SupplySystem_Specs_WF_072916.docx

WEST FORK WATER SYSTEM REHABILITATION

LIST OF DRAWINGS AND TECHNICAL SPECIFICATIONS

LIST OF CONTRACT DRAWINGS

SD-1 STANDARD DETAILS

SD-5 WATER STORAGE TANK DETAILS – (OPTION 1 ITEM)

SD-6 EROSION CONTROL DETAILS

LIST OF TECHNICAL SPECIFICATIONS

AG-0343-S-16-0071

West Fork Water System Rehabilitation

DIVISION 1 – GENERAL REQUIREMENTS

SECTION 011000 SUMMARY OF WORK

GENERAL

Summary This project is located at West Fork Ranger Station, approximately 36 miles south of Hamilton, MT, just off the West Fork Rd. Darby is the largest town close to the site, and is 20 miles northeast.

Project Summary Description: The following descriptions are provided as an outline of major work items, and shall not be constructed as an inclusive or complete listing of all items of Work under this Contract.

0. Demolition: all existing electrical and plumbing equipment inside the existing pump house building, including removal of existing pump and drop pipe, and existing float system in the water storage tank.

Installation of new plumbing and electrical equipment in pump house, including new pump and drop pipe in existing well.

Installation of water supply line from existing pump house to existing water storage tank. Includes new tank entrance, and replacement of shut-off valve on overflow/drain line. Also includes installation of new control wires and power from water storage tank to pump house.

Drain and abandon existing water supply line as shown on drawings. Abandoned lines that conflict with proposed construction shall be removed as required. Abandoned lines not removed shall be capped at all open ends.

Includes clearing & grubbing, erosion control, and grading and seeding of all disturbed areas.

General site conditions and weather The elevation of the site is approximately 4,390 feet above mean sea level. The construction site experiences moderate snowfall and moderate to cold temperatures, with snow on the ground typically from December through April. Precipitation averages 15.72 inches per year, with average total snowfall of 39.8 inches, as measured at the weather station at Darby.

use of premises General: Contractor shall have limited use of premises for construction operations, including use of Project Site, during construction period. Contractor's use of premises is limited by the Government's right to perform work at the site. The bunkhouses and houses are normally occupied year round.

Contractor shall at all times conduct his operations to ensure the least inconvenience to the public and employees.

Confine storage of materials to areas as approved by the CO.

Contractor shall provide adequate signing and barricades and take necessary safety measures to protect the public during all construction operations. Contractor shall minimize disturbance of all undisturbed areas.

Preservation of Natural Features: Confine all operations to work limits of the project. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

Provide temporary barriers to protect existing trees and plants and root zones.

Do not remove, injure, or destroy trees or other plants without prior approval. Consult with CO and remove agreed-on roots and branches that interfere with construction.

Do not fasten ropes, cables, or guys to existing trees.

Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

Existing Utilities: Notify CO of proposed locations and times for excavation.

Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

Interruption of Existing Utility Service: Notify CO, 48 hours in advance of any interruption of existing utilities.

meals and lodging Meals and lodging are commercially available in Darby within 20 miles of the construction site. Meals will not be available at Forest Service facilities. Camping at nearby campgrounds may be allowed if approved camping Camping is not allowed at the construction site. Permission may be granted to camp at a nearby location.

field verification Field verify all new and existing dimensions affecting the work of this contract before ordering products Requirements of the Offerer’s proposal The Government Drawings and Specifications are the basis for this Contract.

The work shall conform to the Drawings as closely as possible. Those products listed in the Specifications are preferred products, chosen for compatibility, longevity, durability and quality. However, equal or better alternatives submitted by the Offerer will be considered.

permitting The Contractor shall be responsible for obtaining all permits and associated fees required to complete the project.

PRODUCTS (Not Used) EXECUTION (Not Used)

END SECTION

3 011000

SECTION 010250 CONSTRUCTION STAKING

1. GENERAL

0. Summary Specific construction staking is not required. Water supply and distribution lines shall follow the alignments identified in the plans and specifications. Deviations from alignments shown shall be agreed to by the CO. Deviations for specific site conditions such as large trees, boulders, or other built feature can be expected.

measurement and Payment No separate payment will be made for the work included under this section; rather payment shall be considered to be included in the items of work listed in the Schedule of Items.

PRODUCTS

1. GOVERNMENT-FURNISHED staking The government will provide the contractor with a survey control sheet which shows horizontal and vertical control for site if the contractor wishes to stake the project.

END OF SECTION

4 010250

SECTION 011400 WORK RESTRICTIONS

1. GENERAL

USE OF PREMISES

Use of Site: Limit use of premises to work in areas indicated. Do not disturb portions of site beyond areas in which the Work is indicated. Assume full responsibility for the protection and safekeeping of materials and products stored on the site.

Limits: Confine constructions operations to area designated by the Contracting Officer.

Government Occupancy: Allow for Government occupancy of site for use during periods of wildfire protection activities and other activities as requested by the Contracting Officer.

Driveways and Entrances: Keep driveways and entrances serving premises clear and available to Occupants, Government employees, and emergency vehicles at all times. Do not use these areas for parking or storage of materials.

Schedule deliveries to minimize use of driveways and entrances.

Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

OCCUPANCY REQUIREMENTS

Full Government Occupancy: Government will occupy site during entire construction period. Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government operations.

SCHEDULING

The Contractor shall coordinate scheduling and timing of required administrative procedures to avoid conflicts and insure orderly progress of the work. Proposed schedule shall be provided to the Contracting Officer 14 days prior to initiation of on-site work.

Schedule and conduct operations to minimize down time of water supply to facilities. Submit schedule to the Contracting Officer, outlining proposed construction sequence.

Schedule and conduct operations to minimize erosion of soils.

The Contractor’s schedule shall consider seasonal weather patterns for the project area. Any costs incurred by the Contractor due to weather delays shall be borne by the Contractor at no additional cost to the Government.

PROTECTION OF PUBLIC AND PROPERTY

Provide and maintain temporary barricades and warning signs to control access to protect the public and construction personnel from construction hazards.

Comply with Federal, State, and local laws, rules, and regulations concerning construction safety and health standards. Do not expose the public to, or require any workers to work under conditions that are unsanitary, hazardous, or dangerous to health and safety.

Repair damage to existing public and private improvements to original condition at no additional cost to the Government. Control dust and noise to protect adjacent property from damage.

SAFETY

The Contractor shall familiarize him/herself with current OSHA rules and observe these regulations at all times during the term of this Contract.

RECYCLED PRODUCTS

The Contractor is encouraged to use construction products and materials manufactured from recovered materials or recycled where it is economical and practical to do so.

waste DISPOSAL SITE A waste disposal site is available within 1 mile of the project site, and the location will be designated by the Contracting Officer.

All excavated material not used in the construction of embankments or backfilling of trenches, or other excess material resulting from the excavation and embankment operation shall be hauled to the designated disposal area.

All demolition materials, garbage, and other refuse generated shall be removed from the project site and legally disposed of off Government property in an approved landfill or legal disposal area. It shall be the Contractor's responsibility to locate a legal disposal area, to secure any necessary permits and to pay all costs involved in the disposal of materials.

The disposal site shall be left suitable for seeding.

Remove all waste materials from the site on a regular basis. Do not dispose of any materials onsite by burial or burning.

Dispose of all hazardous waste, including treated wood, in accordance with applicable state and federal regulations.

INTENT TO BEGIN WORK

After Notice to Proceed is issued and the Post-Award Conference, the Contractor shall notify the Contracting Officer of his/her intent to begin initial construction at least five days in advance.

PROGRESS MEETINGS

Meetings shall be scheduled as directed by the Contracting Officer to review progress and facilitate efficient, orderly prosecution of the Work.

Meetings shall be held at the Contractor's project site field office. The Contracting Officer’s Representative and Contractor's Project Superintendent shall be in attendance. Others shall attend as necessary for issues to be discussed.

PRODUCTS (NOT USED)

EXECUTION (NOT USED)

END OF SECTION

7 011400

SECTION 011700 ACCIDENT PREVENTION

1. GENERAL

DESCRIPTION

The work of this section consists of establishing an effective accident prevention program and providing a safe environment for all personnel and visitors.

SUBMITTALS

Accident Prevention Program: Before on-site work begins, submit for approval an accident prevention program. The Contracting Officer will review the proposed program for compliance with OSHA and project requirements. If the program requires any revisions or corrections, the Contractor shall resubmit the program within 10 days. No progress payments will be processed until the program is approved. The program shall include:

Name of responsible supervisor to carry out the program.

Weekly and monthly safety meetings.

First aid procedures.

Outline of each phase of the work, the hazards associated with each major phase, and the methods proposed to ensure property protection and safety of the public, government personnel, and the Contractor's employees. Identify the work included under each phase by reference to specification section or division numbers.

Training, both initial and continuing.

Planning for possible emergency situations, such as floods, fires, cave-ins, slides, explosions, power outages, and wind storms. Such planning shall take into consideration the nature of construction, site conditions, and degree of exposure of persons and property.

Certificates: Provide certificates from a mechanic that all mechanical equipment has been inspected and meets OSHA requirements.

Submit a copy of test reports, as required by OSHA, for personnel working with hazardous materials.

Submit a brief report of safety meetings and of inspections.

Upon request, submit proof of employees' qualifications to perform assigned duties in a safe manner.

QUALITY ASSURANCE

In case of conflicts between Federal, state, and local safety and health requirements, the most stringent shall apply. Equipment or tools not meeting OSHA requirements will not be allowed on the project sites. Failure to comply with the requirements of this section and related sections may result in suspension of work.

Qualifications of Employees:

Ensure that employees are physically qualified to perform their assigned duties in a safe manner.

To as great an extent as possible, do not allow employees to work whose ability or alertness is impaired because of drugs, fatigue, illness, intoxication, or other conditions that may expose themselves or others to injury.

Operators of vehicles, mobile equipment, hoisting equipment, and hazardous plant equipment shall be able to understand signs, signals, and operating instructions, and be capable of operating such equipment. Provide operating instructions for all equipment. Newly hired operators shall be individually tested by an experienced operator or supervisor to determine if they are capable of safely operating equipment.

accident reporting Reportable Accidents: A reportable accident is defined as death, occupational disease, traumatic injury to employees or the public, property damage by accident in excess of $100, and fires. Within 7 days of a reportable accident, fill out and forward to the Contracting Officer a DI-134 form, which may be obtained from Contracting Officer.

All Other Accidents: The Contractor shall report all other accidents to the Contracting Officer as soon as possible and assist the Contracting Officer and other officials as required in the investigation of the accident.

PRODUCTS

first aid facilities.

Provide adequate facilities for the number of employees and the type of construction at the site.

PERSONNEL PROTECTIVE EQUIPMENT

Meet requirements of NIOSH and MSHA, where applicable, as well as ANSI.

barriers See Division 1, Section 015100 “Temporary Facilities and Controls” for barriers.

EXECUTION

EMERGENCY INSTRUCTIONS

Post telephone numbers and reporting instructions for ambulance, physician, hospital, fire department, and police in conspicuous locations at the work site.

ESCAPE ROUTES

Provide and maintain adequate escape routes at all times in accordance with the Life Safety Code (NFPA 101-91). No corridor, aisle, stairway, door, or exit shall be obstructed or used in a manner that interferes with escape routes.

PROTECTIVE EQUIPMENT

Inspect personal protective equipment daily and maintain in a serviceable condition. Clean, sanitize, and repair, as appropriate, personal items before issuing them to another individual.

Inspect and maintain other protective equipment and devices before use and on a periodic basis to ensure safe operation.

SAFETY MEETINGS

As a minimum, conduct weekly 15-minute "toolbox" safety meetings. These meetings shall be conducted by a foreman and attended by all construction personnel at the worksite.

Conduct monthly safety meetings for all levels of supervision. Notify the Contracting Officer so that he may attend. These meetings shall be used to review the effectiveness of the Contractor's safety effort, to resolve current health and safety problems, to provide a forum for planning safe construction activities, and for updating the accident prevention program. The Contracting Officer will enter the results of the meetings into his daily log.

HARD HATS AND PROTECTIVE EQUIPMENT AREAS

A hard hat area will be designated by the Contracting Officer. The hard hat area shall be posted by the Contractor in a manner satisfactory to the Contracting Officer.

It is the Contractor's responsibility to require all those working on or visiting the site to wear hard hats and other necessary protective equipment at all times. As a minimum, provide six hard hats for use by visitors. Change liners before reissuing hats.

TRAINING

First Aid: Provide adequate training to ensure prompt and efficient first aid.

Hazardous Material: Train and instruct each employee exposed to hazardous material in safe and approved methods of handling and storage. Hazardous materials are defined as explosive, flammable, poisonous, corrosive, oxidizing, irritating, or otherwise harmful substances that could cause death or injury.

END OF SECTION

8 011700

SECTION 012900 PAYMENT PROCEDURES

1. GENERAL

summary Measurement and payment for contract work will be made only for and under those pay items included in the Schedule of Items. All other work, labor, materials, equipment, and incidentals necessary to successfully complete the project will be considered as included in the payment for items shown. This section defines the method of measurements and basis of payment for work items listed in the Schedule of Items.

DETERMINATION OF QUANTITIES

The following measurements and calculations shall be used to determine contract quantities for payment.

For individual construction items, longitudinal and lateral measurements for area computations shall be made horizontally or corrected to horizontal measurement unless otherwise specified. Measurements for geotextiles, netting and erosion control blankets shall be along slope lines.

For excavation or embankment volumes, the average end area method shall be used to compute volumes. However, if in the judgment of the Contracting Officer, the average end area method is impractical, measurement shall be made by volume in hauling vehicles or by other three-dimensional methods.

For Structures, they shall be measured according to neat lines shown on the drawings or as altered by the Contracting Officer, in writing, to fit field conditions.

For items that are measured by the linear foot, such as pipe culverts, fencing, guardrail, piping, utilities, and underdrains, measurements shall be made parallel to the base or foundation upon which the structures are placed.

For aggregates weighed for payment, the tonnage shall not be adjusted for moisture content, unless otherwise provided for.

For standard manufactured items (such as fence, wire, plates, rolled shapes, pipe conduits) identified by gauge, weight, section dimensions, and so forth, such identifications shall be considered the nominal weights or dimensions. Unless controlled by tolerances in cited specifications, manufacturer's tolerances shall be accepted.

UNITS OF MEASUREMENT

Payment shall be by units defined and determined according to U.S. Standard measure and by the following:

Cubic Yard (CY): A measurement computed by one of the following methods:

Excavation, Embankment, or Borrow -- The measurement computed by the average end area method from measurements made longitudinally along a centerline or reference line.

Material in Place or Stockpile -- The measurement computed using the dimensions of the in-place material.

Material in the Delivery Vehicle -- The measurement computed using measurements of material in the hauling vehicles at the point of delivery. Vehicles shall be loaded to at least their water level capacity. Leveling of the loads may be required when vehicles arrive at the delivery point.

Each (EA): One complete unit, which may consist of one or more parts.

Linear Foot (LF): Linear feet measured horizontally.

Lump Sum (LS): One complete unit, which may consist of one or more parts.

method of measurement One of the following methods of measurement for determining final payment is designated on the Schedule of Items for each pay item:

Actual Quantities (AQ) - These quantities are determined from actual measurements of completed work Lump Sum Quantities (LSQ) - These quantities denote one complete unit of work as required by or described in the contract, including necessary materials, equipment, and labor to complete the job. They shall not be measured.

PRODUCTS(NOT APPLICABLE)

EXECUTION(NOT APPLICABLE)

END OF SECTION

12 012900

SECTION 012910 MOBILIZATION

1. GENERAL

summary This item is intended to compensate the Contractor for operations including, but not limited to, those necessary for the movement of personnel, equipment, supplies, and incidentals to the project site; for payment of premiums for bonds and insurance for the project; and for any other work and operations which must be performed or costs that must be incurred incident to the initiation of meaningful work at the site and for which payment is not otherwise provided for under the contract.

measurement and Payment The measurement shall be lump sum for mobilization.

Payment:

Bond premiums will be reimbursed after receipt of the evidence of payment.

50% of the lump sum, not to exceed 5% of the original contract amount, will be paid following completion of 5% of the original contract amount not including mobilization and bond premiums.

Payment of the remaining portion of the lump sum, up to 10% of the original contract amount, will be paid following completion of 10% of the original contract amount not including mobilization and bond premiums.

Any portion of the lump sum in excess of 10% of the original contract amount will be paid after final acceptance.

Progress payments for mobilization and preparatory work shall be subject to retainage.

PRODUCTS (NOT USED)

EXECUTION (NOT USED)

END OF SECTION

13 012910

SECTION 013300 SUBMITTALS

1. GENERAL

summary This Section includes administrative and procedural requirements for submitting Shop Drawings, Product Data, Samples, and other miscellaneous submittals.

See other specification section within this package for additional requirements on submittal.

SUBMITTAL PROCEDUREs Coordination: Coordinate preparation and processing of submittals with performance of construction activities.

Coordinate transmittal of different types of submittals for related parts of the Work so processing will not be delayed because of need to review submittals concurrently for coordination.

The Contracting Officer reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received Processing Time: Allow enough time for submittal review, including time for re-submittals, as follows. Time for review shall commence on Contracting Officer's receipt of submittal.

Initial Review: Allow 14 days for initial review of each submittal. Allow additional time if processing must be delayed to permit coordination with subsequent submittals. Contracting Officer will advise Contractor when a submittal being processed must be delayed for coordination.

If intermediate submittal is necessary, process it in same manner as initial submittal.

Allow 14 days for processing each re-submittal.

No extension of the Contract Time will be authorized because of failure to transmit submittals enough in advance of the Work to permit processing.

Identification: Place a permanent label or title block on each submittal for identification.

Indicate name of firm or entity that prepared each submittal on label or title block.

Provide a space on label or beside title block to record Contractor's review and approval markings and action taken by Contracting Officer.

Include the following information on label for processing and recording action taken:

Project name Date Name and address of Contractor Name of manufacturer Unique identifier, including revision number Number and title of appropriate Specification Section.

Drawing number and detail references, as appropriate.

If more than one item is shown on submittal sheet, identify item.

Deviations: Highlight, encircle, or otherwise identify deviations from the Contract Documents on submittals.

Additional Copies: Unless additional copies are required for final submittal, and unless Contracting Officer observes noncompliance with provisions of the Contract Documents, initial submittal may serve as final submittal.

Use for Construction: Use only final submittals with mark indicating action taken by Contracting Officer in connection with construction.

measurement and payment No separate measurement and/or payment will be made for this section. Payment shall be included with work shown in the schedule of items.

PRODUCTS

ACTION SUBMITTALS – (Submittals requiring Contracting Officer approval) General: Prepare and submit Action Submittals required by individual Specification Sections.

Number of Copies: Submit three copies of each submittal, unless otherwise indicated. Contracting Officer will return two copies. Mark up and retain one returned copy as a Project Record Document.

Product Data: Collect information into a single submittal for each element of construction and type of product or equipment.

If information must be specially prepared for submittal because standard printed data are not suitable for use, submit as Shop Drawings, not as Product Data.

Mark each copy of each submittal to show which products and options are applicable.

Include the following information, as applicable:

Manufacturer's written recommendations.

Manufacturer's product specifications.

Manufacturer's installation instructions.

Manufacturer's catalog cuts.

Wiring diagrams showing factory-installed wiring.

Compliance with recognized trade association standards.

Compliance with recognized testing agency standards.

Shop Drawings: Prepare Project-specific information, drawn accurately to scale. Do not base Shop Drawings on reproductions of the Contract Documents or standard printed data.

Preparation: Include the following information, as applicable:

Dimensions.

Identification of products.

Fabrication and installation drawings.

Roughing-in and setting diagrams.

Wiring diagrams showing field-installed wiring, including power, signal, and control wiring.

Notation of dimensions established by field measurement.

Wiring Diagrams: Differentiate between manufacturer-installed and field-installed wiring.

Contractor's Construction Schedule: The contractor shall submit a Construction Schedule, for approval by Contracting Officer, in accordance with the contract provisions within 5 day of commencement of work.

Samples: Prepare physical units of materials or products, including the following:

Samples for Initial Selection: Submit manufacturer's color charts consisting of units or sections of units showing the full range of colors, textures, and patterns available.

INFORMATIONAL SUBMITTALS - (Submittals NOT requiring Contracting Officer approval) General: Prepare and submit Informational Submittals required by other Specification Sections.

Number of Copies: Submit three copies of each submittal, unless otherwise indicated. Contracting Officer will not return copies.

Certificates and Certifications: Provide a notarized statement that includes signature of entity responsible for preparing certification. Certificates and certifications shall be signed by an officer or other individual authorized to sign documents on behalf of that entity.

Test and Inspection Reports: Comply with requirements in Division 1 Section "Quality Requirements."

Material Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting test results of material for compliance with requirements.

Field Test Reports: Prepare reports written by a qualified testing agency, on testing agency's standard form, indicating and interpreting results of field tests performed either during installation of product or after product is installed in its final location, for compliance with requirements.

Maintenance Data: Prepare written and graphic instructions and procedures for operation and normal maintenance of products and equipment. Comply with requirements in Division 1 Section "Closeout Procedures."

Manufacturer's Instructions: Prepare written or published information that documents manufacturer's recommendations, guidelines, and procedures for installing or operating a product or equipment. Include name of product and name, address, and telephone number of manufacturer.

EXECUTION

GENERAL

Review each submittal and check for compliance with the Contract Documents. Note corrections and field dimensions. Mark with approval stamp before submitting to Contracting Officer.

Approval Stamp: Stamp each submittal with a uniform, approval stamp. Include Project name and location, submittal number, Specification Section title and number, name of reviewer, date of Contractor's approval, and statement certifying that submittal has been reviewed, checked, and approved for compliance with the Contract Documents.

Contracting Officer will not review submittals that do not bear Contractor's approval stamp and will return them without action.

Submittals not required by the Contract Documents will not be reviewed and may be discarded.

Substitutions – Whenever materials, products, and equipment are listed by name or brand in the specifications and/or on the drawings, it is used as a measure of quality, utility, or standard. If the Contractor prefers to use any other brand or manufacturer of same quality, appearance and utility to that specified, he shall request substitution as provided below, not less than 30 days before the planned installation of the item. The Contracting Officer will approve or disapprove the request for substitution.

Requests for substitutions will only be considered if contractor submits the following:

Complete technical data including drawings, complete performance specifications, test data, samples and performance tests of the article proposed for substitution. Submit additional information if required by Contracting Officer. All items in the above information shall be circled, tagged, or marked in some way to indicate all deviations or differences which the proposed item differs from the originally specified item.

Similar data as above for item originally specified. All items shall be marked to identify where/how the proposed substitution will differ.

A statement by the Contractor that the proposed substitution is in full compliance with the contract documents, applicable codes, and laws.

The Contractor shall be responsible for any effect upon related work in the project for any substitution and shall pay any additional costs generated by any substitutions.

Submittals shall be made as required by and called for in the drawings and specifications.

SUBMITTAL SCHEDULE

Submittals shall be made as required by and called for in the drawings and specifications.

REVIEW OF SUBMITTALS

The Contracting Officer will review submittals with reasonable promptness, indicating in writing the appropriate approval category ("Approved," "Disapproved," "Approved Subject to Corrections Shown") upon them. One (1) copy of the plan shall be returned to the Contractor and when corrections are required, the Contractor shall make such corrections. The plan shall then be resubmitted by the Contractor for approval until an unqualified approval is obtained. After unqualified approval is obtained, the Contractor shall furnish the Contracting Officer with three (3) copies of the approved submittals.

Review by the Contracting Officer does not relieve the Contractor from responsibility for errors which may exist in the submitted data.

Revisions:

Make revisions required by Contracting Officer.

If the Contractor considers any required revision to be a change, the Contractor shall notify the Contracting Officer as provided for in the General Conditions.

END OF SECTION

17 013300

SECTION 014000 QUALITY REQUIREMENTS

1. GENERAL

SUMMARY

This Section includes administrative and procedural requirements for quality assurance and quality control.

Testing and inspecting services are required to verify compliance with requirements specified or indicated. These services do not relieve Contractor of responsibility for compliance with the Contract Document requirements.

Specified tests, inspections, and related actions do not limit Contractor's quality-control procedures that facilitate compliance with the Contract Document requirements.

Requirements for Contractor to provide quality-control services required by Contracting Officer, or authorities having jurisdiction are not limited by provisions of this Section.

See Divisions 2 through 32 Sections for specific test and inspection requirements.

DEFINITIONS

Quality-Assurance Services: Activities, actions, and procedures performed before and during execution of the Work to guard against defects and deficiencies and ensure that proposed construction complies with requirements.

Quality-Control Services: Tests, inspections, procedures, and related actions during and after execution of the Work to evaluate that completed construction complies with requirements. Services do not include contract enforcement activities performed by Contracting Officer.

Testing Agency: An entity engaged to perform specific tests, inspections, or both. Testing laboratory shall mean the same as testing agency.

SUBMITTALS

Contractor Quality Control Plan Permits, Licenses, and Certificates As-Built Drawings Qualification Data: For testing agencies specified in "Quality Assurance" Article to demonstrate their capabilities and experience. Include proof of qualifications in the form of a recent report on the inspection of the testing agency by a recognized authority.

Test and Inspection Reports: Prepare and submit certified written reports that include the following:

Date of issue.

Project title and number.

Name, address, and telephone number of testing agency.

Dates and locations of samples and tests or inspections.

Names of individuals making tests and inspections.

Description of the Work and test and inspection method.

Identification of product and Specification Section.

Complete test or inspection data.

Test and inspection results and an interpretation of test results.

Ambient conditions at time of sample taking and testing and inspecting.

Comments or professional opinion on whether tested or inspected Work complies with the Contract Document requirements.

Name and signature of laboratory inspector.

Recommendations on retesting and re-inspecting.

QUALITY ASSURANCE

Fabricator Qualifications: A firm experienced in producing products similar to those indicated for this Project and with a record of successful in-service performance, as well as sufficient production capacity to produce required units.

Factory-Authorized Service Representative Qualifications: An authorized representative of manufacturer who is trained and approved by manufacturer to inspect installation of manufacturer's products that are similar in material, design, and extent to those indicated for this Project.

Installer Qualifications: A firm or individual experienced in installing, erecting, or assembling work similar in material, design, and extent to that indicated for this Project, whose work has resulted in construction with a record of successful in-service performance.

Professional Engineer Qualifications: A professional engineer who is legally qualified to practice in jurisdiction where Project is located and who is experienced in providing engineering services of the kind indicated. Engineering services are defined as those performed for installations of the system, assembly, or products that are similar to those indicated for this Project in material, design, and extent.

Testing Agency Qualifications: An agency with the experience and capability to conduct testing and inspecting indicated, as documented by ASTM E 548, and that specializes in types of tests and inspections to be performed.

QUALITY CONTROL

Contractor Responsibilities: Unless otherwise indicated, provide quality-control services specified and required by authorities having jurisdiction.

Where services are indicated as Contractor's responsibility, engage a qualified testing agency to perform these quality-control services.

Contractor shall not employ the same entity engaged by the Government, unless agreed to in writing by Contracting Officer.

Notify testing agencies at least 48 hours in advance of time when Work that requires testing or inspecting will be performed.

Where quality-control services are indicated as Contractor's responsibility, submit a certified written report, in duplicate, of each quality-control service.

Testing and inspecting requested by Contractor and not required by the Contract Documents are Contractor's responsibility.

Submit additional copies of each written report directly to authorities having jurisdiction, when they so direct.

Special Tests and Inspections: Contractor will engage a testing agency to conduct special tests and inspections required by authorities having jurisdiction as the responsibility of Contractor.

Testing agency will notify Contracting Officer and Contractor promptly of irregularities and deficiencies observed in the Work during performance of its services.

Testing agency will submit a certified written report of each test, inspection, and similar quality-control service to Contracting Officer with copy to Contractor and to authorities having jurisdiction.

Testing agency will submit a final report of special tests and inspections at Substantial Completion, which includes a list of unresolved deficiencies.

Testing agency will interpret tests and inspections and state in each report whether tested and inspected work complies with or deviates from the Contract Documents.

Testing agency will retest and re-inspect corrected work.

Manufacturer's Field Services: Where indicated, engage a factory-authorized service representative to inspect field-assembled components and equipment installation, including service connections. Report results in writing.

Re-testing/Re-inspecting: Regardless of whether original tests or inspections were Contractor's responsibility, provide quality-control services, including retesting and re-inspecting, for construction that revised or replaced Work that failed to comply with requirements established by the Contract Documents.

Testing Agency Responsibilities: Cooperate with Contracting Officer and Contractor in performance of duties. Provide qualified personnel to perform required tests and inspections.

Notify Contracting Officer and Contractor promptly of irregularities or deficiencies observed in the Work during performance of its services.

Interpret tests and inspections and state in each report whether tested and inspected work complies with or deviates from requirements.

Submit a certified written report, in duplicate, of each test, inspection, and similar quality-control service through Contractor.

Do not release, revoke, alter, or increase requirements of the Contract Documents or approve or accept any portion of the Work.

Do not perform any duties of Contractor.

Associated Services: Cooperate with agencies performing required tests, inspections, and similar quality-control services, and provide reasonable auxiliary services as requested. Notify agency sufficiently in advance of operations to permit assignment of personnel. Provide the following:

Access to the Work.

Incidental labor and facilities necessary to facilitate tests and inspections.

Adequate quantities of representative samples of materials that require testing and inspecting. Assist agency in obtaining samples.

Facilities for storage and field-curing of test samples.

Preliminary design mix proposed for use for material mixes that require control by testing agency.

Security and protection for samples and for testing and inspecting equipment at Project site.

Coordination: Coordinate sequence of activities to accommodate required quality-assurance and quality-control services with a minimum of delay and to avoid necessity of removing and replacing construction to accommodate testing and inspecting.

Schedule times for tests, inspections, obtaining samples, and similar activities.

measurement and Payment No separate payment will be made for the work included under this section; rather payment shall be considered to be included in the items of work listed in the Schedule of Items.

PRODUCTS(NOT USED)

EXECUTION

REPAIR AND PROTECTION

General: On completion of testing, inspecting, sample taking, and similar services, repair damaged construction and restore substrates and finishes.

Provide materials and comply with installation requirements specified in other Sections of these Specifications. Restore patched areas and extend restoration into adjoining areas in a manner that eliminates evidence of patching.

Comply with the Contract Document requirements for Division 1 Section "Cutting and Patching."

Protect construction exposed by or for quality-control service activities.

Repair and protection are Contractor's responsibility, regardless of the assignment of responsibility for quality-control services.

END OF SECTION

23 014000

SECTION 014030 CONTRACTOR QUALITY CONTROL

1. GENERAL

SUMMARY

The work of this section consists of preparing and executing a quality control program.

SUBMITTALS

As specified in Division 1 Section “Submittal Procedure”.

Quality Control Plan:

At the time of the preconstruction conference, submit for approval a written Contractor Quality Control (CQC) plan.

If the plan requires any revisions or corrections, the Contractor shall resubmit the plan within 10 days.

The Government reserves the right to require changes in the plan during the contract period as necessary to obtain the quality specified.

No change in the approved plan may be made without written concurrence by the Contracting Officer.

The plan shall include:

A list of personnel responsible for quality control and assigned duties. Include each person's qualifications.

A copy of a letter of direction to the Contractor's Quality Control Supervisor outlining assigned duties.

Names, qualifications, and descriptions of laboratories to perform sampling and testing, and samples of proposed report forms.

Methods of performing, documenting, and enforcing quality control of all work.

Methods of monitoring and controlling environmental pollution and contamination as required by regulations and laws.

Contractor's Quality Control Daily Reports: Submit showing all inspections and tests on the first workday following the date covered by the report.

Test Reports:

Submit Daily Test Information Sheets with Quality Control Daily Reports.

Submit failing test results and proposed remedial actions within four hours of noted deficiency.

Submit three copies of complete test results not later than three calendar days after the test was performed.

Off-Site Inspection Reports: Submit prior to shipment.

If the CQC plan and Quality Control Daily Reports are not submitted as specified, the Contracting Officer may retain all payments until such time a plan is approved and implemented.

QUALITY ASSURANCE

General:

The quality of all work shall be the responsibility of the Contractor. Testing shall be the responsibility of an independent testing laboratory Inspect and test all work often enough to ensure that the quality of materials, workmanship, construction, finish, and functional performance is in compliance with applicable specifications and drawings.

Quality Control Daily Reports shall be completed by the Quality Control Supervisor.

Test reports shall be completed by person performing the test.

The Contracting Officer may designate locations of tests.

Design and complexity of the project.

Location of the project.

Characteristics of area construction labor market.

Duration of project.

Cost and type of contract.

Amount and type of off-site fabrication.

Quality Control Staff:

The Contractor’s Quality Control Supervisor may also perform the duties of Project Superintendent.

The Contractor’s Quality Control Supervisor shall be assigned no other duties.

The Contractor’s designated Quality Control Supervisor shall be on the project site whenever contract work is in progress.

The Contractor’s job supervisory staff may be used to assist the Quality Control Supervisor, supplemented as necessary by additional certified testing technicians.

Testing Laboratory and Equipment:

Employ certified independent laboratories to perform sampling and testing. The testing laboratory organization shall be certified for the type of testing work to be done.

All measuring devices, laboratory equipment, and instruments shall be calibrated at established intervals against certified standards in accordance with NBS requirements. Upon request, measuring and testing devices shall be made available for use by the Government for verification tests.

PRODUCTS (NOT USED)

EXECUTION

OFF-SITE CONTROL

Items that are fabricated or assembled off-site shall be inspected for quality control at the place of fabrication.

ON-SITE CONTROL

Notification:

Notify the Contracting Officer at least 48 hours in advance of the preparatory phase meeting Notify the Contracting Officer at least 24 hours in advance of the initial and follow-up phases.

Preparatory Phase: Perform before beginning each feature of work.

Review control submittal requirements with personnel directly responsible for the quality control work. As a minimum, the Contractor's Quality Control Supervisor and the foreman responsible for the feature of work shall be in attendance.

Review all applicable specifications sections and drawings related to the feature of work.

Ensure that copies of all referenced standards related to sampling, testing, and execution for the feature of work are available on site.

Ensure that provisions have been made for field control testing.

Examine the work area to ensure that all preliminary work has been completed.

Verify all field dimensions and advise the Contracting Officer of discrepancies with contract documents.

Ensure that necessary equipment and materials are at the project site and that they comply with approved shop drawings and submittals.

Prepare a report on all preparatory phase activities and discussions. Attach report to Contractor's Quality Control Daily Report.

Initial Phase:

As soon as work begins, inspect and test a representative portion of a particular feature of work for quality of workmanship.

Review control-testing procedures to ensure compliance with contract requirements.

Prepare a report on all initial phase activities and discussions. Attach report to Contractor's Quality Control Daily Report. Exact location of initial phase shall be indicated for future reference and comparison with follow-up phases.

Follow-Up Phase: Inspect and test as work progresses to ensure compliance with contract requirements until completion of work.

Additional Preparatory and Initial Phases: Additional preparatory and initial phases may be required on the same feature of work for the following reasons:

Quality of on-going work is unacceptable.

Changes occur in the applicable quality control staff, on-site production supervision, or work crew.

Work on a particular feature of work is resumed after a substantial period of inactivity.

DOCUMENTATION

Maintain Quality Control Daily Reports and Daily Test Report Information Sheets (samples attached) of quality control activities and tests.

Quality Control Daily Reports may not be substituted for other written reports required under clauses of the contract, such as Disputes, Differing Site Conditions, or Changes.

ENFORCEMENT

The Contractor shall stop work on any item or feature pending satisfactory correction of any deficiency noted by the quality control staff or the Contracting Officer.

END OF SECTION

27 014030

SECTION 014100 REGULATORY REQUIREMENTS

1. GENERAL

DESIGN STANDARDS AND CODES

All work shall comply with the rules and regulations of federal, state, and local agencies having jurisdiction. The Contractor shall acquire all permits, licenses and approval needed to complete the project from applicable state and local officials.

The construction methods shall meet the latest edition of all national, state and local codes. The following standards and codes are made part of the contract specifications. In case of conflict, the most stringent shall apply.

AAN American Association of Nurserymen AASHTO American Association of State Highway and Transportation Officials ACI American Concrete Institute ADAABAAG Americans with Disabilities Act-Architectural Barriers Act Accessibility Guidelines AISC American Institute of Steel Construction AITC American Institute of Timber Construction ANSI American National Standards Institute ARM Administrative Rules of Montana ASTM American Society for Testing and Materials AWPA American Wood Preservers Association AWPB American Wood Preservers Bureau AWS American Welding Society AWWA American Water Works Association FSORAG USDA Forest Service Outdoor Recreation Accessibility…