SOL - AG-4741-S-10-12.pdf

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

���62/,&,7$7,21�12� ���7<3(�2)�62/,&,7$7,21

6($/('�%,'��,)%�

1(*27,$7('��5)3�

���'$7(�,668(' 3$*(�����2)�����3$*(6

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

���,668('�%< &2'( ���$''5(66�2))(5�72

9. FOR INFORMATION

CALL:

D��1$0( E��7(/(3+21(�12���,QFOXGH�DUHD�FRGH���12�&2//(&7�&$//6�

62/,&,7$7,21

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

����7+(�*29(510(17�5(48,5(6�3(5)250$1&(�2)�7+(�:25.�'(6&5,%('�,1�7+(6(�'2&80(176��7LWOH��LGHQWLI\LQJ�QR���GDWH�

����7KH�&RQWUDFWRU�VKDOO�EHJLQ�SHUIRUPDQFH FDOHQGDU�GD\V�DQG�FRPSOHWH�LW�ZLWKLQ FDOHQGDU�GD\V�DIWHU�UHFHLYLQJ

QRWLFH�WR�SURFHHG���7KLV�SHUIRUPDQFH�SHULRG�LVDZDUG� PDQGDWRU\ QHJRWLDEOH����6HH ��

��D� 7+(�&2175$&725�0867�)851,6+�$1<�5(48,5('�3(5)250$1&(�$1'�3$<0(17�%21'6"

�,I��<(6���LQGLFDWH�ZLWKLQ�KRZ�PDQ\�FDOHQGDU�GD\V�DIWHU�DZDUG�LQ�,WHP���E��

<(6 12

��E��&$/(1'$5�'$<6

����$'',7,21$/�62/,&,7$7,21�5(48,5(0(176�

G� 2IIHUV�SURYLGLQJ�OHVV�WKDQ FDOHQGDU�GD\V�IRU�*RYHUQPHQW�DFFHSWDQFH�DIWHU�WKH�GDWH�RIIHUV�DUH�GXH�ZLOO�QRW�EH�FRQVLGHUHG�DQG�ZLOO�EH

UHMHFWHG�

F� $OO�RIIHUV�DUH�VXEMHFW�WR�WKH�����ZRUN�UHTLXUHPHQWV��DQG�����RWKHU�SURYLVLRQV�DQG�FODXVHV�LQFRUSRUDWHG�LQ�WKH�VROLFLWDWLRQ�LQ�IXOO�WH[W�RU�E\

E� $Q�RIIHU�JXDUDQWHH LV� LV�QRW�UHTXLUHG�

D���6HDOHG�RIIHUV�LQ�RULJLQDO�DQG FRSLHV�WR�SHUIRUP�WKH�ZRUN�UHTXLUHG�DUH�GXH�DW�WKH�SODFH�VSHFLILHG�LQ�,WHP���E\ �KRXU�

ORFDO�WLPH �GDWH����,I�WKLV�LV�D�VHDOHG�ELG�VROLFLWDWLRQ��RIIHUV�ZLOO�EH�SXEOLFO\�RSHQHG�DW�WKDW�WLPH���6HDOHG�HQYHORSHV

FRQWDLQLQJ�RIIHUV�VKDOO�EH�PDUNHG�WR�VKRZ�WKH�RIIHURU

V�QDPH�DQG�DGGUHVV��WKH�VROLFLWDWLRQ�QXPEHU��DQG�WKH�GDWH�DQG�WLPH�RIIHUV�DUH�GXH�

161����������������� 67$1'$5'�)250�������5(9�������

3UHVFULEHG�E\�*6$���)$5�����&)5�����������G�

���&2175$&7�12� ���5(48,6,7,21�385&+$6(�5(48(67�12� ���352-(&7�12�

OFFER (Must be fully completed by offeror) ����7(/(3+21(�12���,QFOXGH�DUHD�FRGH�����1$0(�$1'�$''5(66�2)�2))(525��,QFOXGH�=,3�&RGH�

����5(0,77$1&(�$''5(66��,QFOXGH�RQO\�LI�GLIIHUHQW�WKDQ�,WHP�����

&2'( )$&,/,7<�&2'(

��� 7KH�RIIHURU�DJUHHV�WR�SHUIRUP�WKH�ZRUN�UHTXLUHG�DW�WKH�SULFHV�VSHFLILHG�EHORZ�LQ�VWULFW�DFFRUGDQFH�ZLWK�WKH�WHUPV�RI�WKLV�VROLFLWDWLRQ��LI�WKLV�RIIHU�LV�DFFHSWHG

E\�WKH�*RYHUQPHQW�LQ�ZULWLQJ�ZLWKLQ FDOHQGDU�GD\V�DIWHU�WKH�GDWH�RIIHUV�DUH�GXH����,QVHUW�DQ\�QXPEHU�HTXDO�WR�RU�JUHDWHU�WKDQ�WKH�PLQLPXP�UH��

TXLUHPHQW�VWDWHG�LQ�,WHP���G���)DLOXUH�WR�LQVHUW�DQ\�QXPEHU�PHDQV�WKH�RIIHURU�DFFHSWV�WKH�PLQLPXP�LQ�,WHP���G��

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

'$7(�

��D� 1$0(�$1'�7,7/(�2)�3(5621�$87+25,=('�72�6,*1�2))(5��7\SH�RU�

SULQW�

����6,*1$785( ��F��2))(5�'$7(

AWARD (To be completed by Government) ����,7(06�$&&(37('�

����$02817 ����$&&2817,1*�$1'�$335235,$7,21�'$7$

����68%0,7�,192,&(6�72�$''5(66�6+2:1�,1

���FRSLHV�XQOHVV�RWKHUZLVH�VSHFLILHG�

,7(0 ����27+(5�7+$1�)8//�$1'�23(1�&203(7,7,21�38568$17�72

���8�6�&�������F� � ���8�6�&������F��� �

����$'0,1,67(5('�%< ����3$<0(17�:,//�%(�0$'(�%<

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

��D� 1$0(�$1'�7,7/(�2)�&2175$&725�25�3(5621�$87+25,=('�72�6,*1�

�7\SH�RU�SULQW�

����1(*27,$7('�$*5((0(17��&RQWUDFWRU�LV�UHTXLUHG�WR�VLJQ�WKLV

GRFXPHQW�DQG�UHWXUQ FRSLHV�WR�LVVXLQJ�RIILFH����&RQWUDFWRU�DJUHHV

WR�IXUQLVK�DQG�GHOLYHU�DOO� LWHPV�RU�SHUIRUP�DOO�ZRUN�UHTXLUHPHQWV�LGHQWLILHG�RQ�WKLV IRUP�DQG�DQ\�FRQWLQXDWLRQ�VKHHWV�IRU�WKH�FRQVLGHUDWLRQ�VWDWHG�LQ�WKLV�FRQWUDFW���7KH ULJKWV�DQG�REOLJDWLRQV�RI� WKH�SDUWLHV�WR�WKLV�FRQWUDFW�VKDOO�EH�JRYHUQHG�E\��D��WKLV FRQWUDFW� DZDUG�� �E�� WKH� VROLFLWDWLRQ�� DQG� �F�� WKH� FODXVHV�� UHSUHVHQWDWLRQV� FHUWLILFDWLRQV�� DQG� VSHFLILFDWLRQV� LQFRUSRUDWHG� E\� UHIHUHQFH� LQ� RU� DWWDFKHG� WR� WKLV

FRQWUDFW�

����$:$5'��&RQWUDFWRU�LV�QRW�UHTXLUHG�WR�VLJQ�WKLV�GRFXPHQW����<RXU�RIIHU

RQ�WKLV�VROLFLWDWLRQ�LV�KHUHE\�DFFHSWHG�DV�WR�WKH�LWHPV�OLVWHG���7KLV�DZDUG�FRQVXPPDWHV WKH�FRQWUDFW��ZKLFK�FRQVLVWV�RI��D��WKH�*RYHUQPHQW�VROLFLWDWLRQ�DQG�\RXU�RIIHU��DQG��E�

WKLV�FRQWUDFW�DZDUG���1R�IXUWKHU�FRQWUDFWXDO�GRFXPHQW�LV�QHFHVVDU\�

��D��1$0(�2)�&2175$&7,1*�2)),&(5��7\SH�RU�SULQW�

��E��6,*1$785( ��F��'$7( ��E��81,7('�67$7(6�2)�$0(5,&$ ��F��'$7(

67$1'$5'�)250�������5(9��������%$&.

AG-4741-S-10-12 3

Section B

PART I - THE SCHEDULE

SECTION B - SUPPLIES OR SERVICES AND PRICES/COSTS

B.1. BID SCHEDULE

Item Spec. Unit No. Supplies/Services No. Quantity Unit Price Amount

1. Mobilization & Demobilization 8. 1 Job XXXXX $____________

2. Clearing & Grubbing 2. 1 Job XXXXX $____________

3. Pollution Control, Silt Fence 5. 1,050 L.F. $________ $____________

4. Pollution Control, Erosion Control Rock 5. 171 Ton $________ $____________

5. Pollution Control, Storm Water Pollution Prevention Plan 5. 1 Job XXXXX $____________

6. Pollution Control, Gradient Treatment 5. 1 Acre XXXXX $____________

7. Protective Cover, Vegetation 6. 2 Acre XXXXX $____________

8. Construction Surveys 7. 1 Job XXXXX $____________

9. Removal of Water 11. 1 Job XXXXX $____________

10. Excavation Common, Rock Riprap Chutes 21. 6,919 C.Y. $________ $____________

11. Earthfill, Class C 23. 5,141 C.Y. $________ $____________

12. Sand Bedding, Chutes 24. 910 Ton $________ $____________

13. Rock Riprap, Chutes 61. 6,942 Ton $________ $____________

14. Geotextile, Nonwoven 95. 4,554 S.Y. $________ $____________

15. Construction Access Road 435. 1 Job XXXXX $____________

AG-4741-S-10-12 4

B.1. BID SCHEDULE – Continued

16. Drainfill, Fine 24. 51 Ton $________ $____________

17. Drainfill, Coarse 24. 13 Ton $________ $____________

18. Corrugated Aluminum Riser – 30” 51. 1 Job $________ $____________

19. Corrugated Aluminum Pipe – 24” 51. 102 L.F. $________ $____________

TOTAL BID $ ________________________

B.2. AWARD RESTRICTION (NRCS, AMB) (Aug 1987)

One award for the aggregate of all items will be made under this solicitation.

AG-4741-S-10-12 5

SECTION C - DESCRIPTION/SPECIFICATIONS/WORK STATEMENT

C.1. AGAR 452-211-72 STATEMENT OF WORK/SPECIFICATIONS FEB 1988)

The contractor shall furnish the necessary personnel, material, equipment, services and facilities (except as otherwise specified) to perform the installation of a 250 feet long, 10-foot tall rock riprap grade stabilization structure in Cane Creek below Highway 19 bridge in Ripley, TN. The riprap will consist of the placement of large rock riprap (D50=24”) to form a chute with a bottom width dimension of 55 feet and 2:1 side slopes. The chute will consist of a 65-foot level entrance section, a 165-foot sloped section, and a 31-foot level section at the exit. The volume of rock to be placed will be approximately 7,000 tons. Work will be accomplished by diverting creek flow around the work area, in accordance with the following specifications and drawings:

CONSTRUCTION SPECIFICATIONS:

Number Title

2 Clearing and Grubbing 3 Structure Removal 5 Pollution Control

6 Seeding, Sprigging and Mulching 7 Construction Surveys 8 Mobilization and Demobilization

10 Water for Construction 11 Removal of Water 21 Excavation 23 Earthfill 24 Drainfill 32 Structure Concrete 34 Steel Reinforcement 51 Corrugated Metal Pipe 61 Rock Riprap 81 Metal Fabrication 95 Geotextile 435 Construction Access Roads

MATERIAL SPECIFICATIONS

521 Aggregates for Drainfill and Filters 522 Aggregates for Portland Cement Concrete 523 Rock for Riprap 531 Portland Cement 532 Mineral Admixtures for Concrete 533 Chemical Admixtures for Concrete 534 Concrete Curing Compound 539 Steel Reinforcement

AG-4741-S-10-12 6

MATERIAL SPECIFICATIONS

552 Aluminum Corrugated Pipe 581 Metal 582 Galvanizing 592 Geotextile

DRAWINGS

Cane Creek Watershed – Highway 19 Bridge – Stabilization Structure Lauderdale County, TN Sheets 1 through 9

C.2. AGAR 452.211-73 ATTACHMENTS TO STATEMENT OF WORK/SPECIFICATIONS

(FEB 1988)

The attachments to the Statement of Work/Specifications listed in Section J are hereby made part of this solicitation and any resultant contract.

AG-4741-S-10-12 7

SECTION D - PACKAGING AND MARKING

THERE ARE NO CLAUSES INCLUDED IN THIS SECTION

AG-4741-S-10-12 8

SECTION E - INSPECTION AND ACCEPTANCE

E.1 52.246.12 Inspection of Construction (Aug 1995)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not—

(1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance;

(3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes re-inspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

AG-4741-S-10-12 9

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

AG-4741-S-10-12 10

SECTION F - DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 150 calendar days after receipt of the notice to proceed. The time stated for completion shall include final cleanup of the premises.

F.2 52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

F.3 52-242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

AG-4741-S-10-12 11

SECTION G - CONTRACT ADMINISTRATION DATA

G.1 DESIGNATED PAYMENT OFFICE CONTACT POINT (SCS, AMB) (AUGUST 1989)

The contact point described below coordinates the issuance of payments under this contract. If payment is not received within 30 days after the due date specified in the contract, contact the payment office designated below for information on when payment will be made or questions arise on the amount paid, contact:

Patty Lane, Contracting Officer Email - patty.lane@tn.usda.gov

Telephone No. - (615) 277-2544 Natural Resources Conservation Service 675 U. S. Courthouse Nashville, TN 37203

AG-4741-S-10-12 12

SECTION H - SPECIAL CONTRACT REQUIREMENTS

H.1 AGAR 452.215-73 POST AWARD CONFERENCE (NOV 1996) (NRCS-TN-Variation)

A post award conference will be held with the successful offeror is required. A date and time will be agreed upon prior to commencement of work.

H.2. AGAR 452.236-73 ARCHAEOLOGICAL OR HISTORIC SITES (FEB 1988)

If a previously identified archaeological or historic site(s) is encountered, the contractor shall discontinue work in the general area of the site(s) and notify the Contracting Officer immediately.

H.3 AGAR 452.236-74 CONTROL OF EROSION, SEDIMENTATION, AND POLLUTION

(NOV 1996)

(a) Operations shall be scheduled and conducted to minimize erosion of soils and to prevent silting and muddying of streams, rivers, irrigation systems, and impoundments (lakes, reservoirs, etc.).

(b) Pollutants such as fuels, lubricants, bitumen, raw sewage, and other harmful materials shall not be discharged on the ground; into or nearby rivers, streams, or impoundments; or into natural or man-made channels. Wash water or waste from concrete or aggregate operations shall not be allowed to enter live streams prior to treatment by filtration, settling, or other means sufficient to reduce the sediment content to not more than that of the stream into which it is discharged.

(c) Mechanized equipment shall not be operated in flowing streams without written approval by the Contracting Officer.

H.4 AGAR 452.236-75 MAXIMUM WORKWEEK – CONSTRUCTION SCHEDULE (NOV 1996)

Within five (5) calendar days after receipt of a written request from the Contracting Officer, the Contractor must submit the following in writing for approval.

(a) A schedule as required by FAR clause 52.236-15, Schedules for Construction Contracts, and

(b) The hours (including daily starting and stopping times) and the days of the week that the

Contractor proposes to carry out the work.

(c) The maximum workweek that will be approved is 24 hours per day, 7 days per week.

H.5 WORK PERFORMANCE ON HOLIDAYS (NRCS-TN)

The Contractor shall not perform work on the following holidays except in the case of emergency as permitted elsewhere in this contract:

Independence Day Labor Day Thanksgiving Day Christmas Day New Year's Day

The contract performance time has been established to allow for the non-working holidays stated above.

AG-4741-S-10-12 13

The Contractor may be permitted to work the following remaining designated Federal holidays provided that he/she submits a letter of request to the Contracting Officer at least five (5) days in advance of the holiday.

Columbus Day Veterans Day Washington's Birthday Martin Luther King, Jr.'s Birthday Memorial Day

H.6 COMPLIANCE WITH OPEN BURNING LAW (NRCS-TN)

Between October 15 and May 15, inclusive the contractor shall obtain a valid burning permit number from the Tennessee Division of Forestry in accordance with Tennessee Code Annotated Section 39-14- 306 prior to any open burning at the site. Permits are not issued more than three (3) days prior to the burn date and all permits expire three (3) days after issuance. The contractor shall furnish the Contracting Officer’s Technical Representative (COTR) or Government Inspector the burning permit number prior to starting any opening burning at the site.

Burning permit numbers may be obtained by calling the Tennessee Division of Forestry listed in the local telephone directory. The information required in the burner's name, location and planned burning time.

H.7 EQUIPMENT RATES (NRCS-TN)

As stated in Part 31 of the Federal Acquisition Regulation, allowable ownership and operating cost shall be determined from actual cost data when such data can be determined for both ownership and operations for each piece of equipment from the contractor's accounting records. When such costs cannot be so determined, the Contractor's Equipment Cost Guide, published by Dataquest, 1290 Ridder Park Drive, San Jose, California 95131, in cooperation with the Associated General Contractors of America, shall be used to determine ownership and/or operating costs of such construction equipment. This clause does not otherwise change any of the contract cost principles and procedures or any other part of the Federal Acquisition Regulation.

H.8 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (NSCS, AMB) (JULY 1993)

(a) This clause specifies the procedures for determination o time extensions for unusually severe weather in accordance with the FAR Clause 52.249-10 DEFAULT (Fixed Price Construction). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

(1) The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

AG-4741-S-10-12 14

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the baseline for monthly weather time evaluations. The Contractor's progress schedule must reflect those anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS BASED ON A FIVE DAYWORK WEEK:

January February March April May June July 29 days 26 days 24 days 24 days 12 days 9 days 9 Days

August September October November December 9 Days 8 days 8 days 15 days 24 days

(c) Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay must prevent work on critical activities for fifty

(50) percent or more of the contractor's scheduled work day. The number of actual adverse weather days shall include days impacted by actual adverse weather (even if adverse weather occurred in the previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph (b) above, the contractor may submit a written request for a modification for extension of performance time due to unusually severe weather. The Contracting Officer will convert any qualifying delays into calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with FAR clause 52.249-10, Default (Fixed Price Construction).

H.9 NATURAL RESOURCES CONSERVATION SERVICE SUPPLEMENT TO OSHA PARTS 1910 and 1926

CONSTRUCTION INDUSTRY AND INTERPRETATIONS

The contractor shall comply with OSHA (Occupational Safety and Health Administration) Parts 1910 and 1926, Construction Industry Standards and Interpretations, and with this supplement.

Requests for variances or waivers from this supplement are to be made to the contracting officer in writing supported by evidence that every reasonable effort has been made to comply with the contractual requirements. A written request for a waiver or a variance shall include--

(1) Specific reference to the provision or standard in question

(2) An explanation as to why the waiver is considered justified

(3) The contractor's proposed alternative, including technical drawings, materials, or equipment specifications needed to enable the contracting officer to render a decision.

No waiver or variance will be approved if it endangers any person. The contractor shall not proceed under any requested revision of a provision until the contracting officer has given written approval.

The contractor is to hold and save harmless the Natural Resources Conservation Service free from any claims or causes of action whatsoever resulting from the contractor or subcontractors proceeding under a waiver or approved variance.

AG-4741-S-10-12 15

Copies of OSHA Part 1910 and 1926, Construction Industry Standards and Interpretations, may be obtained from:

Superintendent of Documents U. S. Government Printing Office, Washington, D.C. 20402

GENERAL CONTRACTOR REQUIREMENTS

1.1 SAFETY PROGRAM. Each contractor is to demonstrate that he or she has the facilities for conducting a safety program commensurate with the work under the contract. The contractor is to submit in w safety program to the contracting officer for approval before the start of construction operations. The program is to specifically state what provisions the contractor proposes to take for the health and safety of

All employees.

1.2 PRECONSTRUCTION SAFETY MEETING. Representatives for the contractor are to meet with the contracting officer (CO) or the CO's representative before the start of construction to discuss the safety program and the implementation of all health and safety standards pertinent to the work under this contract.

1.3 JOINT SAFETY POLICY COMMITTEE. The contractor or designated onsite representative is to participate in monthly meetings of a Joint Safety Committee, composed of Natural Resources Conservation Service and contractor supervisory personnel. At these meetings the contractor's project manager and the Contracting Officer will review the effectiveness of the contractor's safety effort, resolve current health and safety problems, and coordinate safety activities for upcoming work.

1.4 SAFETY PERSONNEL. Each contractor is to designate a competent supervisory employee satisfactory to the Contracting officer to administer the safety program.

1.5 SAFETY MEETINGS. A minimum of one "one-the-job" or "toolbox" safety meeting is to be conducted each week by all field supervisors for all construction personnel at the job site. The contractor is to also conduct regularly scheduled supervisory safety meetings at least monthly for all levels of job supervision.

1.6 SAFETY INSPECTION. The contractor shall perform frequent and regular safety inspections of the jobsite, materials, and equipment, and shall correct deficiencies.

1.7 FIRST AID TRAINING. Every contractor foreman's work crew must include an employee who has a current first aid certificate from the Mine Safety and Health Administration, American Red Cross, or other state-approved organization.

1.8 REPORTS. Each contractor is to maintain an accurate record of all job related deaths, diseases, or disabling injuries. The records shall be maintained in a manner approved by the contracting officer. A copy of all reports is to be provided to the contracting officer. All fatal or serious injuries are to be reported immediately to the contracting officer, and every assistance is to be given to the investigation of the incident, including submission of a comprehensive narrative report to the contracting officer.

Other occurrences with serious accident potential, such as equipment failures, slides and cave-ins, must also be reported immediately. The contractor is to assist and cooperate fully with the contracting officer in conducting accident investigations. The contracting officer is to be furnished all information and data pertinent to investigation of the accident.

FIRST-AID AND MEDICAL FACILITIES

2.1 FIRST AID KITS. A 16-unit first aid kit approved by the American Red Cross is to be provided at

AG-4741-S-10-12 16

accessible, well identified, locations at the ratio of at least 1 kit for each 25 employees. The first aid kits are to be moisture proof and dust tight, and the contents of the kits are to be replenished as used or as they become ineffective or outdated.

2.2 EMERGENCY FIRST AID. At least one employee certified to administer emergency first aid must be available on each shift and duly designated by the contractor to care for injured employees. The names of the certified employees shall be posted at the job site.

2.3 COMMUNICATION AND TRANSPORTATION. Prior to the start to work, the contractor is to make necessary arrangements for prompt and dependable communications, transportation, and medical care for injured employees. At least one stretcher and two blankets shall be readily available for transporting injured employees.

2.4 FIRST AID AND MEDICAL REPORTS. The contractor is to maintain a record system for first aid and medical treatment on the jobsite. Such records are to be readily available to the contracting officer and are to include:

(a) A daily treatment log listing chronologically all persons treated for occupational injuries and illnesses;

(b) Cumulative record of injury for each individual;

(c) Monthly statistical records of occupational injuries, classified by type and nature of injury; and

(d) Required records for worker's compensation.

2.5 SIGNS AND DIRECTIONAL MARKINGS. Adequate identification and directional markers are to be provided to readily denote the location of all first aid stations.

2.6 EMERGENCY LISTING. A listing of telephone numbers and addresses of doctor, rescue squad, hospital, police, and fire departments is to be provided at all first aid locations.

PHYSICAL QUALIFICATION OF EMPLOYEES

3.1 GENERAL REQUIREMENTS. Persons employed throughout the contract are to be physically qualified to perform their assigned duties. Employees must not knowingly be permitted or required to work while their ability or alertness is impaired by fatigue, illness, or other reason that may jeopardize themselves or others.

3.2 HOIST OPERATORS. Operators of cranes, cableways, and other, hoisting equipment shall be examined annually by a physician and provided with a certification stating that they are physically qualified to safely operate hoisting equipment. The contractor is to submit a copy of each certification to the contracting officer.

3.3 MOTOR VEHICLE OPERATORS. Operators of motor vehicles engaged primarily in the transportation of personnel are to be 18 years of age or older and have a valid state operator's permit or license for the equipment being operated. The operators must have passed a physical examination administered by a licensed physician within the part year showing that they are physically qualified to operate vehicles safely.

PERSONAL PROTECTIVE EQUIPMENT

4.1 HARDHAT AREAS. The entire jobsite, with the exception of offices, will be considered a hardhat area. All persons entering the area are, without exception, required to wear hardhats. The contractor shall provide hardhats to visitors entering hardhat areas.

4.1.1 LABELS. Hardhats shall bear a manufacturer's label indicating design compliance with the appropriate ANSI (American National Standards Institute) standard.

4.2 POSTING. Signs at least 3 by 4 feet worded as follows with red letters (minimum 6 inches high) with white background shall be erected at access points to designated hardhat areas:

AG-4741-S-10-12 17

CONSTRUCTION AREA -- HARDHATS REQUIRED BEYOND THIS POINT

These signs are to be furnished and installed by the contractor at entries to shops, construction yards, and job access points.

MACHINERY AND MECHANIZED EQUIPMENT

5.1 SAFE CONDITION. Before any machinery or mechanized equipment is initially used on the job, it must be inspected and tested by qualified personnel and determined to be in safe operating condition and appropriate for the intended use. Operators shall inspect their equipment prior to the beginning of each shift. Any deficiencies or defects shall be corrected prior to using the equipment. Safety equipment, such as seatbelts, installed on machinery is to be used by equipment operators.

5.2 TAGGING AND LOCKING. The controls of power-driven equipment under repair are to be locked.

An effective lockout and tagging procedure is to be established, prescribing specific responsibility and safety procedures to be followed by the persons performing repair work.

5.3 HAUL ROAD FOR EQUIPMENT

5.3.1 ROAD MAINTENANCE. The contractor shall maintain all roadways, including haul roads and access roads, in a safe condition so as to eliminate or control dust and ice hazards. Wherever dust is a hazard adequate dust-laying equipment shall be available at the jobsite and utilized to control dust.

5.3.2 SINGLE LANE HAUL ROADS. Single-lane haul roads with two-way traffic shall have adequate turnouts. Where turnouts are not practical, a traffic control system shall be provided to prevent accidents.

5.3.3 TWO-WAY HAUL ROADS. On two-way haul roads, arrangements are to be such that vehicles travel on the right side wherever possible. Signs and traffic control devices are to be employed to indicate clearly any variations from a right-hand traffic pattern. The road shall be wide enough to permit safe passage of opposing traffic, considering the type of hauling equipment used.

5.3.4 DESIGN AND CONSTRUCTION OF HAUL ROADS. Haul road design criteria and drawings, if requested by the contracting officer, are to be submitted for approval prior to road construction.

Sustained grades shall not exceed 12 percent and all curves shall have open-sight line with as great a radius as practical. All roads shall be posted with curve signs and maximum speed limits that will permit the equipment to be stopped within one-half the minimum sight distance.

5.3.5 OPERATORS. Machinery and mechanized equipment shall be operated only by authorized qualified persons.

5.3.6 RIDING ON EQUIPMENT. Riding on equipment by unauthorized personnel is prohibited. Seating and safety belts shall be provided for the operator and all passengers.

5.3.7 GETTING ON OR OFF EQUIPMENT. Getting on or off equipment while the equipment is in motion is prohibited.

5.3.8 HOURS OF OPERATION. Except in emergencies, an equipment operator shall not operate any mobile or hoisting equipment for more than 12 hours without an 8-hour rest interval away from the job.

5.4 POWER CRANES AND HOISTS (TRUCK CRANES, CRAWLER CRANES, TOWER CRANES, GANTRY

CRANES, HAMMERHEAD CRANES, DERRICKS, CABLEWAYS, AND HOISTS)

5.4.1 PERFORMANCE TEST. Before initial onsite operation, at 12-month intervals, and after major repairs or modification, power cranes, derricks, cableways, and hoists must satisfactorily complete a performance test to demonstrate the equipment's ability to safety handle and maneuver the rated loads. The tests shall be conducted in the presence of a representative of the contracting officer. Test data shall be recorded and a copy furnished the contracting officer.

5.4.2. PERFORMANCE TEST--POWER CRANES (Crawler mounted, truck mounted, and wheel

AG-4741-S-10-12 18

mounted). The performance test is to be carried out with outriggers set and with a test load weighing 110 percent of the rated load. In testing cableways the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.3. PERFORMANCE TEST--DERRICKS, GANTRY CRANES, TOWER CRANES, CABLEWAYS, AND

HOISTS, INCLUDING OVERHEAD CRANES. This equipment is to be performance tested with a test load weighing 110 percent of the rated load. In testing cableways, the test load is to be traveled to the upstream and downstream limits of travel and thoroughly performance tested in at least three travel positions, including both limits of travel.

5.4.4 BOOM ANGLE INDICTOR. Power cranes (includes draglines) with booms capable of moving in the vertical plane shall be provided with a boom angle indicator in good working order.

5.4.5 CRANE TEST CERTIFICATION. The performance test required by 5.4.2 and 5.4.3 is fulfilled if the contractor provides the contracting officer a copy of the certificate of inspection made within the past 12 months by a qualified person or by a government or private agency satisfactory to the contracting officer.

5.4.6 POSTING FOR HIGH VOLTAGE LINES. A notice of the 10-foot (or greater) clearance required by OSHA 1926.550, Subpart N, shall be posted in the operator's cab of cranes, shovels, boom-type concrete pumps, backhoes and related equipment.

5.4.7 BOOM STOPS. Cranes or derricks with cable-supported booms, except draglines, shall have a device attached between the gantry of the A-frame and the boom chords to limit the elevation of the boom. The device shall control the vertical motions of the boom with increasing resistance from 83 degrees or less, until completely stopping the boom not over 87 degrees above horizontal.

5.4.8 SAFETY HOOKS. Hooks used in hoisting personnel or hoisting loads over construction personnel or in the immediate vicinity of construction personnel shall be forged steel equipped with safety keepers. When shackles are used under these conditions, they shall be of the locking type or have the pin secured to prohibit turning.

5.5 ROLLOVER PROTECTIVE STRUCTURES (ROPS)

5.5.1 ROLLOVER PROTECTIVE STRUCTURES. OSHA 1926 Subpart W Overhead Protection Sections 1000 and 1002 are applicable regardless of the year in which the equipment was manufactured and regardless of the struck capacity of the equipment.

5.5.2 EQUIPMENT REQUIRING ROPS. The requirement for ROPS meeting 5.5.1 above applies to crawler and rubber-tired tractors such as dozers, push and pull tractors, winch tractors with backhoes, and mowers; off-highway, self-propelled, pneumatic-tired earthmovers, including cabs). These requirements shall also apply to agricultural and industrial tractors and similar equipment.

5.5.3 EQUIPMENT REQUIRING SEATBELTS. The requirements for seatbelts as specified in OSHA Subpart 0, Motor Vehicles, Mechanized Equipment, and Marine Operations, Section 1926.602 shall also apply to self-propelled compactors and rollers, and rubber-tired skid-steer equipment.

5.6 LADDERS AND SCAFFOLDING.

5.6.1 LADDERS. OSHA 1926, Subpart L - Section 450. Ladders shall be used as work platforms only when use of small hand tools or handling of light material is involved. No work requiring lifting of heavy materials or substantial exertion shall be done from ladders.

5.6.2 SCAFFOLDING. OSHA 1926, Subpart L - Section 451. Scaffolds, platforms or temporary floors shall be provided for all work except that which can be done safely from the ground or similar footing.

5.6.3 SAFETY BELTS, LIFELINE, AND LANDYARDS. OSHA 1926, Subpart E, Section 104. Lifelines, safety belts and lanyards independently attached or attended, shall be used when performing such work as the following when the requirements of 5.6.1 and 5.6.2 above cannot be met.

a. Work on stored material in hoppers, bins, silos, tanks or other confined spaces.

b. Work on hazardous slopes, structural steel, or poles; erection or dismantling of safety nets, AG-4741-S-10-12 19 typing reinforcing bars; and work from or other unguarded locations at elevations greater than 6 feet.

c. Work on skids and platforms used in shafts by crews when the skip or cage does not block the opening to within 1 foot of the sides of the shaft, unless cages are provided.

AG-4741-S-10-12 20

PART II - CONTRACT CLAUSES

SECTION I - CONTRACT CLAUSES

I.1. 52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov

I. FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.202-1 DEFINITIONS (JUL 2004)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (APR 1984)

52.203-7 ANTI-KICKBACK PROCEDURES (JUL 1995)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR

OR IMPROPER ACTIVITY (JAN 1997)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (SEP 2007)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS

(SEP 2007)

52.203-15 WHISTLEBLOWER PROTECTIONS UNDER THE AMERCIAN RECOVERY AND

REINVESTMENT ACT OF 2009 (MAR 2009)

52.204-4 PRINTED/COPIED DOUBLE-SIDED ON RECYCLED PAPER (AUG 2000)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH

CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (SEP 2006)

52.214-27 PRICE REDUCTION FOR DEFECTIVE COST OR PRICING DATA – MODIFICATIONS--

SEALED BIDDING (OCT 1997) – Applicable if contract award amounts exceeds $650,000

52.214-28 SUBCONTRACTOR COST OR PRICING DATA-MODIFICATIONS - SEALED BIDDING

(OCT 1997) Applicable if contract award amounts exceeds $650,000

52.214-29 ORDER OF PRECEDENCE – SEALED BIDDING {JAN 1986)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (MAY 2004)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (APR 2008)

ALTERNATE 1 (OCT 2001)

52.219-14 LIMITATIONS ON SUBCONTRACTING (DEC 1996)

52.219-28 POST AWARD SMALL BUSINESS (APR 2009)

52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)

52.222-3 CONVICT LABOR (JAN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT--OVERTIME COMPENSATION

(JUL 2005)

52.222-6 DAVIS-BACON ACT (JUL 2005)

52.222-7 WITHHOLDING OF FUNDS (FEB 1998)

52.222-8 PAYROLLS AND BASIC RECORDS (FEB 1998)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

AG-4741-S-10-12 21

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (JUL 2005)

52.222-12 CONTRACT TERMINATION – DEBARMENT (FEB 1998)

52.222-13 COMPLIANCE WITH DAVIS-BACON ANDRELATED ACT REGULATIONS (FEB 1988)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (FEB 1988)

52.22-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999)

52.222-26 EQUAL OPPORTNITY (MAR 2007)

52.222-35 AFFIRMATIVE ACTION FOR SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM

ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (JUN 1998)

52.222-37 EMPLOYMENT REPORTS ON SPECIAL DISABLED VETERANS, VETERANS OF THE VIETNAM

ERA, AND OTHER ELIGIBLE VETERANS (SEP 2006)

52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.227-1 AUTHORIZATION AND CONSENT (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-11 PLEDGES OF ASSETS (SEP 2009)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (OCT 1995)

52.228-14 IRREVOCABLE LETTER OF CREDIT (DEC 1999)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (APR 2003)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (SEP 2002)

52.232-17 INTEREST (OCT 2008)

52.232-23 ASSIGNMENT OF CLAIMS (JAN 1986)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (OCT 2008)

52.232-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER – OTHER THAN CENTAL CONTRACTOR

REGISTRATION (OCT 2009)

52.233-1 DISPUTES (JUL 2002) ALTERNATE 1 (DEC 2001)

52.233-3 PROTEST AFTER AWARD (AUG 1996)

52.233-4 APPLICABLE LAW FOR TREACH OF CONTRACT CLAIM (OCT 2004)

52.233-14 TOXIC CHEMICAL RELEASE REPORTING (AUG 2009)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES,

AND IMPROVEMENTS (APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991) ALTERNATE I (NOV 1991)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-16 QUANTITY SURVEYS (APR 1984) ALTERNATE 1 (APR 1984)

52.236-17 LAYOUT OF WORK (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997)

AG-4741-S-10-12 22

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.242-13 BANKRUPTCY (JUL 1995)

52.243-4 CHANGES (JUN 2007)

52.243-5 CHANGES AND CHANGED CONDITIONS (APR 1984)

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS (DEC 2009)

52.248-3 VALUE ENGINEERING – CONSTRUCTION (SEP 2006) ALTERNATE 1 (APR 1984)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (MAY 2004)

ALTERNATE I (SEP 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION)(APR 1984)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

I. 2 52.203-15 Whistleblower Protections Under The American Recovery And Reinvestment Act of 2009

(MAR 2009)

(a) The Contractor shall post notice of employees rights and remedies for whistleblower protections provided under section 1553 of the American Recovery and Reinvestment Act of 2009 (Pub. L. 111-5)

. (b) The Contractor shall include the substance of this clause including this paragraph (b) in all subcontracts.

I.3 52.204-7 Central Contractor Registration (Apr 2008)

(a) Definitions. As used in this clause—

“Central Contractor Registration (CCR) database” means the primary Government repository for Contractor information required for the conduct of business with the Government.

“Data Universal Numbering System (DUNS) number” means the 9-digit number assigned by Dun and

Bradstreet, Inc. (D&B) to identify unique business entities.

“Data Universal Numbering System +4 (DUNS+4) number” means the DUNS number assigned by D&B plus a

4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional CCR records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at

Subpart 32.11) for the same concern.

“Registered in the CCR database” means that—

(1) The Contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, into the CCR database; and

(2) The Government has validated all mandatory data fields, to include validation of the Taxpayer

Identification Number (TIN) with the Internal Revenue Service (IRS), and has marked the record “Active”.

The Contractor will be required to provide consent for TIN validation to the Government as a part of the

CCR registration process.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the CCR database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

http://www.arnet.gov/far/current/html/Subpart%2032_11.html%20/%20wp1043964�

AG-4741-S-10-12 23

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS +4” followed by the DUNS or DUNS +4 number that identifies the offeror’s name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the CCR database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number—

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and

Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the CCR database in the time prescribed by the Contracting

Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering.

Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) The Contractor is responsible for the accuracy and completeness of the data within the CCR database, and for any liability resulting from the Government’s reliance on inaccurate or incomplete data. To remain registered in the CCR database after the initial registration, the Contractor is required to review and update on an annual basis from the date of initial registration or subsequent updates its information in the CCR database to ensure it is current, accurate and complete. Updating information in the CCR does not alter the terms and conditions of this contract and is not a substitute for a properly executed contractual document.

(g)

(1)

(i) If a Contractor has legally changed its business name, “doing business as” name, or division name

(whichever is shown on the contract), or has transferred the assets used in performing the contract, but has not completed the necessary requirements regarding novation and change-of-name agreements in

Subpart 42.12, the Contractor shall provide the responsible Contracting Officer a minimum of one business day’s written notification of its intention to (A) change the name in the CCR database;

http://fedgov.dnb.com/webform� http://www.arnet.gov/far/current/html/Subpart%2042_12.html%20/%20wp1084217�

AG-4741-S-10-12 24

(B) comply with the requirements of Subpart 42.12 of the FAR; and (C) agree in writing to the timeline and procedures specified by the responsible Contracting Officer. The Contractor must provide with the notification sufficient documentation to support the legally changed name.

(ii) If the Contractor fails to comply with the requirements of paragraph (g)(1)(i) of this clause, or fails to perform the agreement at paragraph…