Sol_F16PS01018.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040290879

FWS, DIVISION OF CONTRACTING AND GR

1875 CENTURY BOULEVARD

SUITE 310

ATLANTA GA 30345-3310

F04

Gerome Jordan 404 6794033

108/17/2016

F16PS01018

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Project Title: Rehab Retaining Wall

Place of Performance: Erwin National Fish Hatchery, 520 Federal Hatchery Rd, Erwin, Tennessee, 37650, Unicoi County

Period of Performance: Sep 1, 2016 through December 31, 2016

Government Technical Point-of-Contact: Norm Heil, 423-743-4712, norm_heil@fws.gov, Anthony Garland, 423-743-4712, anthony_garland@fws.gov

Please contact the Government Technical POC to schedule a site visit before Aug 24, 2016.

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

10 30 calendar days and complete it within ________________ ________________ calendar days after receiving

08/26/2016

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

FWS, DIVISION OF CONTRACTING AND GR

1875 CENTURY BOULEVARD

SUITE 310

ATLANTA GA 30345-3310

F04

Gerome Jordan

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 31

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

F16PS01018

Legacy Doc #: FWS

Delivery: 12/31/2016

Delivery Location Code: 0008349723

FWS ERWIN NATIONAL FISH HATCHERY

520 FEDERAL HATCHERY ROAD

ERWIN TN 37650-0548 US

FOB: Destination

00010 Rehab Retaining Wall

Period of Performance: 09/01/2016 to 12/31/2016

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

Contract No. F16P X0 XXXX Solicitation No. F16P S0 1018

Erwin National Fish Hatchery, 520 Federal Hatchery Rd, Erwin, Tennessee, 37650, Unicoi County

SECTION A - Solicitation/Contract Form

NOTICE TO CONTRACTOR – Superintendent Requirement

The Government will hold the Contractor in strict compliance of 52.236-6, Superintendence by the Contractor, contained herein Section A. After issuance of the award and prior to issuance of the Notice to Proceed, the Contractor shall submit to the Government the name and qualifications of the Superintendent on the Contractor’s official letterhead. The Superintendent shall be a current employee on the Contractor’s payroll; or the Contractor shall hire the Superintendent with the intent of the Contractor issuing an IRS form 1099-Misc. The Superintendent shall not be an employee of the Subcontractor that is hired by the Contractor to perform the work. The Contractor shall incorporate this cost into the proposal prior to submitting it to the Government. Failure of the Contractor to comply with this requirement will be an event of default and this Contract may be terminated for this default.

NOTICE TO CONTRACTOR – Construction Schedule

The Contractor shall submit to the Government a schedule utilizing the Critical Path Method (CPM) technique. The Contractor may develop the CPM with Microsoft Project software or any similar project management software. The Contractor shall submit the construction schedule in strict compliance with 52.236-15, Schedules for Construction Contracts, contained herein Section A.

Commencement, Prosecution, and Completion of Work. (APR 1984) 52.211-10

The Contractor shall be required to (a) commence work under this contract within [10] ten calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [200] two-hundred calendar days. The time stated for completion shall include final cleanup of the premises. (End of Clause)

Affirmative Action Compliance Requirements for Construction. (FEB 1999) 52.222-27

Payments under Fixed-Price Construction Contracts. (SEP 2002) 52.232-5

Performance of Work by the Contractor. (APR 1984) 52.236-1

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 10% percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.(End of Clause)

Differing Site Conditions. (APR 1984) 52.236-2

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of -

(1) Subsurface or latent physical conditions at the site which differ materially from those indicated in this contract; or

(2) Unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.

(b) The Contracting Officer shall investigate the site conditions promptly after receiving the notice. If the conditions do materially so differ and cause an increase or decrease in the Contractor's cost of, or the time required for, performing any part of the work under this contract, whether or not changed as a result of the conditions, an equitable adjustment shall be made under this clause and the contract modified in writing accordingly.

(c) No request by the Contractor for an equitable adjustment to the contract under this clause shall be allowed, unless the Contractor has given the written notice required; provided, that the time prescribed in paragraph (a) of this clause for giving written notice may be extended by the Contracting Officer.

(d) No request by the Contractor for an equitable adjustment to the contract for differing site conditions shall be allowed if made after final payment under this contract.(End of Clause)

Site Investigation and Conditions Affecting the Work. (APR 1984) 52.236-3

(a) The Contractor acknowledges that it has taken steps reasonably necessary to ascertain the nature and location of the work, and that it has investigated and satisfied itself as to the general and local conditions which can affect the work or its cost, including but not limited to (1) conditions bearing upon transportation, disposal, handling, and storage of materials; (2) the availability of labor, water, electric power, and roads; (3) uncertainties of weather, river stages, tides, or similar physical conditions at the site; (4) the conformation and conditions of the ground; and (5) the character of equipment and facilities needed preliminary to and during work performance. The Contractor also acknowledges that it has satisfied itself as to the character, quality, and quantity of surface and subsurface materials or obstacles to be encountered insofar as this information is reasonably ascertainable from an inspection of the site, including all exploratory work done by the Government, as well as from the drawings and specifications made a part of this contract. Any failure of the Contractor to take the actions described and acknowledged in this paragraph will not relieve the Contractor from responsibility for estimating properly the difficulty and cost of successfully performing the work, or for proceeding to successfully perform the work without additional expense to the Government.

(b) The Government assumes no responsibility for any conclusions or interpretations made by the Contractor based on the information made available by the Government. Nor does the Government assume responsibility for any understanding reached or representation made concerning conditions which can affect the work by any of its officers or agents before the execution of this contract, unless that understanding or representation is expressly stated in this contract.

(End of Clause)

Superintendence by the Contractor. (APR 1984) 52.236-6

At all times during performance of this contract and until the work is completed and accepted, the Contractor shall directly superintend the work or assign and have on the worksite a competent superintendent who is satisfactory to the Contracting Officer and has authority to act for the Contractor.(End of Clause)

Schedules for Construction Contracts. (APR 1984) 52.236-15

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor's right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

(End of Clause)

Layout of Work. (APR 1984) 52.236-17

The Contractor shall lay out its work from Government established base lines and bench marks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.(End of Clause)

52.249-2 --Termination for Convenience of the Government (Fixed-Price) (Apr 2012)

(a) The Government may terminate performance of work under this contract in whole or, from time to time, in part if the Contracting Officer determines that a termination is in the Government’s interest. The Contracting Officer shall terminate by delivering to the Contractor a Notice of Termination specifying the extent of termination and the effective date.

(b) After receipt of a Notice of Termination, and except as directed by the Contracting Officer, the Contractor shall immediately proceed with the following obligations, regardless of any delay in determining or adjusting any amounts due under this clause:

(1) Stop work as specified in the notice.(2) Place no further subcontracts or orders (referred to as subcontracts in this clause) for materials, services, or facilities, except as necessary to complete the continued portion of the contract.(3) Terminate all subcontracts to the extent they relate to the work terminated.(4) Assign to the Government, as directed by the Contracting Officer, all right, title, and interest of the Contractor under the subcontracts terminated, in which case the Government shall have the right to settle or to pay any termination settlement proposal arising out of those terminations.(5) With approval or ratification to the extent required by the Contracting Officer, settle all outstanding liabilities and termination settlement proposals arising from the termination of subcontracts; the approval or ratification will be final for purposes of this clause.(6) As directed by the Contracting Officer, transfer title and deliver to the Government --

(i) The fabricated or unfabricated parts, work in process, completed work, supplies, and other material produced or acquired for the work terminated; and(ii) The completed or partially completed plans, drawings, information, and other property that, if the contract had been completed, would be required to be furnished to the

Government.

(7) Complete performance of the work not terminated.(8) Take any action that may be necessary, or that the Contracting Officer may direct, for the protection and preservation of the property related to this contract that is in the possession of the Contractor and in which the Government has or may acquire an interest. (9) Use its best efforts to sell, as directed or authorized by the Contracting Officer, any property of the types referred to in subparagraph (b)(6) of this clause; provided, however, that the Contractor

(i) is not required to extend credit to any purchaser and(ii) may acquire the property under the conditions prescribed by, and at prices approved by, the Contracting Officer. The proceeds of any transfer or disposition will be applied to reduce any payments to be made by the Government under this contract, credited to the price or cost of the work, or paid in any other manner directed by the Contracting Officer.

(c) The Contractor shall submit complete termination inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period.

(d) After expiration of the plant clearance period as defined in Subpart 49.001 of the Federal Acquisition Regulation, the Contractor may submit to the Contracting Officer a list, certified as to quantity and quality, of termination inventory not previously disposed of, excluding items authorized for disposition by the Contracting Officer. The Contractor may request the Government to remove those items or enter into an agreement for their storage. Within 15 days, the Government will accept title to those items and remove them or enter into a storage agreement. The Contracting Officer may verify the list upon removal of the items, or if stored, within 45 days from submission of the list, and shall correct the list, as necessary, before final settlement.

(e) After termination, the Contractor shall submit a final termination settlement proposal to the Contracting Officer in the form and with the certification prescribed by the Contracting Officer. The Contractor shall submit the proposal promptly, but no later than 1 year from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 1-year period. However, if the Contracting Officer determines that the facts justify it, a termination settlement proposal may be received and acted on after 1 year or any extension. If the Contractor fails to submit the proposal within the time allowed, the Contracting Officer may determine, on the basis of information available, the amount, if any, due the Contractor because of the termination and shall pay the amount determined.

(f) Subject to paragraph (e) of this clause, the Contractor and the Contracting Officer may agree upon the whole or any part of the amount to be paid or remaining to be paid because of the termination. The amount may include a reasonable allowance for profit on work done. However, the agreed amount, whether under this paragraph (f) or paragraph (g) of this clause, exclusive of costs shown in subparagraph (g)(3) of this clause, may not exceed the total contract price as reduced by

(1) the amount of payments previously made and (2) the contract price of work not terminated.

The contract shall be modified, and the Contractor paid the agreed amount. Paragraph (g) of this clause shall not limit, restrict, or affect the amount that may be agreed upon to be paid under this paragraph.

(g) If the Contractor and the Contracting Officer fail to agree on the whole amount to be paid because of the termination of work, the Contracting Officer shall pay the Contractor the amounts determined by the Contracting Officer as follows, but without duplication of any amounts agreed on under paragraph (f) of this clause:

(1) The contract price for completed supplies or services accepted by the Government (or sold or acquired under subparagraph (b)(9) of this clause) not previously paid for, adjusted for any saving of freight and other charges. (2) The total of --

(i) The costs incurred in the performance of the work terminated, including initial costs and preparatory expense allocable thereto, but excluding any costs attributable to supplies or services paid or to be paid under subparagraph (g)(1) of this clause;(ii) The cost of settling and paying termination settlement proposals under terminated subcontracts that are properly chargeable to the terminated portion of the contract if not included in subdivision (g)(2)(i) of this clause; and (iii) A sum, as profit on subdivision (g)(2)(i) of this clause, determined by the Contracting Officer under 49.202 of the Federal Acquisition Regulation, in effect on the date of this contract, to be fair and reasonable; however, if it appears that the Contractor would have sustained a loss on the entire contract had it been completed, the Contracting Officer shall allow no profit under this subdivision (g)(2)(iii) and shall reduce the settlement to reflect the indicated rate of loss.

(3) The reasonable costs of settlement of the work terminated, including --

(i) Accounting, legal, clerical, and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data; (ii) The termination and settlement of subcontracts (excluding the amounts of such settlements); and (iii) Storage, transportation, and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory.

(h) Except for normal spoilage, and except to the extent that the Government expressly assumed the risk of loss, the Contracting Officer shall exclude from the amounts payable to the Contractor under paragraph (g) of this clause, the fair value as determined by the Contracting Officer, for the loss of the Government property.

(i) The cost principles and procedures of Part 31 of the Federal Acquisition Regulation, in effect on the date of this contract, shall govern all costs claimed, agreed to, or determined under this clause.

(j) The Contractor shall have the right of appeal, under the Disputes clause, from any determination made by the Contracting Officer under paragraph (e), (g), or (l) of this clause, except that if the Contractor failed to submit the termination settlement proposal or request for equitable adjustment within the time provided in paragraph (e) or (l), respectively, and failed to request a time extension, there is no right of appeal.

(k) In arriving at the amount due the Contractor under this clause, there shall be deducted --

(1) All unliquidated advance or other payments to the Contractor under the terminated portion of this contract; (2) Any claim which the Government has against the Contractor under this contract; and (3) The agreed price for, or the proceeds of sale of, materials, supplies, or other things acquired by the Contractor or sold under the provisions of this clause and not recovered by or credited to the Government.

(l) If the termination is partial, the Contractor may file a proposal with the Contracting Officer for an equitable adjustment of the price(s) of the continued portion of the contract. The Contracting Officer shall make any equitable adjustment agreed upon. Any proposal by the Contractor for an equitable adjustment under this clause shall be requested within 90 days from the effective date of termination unless extended in writing by the Contracting Officer.

(m)

(1) The Government may, under the terms and conditions it prescribes, make partial payments and payments against costs incurred by the Contractor for the terminated portion of the contract, if the Contracting Officer believes the total of these payments will not exceed the amount to which the Contractor will be entitled. (2) If the total payments exceed the amount finally determined to be due, the Contractor shall repay the excess to the Government upon demand, together with interest computed at the rate established by the Secretary of the Treasury under 50 U.S.C. App. 1215(b)(2). Interest shall be computed for the period from the date the excess payment is received by the Contractor to the date the excess is repaid.

Interest shall not be charged on any excess payment due to a reduction in the Contractor’s termination settlement proposal because of retention or other disposition of termination inventory until 10 days after the date of the retention or disposition, or a later date determined by the Contracting Officer because of the circumstances.

(n) Unless otherwise provided in this contract or by statute, the Contractor shall maintain all records and documents relating to the terminated portion of this contract for 3 years after final settlement. This includes all books and other evidence bearing on the Contractor’s costs and expenses under this contract. The Contractor shall make these records and documents available to the Government, at the Contractor’s office, at all reasonable times, without any direct charge. If approved by the Contracting Officer, photographs, microphotographs, or other authentic reproductions may be maintained instead of original records and documents.(End of Clause)

Alternate I (Sep 1996). If the contract is for construction, substitute the following paragraph (g) for paragraph (g) of the basic clause:

(g) If the Contractor and Contracting Officer fail to agree on the whole amount to be paid the Contractor because of the termination of work, the Contracting Officer shall pay the Contractor the amounts determined as follows, but without duplication of any amounts agreed upon under paragraph (f) of this clause:

(1) For contract work performed before the effective date of termination, the total (without duplication of any items) of --

(i) The cost of this work; (ii) The cost of settling and paying termination settlement proposals under terminated subcontracts that are properly chargeable to the terminated portion of the contract if not included in subdivision (g)(1)(i) of this clause; and (iii) A sum, as profit on subdivision (g)(1)(i) of this clause, determined by the Contracting Officer under 49.202 of the Federal Acquisition Regulation, in effect on the date of this contract, to be fair and reasonable; however, if it appears that the Contractor would have sustained a loss on the entire contract had it been completed, the Contracting Officer shall allow no profit under this subdivision (g)(1)(iii) and shall reduce the settlement to reflect the indicated rate of loss.

(2) The reasonable costs of settlement of the work terminated, including --

(i) Accounting, legal, clerical, and other expenses reasonably necessary for the preparation of termination settlement proposals and supporting data; (ii) The termination and settlement of subcontracts (excluding the amounts of such settlements); and (iii) Storage, transportation, and other costs incurred, reasonably necessary for the preservation, protection, or disposition of the termination inventory.

Default (Fixed-Price Construction). (APR 1984) 52.249-10

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed.

In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor's refusal or failure to complete the work within the specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if -

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include -

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.(End of Clause)

Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction. (FEB 1999) 52.222-23

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation for Each Trade: 20% Goals for Female Participation for Each Trade: 10%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on

(1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled Affirmative Action Compliance Requirements for Construction, and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4.

Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S.

Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the -

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the covered area is Erwin National Fish Hatchery, 520 Federal Hatchery Rd, Erwin, Tennessee, 37650, Unicoi County (End of Clause)

SECTION B - Supplies or Services and Prices

See SECTION J - List of Documents, Exhibits and Other Attachments

Hydra Engineering and Construction, Radial Gate Control Structure – Electrical Motors Price Proposal is hereby incorporated into this award.

SECTION C - Description/Specifications

The Contractor shall provide all labor, materials, supplies, tools, equipment, transportation, facilities, plants, permits, fees, licenses, insurance, bonds, expertise and supervision as necessary to perform all of the work stated in the subject solicitation and subsequent award.

SECTION D - Packaging and Marking

PAYMENT OF POSTAGE AND FEES

All postage and fees related to submitting information including submittals, forms, reports, etc., to the Contracting Officer or the Contracting Specialist shall be paid by the Contractor.

CORRESPONDENCE/SUBMITTALS

Contractor initiated correspondence and submittals shall identify the contract number. All information shall be forwarded to the addresses found in Section G. Correspondence shall be provided in duplicate and mailed to the Contracting Officer (CO). This would include the Submittal Register and Construction Schedule/Reports. Submittals shall be submitted to the Site Representative (SR) with a duplicate copy of the cover letter forwarded to the CO.

SECTION E - Inspection and Acceptance

Material and Workmanship. (APR 1984) 52.236-5

Permits and Responsibilities. (NOV 1991) 52.236-7

Inspection of Construction. (APR 1996) 52.246-12

(a) Definition. Work includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not -

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer's written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes reinspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may -

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor's right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government's rights under any warranty or guarantee.(End of Clause)

Warranty of Construction. (MAR 1994) 52.246-21

Pre-Final Inspection

The Contractor shall give written notice to the Contracting Officer at least 15 calendar days before the date the construction work will be completed and ready for final inspection. The contractor shall conduct a pre-final and final inspection in the presence of the Contracting Officer’s Representative (COR) and/or Site Representative (SR). Other Government personnel may attend both inspections. A Government Pre-Final Punch List may be developed as result of this inspection of any items not meeting Contract requirements for final acceptance. The list of deficiencies may include the estimated date by which the deficiencies will be corrected. Any discrepancies noted shall be corrected prior to final inspection.

Final Inspection

(a) The Contracting Officer shall be notified in writing by the Contractor when the final inspection can be conducted. The final inspection shall be requested ten (10) calendar days before the desired completion date or required completion date of the contract.

(b) The final inspection shall be performed with the Contractor by the Contracting Officer's Representative and/or Site Representative. Other Government personnel may attend the inspection. The Contractor and/or his Project Superintendent shall be present at the job site during final inspection. The Contracting Officer will present to the Contractor, after inspection, a punch list of any items not meeting Contract requirements for final acceptance.

The punch list items and all non-conforming work must be made acceptable before final payment will be made. Any discrepancies noted shall be corrected within the time specified in the contract for final completion. Only the Contracting Officer is authorized to accept work performed.

Inspection

(a) The Contracting Officer or the duly authorized representative will perform inspection of materials and services to be provided.

(b) For the purpose of this clause, Norm Heil is the authorized representative of the Contracting Officer.

(c) Inspections will be performed at the construction site.

SECTION F - Deliveries or Performance

Suspension of Work. (APR 1984) 52.242-14

CONTRACT WORK HOURS (NOV 2007) 1452.211-71

The performance period established for this contract is based upon all work being conducted during regular working hours. Regular working hours are limited to the time between 7:30am to 4:00pm, Monday through Friday, excluding Government holidays. If the Contractor desires to carry on work outside regular hours, including Saturdays, Sundays, and Government holidays, a request must be submitted to the Contracting Officer Representative in sufficient time to allow satisfactory arrangements to be made by the Government for access to the work site and inspection.(End of Clause)

SECTION G - Contract Administration Data

1. CONTRACT REPRESENTATIVE

Contracting Officer (CO) responsible for this contract: Gerome Jordan

U.S. Fish and Wildlife Service Div. of Contracting and Grants Services 1875 Century Boulevard, Suite 310 Atlanta, GA 30345 Telephone Number: 404-679-4033

Primary Contracting Specialist (CS) responsible for this contract: Gerome Jordan

U.S. Fish and Wildlife Service Div. of Contracting and Grants Services 1875 Century Boulevard, Suite 306 Atlanta, GA 30345 Telephone Number: 404-679-4033

Contracting Officer's Representative (COR) for this contract: TBD

U.S. Fish and Wildlife Service Div. of Contracting and General Services 1875 Century Boulevard, Suite 310 Atlanta, GA 30345

Telephone Number: 404-679-XXXX

Construction Representative (CR) for this contract: Not Assigned

Site Representative (SR) for this contract: TBD

Telephone Number: 704-694-XXXX

2. CONTRACTING OFFICER’S REPRESENTATIVE – LIAISON

The COR will act like as a liaison between the U.S. Fish & Wildlife Service herein referred to as “Service” and the Contractor, and, when necessary, will provide technical direction to the Contractor. The COR, however, is not authorized to change any of the terms and conditions of the contract, issue new assignments of work, make decisions concerning disputes arising under the contract, or resolve differing site condition matters. Neither the presence nor absence of the government representative shall relieve the Contractor of its responsibilities under the contract.

3. JOB SITE ADMINISTRATION

The Government will designate a CR or SR who will be available at the site to inspect the work as it progresses. The CR or SR will prepare an Inspector’s Daily Log, beginning with the first day of the contract, detailing ground and weather conditions, work being performed, materials delivered, and notes of any problems or difficulties. Government inspections do not relieve the Contractor of responsibility for providing adequate quality control measures. At the end of every day of work on this contract, the Contractor’s Superintendent, as defined below, shall contact the CR or SR, review the daily log, and sign as the Contractor’s representative.

Unless the Contractor’s Superintendent makes notation of the contrary on the daily log, the log shall be presumed to be accurate.

The CR or SR is not authorized to make technical decisions or give technical directions; the Contractor or the Contractor’s Superintendent must contact the COR regarding such decision and direction. The Contractor shall have a competent superintendent (hereinafter referred to as the “Contractor’s Superintendent” who is (i) deemed acceptable to the Government; (ii) authorized to act on the Contractor’s behalf; and (iii) be present on the job site at all times when contract work is being performed.

(See Superintendence by the Contractor, Section I, Federal Acquisition Regulations (FAR) Clause 52.236-6.)

4. ELECTRONIC INVOICING AND PAYMENT REQUIREMENTS – INTERNET PAYMENT PLATFORM (IPP) (APRIL 2011)

Beginning May 1, 2011, payment requests for all new awards must be submitted electronically through the U.S. Department of the Treasury’s Internet Payment Platform (IPP) System. Payment terms for existing contracts and orders awarded prior to May 1 remain the same. The Contractor must use IPP for contracts and orders awarded May 1 and later, and must use the non-IPP invoicing process for those contracts and orders awarded prior to May 1.

“Payment request” means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in FAR 33.905(b), “Payment documentation and process” and the applicable Prompt Payment clause included in this contract. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [CO to edit and include the appropriate documentation required under this contract]:

Prime contractor and subcontract payrolls (if applicable) Payment Request Certification Release of Claims SF 1413 – Statement and Acknowledgment Construction Schedule (Microsoft Project or other Industry Standard Software) Schedule of Values Owner/Operator manuals (if applicable) Warranty Certificates (if applicable)

The Contractor must use the IPP website to enroll, access and use IPP for submitting requests for payment. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via e-mail ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the contracting officer. (End of Clause)

SECTION H - Special Contract Requirements

1. UTILITIES

a. Not Used

b. The following utility services will not be provided by the Government. The Contractor, at its expense and in a workmanlike manner satisfactory to the Contracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to measure the amount of each utility used for the purpose of determining charges. Before final acceptance of the work by the Government, the Contractor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia.

Electricity Water

2. GENERIC GENDER TERMINOLOGY

Except where stipulated by the Federal Acquisition Regulations, the use of terms such as he, she, his, and her are not to be interpreted as implying other than neutral gender terms such as "it" or "their"

3. SAFETY

a. The Contractor shall have the ultimate responsibility for safety on the project site at all times until final completion and acceptance of the project.

b. The Contractor shall comply with all Occupational Safety and Health Administration (OSHA) regulations, as found in 29 CFR 1910 and 1926, which are applicable to the construction project, including requirements set forth within solicitation provisions and contract clauses. In addition to OSHA safety standards, the Contractor shall also adhere to all current local, federal, and state safety requirements. In the event where any safety standard referenced herein conflicts with another, the more stringent shall govern.

c. The Contractor shall initiate and maintain an effective safety program that provides adequate systematic policies, procedures, and practices to protect their employees from and allow them to recognize, job-related safety and health hazards. The program shall include provisions for the systematic identification, evaluation, prevention and control of general work site hazards, specific job hazards, and potential hazards that may arise from foreseeable construction methods and conditions, as well as providing a competent person to conduct frequent and regular inspections. Each employee must be instructed in the recognition and avoidance of unsafe conditions and the regulations applicable to the work environment.

d. The Contractor shall immediately notify the CO of any accident, incident, or exposure resulting in a fatality, lost-time injury, or property loss/damage of $2,500 or more arising out of work performed under this contract. The Contractor shall investigate all work-related accidents/incidents to the extent necessary to determine their cause(s) and furnish the CO an investigative report outlining findings and proposed or completed corrective actions.