A06_-_140L1721Q0055-Section_01009.pdf

GENERAL INFORMATION AND REQUIREMENTS

King Mountain Well Abandonment 11/01

01009 - 1

SECTION 01009

PART 1: GENERAL

1.1 SUMMARY

A. Description of Work: Furnishing labor, equipment, supplies, and materials, to plug/abandon one water well.

B. Location: Work under this Contract is located in Routt County, Colorado.

The work location is shown on the drawings.

1.2 DEFINITIONS

A. Approvals: Approval of the submittals is an indication that the Contractor's submittals have been reviewed and that there are no objections, except as noted. Approval of deviations shall apply only to those deviations or omissions from the requirements of the drawings and specifications brought to the Contracting Officer's attention in writing.

After approval of an item, submit a substitute for approval when the approved item cannot be purchased or delivered in time to avoid delay in completion of the project.

1.3 SUBMITTALS

A. Submittals:

1. A current and valid copy of the contractor’s license for drilling water well in the State of Colorado. Information shall include license number and well drillers name.

2. A Well Abandonment Report as instructed in section 17.1.4 of the Colorado

Division of Water Resources, Water Well Construction Rules, 2 CCR 402-2.

Submit a copy of the report to the Contracting Officers representative after completion of the project and in addition to submitting the original report to the State of Colorado.

B. Requirements: Refer to specifications for submittals required. Allow at least 5 working days for review. Submittals shall be delivered in PDF format and sent via email to bvecchia@blm.gov.

1.4 QUALITY ASSURANCE

A. Codes and Standards: The work shall comply with codes and standards applicable to each type of work and as listed in the individual sections of these specifications. This Contract incorporates materials, applications, and tests by reference, with the same force and effect as when they were given in full text.

B. Conflict: Where a conflict occurs between reference documents and project specifications, the project specifications shall govern.

01009 - 2

1.5 PROJECT/SITE CONDITIONS

A. Access to the Work: As per Federal Acquisitions Regulations Clause 52.236-10.

B. Environmental Considerations: As per Federal Acquisitions Regulations

Clause 52.236-9 and 52.236-10.

1.6 SEQUENCING AND SCHEDULING

A. The schedule shall be submitted within 5 calendar days after signing the Notice to Proceed and as per Federal Acquisitions Regulations Clause 52.236-15. When requested, submit an updated schedule.

PART 2: PRODUCTS

(There are no applicable requirements.)

PART 3: EXECUTION

3.1 PROJECT MEETINGS

A. Pre-Work Conference:

1. Will be held prior to the start of work. The Contractor will be notified in advance of meeting time, date, and place. The purpose will be to review required work, project drawings and specifications, construction schedules, payroll and payments, and administrative provisions of the Contract.

2. The Contractor, subcontractors, and the persons responsible for coordination of the work shall be present at the meeting.

3. Be prepared to summarize and explain procedures planned for the project.

B. Progress Meetings:

1. To be held at the project site, or as determined by the Contracting

Officer.

2. May be called by either the Contracting Officer or the Contractor.

Request shall state who should attend and include an agenda.

C. Final Inspection:

1. To be held at the project site, or as determined by the Contracting

Officer.

2. Notify the Contracting Officer in writing at least 5 working days before the completion date so the Government can schedule final inspection.

3. The superintendent shall be present during this inspection.

3.2 PREPARATION

A. Work Limits and Control Points: Will be established by the Contracting Officer.

3.3 SALVAGEABLE ITEMS

A. Requirements: Salvageable items consisting of one submersible well pump shall become the property of the Government. Remove and store the submersible well pump on site at a location designated by the Contracting Officer. Items including but not limited to drop pipe, wire, concrete

01009 - 3 flatwork at the ground surface of the well casing, and a top section of the surface casing shall become the property of the Contractor and shall be removed from the work site.

3.4 DISPOSAL OF DEBRIS

A. Requirements: Items or debris not designated as salvage for the Government shall become the property of the Contractor. Disposal of materials in a legal manner and payment of fees required is the Contractor's responsibility.

PART 4: MEASUREMENT AND PAYMENT

4.1 METHOD OF MEASUREMENT

A. Units: The work described in this section will not be measured for payment.

4.2 BASIS OF PAYMENT

A. Payment: No direct payment for the work described under this section will be made. Consideration for this item shall be included in the bid price for other items of the Contract.

END OF SECTION