Solicitation_-_FA441819RA022.pdf

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION

CALL:

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory negotiable. (See ).

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

b. An offer guarantee is, is not required.

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

STANDARD FORM 1442 (REV. 8/2014)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

12b. CALENDAR DAYS

YES NO

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

AMOUNTS

OFFER (Must be fully completed by offeror)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

21. ITEMS ACCEPTED:

AWARD (To be completed by Government)

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA

BY

31c. DATE

STANDARD FORM 1442 (REV. 8/2014) BACK

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 3304(a) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

FA441819RA022

Section A - Solicitation/Contract Form

Section B - Supplies or Services and Prices/Cost

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

0001 BASE BID: All work as required by drawings and specifications for Project DKFX 04-10607 Repair Base Water Lines & Hydrants. This project consists of replacement of approximately 2,000 linear feet of potable water mains (material unknown) to include new valves, fittings, service connections, and four (4) fire hydrants at Joint Base Charleston - Air Base. Install two (2) new fire hydrants near building 690 and 1001. The portion of work at Building 1001 will require approximately 390 linear feet of new potable water main to provide connection to new fire hydrant.

Manufacturer's Part Number: Null Product Service Code: Z2LC Firm Fixed Price

CIN: 00000000000004303269

1.0 Job

0002 BID OPTION - Provide asbestos pipe removal of 10 linear feet including but not limited to containment of hazardous waste and disposal Firm Fixed Price

1.0 Job

Section C - Description/Specifications/Statement of Work

Attachment Description Date Pages

Specifications 12 October 2018 283

Drawings 10 October 2018 21

CLAUSES INCORPORATED IN FULL TEXT

PERFORMANCE AND PAYMENT BOND REQUIREMENTS

(IAW FAR 28.101-2 and FAR 28.102-3)

PROPOSAL BOND: The offeror shall submit a Proposal Bond (Standard Form 24) with good and sufficient surety or sureties acceptable to the Government. Proposal Bond in the amount of 20 percent (20%) of the proposal price. The Proposal Bond penalty may be expressed in terms of a percentage of the proposal price or may be expressed in dollars and cents.

The contractor shall submit a Performance Bond (Standard Form 25) and a Payment Bond (Standard Form 25-A) with good and sufficient surety and sureties to the Government within 15 days of award. The penal sum of such bonds will be as follows:

a. PERFORMANCE BOND: The penal sum of the performance bonds shall equal one hundred percent (100%) of the contract price.

b. PAYMENT BOND: The penal sum of the payment bonds shall equal one hundred percent (100%) of the contract price.

BUSINESS LICENSE TAX - SOUTH CAROLINA

In accordance with Contract Clause entitled, "Federal, State and Local Taxes" dated APR 2003/FAR 52.229-3 incorporated by reference, be advised that the Cities of North Charleston, South Carolina and/or Goose Creek South Carolina imposes a business license tax on all contract work within the cities of North Charleston, South Carolina and/or Goose Creek South Carolina. The cities interpret this to include contractors performing work for the United States government within the limits of North Charleston and/or Goose Creek. Joint Base Charleston - Air Base is included within the City of North Charleston, South Carolina and Joint Base Charleston - Weapons Station is included within the city limits of Goose Creek. The cost of the license is proportional to the dollar amount of work being executed. Information for the North Charleston City Tax may be obtained by calling 843-740-2632 and for the Goose Creek City Tax by calling 843-797-6220.

PKI CERTIFICATE FOR PAST PERFORMANCE EVALUATION

Past Performance Evaluations are required on all completed DoD construction contracts. These evaluations are used in past performance evaluations conducted on your future proposals. The evaluations are placed in a computer database called Contractor Performance Assessment Report System (CPARS). This system requires the contractor to include their comments in their evaluation. In order to access the system, it is required that you obtain a PKI (Public Key Infrastructure) certificate. A PKI certificate is software which is purchased from an approved commercial vendor and installed on your computer. Approved vendors are listed at https://www.cpars.csd.disa.mil/main/pki_info.htm under the heading "Approved ECA Vendors". You will be required to purchase an "Identity Certificate" to access CPARS system or the Past Performance Information Report System (PPIRS), which will contain all past performance evaluations for your firm for any DoD contracts.

The average cost for a PKI certificate is about $100 - $120 per certificate, per year.

REQUIRED INSURANCE (IAW FAR 28.306 (b)) Reference FAR clause 52.228-5 entitled "Insurance..." the Contractor shall, as its own expense, procure and thereafter maintain the following kinds of insurance with respect to performance under the contract.

a. Workman's Compensation and Employers Liability Insurance as required by law except that if this contract is to be performed in a state which does not require or permit private insurance, then compliance with the statutory or administrative requirements in any such state will be satisfactory. The required Workman's Compensation Insurance shall extend to cover employer's liability for accidental bodily injury or death and for occupational disease with a minimum liability of $100,000.

b. General Liability Insurance. Bodily injury liability insurance, in the minimum limits of $500,000 per occurrence shall be required on the comprehensive form of policy.

c. Automobile Liability Insurance. The insurance shall be required on the comprehensive form of policy and shall provide bodily liability injury and property damage liability covering the operation of all automobiles used in connection with the performance of this contract. At least the minimum amount of $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage shall be required.

CONTRACTOR CONSENT TO BACKGROUND CHECKS

The contractor and, as applicable, subcontractor shall not employ persons for work on this contract if such employee is identified as a potential threat to the health, safety, security, general well-being or operational mission of the installation and its population, nor shall the contractor or subcontractor employ persons under this contract who have an outstanding criminal warrant, are currently on probation or parole, or are on the state/national Sex Offender Register as identified by south Carolina Law Enforcement Division (SLED)/National Crime Information Center (NCIC). All contractor and subcontractor personnel must consent to NCIC criminal history background checks. Contractor and subcontractor personnel who do not consent to an NCIC check will be denied access to the installation. Information required to conduct an NCIC check includes: full name, driver's license number, social security number, date of birth of the person entering the installation. The contractor shall provide this information using the 628 SFS/CSF JB CH-AB/WS Contract Security Worksheet for Base Access, "Application for Personnel to Work under Department of Defense Contract at Joint Base Charleston", and shall submit it in conjunction with the contractor's request for either base or vehicle passes. Completion of a successful NCIC check does not invalidate the requirement for an escort when contractor or subcontractor personnel are working within controlled or restricted areas. Contractors shall ensure their employees and those of their subcontracts have the proper credentials allowing them to work in the United States. Persons later found to be undocumented or illegal aliens will be remanded to the proper authorities.

The contractor shall not be entitled to any compensation for delays or expenses associated with complying with the provisions of this provision. Furthermore, nothing in this provision shall excuse the contractor from proceeding with the contract as required.

Badges - Contractors and subcontractors shall submit the completed and approved JB CH-AB/WS Contract Security Worksheet for Base Access, "Application for Personnel to Work under Department of Defense Contract at Joint Base Charleston" prior to planning to work. Upon completion of the background check, the employee will report to the installation entry control center, with a photo identification issued by a Federal/State activity, for receipt of a badge with a designation of the area of the base he will be allowed access. Badges will be worn in a visible manner to government personnel at all times.

At the conclusion of work for the prime contractor and any subcontractor, all badges will be turned in to the entry control center.

Contractor Registration of Vehicles on Joint Base Charleston - All contractor or contractor employees' vehicles used for the performance of this contract shall comply with all local, state and federal regulations. To register a privately owned/ commercial vehicle and obtain a vehicle pass, contractor personnel shall provide a valid driver's license, current vehicle registration, and valid vehicle insurance certificate. Additionally, any pass shall be surrendered to Security Forces upon demand to positively identify a person's need to be on Joint Base Charleston.

Access to Installation during Force Protection Conditions (FPCONs) - Contractors will be assigned a mission essential designation IAW requirements contained in CAFBI 31-101, Installation Security Instruction. Only the installation commander or the unit commander requesting contract support will assign the mission essential designation.

Contractors Working in Controlled or Restricted Areas - The unit requesting contract support will provide escort (s) for contractors' at all times when within a controlled area. Contractors shall not escort other contractor employees within controlled or restricted areas. In addition, contractors shall fulfill, maintain, and comply with all security requirements IAW AFI 31-101, The Air Force Installation Security Program, and command/local directives.

Contractors Responsibilities while Working within Controlled or Restricted Areas - Only contractor personnel with proper authority and qualifications shall enter a controlled or restricted area. Certain facilities require the issuance of an AF Form 1199 or AF Form 1199CD. The government, at any time, may revoke the AF Form 1199. The procedures for the issuance of an AF Form 1199CD are contained in JBCIDP 31-1, Installation Security Instruction. Contractors shall not escort other contractor employees within controlled or restricted areas. In addition, contractors shall fulfill, maintain, and comply with all security requirements contained in JBCIDP 31-1, Installation Security Instruction.

Access to Government Facilities with Controlled or Restricted Areas - The contractor shall comply with security regulations imposed by the installation commander and/or the agency responsible for the project location. Due to specific mission requirements inherent in the nature of controlled or restricted areas on Joint Base Charleston, the government may direct the contractor to leave the controlled or restricted areas at any given time.

FORCE PROTECTION CONDITIONS

Force Protection Conditions (FPCON) are implemented on the base to increase protective measures in anticipation of, or in response to, the threat of terrorist attack. The DoD FPCON consists of five progressive levels of increasing protective measures. The circumstances that apply and the purposes of each protective posture are as follows:

- FPCON NORMAL: Applies when a general global threat of possible terrorist activity exists and warrants a routine security posture. At a minimum, access control will be conducted at all DoD installations and facilities.

- FPCON ALPHA: Applies when there is an increased general threat of possible terrorist activity against personnel or facilities, and the nature and extent of the threat are unpredictable. ALPHA measures must be capable of being maintained indefinitely.

- FPCON BRAVO: Applies when an increased or more predictable threat of terrorist activity exists. Sustaining BRAVO measures for a prolonged period may affect operational capability and military-civil relationships with local authorities.

- FPCON CHARLIE: Applies when an incident occurs or intelligence is received indicating some form of terrorist action or targeting against personnel or facilities is likely. Prolonged implementation of CHARLIE measures may create hardship and affect the activities of the unit and its personnel.

- FPCON DELTA: Applies in the immediate area where a terrorist attack has occurred or when intelligence has been received that terrorist action against a specific location or person is imminent. This FPCON is usually declared as a localized condition.

FPCON DELTA measures are not intended to be sustained for an extended duration.

GREEN PROCUREMENT

The Green Procurement Program (GPP) is a mandatory federal acquisition program that focuses on the purchase and use of environmentally preferable products and services. Many different items are covered by the GPP. Recycled-content products are designated by the Environmental Protection Agency (EPA). "Biobased" products made from renewable plant materials are designated by the Department of Agriculture (USDA). Energy and water efficient products are designated by the Department of Energy (DOE). GPP also requires us to avoid purchasing Ozone Depleting Substances (ODS) and EPA-designated Priority Chemicals. Environmentally preferable purchasing (EPP) is a voluntary program, and it encourages the purchase of goods and services that have decreased effects on human health and the environment (compared to the competing goods and serve the same purpose), but are not already required by one of the mandatory GPP elements.

The Environmental Protection Agency (EPA) promulgates this product information via the Federal Register and the World Wide Web/Internet http://www.epa.gov/cpg/products/htm. Green Procurement is mandated, except when the Contractor can show that the product with recycled content does not meet intended specifications, has excessive cost, or cannot be delivered in time to support the schedule of the contract. If the Contractor is unable to locate a specified product meeting the GPP requirement, identify the issue to the Contracting Officer's Technical Representative for guidance. GPP is based on legal requirements and the Department of Defense facilities are subject to enforcement action if these requirements are ignored.

(End Section C)

Requirements This project consists of replacement of approximately 2,000 linear feet of potable water mains (material unknown) to include new valves, fittings, service connections, and four (4) fire hydrants at Joint Base Charleston (Air Base). Install two (2) new fire hydrants near building 690 and 1001. The portion of work at Building 1001 will require approximately 390 linear feet of new potable water main to provide connection to new fire hydrant.

Section D - Packaging and Marking

Section E - Inspection and Acceptance

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.246-12 Inspection of Construction. 1996-08 0001 Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1M3E2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

437 CES CECC

100 W STEWART AVE BLDG 661 RM 101

AF BPN NO MILSBILLS PROCESSES

CHARLESTON AFB, SC 29404 4827

United States

OfficeCode:

Howard Reeder Email: howard.reeder.1@us.af.mil Telephone: 843-963-1457

0002 Inspection and Acceptance Location

Both Destination Instructions: None

DoDAAC: F1M3E2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

437 CES CECC

100 W STEWART AVE BLDG 661 RM 101

AF BPN NO MILSBILLS PROCESSES

CHARLESTON AFB, SC 29404 4827

United States

OfficeCode:

Howard Reeder Email: howard.reeder.1@us.af.mil Telephone: 843-963-1457

Section F - Deliveries or Performance

0001 Delivery Schedule Ship To Address

Delivery Schedule From date of lead time event to completion of performance 123 Calendar Days Date of Notice to Proceed Receipt

Ship To

DoDAAC: F1M3E2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

437 CES CECC

100 W STEWART AVE BLDG 661 RM 101

AF BPN NO MILSBILLS PROCESSES

CHARLESTON AFB, SC 29404 4827

United States

OfficeCode:

Howard Reeder Telephone: 843-963-1457 Email: howard.reeder.1@us.af.mil

0002 Delivery Schedule Ship To Address

Delivery Schedule From date of lead time event to completion of performance 123 Calendar Days Date of Notice to Proceed Receipt

Ship To

DoDAAC: F1M3E2 Cage:

DunsNumber:

Duns4Number:

CountryCode: USA

437 CES CECC

100 W STEWART AVE BLDG 661 RM 101

AF BPN NO MILSBILLS PROCESSES

CHARLESTON AFB, SC 29404 4827

United States

OfficeCode:

Howard Reeder Telephone: 843-963-1457 Email: howard.reeder.1@us.af.mil

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.242-15 Stop-Work Order. 1989-08

FAR Clauses Incorporated by Full Text

52.211-10 Commencement, Prosecution, and Completion of Work. 1984-04 As prescribed in 11.404(b), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate the issuance of orders under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (Apr 1984) The Contractor shall be required to (a)commence work under this contract within __10__ [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b)prosecute the work diligently, and (c)complete the entire work ready for use not later than __87 calendar__.* The time stated for completion shall include final cleanup of the premises. * The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

Section G - Contract Administration Data

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.201-7000 Contracting Officer's Representative 1991-12 252.232-7003 Electronic Submission of Payment Requests and Receiving Reports. 2018-12 252.236-7000 Modification Proposals--Price Breakdown 1991-12

DFARS Clauses Incorporated by Full Text

252.232-7006 Wide Area WorkFlow Payment Instructions. 2018-12 As prescribed in 232.7004(b), use the following clause: WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)

(a) Definitions. As used in this clause- Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization. Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF). Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system. Payment request and receiving report are defined in the clause at 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (b) Electronic invoicing. The WAWF system provides the method to electronically process vendor payment requests and receiving reports, as authorized by Defense Federal Acquisition Regulation Supplement (DFARS) 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports. (c) WAWF access. To access WAWF, the Contractor shall- (1) Have a designated electronic business point of contact in the System for Award Management at https://www.sam.gov; and (2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this web site. (d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the Web Based Training link on the WAWF home page at https://wawf.eb.mil/ (e) WAWF methods of document submission.

Document submissions may be via web entry, Electronic Data Interchange, or File Transfer Protocol. (f) WAWF payment instructions. The Contractor shall use the following information when submitting payment requests and receiving reports in WAWF for this contract or task or delivery order: (1) Document type. The Contractor shall submit payment requests using the following document type(s): (i) For cost-type line items, including labor-hour or time-and-materials, submit a cost voucher.

(ii) For fixed price line items (A) That require shipment of a deliverable, submit the invoice and receiving report specified by the Contracting Officer. ____ (Contracting Officer: Insert applicable invoice and receiving report document type(s) for fixed price line items that require shipment of a deliverable.) (B) For services that do not require shipment of a deliverable, submit either the Invoice 2in1, which meets the requirements for the invoice and receiving report, or the applicable invoice and receiving report, as specified by the Contracting Officer. __COMBO__ (Contracting Officer: Insert either Invoice 2in1 or the applicable invoice and receiving report document type(s) for fixed price line items for services.) (iii) For customary progress payments based on costs incurred, submit a progress payment request. (iv) For performance based payments, submit a performance based payment request. (v) For commercial item financing, submit a commercial item financing request. (2) ) Fast Pay requests are only permitted when Federal Acquisition Regulation (FAR) 52.213-1 is included in the contract. (f) [Note: The Contractor may use a WAWF combo document type to create some combinations of invoice and receiving report in one step.] (3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system. Routing Data Table* | Field Name in WAWF || Data to be entered in WAWF || Pay Official DoDAAC || __F87700__ || Issue By DoDAAC || __FA4418__ || Admin DoDAAC || __FA4418__ || Inspect By DoDAAC || __F1M3E2__ || Ship To Code || __F1M3E2__ || Ship From Code || __N/A__ || Mark For Code || __N/A__ || Service Approver (DoDAAC) || __N/A__ || Service Acceptor (DoDAAC) || __F1M3E2__ || Accept at Other DoDAAC || __N/A__ || LPO DoDAAC || __N/A__ || DCAA Auditor DoDAAC || __N/A__ || Other DoDAAC(s) || __N/A__ | (*Contracting Officer: Insert applicable DoDAAC information. If multiple ship to/acceptance locations apply, insert See Schedule or Not applicable.) (**Contracting Officer: If the contract provides for progress payments or performance-based payments, insert the DoDAAC for the contract administration office assigned the functions under FAR 42.302(a)(13).) (4) Payment request. The Contractor shall ensure a payment request includes documentation appropriate to the type of payment request in accordance with the payment clause, contract financing clause, or Federal Acquisition Regulation 52.216-7, Allowable Cost and Payment, as applicable. (5) Receiving report. The Contractor shall ensure a receiving report meets the requirements of DFARS Appendix F. (g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activitys WAWF point of contact. __Mike Mesko, michael.mesko@us.af.mil__ (Contracting Officer: Insert applicable information or Not applicable.) (2) Contact the WAWF helpdesk at 866-618-5988, if assistance is needed. (End of clause)

Section H - Special Contract Requirements

SPECIAL INFORMATION AND INSTRUCTIONS TO ALL INTERESTED CONTRACTORS:

IT SHALL BE THE RESPONSIBILITY OF THE CONTRACTOR TO ENSURE THEY CHECK THE WWW.FBO.GOV WEB SITE FOR ANY AMENDMENTS TO THE SOLICITATION. YOU ARE ENCOURAGED TO REGISTER ON THE WWW.FBO.GOV WEB SITE TO RECEIVE NOTIFICATION OF CHANGES TO THE SOLICITATION. FAILURE TO

ACKNOWLEDGE AMENDMENTS MAY RENDER YOUR PROPOSAL NONRESPONSIVE.

1. The following items represent the "Offer", or proposal package, that should be returned in response to this solicitation (See Section L & M of the solicitation):

a. SF 1442, Solicitation, Offer, and Award

b. The Schedule, Section B

c. Complete the necessary fill-ins and certifications in Sections I through K. Section K shall be returned in its entirety. For Section I, the offeror shall submit only those pages that require a fill-in.

d. Sub-contracting Plan (if required)

e. Past Performance Information

f. SF 30, Amendment of Solicitation/Modification of Contract (applicable if amendments are not acknowledged on page 2 (reverse) of SF 1442)

g. Standard Form 24, Proposal Bond

2. PRE-PROPOSAL CONFERENCE/SITE VISIT:

a. A pre-proposal conference and site visit is scheduled for 16 April 2019 at 9:00 AM. The conference/site visit will be conducted at Joint Base Charleston-Air Base, Charleston, SC. Meet 30 minutes prior at 8:30 AM at the Air Base Visitor Control Center, 102 E Hill Blvd, Charleston, SC 29404. Bus transportation will be provided from the Visitor Control Center to meeting location, during site visit traveling to project site, and returning to Visitor Control Center at conference/site visit conclusion. Offerors are encouraged to attend and are requested to contact Denise Hinojosa, Contract Specialist, at (843) 963-5175, or e-mail at denise.hinojosa@us.af.mil at least three (3) days prior to the conference date if they plan to attend.

Special arrangements will be required to gain access to Joint Base Charleston, SC. Offerors are cautioned that Joint Base Charleston has visitor control procedures requiring individuals not affiliated with the installation to obtain a visitor pass prior to entrance. SOME DELAYS SHOULD BE ANTICIPATED. Offerors should allow sufficient time to obtain a visitor pass (requiring valid driver's license, vehicle registration, and current proof of insurance).

b. The purpose of this conference is to visit the construction site, clarify the statement of work and terms of the solicitation, and to answer any questions concerning the solicitation. Offerors are requested to prepare all questions in writing prior to the scheduled date of the conference. Submission of questions prior to the conference is encouraged.

The deadline for all questions pertaining to this solictation will 22 April 2019 at 2:00PM EST

c. Remarks and explanations provided at the conference shall NOT qualify the terms of the solicitation and statement of work. Unless the solicitation is amended in writing, it will remain unchanged. Should an amendment be issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

(End Section H)

Section I - Contract Clauses

FAR Clauses Incorporated by Reference

Number Title Effective Date 52.202-1 Definitions. 2013-11 52.203-5 Covenant Against Contingent Fees. 2014-05 52.203-6 Restrictions on Subcontractor Sales to the Government. 2006-09 52.203-7 Anti-Kickback Procedures. 2014-05 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper

Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. 2014-05 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. 2010-10 52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform

Employees of Whistleblower Rights.

2014-04

52.203-18 Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation.

2017-01

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper.2011-05 52.204-9 Personal Identity Verification of Contractor Personnel. 2011-01 52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. 2018-10 52.204-13 System for Award Management Maintenance. 2018-10 52.204-18 Commercial and Government Entity Code Maintenance. 2016-07 52.204-19 Incorporation by Reference of Representations and Certifications. 2014-12 52.204-22 Alternative Line Item Proposal. 2017-01 52.204-23 Prohibition on Contracting for Hardware, Software, and Services

Developed or Provided by Kaspersky Lab and Other Covered Entities.

2018-07

52.209-6 Protecting the Government's Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment.

2015-10

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. 2015-11 52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a

Felony Conviction under any Federal Law.

2016-02

52.215-8 Order of Precedence-Uniform Contract Format. 1997-10 52.219-6 Notice of Total Small Business Set-Aside. 2011-11 52.219-6 Alternate I Notice of Total Small Business Set-Aside. - (Alternate I) 2011-11 52.219-8 Utilization of Small Business Concerns. 2018-10 52.219-13 Notice of Set-Aside of Orders. 2011-11 52.219-14 Limitations on Subcontracting. 2017-01 52.222-6 Construction Wage Rate Requirements. 2018-08 52.222-7 Withholding of Funds. 2014-05 52.222-8 Payrolls and Basic Records. 2018-08 52.222-9 Apprentices and Trainees. 2005-07 52.222-10 Compliance with Copeland Act Requirements. 1988-02 52.222-11 Subcontracts (Labor Standards). 2014-05 52.222-12 Contract Termination-Debarment. 2014-05 52.222-13 Compliance with Construction Wage Rate Requirements and Related

Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. 1988-02 52.222-15 Certification of Eligibility. 2014-05 52.222-21 Prohibition of Segregated Facilities. 2015-04 52.222-27 Affirmative Action Compliance Requirements for Construction. 2015-04 52.222-37 Employment Reports on Veterans. 2016-02 52.222-55 Minimum Wages Under Executive Order 13658. 2015-12 52.222-62 Paid Sick Leave Under Executive Order 13706. 2017-01 52.223-5 Pollution Prevention and Right-to-Know Information. 2011-05 52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving. 2011-08 52.223-19 Compliance with Environmental Management Systems. 2011-05 52.223-21 Foams. 2016-06

52.225-13 Restrictions on Certain Foreign Purchases. 2008-06 52.228-2 Additional Bond Security. 1997-10 52.228-5 Insurance-Work on a Government Installation. 1997-01 52.228-11 Pledges of Assets. 2018-08 52.228-14 Irrevocable Letter of Credit. 2014-11 52.229-3 Federal, State, and Local Taxes. 2013-02 52.232-17 Interest. 2014-05 52.232-23 Assignment of Claims. 2014-05 52.232-33 Payment by Electronic Funds Transfer-System for Award Management.2018-10 52.232-39 Unenforceability of Unauthorized Obligations. 2013-06 52.232-40 Providing Accelerated Payments to Small Business Subcontractors. 2013-12 52.233-1 Disputes. 2014-05 52.233-3 Protest after Award. 1996-08 52.233-4 Applicable Law for Breach of Contract Claim. 2004-10 52.236-2 Differing Site Conditions. 1984-04 52.236-3 Site Investigation and Conditions Affecting the Work. 1984-04 52.236-5 Material and Workmanship. 1984-04 52.236-6 Superintendence by the Contractor. 1984-04 52.236-7 Permits and Responsibilities. 1991-11 52.236-8 Other Contracts. 1984-04 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and

Improvements.

1984-04

52.236-10 Operations and Storage Areas. 1984-04 52.236-11 Use and Possession Prior to Completion. 1984-04 52.236-12 Cleaning Up. 1984-04 52.236-13 Accident Prevention. 1991-11 52.236-15 Schedules for Construction Contracts. 1984-04 52.242-13 Bankruptcy. 1995-07 52.242-14 Suspension of Work. 1984-04 52.243-1 Changes-Fixed-Price. 1987-08 52.243-1 Alternate I Changes-Fixed-Price. - (Alternate I) 1984-04 52.243-4 Changes. 2007-06 52.244-6 Subcontracts for Commercial Items. 2018-10 52.249-2 Termination for Convenience of the Government (Fixed-Price). 2012-04 52.249-4 Termination for Convenience of the Government (Services) (Short

Form).

1984-04

52.249-10 Default (Fixed-Price Construction). 1984-04

DFARS Clauses Incorporated by Reference

Number Title Effective Date 252.203-7000 Requirements Relating to Compensation of Former DoD Officials 2011-09 252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense-Contract-

Related Felonies.

2008-12

252.203-7002 Requirement to Inform Employees of Whistleblower Rights. 2013-09 252.204-7003 Control of Government Personnel Work Product. 1992-04 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. 2016-10 252.204-7012 Safeguarding Covered Defense Information and Cyber Incident

Reporting.

2016-10

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support. 2016-05 252.209-7004 Subcontracting with Firms that are Owned or Controlled by the

Government of a Country that is a State Sponsor of Terrorism.

2015-10

252.223-7004 Drug-Free Work Force. 1988-09 252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous

Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium. 2013-06 252.225-7001 Buy American and Balance of Payments Program. 2017-12 252.225-7002 Qualifying Country Sources as Subcontractors. 2017-12 252.225-7012 Preference for Certain Domestic Commodities. 2017-12 252.225-7016 Restriction on Acquisition of Ball and Roller Bearings. 2011-06 252.225-7048 Export-Controlled Items. 2013-06 252.226-7001 Utilization of Indian Organizations, Indian-Owned Economic

Enterprises, and Native Hawaiian Small Business Concerns.

2004-09

252.232-7010 Levies on Contract Payments. 2006-12

252.237-7010 Prohibition on Interrogation of Detainees by Contractor Personnel. 2013-06 252.243-7001 Pricing of Contract Modifications. 1991-12 252.243-7002 Requests for Equitable Adjustment. 2012-12 252.244-7000 Subcontracts for Commercial Items 2013-06 252.246-7004 Safety of Facilities, Infrastructure, and Equipment for Military

Operations.

2010-10

FAR Clauses Incorporated by Full Text

52.203-16 Preventing Personal Conflicts of Interest. 2011-12 As prescribed in 3.1106 , insert the following clause: Preventing Personal Conflicts of Interest (Dec 2011) (a) Definitions. As used in this clause- "Acquisition function closely associated with inherently governmental functions" means supporting or providing advice or recommendations with regard to the following activities of a Federal agency: (1) Planning acquisitions.

(2) Determining what supplies or services are to be acquired by the Government, including developing statements of work.

(3) Developing or approving any contractual documents, to include documents defining requirements, incentive plans, and evaluation criteria. (4) Evaluating contract proposals. (5) Awarding Government contracts. (6) Administering contracts (including ordering changes or giving technical direction in contract performance or contract quantities, evaluating contractor performance, and accepting or rejecting contractor products or services). (7) Terminating contracts. (8) Determining whether contract costs are reasonable, allocable, and allowable. "Covered employee" means an individual who performs an acquisition function closely associated with inherently governmental functions and is- (1) An employee of the contractor;

or (2) A subcontractor that is a self-employed individual treated as a covered employee of the contractor because there is no employer to whom such an individual could submit the required disclosures. "Non-public information" means any Government or third-party information that- (1) An employee of the contractor; or (2) A subcontractor that is a self-employed individual treated as a covered employee of the contractor because there is no employer to whom such an individual could submit the required disclosures. "Non-public information" means any Government or third-party information that- (1) Is exempt from disclosure under the Freedom of Information Act (5U.S. C.552) or otherwise protected from disclosure by statute, Executive order, or regulation; or (2) Has not been disseminated to the general public and the Government has not yet determined whether the information can or will be made available to the public. "Personal conflict of interest" means a situation in which a covered employee has a financial interest, personal activity, or relationship that could impair the employee's ability to act impartially and in the best interest of the Government when performing under the contract. (A de minimis interest that would not "impair the employee's ability to act impartially and in the best interest of the Government" is not covered under this definition.) (1) Among the sources of personal conflicts of interest are- (i) Financial interests of the covered employee, of close family members, or of other members of the covered employee's household; (ii) Other employment or financial relationships (including seeking or negotiating for prospective employment or business); and (iii) Gifts, including travel. (2) For example, financial interests referred to in paragraph (1) of this definition may arise from- (i) Compensation, including wages, salaries, commissions, professional fees, or fees for business referrals; (ii) Consulting relationships (including commercial and professional consulting and service arrangements, scientific and technical advisory board memberships, or serving as an expert witness in litigation); (iii) Services provided in exchange for honorariums or travel expense reimbursements; (iv) Research funding or other forms of research support; (v) Investment in the form of stock or bond ownership or partnership interest (excluding diversified mutual fund investments); (vi) Real estate investments;

(vii) Patents, copyrights, and other intellectual property interests; or (viii) Business ownership and investment interests.

(c) Requirements. The Contractor shall- (1) Have procedures in place to screen covered employees for potential personal conflicts of interest, by- (i) Obtaining and maintaining from each covered employee, when the employee is initially assigned to the task under the contract, a disclosure of interests that might be affected by the task to which the employee has been assigned, as follows: (A) Financial interests of the covered employee, of close family members, or of other members of the covered employee's household. (B) Other employment or financial relationships of the covered employee (including seeking or negotiating for prospective employment or business). (C) Gifts, including travel; and (ii) Requiring each covered employee to update the disclosure statement whenever the employee's personal or financial circumstances change in such a way that a new personal conflict of interest might occur because of the task the covered employee is performing. (2) For each covered employee- (i) Prevent personal conflicts of interest, including not assigning or allowing a covered employee to perform any task under the contract for which the Contractor has identified a personal conflict of interest for the employee that the Contractor or employee cannot satisfactorily prevent or mitigate in consultation with the contracting agency; (ii) Prohibit use of non-public information accessed through performance of a Government contract for personal gain; and (iii) Obtain a signed non-disclosure agreement to prohibit disclosure of non-public information accessed through performance of a Government contract. (3) Inform covered employees of their obligation- (i) To disclose and prevent personal conflicts of interest; (ii) Not to use non-public information accessed through performance of a Government contract for personal gain; and (iii) To avoid even the appearance of personal conflicts of interest; (4) Maintain effective oversight to verify compliance with personal conflict-of-interest safeguards; (5) Take appropriate disciplinary action in the case of covered employees who fail to comply with policies established pursuant to this clause; and (6) Report to the Contracting Officer any personal conflict-of-interest violation by a covered employee as soon as it is identified. This report shall include a description of the violation and the proposed actions to be taken by the Contractor in response to the violation. Provide follow-up reports of corrective actions taken, as necessary. Personal conflict-of-interest violations include- (i) Failure by a covered employee to disclose a personal conflict of interest; (ii) Use by a covered employee of non-public information accessed through performance of a Government contract for personal gain; and (iii) Failure of a covered employee to comply with the terms of a non-disclosure agreement.

(d) Mitigation or waiver. (1) In exceptional circumstances, if the Contractor cannot satisfactorily prevent a personal conflict of interest as required by paragraph (b)(2)(i) of this clause, the Contractor may submit a request through the Contracting Officer to the Head of the Contracting Activity for- (i) Agreement to a plan to mitigate the personal conflict of interest; or (ii) A waiver of the requirement. (2) The Contractor shall include in the request any proposed mitigation of the personal conflict of interest. (3) The Contractor shall- (i) Comply, and require compliance by the covered employee, with any conditions imposed by the Government as necessary to mitigate the personal conflict of interest; or (ii) Remove the Contractor employee or subcontractor employee from performance of the contract or terminate the applicable subcontract. (e) Subcontract flowdown.

The Contractor shall include the substance of this clause, including this paragraph (d), in subcontracts- (1) That exceed $150,000; and (2) In which subcontractor employees will perform acquisition functions closely associated with inherently governmental functions (i.e., instead of performance only by a self-employed individual). (End of clause) 52.211-11 Liquidated Damages-Supplies, Services, or Research and Development. 2000-09 As prescribed in 11.503(a), insert the following clause in solicitations and contracts: Liquidated Damages-Supplies, Services, or Research and Development (Sept 2000) (a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $____ per calendar day of delay [Contracting Officer insert amount]. (b) If the Government terminates this contract in whole or in part under the Default-Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default-Fixed-Price Supply and Service clause in this contract. (End of clause) 52.211-12 Liquidated Damages-Construction. 2000-09 As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages-Construction (Sept 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __$222.00__ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted. (b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (End of clause) 52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. 2014-10 As prescribed in 19.1309(b), insert the following clause: Notice of Price Evaluation preference for HUBZone Small Business Concerns (Oct 2014) (a) Definitions. See 13 CFR 125.6(e) for definitions of terms used in paragraph (d). (b) Evaluation preference. (1) Offers will be evaluated by adding a factor of 10percent to the price of all offers, except- (i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and (ii) Otherwise successful offers from small business concerns. (2) The factor of 10percent shall be applied on a line item basis or to any group of items on which award may be made. Other evaluation factors described in the solicitation shall be applied before application of the factor.

(3) When the two highest rated offerors are a HUBZone small business concern and a large business, and the evaluated offer of the HUBZone small business concern is equal to the evaluated offer of the large business after considering the price evaluation preference, award will be made to the HUBZone small business concern. (c) Waiver of evaluation preference. A HUBZone small business concern may elect to waive the evaluation preference, in which case the factor will be added to its offer for evaluation purposes. The agreements in paragraphs(d) and (e) of this clause do not apply if the offeror has waived the evaluation preference. [_] Offeror elects to waive the evaluation preference. (d) Agreement. A HUBZone small business concern agrees that in the performance of the contract, in the case of a contract for- (1) Services (except construction), at least 50percent of the cost of personnel for contract performance will be spent for employees of the concern or employees of other HUBZone small business concerns; (2) Supplies (other than procurement from a nonmanufacturer of such supplies), at least 50percent of the cost of manufacturing, excluding the cost of materials, will be performed by the concern or other HUBZone small business concerns; (3) General construction.