FA448617Q0018.pdf

Any aw ard made as a result of this Solicitation shall be a Firm Fixed Price Contract, in accordance w ith FAR Subpart 16.2.

In accordance w ith FAR36.204(b), the magnitude of this project is betw een $25,000.00 and $100,000.00.

The aw ard shall be made to the offeror w ho is deemed resposible and w hose quote confoms to ALL solicitation requirements, to include all stated terms, conditions, representations, certif ications, and all other information required by Section L of this Solicitation. Offerors are advised to read the Quote Instructions carefully.

The evaluation of all quotes shall be conducted in accordance w ith the Evaluation Factors in Section M of this Solicitation.

Offerors shall consider the follow ing documents in their quote, since they shall become part of any aearded contract:

i. Specif ications (Attachment 1)

ii. Project Draw ings (Attachment 2)

iii. Submittal Register (Attachment 3) IV. Site Visit Reservation (Attachment 4)

TANIA A CARDOSO 351-295-571173

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

25-Aug-2017

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________90 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time ______________11 Sep 2017 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

65 CONF/LGCA

65TH CONTRACTING FLIGHT

APO AE 09720-7710

FA4486

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

03:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

011-351-295-573758FAX:TEL: 011-351-295-571468 TEL: FAX:

FA448617Q0018 21

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

FA448617Q0018

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Project Repair Floor T-605

FFP

The contractor shall furnish all labor, equipment, materials, transportation, supervision and any other necessary work to Repair Floor at T-605, Lajes Field, Azores, Portugal. All work shall be performed in accordance with the Specifications and Project Drawings.

FOB: Destination

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.236-5 Material and Workmanship APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. "Work" includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not--

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may (1) by contract or otherwise, replace or correct the work and charge the cost to the Contractor or (2) terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 90 dys. ANP 1 65 CES/CEOE - F2N33S

JOSE BARBOSA

BASE CIVIL ENGINEERING

BLDG T-570

APO AE 09720

535-3616 FOB: Destination

F2N33S

52.211-13 Time Extensions SEP 2000 52.242-14 Suspension of Work APR 1984

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 90 calendar days after issue of Notice to Proceed, including material acquisition.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $104.50 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section G - Contract Administration Data

252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Invoice

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

F2N33Q/FA4486

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC F78900 Issue By DoDAAC FA4486 Admin DoDAAC FA4486 Inspect By DoDAAC F2N33Q Service Acceptor (DoDAAC) FA4486

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

tania.cardoso.2.pt@us.af.mil 65CONF.LGC.ALL@us.af.mil

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

tania.cardoso.2.pt@us.af.mil 65CONF.LGC.ALL@us.af.mil

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

Section I - Contract Clauses

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-13 System for Award Management Maintenance OCT 2016 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.213-4 Terms and Conditions--Simplified Acquisitions (Other Than Commercial Items).

JAN 2017

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997 52.223-18 Encouraging Contractor Policies To Ban Text Messaging

While Driving

AUG 2011

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.243-5 Changes and Changed Conditions APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7003 Control Of Government Personnel Work Product APR 1992 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting

OCT 2016

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

MAY 2016

252.222-7002 Compliance With Local Labor Laws (Overseas) JUN 1997 252.223-7006 Prohibition On Storage, Treatment, and Disposal of Toxic or

Hazardous Materials

SEP 2014

252.223-7008 Prohibition of Hexavalent Chromium JUN 2013 252.225-7048 Export-Controlled Items JUN 2013 252.232-7010 Levies on Contract Payments DEC 2006 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.244-7000 Subcontracts for Commercial Items JUN 2013 252.247-7023 Transportation of Supplies by Sea APR 2014

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

NUMBER DRAWING TITLE

01 Situation Plan 02 Building Dimensions 03 Office Space Dimensions 04 Floor Areas to Repair 05 Floor Joints 06 Joints Detail 07 Floor Joints 08 Pictures

OMBUDSMAN (APR 2014)

(a) An ombudsman has been appointed to hear and facilitate the resolution of concerns from offerors, potential offerors, and others for this acquisition. When requested, the ombudsman will maintain strict confidentiality as to the source of the concern. The existence of the ombudsman does not affect the authority of the program manager, contracting officer, or source selection official. Further, the ombudsman does not participate in the evaluation of proposals, the source selection process, or the adjudication of protests or formal contract disputes. The ombudsman may refer the interested party to another official who can resolve the concern.

(b) Before consulting with an ombudsman, interested parties must first address their concerns, issues, disagreements, and/or recommendations to the contracting officer for resolution. Consulting an ombudsman does not alter or postpone the timelines for any other processes (e.g., agency level bid protests, GAO bid protests, requests for debriefings, employee-employer actions, contests of OMB Circular A-76 competition performance decisions).

(c) If resolution cannot be made by the contracting officer, the interested party may contact the ombudsman, Primary:

Mr. Douglas Guldan

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: douglas.guldan@us.af.mil Tel: DSN: (314)480-2209 Fax: (49)-6731-47-2025

Alternate:

Ms. Heidi Hoehn

AFICA/KU, UNIT 3103, APO, AE 09094-3103

AFICA/KU, Geb 404, Flugplatz Ramstein, 66877 Ramstein-Miesenbach, Germany E-mail: heidi.hoehn.de@us.af.mil Tel: DSN: (314)480-9330 Fax: (49)-6731-47-2025

Concerns, issues, disagreements, and recommendations that cannot be resolved at the Center/MAJCOM/DRU/HQ AFICA/AFISRA/SMC ombudsman level, may be brought by the interested party for further consideration to the Air Force ombudsman, Associate Deputy Assistant Secretary (ADAS) (Contracting), SAF/AQC, 1060 Air Force Pentagon, Washington DC 20330-1060, phone number (571) 256-2395, facsimile number (571) 256-2431.

(d) The ombudsman has no authority to render a decision that binds the agency.

(e) Do not contact the ombudsman to request copies of the solicitation, verify offer due date, or clarify technical requirements. Such inquiries shall be directed to the Contracting Officer.

5352.223-9000 ELIMINATION OF USE OF CLASS I OZONE DEPLETING SUBSTANCES (ODSs) (APR 2003)

(a) Unless the requiring activity has obtained prior Senior Acquisition Official (SAO) approval, contractors may not:

(1) Provide any service or product with any specification, standard, drawing, or other document that requires the use of a Class I ODS in the test, operation, or maintenance of any system, subsystem, item, component, or process; or

(2) Provide any specification, standard, drawing, or other document that establishes a test, operation, or maintenance requirement that can only be met by use of a Class I ODS.

[Note: This prohibition does not apply to manufacturing.]

(b) For the purposes of Air Force policy, the following products that are pure (i.e., they meet the relevant product specification identified in AFI 32-7086) are Class I ODSs:

(1) Halons: 1011, 1202, 1211, 1301, and 2402;

(2) Chlorofluorocarbons (CFCs): CFC-11, CFC-12, CFC-13, CFC-111, CFC-112, CFC-113, CFC-114, CFC-115, CFC-211, CFC-212, CFC-213, CFC-214, CFC-215, CFC-216, and CFC-217, and the blends R-500, R-501, R-502, and R-503; and

(3) Carbon Tetrachloride, Methyl Chloroform, and Methyl Bromide.

[NOTE: Material that uses one or more of these Class I ODSs as minor constituents do not meet the Air Force definition of a Class I ODS.]

(c) The requiring activity has obtained SAO approval to permit the contractor to use the following Class I ODS(s):

Class I ODS/ Application or Use/Quantity (lbs.) per contract period of performance

(d) The offeror/contractor is required to notify the contracting officer if any Class I ODS that is not specifically listed above is required in the test, operation, or maintenance of any system, subsystem, item, component, or process.

5352.223-9001 HEALTH AND SAFETY ON GOVERNMENT INSTALLATIONS (JUN 1997)

(a) In performing work under this contract on a Government installation, the contractor shall:

(1) Comply with the specific health and safety requirements established by this contract;

(2) Comply with the health and safety rules of the Government installation that concern related activities not directly addressed in this contract;

(3) Take all reasonable steps and precautions to prevent accidents and preserve the health and safety of contractor and Government personnel performing or in any way coming in contact with the performance of this contract; and

(4) Take such additional immediate precautions as the contracting officer may reasonably require for health and safety purposes.

(b) The contracting officer may, by written order, direct Air Force Occupational Safety and Health (AFOSH) Standards and/or health/safety standards as may be required in the performance of this contract and any adjustments resulting from such direction will be in accordance with the Changes clause of this contract.

(c) Any violation of these health and safety rules and requirements, unless promptly corrected as directed by the contracting officer, shall be grounds for termination of this contract in accordance with the Default clause of this contract.

5352.242-9000 CONTRACTOR ACCESS TO AIR FORCE INSTALLATIONS (JUN 2002)

(a) The contractor shall obtain base identification and vehicle passes for all contractor personnel who make frequent visits to or perform work on the Air Force installation(s) cited in the contract. Contractor personnel are required to wear or prominently display installation identification badges or contractor-furnished, contractor identification badges while visiting or performing work on the installation.

(b) The contractor shall submit a written request on company letterhead to the contracting officer listing the following: contract number, location of work site, start and stop dates, and names of employees and subcontractor employees needing access to the base. The letter will also specify the individual(s) authorized to sign for a request for base identification credentials or vehicle passes. The contracting officer will endorse the request and forward it to the issuing base pass and registration office or security police for processing. When reporting to the registration office, the authorized contractor individual(s) should provide a valid driver’s license, current vehicle registration, valid vehicle insurance certificate, and “imposto de circulacao” to obtain a vehicle pass.

(c) During performance of the contract, the contractor shall be responsible for obtaining required identification for newly assigned personnel and for prompt return of credentials and vehicle passes for any employee who no longer requires access to the work site.

(d) When work under this contract requires unescorted entry to controlled or restricted areas, the contractor shall comply with AFI 31-101, Volume 1, The Air Force Installation Security Program, and AFI 31-501, Personnel Security Program Management, as applicable.

(e) Upon completion or termination of the contract or expiration of the identification passes, the prime contractor shall ensure that all base identification passes issued to employees and subcontractor employees are returned to the issuing office.

(f) Failure to comply with these requirements may result in withholding of final payment.

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

ATTACHMENT

NUMBER

TITLE OF ATTACHMENT NUMBER OF PAGES

1 Specifications 69 2 Project Drawings 8 3 Submittal Register 1 4 Site Visit Reservation Form 2

Section K - Representations, Certifications and Other Statements of Offerors

52.203-18 Prohibition on Contracting With Entities That Require Certain

Internal Confidentiality Agreements or Statements-- Representation

JAN 2017

52.204-8 Annual Representations and Certifications JAN 2017 52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-2 Prohibition on Contracting with Inverted Domestic Corporations--Representation

NOV 2015

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under and Federal Law

FEB 2016

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

252.203-7005 Representation Relating to Compensation of Former DoD Officials

NOV 2011

252.225-7031 Secondary Arab Boycott Of Israel JUN 2005

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

Section L - Instructions, Conditions and Notices to Bidders

52.204-7 System for Award Management OCT 2016

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for 31 August 2017, 09:00h, local time.

(c) Interested participants shall meet at 65th Contracting Flight, building T-615, and complete the Site Visit Reservation Form (Attachment 4) in accordance with the instructions.

(End of provision)

QUOTE INSTRUCTIONS

A. To assure timely and equitable evaluation of quotes, offerors must follow the instructions contained herein. Offerors are required to meet all solicitation requirements, including terms and conditions, representations and certifications, and technical requirements. Failure to meet a requirement may result in a quote being ineligible for award. Offerors must clearly identify any exception to the solicitation terms and conditions and provide complete accompanying rationale. The response shall consist of two (2) separate parts: Part I – Price Quotation and Part II – Alvara Certification.

B. The Government intends to award one (1) Firm-Fixed Price Contract, in accordance with FAR Subpart

16.2. In accordance with FAR 36.204(b), the magnitude of this project is between $25,000.00 and $100,000.00.

C. SPECIFIC INSTRUCTIONS

1. PART I – PRICE QUOTATION

(a) Complete blocks 14 through 20C of Section A in the Standard Form (SF) 1442. In doing so, the offeror assents to the contract terms and conditions as written in the Sections A through K. These sections constitute the model contract.

(b) Insert proposed unit and extended prices in Section B for each Contract Line Item Number

(CLIN).

(c) Complete the necessary fill-ins and certifications in Sections I through K. Section K shall be returned in its entirety. For Sections F through J, the offeror shall submit only those pages that require a fill-in.

2. PART II – ALVARA CERTIFICATION

(a) CRITERIA: Offeror shall furnish their Alvara Certification.

D. GENERAL INFORMATION

1. A site visit will be conducted on 31 August 2017 at 9:00h local time. Interested offerors should be at Building T-615 (65th Contracting Flight) by this time to proceed to the project site. Late arrival will disqualify the offeror from attending the pre-proposal site visit. Only one site visit will be conducted.

Offerors that wish to take part in the site visit shall submit the Site Visit Reservation Form (Attachment 4) no later than 30 August 2017 at 9:00h local time.

2. All contractor’s questions regarding this solicitation must be emailed to tania.cardoso.2.pt@us.af.mil and 65CONF.LGC.ALL@us.af.mil no later than 4 September 2017. The US Government will not be held responsible for answering any questions after this time. The answers to the questions received shall be disseminated in the same manner this Solicitation was.

3. The quote must be completed and returned no later than 11 September 2017 at 15:00h local time. If submitting by e-mail, only submit one copy and the maximum size of email shall not exceed 8MB.

If the offeror chooses to mail the quote via postal services, the Government will not be responsible for any non-receipt of the quote, or any failure of the offeror to verify receipt of the mailed offer.

The mailing addresses are as follows:

Commercial:

Seccao de Contratos, Base Aerea No. 4 Attn: Tania Cardoso (or 65 CONF/LGCA) Avenida do Imperio, Edf. T-615 Terceira, Azores, Portugal 9760-277

US Postal:

65th Contracting Flight Attn: Ana Areias (or 65 CONF/LGCA) Bldg. T-615, Rm. 203

APO AE 09720-7775

4. The quote may also be delivered at the 65 Contracting Flight, Building T-615, room 203. Offerors should allow sufficient time to arrive and submit the proposals to Contracting Flight prior to the set closing time. Late quotes will be processed in accordance with FAR 15.208 “Late Submission, Modifications, and Withdrawals of Proposals”. If a gate access is not granted, please contact the Flight immediately. The contractors are responsible for coordinating and processing gate pass requests in a timely manner. The Government shall not be responsible for any delays due to in-processing or out-processing the base

5. If there are any amendments to this Solicitation, the offerors must acknowledgement of all and return in accordance with the instructions on the SF 30.

6. Notice to Offerors: Funds are not presently available for this effort. Therefore, offerors must ensure their proposal is valid until 30 September 2017. No award will be made under this solicitation until funds are available. The Government reserves the right to cancel this solicitation, either before or after the closing date. In the event the Government cancels this solicitation, the Government has no obligation to reimburse an offeror for any costs.

Section M - Evaluation Factors for Award

EVALUATION FACTORS

1. The 65th Contracting Flight is issuing this Solicitation FA448617Q0018 as a Request for Quote (RFQ) using Federal Acquisition Regulation (FAR) FAR Part 13, Simplified Acquisition Procedures. This is supplemented by the Defense Federal Acquisition Regulation Supplement (DFARS), and the Air Force Federal Acquisition Regulation Supplement (AFFARS) These regulations are available electronically at http://farsite.hill.af.mil.

The Government will select the quote with the lowest evaluated price from among those with an acceptable Alvara Certification and that conforms to all the solicitation’s requirements (to include all stated terms, conditions, representations, certifications, and all other information required by Section L).

2. The Government intends to award one (1) Firm-Fixed Price contract to Repair Floor at T-605, Project

MQNA 17-1010.

3. Exchanges: The Government intends to make the award without conducting exchanges with any offerors.

Nevertheless, the Government reserves the right to conduct interchanges with some, all or none of the offerors.

4. Evaluation Factors: The following evaluation factors will be used to evaluate each quote received in a timely manner.

FACTOR 1 – PRICE QUOTATION

All offerors must insert quote unit and extended prices in Section B of the Standard Form (SF) 1442 for each Contract Line Item Number (CLIN). All offerors must quote on all line items in Section B of the SF 1442.

The offeror’s price will be evaluated in accordance with FAR 13.106-2, Evaluations of Quotations or Offers.

FACTOR 2 – ALVARA CERTIFICATION

The Government shall evaluate the Alvara Certification on an acceptable or unacceptable basis, assigning one of the ratings described below in accordance with the measure of merit described.

TABLE 1 - TECHNICAL RATINGS

Rating Description

ACCEPTABLE Alvara Certification clearly meets the minimum requirements of the solicitation.

UNACCEPTABLE Alvara Certification does not clearly meet the minimum requirements of the solicitation.

(a) CRITERIA: Offeror shall furnish their Alvara Certification.

(b) MEASURE OF MERIT: This requirement is met if the Alvara Certification is provided attesting that the offeror can conduct business in the country of Portugal using the scope and magnitude of this requirement.

5. Award Process: The Government intends to award to the lowest priced quote with an acceptable Alvara

Certification. The evaluation process will go as follows:

(a) The Government will evaluate all quotes for price, ranking from lowest to highest.

(b) The lowest priced quote will then have their Alvara Certification evaluated. The Alvara must be rated

“acceptable” in order to be considered for award.

(c) If the Alvara of the lowest priced quote is measured “unacceptable”, the second lowest one will be evaluated. This shall continue until an Alvara with an “acceptable” rating is identified.