SECTION_F_-__Riverside.docx
DOCX document 13 KB Posted
- Attached to
- End-product contract for continued fire remote-sensing data collection with Contractor-owned, air-borne FireMapper 2. 0 sensor Federal contract opportunity
- Solicitation number
- AG-9AD6-S-16-0007
About this file
Deliveries or Performance
View the file
Other files for this federal contract opportunity
| File | Type | Posted |
|---|---|---|
| Section_G_-_Riverside.docx | DOCX document | |
| Riverside_SF1449-12a2.pdf | ||
| Statement_of_Work_fy16_2_end_product_contractor_fire_remote_sensing.pdf | ||
| Part_II_-_Section_I_-_Contract_Clauses.docx | DOCX document | |
| PART_IV_.docx | DOCX document | |
| SECTION_L_-__Riverside_.docx | DOCX document |
On GovTribe
Work with this file on GovTribe
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
SECTION F – DELIVERIES OR PERFORMANCE
CLAUSES INCORPORATED BY REFERENCE ((FAR 52.252-2)(FEB 1998)
This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):
www.acquisition.gov/far/
FEDERAL ACQUISITION REGULATION 948 CFR CHAPTER 1) CLAUSES
FAR 52.242-14 Suspension of Work (APR 1984) FAR 52.242-15 Stop Work Order (AUG 1989)
PERIOD OF PERFORMANCE (AGAR 452.211-74)(FEB 1988)
The period of performance of this contract is from award date through __31 August, 2017.__________________.
Work Timing Delays due to normal adverse weather, weekends, and holidays have been included in the calculation of contract time.
File details come from the government source that posted it. Updated .