and Further Continuing

Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use funds appropriated (or otherwise made available) for contracts with an entity that requires employees or subcontractors of such entity seeking to report waste, fraud, or abuse to sign internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting such waste, fraud, or abuse to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information.

(c) The prohibition in paragraph (b) of this provision does not contravene requirements applicable to Standard Form

312, (Classified Information Nondisclosure Agreement), Form 4414 (Sensitive Compartmented Information

Nondisclosure Agreement), or any other form issued by a Federal department or agency governing the nondisclosure of classified information.

(d) Representation. By submission of its offer, the Offeror represents that it will not require its employees or subcontractors to sign or comply with internal confidentiality agreements or statements prohibiting or otherwise restricting such employees or subcontractors from lawfully reporting waste, fraud, or abuse related to the performance of a Government contract to a designated investigative or law enforcement representative of a Federal department or agency authorized to receive such information (e.g., agency Office of the Inspector General).

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2017)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 238220.

(2) The small business size standard is $15,000,000.00.

(3) The small business size standard for a concern which submits an offer in its own name, other than on a construction or service contract, but which proposes to furnish a product which it did not itself manufacture, is 500 employees.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7 is not included in this solicitation, and the offeror is currently registered in System for Award Management (SAM), and has completed the Representations and Certifications section of SAM electronically, the offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The offeror shall indicate which option applies by checking one of the following boxes:

( ) Paragraph (d) applies.

( ) Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or

Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at

52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.209-2; Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(vii) 52.209-5; Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(viii) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(ix) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(x) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xi) 52.219-1, Small Business Program Representations (Basic & Alternate I). This provision applies to solicitations when the contract will be performed in the United States or its outlying areas.

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(xii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract will be performed in the United States or its outlying areas.

(xiii) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xiv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial items.

(xvi) 52.222-57, Representation Regarding Compliance with Labor Laws (Executive Order 13673). This provision applies to solicitations expected to exceed $50 million which are issued from October 25, 2016 through April 24, 2017, and solicitations expected to exceed $500,000, which are issued after April 24, 2017.

Note to paragraph (c)(1)(xvi): By a court order issued on October 24, 2016, 52.222-57 is enjoined indefinitely as of the date of the order. The enjoined paragraph will become effective immediately if the court terminates the injunction. At that time, DoD, GSA, and NASA will publish a document in the Federal

Register advising the public of the termination of the injunction.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of USDA-designated items; or include the clause at 52.223-2, Affirmative Procurement of Biobased

Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the clause at 52.204-7.)

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American--Free Trade Agreements--Israeli Trade Act Certificate. (Basic, Alternates I, II, and

III.) This provision applies to solicitations containing the clause at 52.225- 3.

(A) If the acquisition value is less than $25,000, the basic provision applies.

(B) If the acquisition value is $25,000 or more but is less than $50,000, the provision with its Alternate I applies.

(C) If the acquisition value is $50,000 or more but is less than $77,533, the provision with its Alternate II applies.

(D) If the acquisition value is $77,533 or more but is less than $100,000, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at

52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for

Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Certification.

(vi) 52.223-9, with its Alternate I, Estimate of Percentage of Recovered Material Content for EPA-

Designated Products (Alternate I only).

(vii) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(viii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through https://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-2 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS--

REPRESENTATION (NOV 2015)

(a) Definitions. Inverted domestic corporation and subsidiary have the meaning given in the clause of this contract entitled Prohibition on Contracting with Inverted Domestic Corporations (52.209-10).

(b) Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with either an inverted domestic corporation, or a subsidiary of an inverted domestic corporation, unless the exception at 9.108-2(b) applies or the requirement is waived in accordance with the procedures at 9.108-4.

(c) Representation. The Offeror represents that--

(1) It [ ___ ] is, [ ___ ] is not an inverted domestic corporation; and

(2) It [ ___ ] is, [ ___ ] is not a subsidiary of an inverted domestic corporation.

52.209-5 CERTIFICATION REGARDING RESPONSIBILITY MATTERS (OCT 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that-

(i) The Offeror and/or any of its Principals-

(A) Are ( ) are not ( ) presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

https://www.acquisition.gov/

(B) Have ( ) have not ( ), within a three-year period preceding this offer, been convicted of or had a civil judgment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, attempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or

State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks “have”, the offeror shall also see 52.209-7, if included in this solicitation); and

(C) Are ( ) are not ( ) presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision.;

and

(D) Have , have not , within a three-year period preceding this offer, been notified of any delinquent

Federal taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial challenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced collection action is precluded.

(2) Examples. (i) The taxpayer has received a statutory notice of deficiency, under I.R.C. Sec. 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. Sec. 6320 entitling the taxpayer to request a hearing with the IRS Office of Appeals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the taxpayer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. Sec. 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collection action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has ( ) has not ( ), within a three-year period preceding this offer, had one or more contracts terminated for default by any Federal agency.

(2) Principal, for the purposes of this certification, means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to contract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in order to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and information of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certification, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian

Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a

Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than

$10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the

Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations

Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant…