SOLICITATION FOR THE CGC ROBERT G. WARD.11FEB2020.docx

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time- consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process, the agency is not required to suspend contract award performance. Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman. The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program.

Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government. The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed. To be timely protests must be filed within the period specified in FAR 33.103(e). Formal protests filed under the OPAP program should be submitted electronically to OPAP@uscg.mil and the Contracting Officer or by hand delivery to the Contracting Officer.

Election of Forum. After an interested party protests a Coast Guard procurement to the Contracting Officer or the Ombudsman, and while the protest is pending, the protester agrees not to file a protest with the GAO or other external forum. If the protest is filed with an external forum, the agency protest will be dismissed.

The Ombudsman Hotline telephone number is 202.372.3695.

USCGC ROBERT G. WARD (WPC-1130) DOCKSIDE REPAIRS 70Z080-20-Q-P4504800

This is a combined synopsis/solicitation for commercial items prepared in accordance with Federal Acquisition Regulation (FAR) subpart 12.6 and part 13 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; quotations are being requested and a written solicitation will not be issued. Solicitation number 70Z080-20-Q-P4504800 is issued as a Request for Quotations (RFQ). This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular (FAC) 2019-06 effective September 10, 2019, Department of Homeland Security Acquisition Regulation (HSAR) effective January 28, 2019, Homeland Security Acquisition Manual (HSAM) effective July 31, 2019, and Coast Guard Acquisition Procedures (CGAP) effective September 29, 2017.

The applicable North American Industry Classification Standard Code is 336611. The small business size standard is 1,250 employees. This solicitation is issued as a 100% Total Small Business Set Aside. All responsible small business sources may submit a quotation, which shall be considered by the agency.

It is anticipated that one (1) firm fixed price contract will be awarded as a result of this synopsis/solicitation.

SOLICITATION DOCUMENTS:

Attachment 1: Schedule of Services – Blank Price Schedule Attachment 2: Statement of Work – Specification

AGENCY INFORMATION:

Donna Eubanks Contract Specialist

(757) 628-4661 donna.y.eubanks@uscg.mil Tracey M. Strawbridge Contracting Officer

(757) 628-4644 tracey.strawbridge@uscg.mil

LTJG

Contracting Officer’s Representative

(703) 943-0590 joseph.a.rizzardi@uscg.mil

PERIOD OF PERFORMANCE: The period of performance for this contract is 7 April 2020 to 19 May 2020. Contractors that have this capability are invited to submit quotations in accordance with the requirements stipulated in this solicitation.

PLACE OF PERFORMANCE: The place of performance will be at the cutter’s homeport located at 100 S. Seaside Ave, San Pedro, CA 90731.

REQUEST FOR DRAWINGS: The last day to request drawings regarding this solicitation is 17 February 2020. After this date, further requests may not be accepted due to time constraints. To request drawings, contact the Contract Specialist via email. All requests should identify the solicitation number.

QUESTIONS: The last day for questions regarding this solicitation is 17 February 2020. Email questions to the Contract Specialist and the Contracting Officer. All questions need to identify the solicitation number and will be answered by an Amendment.

SUBMISSION OF QUOTES: E-mail quotations shall be sent to Contract Specialist. Please indicate 70Z080-20-Q-P4504800 in the subject line. Contractor must affirm that the pricing provided from the quote shall be valid up to the date of contract award. Anticipated award date is on or about 17 March 2020.

Statement of Requirement The proposed contract to be awarded by the United States Coast Guard (USCG) shall be for Dockside repairs to the USCGC ROBERT G. WARD (WPC-1130) as specified in the Specification for Dockside Repairs Rev-0, 2 October 2019. Contractor shall provide all labor, materials, necessary to meet the requirements of the specification.

The following clauses and provisions are included:

52.212-1 Instructions to Offerors - Commercial Items

52.212-1(f) Late submissions, modifications, revisions, and withdrawals of offers are tailored as follows:

Quotes shall be submitted no later than 11 March 2020 at 10:00 AM Eastern Standard Time. After that time, the Government will begin evaluating quotes, making an award decision, and issuing a purchase order. Quotes submitted after that time may not be considered.

Evaluation Criteria The provision at Federal Acquisition Regulation (FAR) 52.212-2 Evaluation of Commercial Items is not applicable to this solicitation. In lieu of this provision, quotes will be evaluated in accordance with FAR 13.106-2 based on the criteria listed below. The Government will award a contract resulting from this solicitation to the responsible contractor whose quote is the most advantageous best value to the Government, price and non-price factors considered. The following factors shall be used to evaluate quotes:

A. Technical Capabilities B. Past Performance C. Price

Technical Capabilities:

Technical Acceptability will be evaluated to determine an overall rating. This will be determined by evaluating the ability of the contractor to provide a sound, compliant approach that meets all requirements listed in the Specification and demonstrates a thorough knowledge and understanding of the requirements. It is the contractor’s responsibility to ensure that their quote clearly demonstrates their ability to perform these requirements. All contractors must provide the following minimum information and documentation with their quotes to be considered technically acceptable:

Technical Approach: - I. Strategy for Meeting Technical Requirements - Submit a brief overview planning document using any means (computer generated, etc.) that outlines the strategy for ensuring that this requirement is completed on or before the contract completion date. The planning document shall include at least:

1) Proposed schedule, resources, completion-dates, float, and major milestones for the various tasks required to complete this contract and

2) Identify a list of items that may pose the most contract schedule risk and approach to mitigate or eliminate each risk.

II. Welding Certifications/Procedures Submit welding documentation (e.g. WPSs, welder certs, etc.) in accordance with SFLC Standard Specification 0740, specific to your internal or subcontracted staff for the weld joints that will be installed.

III. Preservation/Coatings Certification Requirements Submit a description of how you intend to meet SFLC Standard Specification 0000 coatings QC/QA requirements for this contract. This plan must include the names of any subcontractors and resumes for any proposed QP1 certified painters and/or independent NACE CIP Level 3 inspectors.

IV. Sewage and Grey Water System Cleaning Procedures Submit a description of the methods that will be employed to clean the sewage and grey water system piping and tanks (e.g. chemical cleaning, pressure washing, etc.) and if applicable, a description of the subcontracting plan.

V. Watertight Closure Assessment Qualification Requirements Submit documentation describing prior experience with repairing and/or grooming watertight hull fittings to include doors, hatches and scuttles, both individually dogged and quick-acting styles. Describe frequently used techniques for alignment and establishing a watertight seal.

VI. Thermographic Inspection Experience and Certifications / Qualifications Submit documentation indicating that an employee or subcontractor performing the work possesses a current "ANSI/ASNT LEVEL I certification (or higher) meeting SNT-TC-1A: Personnel Qualification and Certification in Nondestructive Testing", and/or any other relevant job experience or skills that indicate adequate qualifications for performing the work.

Past Performance:

The Government may utilize any references provided by the Contractor, along with information available from past contracts/orders with the USCG and any information found using sources such as Federal Government sources, Past Performance Information Retrieval System (PPIRS)/Contractor Performance Assessment Reporting System (CPARS) to determine if the Contractor has satisfactory or neutral Past Performance. The Government reserves the right to limit or expand the number of references it decides to contact and to contact references other than those provided by the contractor. The contractor should provide at least two relevant past performance evaluations within the last two (2) years. Past performance less than satisfactory may not be considered for award.

Price:

The contractor shall provide pricing as requested in the attached spreadsheet titled “ROBERT G. WARD (WPC 1130) FY20 DS Repairs – Blank Schedule of Services.” The contractor’s price shall represent the best price in response to the request for quote. The price shall be evaluated to determine fairness and reasonableness. Pricing for travel shall be detailed (i.e. number of travelers, lodging, airfare, etc.) Additional detailed information may be required to determine price reasonableness. Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

Evaluation Method The Government will evaluate quotes using a trade-off analysis to determine the best overall value. The relative importance of technical and past performance combined are more important than cost or price. The evaluation factors above are the mandatory minimum requirement for eligibility for evaluation. Failure to comply with the requirement may lead to outright rejection of the quote.

The contractor shall complete only paragraph (b) of this provision if the contractor has completed the annual representations and certification electronically in the System for Award Management (SAM) accessed through https://www.sam.gov. If the contractor has not completed the annual representations and certifications electronically, the contractor shall complete only paragraphs (c) through (u) of this provision.

(End of Provision)

52.212-4 Contract Terms and Conditions – Commercial Items (Addendum)

The paragraphs below are supplemented or added as follows:

(a) Material Inspection and Receiving Report (DD-250) Upon 25% completion of the overall contract requirement and then in weekly increments thereafter, the Contractor shall prepare and furnish to the COR/Alternate COR a DD Form 250, Material Inspection and Receiving Report (MIRR) or an equivalent report approved by the Contracting Officer unless otherwise specified. One (1) copy of each DD Form 250 or approved equivalent shall be submitted with the invoice.

(c) Changes – ship repair

(1) The Contracting Officer may, at any time, by written order, and without notice to the sureties, if any, make changes within the general scope of this contract, in any one or more of the following:

(a) Drawings, designs, or specifications, when the supplies to be furnished are to be specially manufactured for the Government in accordance with the drawings, designs, or specifications;

(b) Method of shipment or packing;

(c) Place of performance of the work;

(d) Time of commencement or completion of the work; and

(e) Other requirements within the general scope of the contract.

(2) If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under this contract, whether changed or not changed by the order, the Contracting Officer shall make an equitable adjustment in the contract price, the delivery schedule, or both, and shall modify the contract accordingly.

(3) The contractor must submit any proposal for adjustment under this clause within 5 days from the date of receipt of the written order. At the Contracting Officer's discretion, the 5-day period may be shortened. However, if the Contracting Officer decides that the facts justify it, the Contracting Officer may receive and act upon a proposal submitted before final payment of the contract.

(4) If the contractor's proposal includes the cost of property rendered obsolete or excess by the change, the Contracting Officer shall have the right to prescribe the manner of the disposition of the property.

(5) Failure to agree to any adjustment shall be a dispute under the Disputes clause. However, nothing in this clause shall excuse the contractor from proceeding with the contract as changed.

(w) Required Insurance Prior to start of performance, the Contractor shall, at its own expense, procure and maintain the following kinds of insurance with respect to performance under the contract. In accordance with HSAR 3052.217-95, Liability and Insurance (DEC 2003), and 3052.228-70, Insurance (DEC 2003) the Contractor shall furnish the Contracting Officer with proof of insurance for the duration of the contract, including:

(1) Ship Repairer's Liability - $500,000 per occurrence.

(2) Comprehensive General Liability - $500,000 per occurrence.

(3) Full insurance coverage in accordance with the United States’ Longshoremen's and Harbor Worker's Act.

(4) Full insurance coverage in accordance with the State's Workmen's Compensation Law (or its equivalent) for all places of performance under this contract.

The insurance certificate must provide the name of the US Coast Guard vessel and the contract number as specifically insured.

(x) Change Request (CR) – Growth Work

(1) The Contractor shall not perform growth work without the Contracting Officer's authorization. This clause applies to Change Requests (CR), also known as growth and emergent work ordered by the Contracting Officer pursuant to the Changes clause. The Contractor shall perform the CR at the labor billing rates designated in the Schedule, as described in paragraph (2) of this clause. All growth work shall be paid at the prices stated in the Schedule.

(2) The CR composite labor rate is a flat, hourly rate used to price direct production labor hours. Contractors shall provide a detailed breakdown that fully supports the quoted CR composite labor rate. The CR composite labor rate shall be burdened to include the cost of direct production labor, all associated indirect costs, and profit/fee as described below:

a. Direct production labor is defined as work that is directly related to the alteration, modification, and repair tasks performed directly on, or in direct support of, components or systems identified in the CR or elsewhere in the contract. Examples of direct production labor include the following: abrasive cleaning/water blasting, tank cleaning, welding, burning, brazing, blacksmithing, machining (inside and outside), carpentry, electrical/electronic work, crane operation, shipfitting, lagging/insulating, painting, boilermaking, pipe fitting, engineering (production), sheetmetal work, installation and removal of staging/scaffolding, rigging, material handling (shop to ship and within the worksite in support of labor task), set-up (moving tools and equipment from shop to ship to perform a task), fire watch, general labor (including general support of journeyman tasks), cleaning (including debris pickup and removal), and pattern making.

b. Indirect costs are defined as all non-direct production costs and support functions, defined as functions that do not directly contribute to the alteration, modification, or repair of the item or system identified. Examples of indirect costs include the following: planning, estimating, supervision, management, ship superintendent functions, clerical, surveying, security, transportation, supervision, labor costs, worker-compensation, taxes, inventory control, warehousing, licensing, insurance, all other support items and functions, fixed asset costs, rentals on items normally owned as fixed assets such as tools and hand operated power tools, electrical generators and compressors for operating tools (for dry-docks), jigs and fixtures fabricated and used in shop to support production functions, security, contractor facility upkeep and utilities, workman’s compensation, taxes, office supplies, etc.

c. Direct consumables and expendables: supply items, manufactured or procured by the Contractor that are consumed or expended in conjunction with direct production (e.g. rags, gloves, respirators/masks, welding rods, etc.)

(3) Detailed pricing for the following shall be priced and itemized separately to include all costs and profit/fee as described below and shall not be included in the CR composite labor rate:

a. Direct materials: supply items, manufactured or procured by the Contractor, that are installed in conjunction with direct production, or are otherwise turned over to the Coast Guard (e.g. plate, angle iron, welding rods, paint, pumps, motors, engine and gearbox oil, engine jacket water, etc.)

b. Direct subcontracted services: direct production service items and procured by the Contractor to support the contract (e.g. gas-free engineering services, rented crane services, rented temporary air conditioning units and other rented tools not normally owned as fixed assets, etc.)

(4) CRs do not include replacement work performed pursuant to HSAR 3052.217- 92 Inspection and Manner of Doing Work clause or HSAR 3052.217-100 Guarantees clause.

(5) It is the Government's intention to award any growth work identified during the contract performance period to the contractor, if a fair and reasonable price can be negotiated for such work, based on Schedule rates. If a fair and reasonable price cannot be negotiated, the Government may, at its discretion, obtain services outside of the contract. Such services may be performed while the ship is undergoing repair in the contractor's facility pursuant to the Access to Vessels clause.

(6) Change Requests shall be transmitted electronically via email. The bullets below display the process of how change requests are to be followed during the availability:

CR Process will occur in the following order:

a. Condition Found Report (CFR)-Generated by the Contractor and provided to COR

b. Condition Report Reply(CRR)-Generated by the COR and provided to Contractor

c. Change Request- CR and IGE are generated by the COR and forwarded to KO

d. COR provides copy of Change Request to the Contractor.

e. Contractor’s Proposal- Provided to the KO for the identified tasking on CR

f. Negotiations- If needed, take place to establish pricing

g. Approved Work Request- Forwarded to Contractor and COR by the KO

h. Modification to Contract- the KS/KO will issue a modification covering all CR’s.

(7) The contractor shall submit to the Contracting Officer the following information in all CR quotes:

a. The number of direct production labor hours that will be used to accomplish the tasks specified in the CR.

b. A list of each direct material, direct subcontracted service, and direct consumable and expendable item that will be used to accomplished the CR, and a corresponding price for each item. The Contracting Officer may request evidence in support of the offered prices such as material receipts and quotes received from subcontractor.

c. Any proposed changes to the Schedule of Work.

(8) The contractor shall not be entitled to payment for any hours ordered pursuant to this clause until such time as a written contract modification is executed.

(y) Schedule of work

(1) Notwithstanding other requirements specified in this contract, the contractor shall provide to the Contracting Officer and COR the following documents within three (3) working days of the vessel's arrival at the contractor's facility for dry-dock availabilities and at the arrival conference for dockside availabilities:

a. Production Schedule.

b. Work Package Network.

c. Total Manpower Loading Curve.

d. Trade Manning Curves.

e. Subcontracting List.

(2) Change requests/growth work ordered and agreed upon, whether or not yet formalized via a change order (contract modification), shall be added to the Planning Document and submitted to the Contracting Officer and COR at each weekly Progress Meeting. Any anticipated or unanticipated deviation (greater than two (2) calendar days) from the Planning Document shall be immediately brought to the attention of the Contracting Officer and COR.

(3) Any deviation in the Production Schedule which results in a delay in the completion of work on a vessel past the established performance period completion date may entitle the Government to remedies for late performance under subparagraph (f) of this clause titled Excusable delays.

(z) Access to the Vessel

(1) As authorized by the Contracting Officer, a reasonable number of officers, employees and personnel designated by the Government, or representatives of other contractors and their subcontractors shall have admission to the facility and access to the vessel at all reasonable times to perform and fulfill their respective obligations to the Government on a noninterference basis. The contractor shall make reasonable arrangements to provide access for these personnel to office space, work areas, storage or shop areas, and other facilities and services reasonable and necessary to perform their duties. All such personnel shall comply with contractor rules and regulations governing personnel at its shipyard, including those regarding safety and security.

(2) The contractor further agrees to allow a reasonable number of officers, employees, and designated personnel of contractors on other contemplated work, the same privileges of admission to the contractor's facility and access to the vessel(s) on a noninterference basis, subject to contractor rules and regulations governing personnel in its shipyard, including those regarding safety and security.

(aa) Temporary Services

(1) Temporary services are services incidental to the performance of work which are required in the schedule or specifications to be provided by the contractor. Temporary services may include the furnishing of water, electricity, telephone service, toilet facilities, garbage removal, office space, parking places or similar facilities.

(2) If performance time is extended due to Government-caused delay, the contractor may request an equitable adjustment for providing temporary services at the rate stated in the Schedule.

(ab) Contract Deficiency Report The Contracting Officer or Contracting Officer’s Representative (COR) may issue a Contract Deficiency Report (CDR), SFLC Form 005. The Contractor shall respond in writing within 24 hours of receipt, unless otherwise approved by the Contracting Officer, to the COR. The COR will comment on the Contractor's response and will forward the Deficiency Report and comments to the Contracting Officer, with a copy to the Contractor and Availability Program Manager. The Contracting Officer will render a final determination and provide it to the Contractor and COR in writing.

(ac) Option for Increased Quantity – Separately Priced Line Item (REMOVE IF NO OPTIONAL CLIN’S) The Government may require the performance of the numbered line items, identified in the Schedule as option items, at the unit prices stated in the Schedule. The option quantities shown in the Schedule are estimates only. The Government has the right to require performance of these items at the quantities deemed necessary. Therefore, the Government may exercise an option item on more than one occasion during the contract performance period. The Contracting Officer will provide initial notification of the exercise of an option either verbally, by facsimile, or both. When time is of essence initial notification will be provided verbally followed within 24 hours by a facsimile of confirmation. A contract modification will be executed shortly thereafter to include those options wherein exercise notification was provided. Such options may be exercised at any phase during the contract performance period as stated herein, or any extension of the performance period. To maintain the contract performance period the Contractor shall commence performance of an option item immediately upon receiving initial notification; but, not later than 24 hours thereafter, unless proper sequencing of the work requires a delay in beginning performance of the option. In that case, the option item shall be commenced as soon as proper sequencing permits. The exercise of any option item listed in the Schedule will not normally extend the contract performance period. However, the Contracting Officer may consider a request by the Contractor for contract extension if an option is exercised after 50% of the contract performance period has expired.

(End of FAR 52.212-4 Addendum)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Items.

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (Jul 2018) (Section 1634 of Pub. L. 115-91).

(3) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(4) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(5) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

(4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2018) (Pub. L. 109-282) (31 U.S.C. 6101 note). REMOVE IF UNDER $30K

(8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note). REMOVE IF UNDER $30K

(18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

(22) 52.219-28, Post Award Small Business Program Representation (Jul 2013) (15 U.S.C. 632(a)(2)).

(25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

(27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(28) (i) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793). (33)(i) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter 78 and E.O. 13627).

(33)(i) 52.222-50, Combating Trafficking in Persons (Jan 2019) (22 U.S.C. chapter 78 and E.O. 13627).

(36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (Jun 2016) (E.O. 13693).

(37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (Jun2016) (E.O. 13693). REMOVE IF NO HVAC CLINS

(42) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011) (E.O. 13513).

(49) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

(55) 52.232-33, Payment by Electronic Funds Transfer. System for Award Management (Oct 2018) (31 U.S.C. 3332).

(a) (b)

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records—Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (JUL 2018) (Section 1634 of Pub. L. 115-91).

(iv) 52.219-8, Utilization of Small Business Concerns (Oct 2018) (15 U.S.C. 637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(v) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in accordance with paragraph (l) of FAR clause 52.222-17.

(vi) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)

(vii) 52.222-26, Equal Opportunity (Sept 2016) (E.O. 11246).

(viii) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(ix) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(x) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)

(xi) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xii) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67).

(xiii) (a) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627).

(xiv) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xv) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xvi) 52.222-54, Employment Eligibility Verification (OCT 2015) (E.O. 12989).

(xvii) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

(xviii) 52.222-62, Paid Sick Leave Under Executive Order 13706 (JAN 2017) (E.O. 13706).

(xix)(A) 52.224-3, Privacy Training (JAN 2017) (5 U.S.C. 552a).

(B) Alternate I (JAN 2017) of 52.224-3.

(xx) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxi) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx. 1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause) Full Text Clauses

52.204-21 Basic Safeguarding of Covered Contractor Information Systems.

(a) Definitions. As used in this clause– “Covered contractor information system” means an information system that is owned or operated by a contractor that processes, stores, or transmits Federal contract information.

“Federal contract information” means information, not intended for public release, that is provided by or generated for the Government under a contract to develop or deliver a product or service to the Government, but not including information provided by the Government to the public (such as on public websites) or simple transactional information, such as necessary to process payments.

“Information” means any communication or representation of knowledge such as facts, data, or opinions, in any medium or form, including textual, numerical, graphic, cartographic, narrative, or audiovisual (Committee on National Security Systems Instruction (CNSSI) 4009).

“Information system” means a discrete set of information resources organized for the collection, processing, maintenance, use, sharing, dissemination, or disposition of information (44 U.S.C. 3502).

“Safeguarding” means measures or controls that are prescribed to protect information systems.

(b) Safeguarding requirements and procedures.

(1) The Contractor shall apply the following basic safeguarding requirements and procedures to protect covered contractor information systems. Requirements and procedures for basic safeguarding of covered contractor information systems shall include, at a minimum, the following security controls:

(i) Limit information system access to authorized users, processes acting on behalf of authorized users, or devices (including other information systems).

(ii) Limit information system access to the types of transactions and functions that authorized users are permitted to execute.

(iii) Verify and control/limit connections to and use of external information systems.

(iv) Control information posted or processed on publicly accessible information systems.

(v) Identify information system users, processes acting on behalf of users, or devices.

(vi) Authenticate (or verify) the identities of those users, processes, or devices, as a prerequisite to allowing access to organizational information systems.

(vii) Sanitize or destroy information system media containing Federal Contract Information before disposal or release for reuse.

(viii) Limit physical access to organizational information systems, equipment, and the respective operating environments to authorized individuals.

(ix) Escort visitors and monitor visitor activity; maintain audit logs of physical access; and control and manage physical access devices.

(x) Monitor, control, and protect organizational communications (i.e., information transmitted or received by organizational information systems) at the external boundaries and key internal boundaries of the information systems.

(xi) Implement subnetworks for publicly accessible system components that are physically or logically separated from internal networks.

(xii) Identify, report, and correct information and information system flaws in a timely manner.

(xiii) Provide protection from malicious code at appropriate locations within organizational information systems.

(xiv) Update malicious code protection mechanisms when new releases are available.

(xv) Perform periodic scans of the information system and real-time scans of files from external sources as files are downloaded, opened, or executed.

(2) Other requirements. This clause does not relieve the Contractor of any other specific safeguarding requirements specified by Federal agencies and departments relating to covered contractor information systems generally or other Federal safeguarding requirements for controlled unclassified information (CUI) as established by Executive Order 13556.

(c) Subcontracts. The Contractor shall include the substance of this clause, including this paragraph (c), in subcontracts under this contract (including subcontracts for the acquisition of commercial items, other than commercially available off-the-shelf items), in which the subcontractor may have Federal contract information residing in or transiting through its information system.

(End of Clause)

52.219-6 Notice of Total Small Business Set-Aside (DEVIATION 2019-01) USE IF DOING A TOTAL SMALL BUSINESS SET-ASIDE

(a) Definition. Small business concern, as used in this clause, means a concern, including its affiliates that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the size standards in this solicitation.

(b) Applicability. This clause applies only to—

(1) Contracts that have been totally set aside or reserved for small business concerns; and

(2) Orders set aside for small business concerns under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).

(c) General.

(1) Offers are solicited only from small business concerns. Offers received from concerns that are not small business concerns shall be considered nonresponsive and will be rejected.

(2) Any award resulting from this solicitation will be made to a small business concern.

(d) Agreement.

(1) For a contract at or below the simplified acquisition threshold, a small business concern may provide the end item of any firm. For a contract exceeding the simplified acquisition threshold, a small business concern that provides an end item it did not manufacture, process, or produce, shall—

(i) Provide an end item that a small business has manufactured, processed, or produced in the United States or its outlying areas;

(ii) Be primarily engaged in the retail or wholesale trade and normally sell the type of item being supplied; and

(iii) Take ownership or possession of the item(s) with its personnel, equipment, or facilities in a manner consistent with industry practice; for example, providing storage, transportation, or delivery.

(2) Paragraph (d)(1) of this clause does not apply to construction or service contracts.

(End of Clause)

52.237-1 Site Visit This RFQ is for the dockside repairs of the USCGC ROBERT G. WARD (WPC-1130) hereinafter referred to as “vessel.” The vessel will be located in San Pedro, CA. The point of contact for site surveys is LTJG Joseph Rizzardi, who can be reached at (703) 943-0590 or via email Joseph.A.Rizzardi@uscg.mil. Contractors are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award. . Site Visits/Ship Check should be scheduled and completed NLT 17 February 2020

52.252-6 Authorized Deviations in Clauses

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter

1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Homeland Security Acquisition Regulation (48 CFR 30) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

Homeland Security Acquisition Regulation (HSAR) Clauses

HSAR 3052.212-70 Contract Terms and Conditions Applicable To DHS Acquisition of Commercial Items.

The Contractor agrees to comply with any provision or clause that is incorporated herein by reference to implement agency policy applicable to acquisition of commercial items or components. The provision or clause in effect based on the applicable regulation cited on the date the solicitation is issued applies unless otherwise stated herein. The following provisions and clauses are incorporated by reference:

(b) Clauses.

3052.204-71 Contractor Employee Access 3052.217-91 Performance 3052.217-92 Inspection and Manner of Doing Work 3052.217-93 Subcontracts 3052.217-95 Liability and Insurance 3052.217-96 Title 3052.217-97 Discharge of Liens 3052.217-98 Delays 3052.217-99 Department of Labor Safety and Health Regulations for Ship Repair 3052.228-70 Insurance 3052.242-72 Contracting Officer’s Technical Representative

(End of clause)

HSAR 3052.217-100 Guarantee (USCG).

(a) In the event any work performed or materials furnished by the contractor prove defective or deficient within 60 days from the date of redelivery of the vessel(s), the Contractor, as directed by the Contracting Officer and at its own expense, shall correct and repair the deficiency to the satisfaction of the Contracting Officer.

(b) If the Contractor or any subcontractor has a guarantee for work performed or materials furnished that exceeds the 60 day period, the Government shall be entitled to rely upon the longer guarantee until its expiration.

(c) With respect to any individual work item identified as incomplete at the time of redelivery of the vessel(s), the guarantee period shall run from the date the item is completed.

(d) If practicable, the Government shall give the Contractor an opportunity to correct the deficiency.

(1) If the Contracting Officer determines it is not practicable or is otherwise not advisable to return the vessel(s) to the Contractor, or the Contractor fails to proceed with the repairs promptly, the Contracting Officer may direct that the repairs be performed elsewhere, at the Contractor's expense.

(2) If correction and repairs are performed by other than the Contractor, the Contracting Officer may discharge the Contractor's liability by making an equitable deduction in the price of the contract.

(e) The Contractor's liability shall extend for an additional 60-day guarantee period on those defects or deficiencies that the Contractor corrected.

(f) At the option of the Contracting officer, defects and deficiencies may be left uncorrected. In that event, the Contractor and Contracting Officer shall negotiate an equitable reduction in the contract price. Failure to agree upon an equitable reduction shall constitute a dispute under the Disputes clause of this contract.

(End of clause)

52.252-2 Clauses Incorporated by Reference

This solicitation incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also the full text of the clause may be accessed electronically at Internet address http://acquisition.gov/far/index.html.

Contract Administration

(a) Invoicing Instructions

(1) The contractor shall prepare a proper invoice IAW FAR 52.212-4, and in addition to the information required by FAR 52.212-4(g) as cited in the contract. All invoices shall be itemized to correlate to the Schedule of Supplies/Services. The invoice shall include:

· Vessel Name

· Name of the Contract Specialist, Contracting Officer, and COR

· Contractor DUNS Number

· Name, title, phone number and mailing address of Contractor point of contact for invoicing questions

· CLIN Number, CLIN description, quantity, unit price, and extended price.

· Percentage completion of each CLIN being invoiced

· Description of any invoice deductions.

· 10% of the total contract price will be withheld until all deliverables are received and accepted.

· The Contractor’s final invoice submitted under the contract shall be marked as follows: THIS INVOICE CONSTITUTES THE FINAL INVOICE – UPON PAYMENT OF THIS INVOICE NO OTHER MONIES ARE DUE UNDER CONTRACT NUMBER (to be assigned upon contract award).

(2) Invoices shall be submitted electronically as follows:

1. Invoices shall be submitted to the USCG Finance Center Website at http://www.fincen.uscg.mil/electron_cg24.htm

2. The web submission requires the Contractor to complete the Invoice Receipt Cover Form, select the Invoice Routing Code, and attach a PDF file of the invoice and any other supporting documentation.

3. The Contractor must select the correct Invoice Routing Code for timely invoice processing. The Invoice Routing Code for this contract is SFLC-1. Failure to do so will delay invoice payment.

4. The Contractor shall attach a single PDF file no larger than 1MB as the official invoice.

5. The Contractor shall email a copy of the invoice and supporting documentation to the Contract Specialist and the Contracting Officer’s Representative (COR).

6. A CLIN may not be invoiced until a minimum of 25% completion. This percentage minimum may be waived on a case-by-case basis by the Contracting Officer for large dollar CLINS. In addition, 10% of the total contract price will be withheld until all deliverables are received and accepted.

7. A sample of the Invoice Receipt Cover Form is provided below.