B08_-_SolicitationB0004_Atch1Specs.pdf

HOT SPRINGS

NATIONAL PARK

Arkansas

SCADA UPGRADES

HOSP

PMIS NO. 207691

PROJECT SPECIFICATIONS

(FINAL Construction Documents)

NATIONAL PARK SERVICE

MIDWEST REGION

March 2021

140P6221B0004 Attachment 1

THIS PAGE INTENTIONALLY LEFT BLANK

HOSP - 207691 00 01 10 - 1

Table of Contents

TABLE OF CONTENTS

DIVISION 00 — PROCUREMENT AND CONTRACTING REQUIREMENTS

00 01 07 - SEALS AND SIGNATURES

DIVISION 01 — GENERAL REQUIREMENTS

01 11 00 - SUMMARY OF WORK

01 26 01 - CONTRACT MODIFICATION PROCEDURES

01 27 00 - DEFINITION OF CONTRACT LINE ITEMS

01 31 00 - PROJECT MANAGEMENT AND COORDINATION

01 32 16 - CONSTRUCTION SCHEDULE

01 33 23 - SUBMITTAL PROCEDURES

01 33 23A - SUBMITTAL LIST

01 35 23 - SAFETY REQUIREMENTS

01 40 00 - QUALITY REQUIREMENTS

01 42 00 - REFERENCE STANDARDS

01 50 00 - TEMPORARY FACILITIES AND CONTROLS

01 57 19.11 - INDOOR AIR QUALITY MANAGEMENT

01 57 19.12 - NOISE & ACOUSTICS MANAGEMENT

01 57 23 - UNDER-AN-ACRE POLLUTION PREVENTION

01 61 03 - EQUIPMENT - BASIC REQUIREMENTS

01 67 00 - PRODUCT REQUIREMENTS

01 73 29 - CUTTING AND PATCHING

01 73 40 - EXECUTION

01 74 19 - CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 74 19A - PROJECT WASTE MANAGEMENT PLAN WORKSHEET

01 74 19B - STANDARD SOLID WASTE CONVERSIONS

01 77 00 - CLOSEOUT PROCEDURES

01 77 00A - CLOSEOUT AND OPERATION AND MAINTENANCE REQUIREMENTS

01 78 23 - OPERATION AND MAINTENANCE DATA

01 79 00 - DEMONSTRATION AND TRAINING

DIVISION 10 — SPECIALTIES

10 14 00 - IDENTIFICATION DEVICES

DIVISION 26 — ELECTRICAL

26 05 00 - ELECTRICAL - BASIC REQUIREMENTS

26 05 19 - WIRE AND CABLE - 600 VOLT AND BELOW

26 05 26 - GROUNDING AND BONDING

26 05 33 - RACEWAYS AND BOXES

26 05 43 - ELECTRICAL - EXTERIOR UNDERGROUND

26 05 73 - POWER SYSTEM STUDIES

26 08 13 - ACCEPTANCE TESTING

26 09 13 - ELECTRICAL METERING DEVICES

26 09 16 - CONTROL EQUIPMENT ACCESSORIES

26 22 13 - DRY-TYPE TRANSFORMERS

26 24 16 - PANELBOARDS

HOSP - 207691 00 01 10 - 2

Table of Contents

26 24 19 - MOTOR CONTROL EQUIPMENT

26 27 26 - WIRING DEVICES

26 28 00 - OVERCURRENT AND SHORT CIRCUIT PROTECTIVE DEVICES

26 28 16 - SAFETY SWITCHES

26 29 23 - VARIABLE FREQUENCY DRIVES - LOW VOLTAGE

26 35 26 - HARMONIC CORRECTION EQUIPMENT

26 43 13 - LOW VOLTAGE SURGE PROTECTION DEVICES (SPD)

DIVISION 40 — PROCESS INTERCONNECTIONS

40 61 13 - PROCESS CONTROL SYSTEM GENERAL REQUIREMENTS

40 61 21 - PROCESS CONTROL SYSTEM TESTING

40 61 43 - SURGE PROTECTION DEVICES (SPD) FOR INSTRUMENTATION AND CONTROL

EQUIPMENT

40 61 96 - PROCESS CONTROL DESCRIPTIONS

40 62 05 - COMPUTER SYSTEM HARDWARE AND ANCILLARIES

40 63 43 - PROGRAMMABLE LOGIC CONTROLLER (PLC) CONTROL SYSTEM

40 63 43A - IO LIST

40 66 05 - NETWORK EQUIPMENT

40 66 40 - TELEMETRY SYSTEMS

40 67 00 - CONTROL SYSTEM EQUIPMENT PANELS AND RACKS

40 67 63 - UNINTERRUPTIBLE POWER SUPPLIES (UPS)

40 68 13 - PROCESS CONTROL (HMI) SOFTWARE

40 68 63 - CONFIGURATION OF HMI SOFTWARE AND REPORTS

40 71 00 - FLOW INSTRUMENTATION

40 72 00 - LEVEL INSTRUMENTATION

40 73 00 - PRESSURE INSTRUMENTATION

40 74 00 - TEMPERATURE INSTRUMENTATION

40 78 00 - PANEL MOUNTED INSTRUMENTS

D I V I S I O N 0 0

PROCUREMENT AND CONTRACTING

REQUIREMENTS

HOSP - 207691 00 01 07 - 1

SEALS AND SIGNATURES

00 01 07

SEALS AND SIGNATURES

Owner Name: National Park Service, Interior Region 3/4/5

Facility or Site Name: Hot Springs National Park, Arkansas

Project Name: SCADA Upgrades

Project or Contract Designation: PMIS NO. 207691

Engineer: HDR

William Paul Cassity, PE

License No. 20022

The seal and signature to the left applies to the following Specifications divisions and sections of this project manual:

• Division 01, 10, 26, 40

Engineer’s seal and signature does not apply to the documents that comprise Division 00, Bidding and Contracting

Requirements.

It is a violation of applicable laws and regulations governing professional licensing and registration for any person, unless acting under the direction of the licensed and registered design professional(s) indicated above, to alter in any way the Specifications in this project manual.

END OF SEALS AND SIGNATURES

D I V I S I O N 0 1

GENERAL REQUIREMENTS

HOSP - 207691 01 11 00 - 1

SUMMARY OF WORK

2021/03/24

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Work phases.

3. Work under other contracts.

4. Government Furnished Materials.

5. Contractor use of premises.

6. Public use of site.

7. Occupancy requirements for buildings.

8. Work Restrictions.

9. Special Construction Requirements.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Hot Springs National Park, Administration Building, Cold Water Station, Bathhouse Row, Tank & Spring Sites, Maintenance Yard Hot Springs, Arkansas. The

Administration Building is located at 101 Reserve Street, the Bath Houses and Cold Water

Station are along Central Ave north of the Admin Building. Thermal and cold water storage tanks are located along North Mountain Drive. The Maintenance Building and Whittington

Spring are located at 631 Whittington Ave.

B. The Work consists of the following:

1. The Work includes replacement of the SCADA system for the thermal and cool water distribution system throughout the park. This will include the replacement of outdated electrical components, meters, valves, fiber optic cables, radio communication equipment, and all appurtenances necessary to create a new fully functional SCADA system for the Park.

C. Project will be constructed under a single prime contract.

HOSP - 207691 01 11 00 - 2

1.3 WORK PHASES

A. The Work shall be conducted in one phase:

1. Phase One: Replacement of the SCADA system for the thermal and cool water supplies throughout the park. This will include the replacement of outdated electrical components, meters, valves, fiber optic cables, radio communication equipment, and all appurtenances necessary to create a new fully functional SCADA system for the Park.

Work of this phase shall be substantially complete and ready for occupancy within 180 after commencement of construction of this phase.

1.4 WORK UNDER OTHER CONTRACTS

A. General: Cooperate fully with separate contractors so work on those contracts may be carried out smoothly, without interfering with or delaying work under this Contract. Coordinate the

Work of this Contract with work performed under separate contracts.

1.5 CONTRACTOR USE OF SITE

A. General: Contractor shall have full use of the site for construction operations during the construction period. Contractor's use of the site is limited only by the Government's right to perform work or to retain other contractors on portions of Project.

B. Storage of Materials: Confine storage of materials to areas adjacent to work being performed.

Exact location of storage areas to be coordinated with the park at the Pre Construction meeting.

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with Contracting Officer (CO) and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways, parking areas, and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times.

Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

HOSP - 207691 01 11 00 - 3

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park

Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

1.6 PUBLIC USE OF SITE

A. Contractor shall at all times conduct his operations to ensure the least inconvenience to the public. Building or Road closures will be permitted, when required, upon specific approval of

Contracting Officer for a maximum of 2 days.

1.7 OCCUPANCY REQUIREMENTS FOR BUILDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings that will be under construction during the entire contract period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government's day-to-day operations. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from the CO.

b. Maintain existing building in a weather tight condition throughout construction period. Repair damage caused by construction operations. Protect building and its occupants during construction period.

1.8 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests three business days in advance of the work to the Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

HOSP - 207691 01 11 00 - 4

1.9 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of 7 a.m. to 6 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: 7 a.m. to 6 p.m. when approved in advance by the Contracting Officer.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by

Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than three days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Hours for Utility Shutdowns: Any shutdowns of the water system must be coordinated well in advance with the Contracting Officer and the Park. Other utility systems that will require shutdowns shall be coordinated in advance with the Contracting Officer and completed in off peak times when possible.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.10 SPECIAL CONSTRUCTION REQUIREMENTS

A. The water that comes through the park facilities being upgraded on this project supplies the thermal water to all of the bath houses and resorts in the area. Water shutdowns must be coordinated with all of them in advance and should be avoided if at all possible.

PART 2 - PRODUCTS (NOT USED)

PART 3 - EXECUTION (NOT USED)

END OF SECTION 01 11 00

HOSP - 207691 01 26 01 - 1

CONTRACT MODIFICATION PROCEDURES

2021/03/08

SECTION 01 26 01 - CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

HOSP - 207691 01 26 01 - 2

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating

General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

HOSP - 207691 01 26 01 - 3

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the

Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

140P6221B0004 Attachment 1 http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank

HOSP - 207691 01 26 01 - 4

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement.

Contractor may utilize the government provided Contractor Estimate Form, or their own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a

Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction

Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the

Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the NPS. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work. Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

http://www.nps.gov/dscw/publicforms.htm#ct

HOSP - 207691 01 26 01 - 5

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals.

Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US

Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………15%

Profit………………10.00%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

HOSP - 207691 01 26 01 - 6

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 01 26 01

HOSP - 207691 01 27 00 - 1

DEFINITION OF CONTRACT LINE ITEMS

2021/03/24

SECTION 01 27 00 - DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (NOT USED)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No.0001 Replace SCADA System.

1. This item consists of replacement of the SCADA system for the thermal and cool water distribution systems throughout the park. This will include the replacement of outdated electrical components, meters, valves, fiber optic cables, radio communication equipment, and all appurtenances necessary to create a new fully functional SCADA system for the Park..

2. No separate Measurement for payment will be made for the lump sum bid item.

3. Payment will be made at the contract lump sum price.

END OF SECTION 01 27 00

HOSP - 207691 01 31 00 - 1

PROJECT MANAGEMENT AND COORDINATION

2021/03/24

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Coordination Drawings.

5. Requests for Information (RFIs).

6. Project meetings.

7. Environmental Coordination.

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

1.2 DEFINITIONS

A. Agency with Jurisdiction

B. Construction Permits – Contractor Provided

C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

3. Make adequate provisions to accommodate items scheduled for later installation.

140P6221B0004 Attachment 1 http://www.nps.gov/dscw/definitionsdc_a.htm#awj http://www.nps.gov/dscw/definitionsdc_c.htm#cpcp http://www.nps.gov/dscw/definitionsdc_g.htm#gfperm

HOSP - 207691 01 31 00 - 2

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Project closeout activities.

1.4 SUBMITTALS

A. Coordination Drawings: Prepare Coordination Drawings if limited space availability necessitates maximum utilization of space for efficient installation of different components or if coordination is required for installation of products and materials fabricated by separate entities.

1. Content: Project-specific information, drawn accurately to scale. Do not base

Coordination Drawings on reproductions of the Contract Documents or standard printed data. Include the following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on the Contract Drawings and make specific note of dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to the Contracting Officer (CO) for resolution of such conflicts.

c. Indicate space requirements for routine maintenance and for anticipated replacement of components during the life of the installation.

d. Show location and size of access doors required for access to concealed dampers, valves, and other controls.

e. Indicate required installation sequences.

2. Sheet Size: At least 8-1/2 by 11 inchesbut no larger than 22 by 34 inches.

3. Number of Copies: Submit two opaque copies of each submittal. Contracting Officer will return one copy.

HOSP - 207691 01 31 00 - 3

4. Refer to individual Sections for Coordination Drawing requirements for Work in those

Section

B. Coordination Drawing Organization: Organize coordination drawings as follows:

1. Floor Plans and Reflected Ceiling Plans: Show architectural and structural elements, and mechanical, plumbing, fire-protection, fire-alarm, and electrical Work. Show locations of visible ceiling-mounted devices relative to acoustical ceiling grid. Supplement plan drawings with section drawings where required to adequately represent the Work.

2. Plenum Space: Indicate subframing for support of ceiling and wall systems, mechanical and electrical equipment, and related Work. Locate components within ceiling plenum to accommodate layout of light fixtures indicated on Drawings. Indicate areas of conflict between light fixtures and other components.

3. Mechanical Rooms: Provide coordination drawings for mechanical rooms showing plans and elevations of mechanical, plumbing, fire-protection, fire-alarm, and electrical equipment.

4. Structural Penetrations: Indicate penetrations and openings required for all disciplines.

5. Mechanical and Plumbing Work: Show the following:

a. Sizes and bottom elevations of ductwork, piping, and conduit runs, including insulation, bracing, flanges, and support systems.

b. Dimensions of major components, such as dampers, valves, diffusers, access doors, cleanouts and electrical distribution equipment.

c. Fire-rated enclosures around ductwork.

6. Electrical Work: Show the following:

a. Runs of vertical and horizontal conduit 3/4 inches in diameter and larger.

b. Light fixture, exit light, emergency battery pack, smoke detector, and other fire-alarm locations.

c. Panel board, switch board, switchgear, transformer, busway, generator, and motor control center locations.

d. Location of pull boxes and junction boxes, dimensioned from column center lines.

7. Review: Contracting Officer Representative (COR) will review coordination drawings to confirm that the Work is being coordinated, but not for the details of the coordination, which are Contractor's responsibility. If COR determines that coordination drawings are not being prepared in sufficient scope or detail, or are otherwise deficient, CO will so inform Contractor, who shall make changes as directed and resubmit.

8. Coordination Drawing Prints: Prepare coordination drawing prints according to requirements in Section 01 33 23 "Submittal Procedures."

C. Coordination Digital Data Files: Prepare coordination digital data files according to the following requirements:

1. File Preparation Format: Same digital data software program, version, and operating system as original Drawings.

2. File Preparation Format: AutoCad.dwg, Version 2018, operating in Microsoft Windows operating system.

3. File Submittal Format: Submit or post coordination drawing files using Portable

Document Format (PDF) file format.

HOSP - 207691 01 31 00 - 4

4. Contracting Officer (CO) will furnish Contractor one set of digital data files

(AutoCad.dwg) of Drawings for use in preparing coordination digital data files.

a. CO makes no representations as to the accuracy or completeness of digital data files as they relate to Drawings.

b. Digital Data Software Program: Drawings are available in AutoCad.dwg.

D. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Indoor Air Quality (IAQ) Management Plan.

11. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

E. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to

Proceed will not be issued, and the Contracting Officer will consider other contractual remedies.

Work shall not commence until written Notice to Proceed has been issued.

1.5 REQUESTS FOR INFORMATION (RFIS)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI utilizing the form provided by CO during the preconstruction meeting.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

HOSP - 207691 01 31 00 - 5

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond. CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract

Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

HOSP - 207691 01 31 00 - 6

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. Acceptance/rejection of work.

17. Progress meetings.

18. Submittal procedures.

19. As-constructed drawings/operation and maintenance (O&M) manuals.

20. Saturday, Sunday, holiday and night work.

21. Reference materials.

22. Value engineering.

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the

Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings.

All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

HOSP - 207691 01 31 00 - 7

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of agency(ies) with jurisdiction.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the

Work and reconvene the conference at earliest feasible date.

1.7 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the

Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a. Compliance with applicable Federal, State, and local environmental regulations, including maintaining required documentation.

b. Implementation of the Waste Management Plan(WMP).

c. Implementation of the Indoor Air Quality (IAQ) Management Plan.

d. Present an overview of environmental issues and summarize site specific procedures relating to management plans at the Preconstruction conference.

HOSP - 207691 01 31 00 - 8

e. Training for Contractor personnel in accordance with their position requirements.

f. Monitoring and documentation of environmental procedures.

B. Perform project quality control in accordance with requirements specified in Related Sections, including:

1. Quality Requirements.

2. Regulatory Requirements.

3. Indoor Air Quality (IAQ) Management.

4. Noise & Acoustics Management.

5. Construction Waste Management.

C. Contractor’s Environmental Training Program: Contractor shall provide environmental training for workers performing work on the project site. Training shall include the following:

1. Overview of environmental issues related to the building industry.

2. Overview of environmental issues related to the Project.

3. Review of site specific procedures and management plans:

a. Construction Waste Management.

b. Indoor Air Quality (IAQ) Management.

c. Noise & Acoustics Management.

4. Compliance with environmental regulations: As specified in Regulatory Requirements.

Submit Contractor 40 CFR employee training records upon request of Contracting

Officer.

D. Provide documentation for environmental procedures as specified herein and in accordance with approved Waste Management Plan, IAQ Management Plan, and Storm Water Pollution

Prevention Plan.

1.8 PERMITS

A. General:

1. Permits and Responsibilities: The Contractor shall, without additional expense to the

Government, be responsible for obtaining any necessary licenses and permits, and for complying with any Federal, State and municipal laws, codes, and regulations applicable to the performance of the work. The Contractor shall also be responsible for all damages to persons or property that occur as a result of the Contractor’s fault or negligence. The

Contractor shall also be responsible for all materials delivered and work performed until completion and acceptance of the work.

2. For the purpose of this contract the Contractor will not be considered an agent of the

Government. Therefore the Contractor will comply with the appropriate Federal, State and local laws.

HOSP - 207691 01 31 00 - 9

B. Potential Permits: The permits listed below were identified during the design process as likely to be required based on typical means and methods of construction. The list is provided to assist the contractor in determining which permits will be required for the contract’s chosen means and methods. The list shall not be considered complete, as it is the responsibility of the contractor to determine means and methods, and obtain the required permits. It is the responsibility of the Contractor to obtain all permits required to legally conduct the work.

C. Coordination with Agency(ies) with Jurisdiction Issuing Permits

1. Coordination: Contact the Agency(ies) with Jurisdiction as needed and sufficiently in advance to avoid delaying the work: Coordinate meetings, reporting requirements, inspections, or any other requirements.

D. Administrative Procedures:

1. Coordinate scheduling and timing of required administrative provisions of project permits with Agency(ies) with Jurisdiction, Construction Manager, and Park to avoid conflicts and to ensure orderly execution of the Work.

2. Supply all needed information to Agency(ies) with Jurisdiction issuing permits, pay any fees required and provide all material needed to comply with the permit’s conditions and provisions.

3. Provide permits to the CO once permits are obtained.

PART 2 - PRODUCTS (NOT USED)

PART 3 - EXECUTION (NOT USED)

END OF SECTION 01 31 00

HOSP - 207691 01 32 16 - 1

CONSTRUCTION SCHEDULE

2021/03/24

SECTION 01 32 16 - CONSTRUCTION SCHEDULE

PART 1 - GENERAL

1.1 SUMMARY

A. This Section consists of Construction Schedule requirements including but not limited to the following:

1. Schedule of Values

2. Construction Schedule Requirements.

3. Construction Schedule Updates.

4. Time Impact Analysis.

B. Purpose: The purpose of the Construction Schedule is to ensure adequate planning, coordination, scheduling, and reporting during execution of the work by the Contractor. The

Construction Schedule will assist the Contractor and Contracting Officer in monitoring the progress of the work, evaluating proposed changes, and processing the Contractor's monthly progress payment.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical activities are activities on the critical path. They must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

B. Cost Loading: The allocation of the Schedule of Values for the completion of an activity as scheduled. The sum of costs for all activities must equal the total Contract Sum, unless otherwise approved by the Contracting Officer.

C. CPM: Critical path method, which is a method of planning and scheduling a construction project where activities are arranged based on activity relationships. Network calculations determine when activities can be performed and the critical path of Project.

D. Critical Path: The longest connected chain of interdependent activities through the network schedule that establishes the minimum overall Project duration and contains no float.

E. Float: The measure of leeway in starting and completing an activity.

1. Float: Float is not for the exclusive use or benefit of either the Government or the

Contractor but is jointly owned.

HOSP - 207691 01 32 16 - 2

2. Free float is the amount of time an activity can be delayed without adversely affecting the early start of the successor activity.

3. Total float is the measure of leeway in starting or completing an activity without adversely affecting the planned Project completion date.

F. Resource Loading: The allocation of manpower and equipment necessary for the completion of an activity as scheduled.

G. Fragnet: A partial or fragmentary network that breaks down activities into smaller activities for greater detail.

1.3 SUBMITTALS

A. Electronic Copies: All schedules and reports submitted shall be provided electronically to the

CO, provided in the native electronic file format. It is the intent of the Government to limit the number of printed reports to only those reports determined by the project team to be essential.

B. Schedule of Values: After contract award and before the Pre-Construction conference submit a schedule of dollar values based on the Contract Price Schedule.

C. Construction Baseline Schedule: After contract award and before the Pre-Construction conference, submit two paper copies or electronic copy of baseline schedule, large enough to show entire schedule for entire construction period.

D. CPM Reports: Concurrent with CPM schedule, submit two paper copies or electronic copy of each of the following computer-generated reports. Format for each activity in reports shall contain activity number, activity description, resource loading, original duration, remaining duration, early start date, early finish date, late start date, late finish date, and total float in calendar days.

1. Activity…