36C25019B0015-020.pdf

TECHNICAL SPECIFICATIONS

Department of Veterans Affairs Louis Stokes Cleveland VA Medical Center

WADE PARK

10701 East Boulevard Cleveland, OH 44106

Repair Outdoor Ductwork Insulation Project No. 541-18-511

PREPARED BY:

Perspectus Architecture 13212 Shaker Square Cleveland, Ohio 44120

P (216) 752-1800 F (216) 752-3833 Project Director: Tim Huffman

Fredrick, Fredrick & Heller Engineers

672 East Royalton Road Broadview Heights, Ohio 44147

P (440) 546-9696 F (440) 546-9699 Project Director: Lenny Hendrix

100% CONSTRUCTION

DOCUMENTS SUBMISSION

ISSUE DATE: October 12, 2018 bweygandt Stamp

100% Construction Documents VAMC WADE PARK

10/12/18 Repair Outdoor Ductwork Insulation

Table of Contents

00 01 10 - 1

DEPARTMENT OF VETERANS AFFAIRS

SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

SECTION DESCRIPTION PAGES

DIVISION 0 - SPECIAL SECTIONS

00 01 10 Table of Contents 1-2

00 01 15 Drawing Index 1-1

DIVISION 1 - GENERAL REQUIREMENTS

01 00 00 General Requirements 1-8

GENERAL REQUIREMENTS ATTACHMENTS

OSHA Requirements and Safety And Health Regulations –

Attachment 1

1-7

Pre-Construction Risk Assessment (PCRA) – Att. 2 1-4

Construction Safety Poster - Cleveland VA – Att. 3 1-1

Interim Life Safety Risk Assessment Form – Att.4 4ment 4 1-2

Contractor Safety and Security Orientation – Att.5 1-1

Job Safety Check Sheet - Attachment 6 1-2

01 32 16.15 Project Schedule 1-11

01 33 23 Shop Drawings, Product Data, and Samples 1-7

01 35 26 Safety Requirements 1-27

Site Specific Accident Prevention Plan - Sample

Infection Control During Construction

Infection Control Risk Assessment

Infection Control Orientation for Construction Workers

Infection Control Construction Permit

Infection Control Construction Inspection Form

01 42 19 Reference Standards 1-4

01 45 00 Quality Control 1-16

01 74 19 Construction Waste Management 1-6

DIVISION 2 – EXISTING CONDITIONS

02 41 00 Demolition 1-3

DIVISION 3 – CONCRETE

Not Used

DIVISION 4 – MASONRY

Not used

Table of Contents

00 01 10 - 2

DIVISION 5 – METALS

DIVISION 6 - WOOD, PLASTICS AND COMPOSITES

DIVISION 7 - THERMAL AND MOISTURE PROTECTION

07 92 00 Joint Sealants 1-7

DIVISIONS 8 - 22

DIVISION 23 – HEATING, VENTILATING, AND AIR CONDITIONING

23 05 11 Common Work Results for HVAC 1-17

23 07 11 HVAC and Boiler Plant Insulation 1-10

DIVISIONS 26 Through 34

- - - E N D - - -

90% Construction Documents VAMC WADE PARK

Drawing Index

00 01 15 - 1

SECTION 00 01 15

DRAWING INDEX

The Drawings listed below accompanying this Specification form a part of the

Contract.

DRAWING NO. TITLE

GENERAL

1-X.1 COVER SHEET

MECHANICAL

1-M0 MECHANICAL LEGEND, GENERAL NOTES, AND DETAILS.

1-M2A PARTIAL ROOF/SECOND FLOOR DUCTWORK PLAN – AREA “A”.

1-M2B PARTIAL ROOF/SECOND DUCTWORK FLOOR PLAN – AREA “B”.

1-M2C PARTIAL ROOF/SECOND DUCTWORK FLOOR PLAN – AREA “C”.

1-M2D PARTIAL ROOF/SECOND DUCTWORK FLOOR PLAN – AREA “D”.

1-M3 PARTIAL ROOF/THIRD DUCTWORK FLOOR PLAN – AREA “E”.

GENERAL REQUIREMENTS

01 00 00 - 1

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

ARTICLE NUMBER AND SUBJECT PAGE NO.

1.1 APPLICABLE PUBLICATIONS 2

1.2 DEFINITIONS 3

1.3 REGULATORY REQIREMENTS 5

1.4 ACCIDENT PREVENTION PLAN (APP) 5

1.5 ACTIVITY HAZARD ANALYSES (AHAS) 10

1.6 PRECONSTRUCTION CONFERENCE 11

1.7 “SITE SAFETY AND HEALTH OFFICER” (SSHO) AND “COMPETENT PERSON” (CP) 12

1.8 TRAINING 13

1.9 INSPECTIONS 14

1.10 ACCIDENTS, OSHA 300 LOGS, AND MAN-HOURS 15

1.11 PERSONAL PROTECTIVE EQUIPMENT (PPE) 16

1.12 INFECTION CONTROL 16

1.13 TUBERCULOSIS SCREENING 24

1.14 FIRE SAFETY 24

1.15 ELECTRICAL 27

1.16 FALL PROTECTION 28

1.17 SCAFFOLDS AND OTHER WORK PLATFORMS 29

1.18 CONFINED SPACE ENTRY 29

1.19 WELDING AND CUTTING 30

1.20 LADDERS 30

1.21 FLOOR & WALL OPENINGS 30

ATTACHMENTS

OSHA Requirements and Safety and Health Regulations - Attachment 1

Pre-Construction Risk Assessment - Attachment 2

Construction Safety Poster - Cleveland VA - Attachment 3

Interim Life Safety Risk Assessment Form - Attachment 4

Contractor Safety and Security Orientation - Attachment 5

Job Safety Check Sheet - Attachment 6

01 00 00 - 2

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare work sites for demolition and new construction operations, and furnish labor and materials and perform work for Remove Sterile Steam Humidifiers - Project No. 541-18-511 as required by Drawings and specifications.

B. Visits to the site by Bidders may be made only by appointment with the

Medical Center Engineering Officer.

C. Offices of Perspectus Architecture, as the Architect/Engineer representative, will render certain technical services during construction. Such services shall be considered as advisory to the

Government and shall not be construed as expressing or implying a

Contractual act of the Government without affirmations by Contracting

Officer or his duly authorized representative.

E. All employees of Contractor and Subcontractors shall comply with VA security management program and obtain permission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I – BASE BID: Mechanical Work includes all labor, material, equipment and supervision to perform the required mechanical-related demolition and new construction work on this Project including the removal of existing insulation from around existing ductwork and the installation of new insulation materials and wraps complete with all accessories and finish products.

B. ALTERNATE NO.1: Alternate #1: Deduct from the Base Bid, all Work indicated on Drawing #1-M2A “Partial Roof Second Floor Ductwork

Plan”.

C. ALTERNATE NO. 2: Deduct all Work from the Base Bid all Work shown on Drawing #1-M3.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and Contract Documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense, 01 00 00 - 3

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and administrative security procedures that will remain effective for the entire duration of the project.

2. The Contractor is responsible for assuring that all Subcontractors working on the project and their employees also comply with these regulations.

B. Security Procedures:

1. Contractor’s employees shall not enter the project site without appropriate badge. They may also be subject to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the Contractor shall give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separate from any notices required for utility shutdown described later in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order Contractor’s employees off the premises in the event of a national emergency. The Contractor may return to the site only with the written approval of the Contracting Officer.

C. Document Control:

1. Before starting any work, the Contractor/Sub Contractors shall submit an electronic security memorandum describing the approach to following goals and maintaining confidentiality of “sensitive information”.

2. The Contractor is responsible for safekeeping of all Drawings, project manual and other project information. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photographs and Drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Return the information to the Contracting Officer upon request.

4. These security documents shall not be removed or transmitted from the project site without the written approval of Contracting Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

01 00 00 - 4

6. Notify Contracting Officer and Site Security Officer immediately when there is a loss or compromise of “sensitive information”.

7. All electronic information shall be stored in specified location following VA standards and procedures using an Engineering Document

Management Software (EDMS).

a. Security, access and maintenance of all project Drawings, both scanned and electronic shall be performed and tracked through the

EDMS system.

b. “Sensitive information” including Drawings and other documents may be attached to e-mail provided all VA encryption procedures are followed.

D. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitted 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

2. A limited number of (2 to 5) permits shall be issued for Contractor and its employees for parking in designated areas only.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (including storage of materials) on Government premises to areas authorized or approved by the

Contracting Officer. The Contractor shall hold and save the Government, its officers and agents, free and harmless from liability of any nature occasioned by the Contractor's performance.

B. The Contractor shall, under regulations prescribed by the Contracting

Officer, use only established roadways, when and as authorized by the

Contracting Officer.

C. Working space and space available for storing materials shall be as determined by the COR.

D. All Buildings will be occupied during performance of work, but immediate areas of alterations will be available for Contractor access.

1. Contractor shall take all measures and provide all material necessary for protecting existing equipment and property in affected areas of construction against dust and debris, so that equipment and affected areas to be used in the Medical Centers operations will not be hindered. Contractor shall permit access to Department of Veterans

Affairs personnel through other construction areas which serve as routes of access to such affected areas and equipment. Coordinate alteration work in areas occupied by Department of Veterans Affairs so that Medical Center operations will continue during the construction period.

01 00 00 - 5

2. Immediate areas of ductwork insulation replacement and related alterations not mentioned in preceding Subparagraph 1 will be temporarily vacated while alterations are performed.

E. Utilities Services: Maintain all existing utility services for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uninterrupted services.

1. No utility service such as water, gas, steam, roof drains or electricity, or fire protection systems and communications systems may be interrupted without prior approval of COR. Electrical work shall be accomplished with all affected circuits or equipment de-energized. When an electrical outage cannot be accomplished, work on any energized circuits or equipment shall not commence without a detailed work plan, the Medical Center Director’s prior knowledge and written approval.

2. Contractor shall submit a request to interrupt any such services to

COR, in writing, 7 days in advance of proposed interruption. Request shall state reason, date, exact time of, and approximate duration of such interruption.

3. Contractor will be advised (in writing) of approval of request, or of which other date and/or time such interruption will cause least inconvenience to operations of Medical Center. Interruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be requested, in writing, at least 15 calendar days prior to the desired time and shall be performed as directed by the COR.

5. In case of a construction emergency, service will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

1.7 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work removed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of the Government are identified by attached tags or noted on Drawings or in Specifications as items to be stored. Items that remain property of the Government shall be removed or dislodged from present locations in such a manner as to prevent damage which would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

01 00 00 - 6

1.8 AS-BUILT DRAWINGS

A. The Contractor shall maintain two full size sets of As-Built Drawings which will be kept current during construction of the project, to include all Contract changes, modifications and clarifications.

B. All variations shall be shown in the same general detail as used in the

Contract Drawings. To insure compliance, As-Built Drawings shall be made available for the COR review, as often as requested.

C. Contractor shall deliver two approved completed sets of As-Built

Drawings in the electronic version (scanned PDF) to the COR within 15 calendar days after each completed phase and after the acceptance of the project by the COR

D. Paragraphs A, B, & C shall also apply to all Shop Drawings.

1.9 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of existing mechanical and electrical equipment to provide heat, ventilation, plumbing, light and power will be permitted subject to written approval and compliance with the following provisions:

1. If the equipment is not installed and maintained in accordance with the written agreement and following provisions, the COR will withdraw permission for use of the equipment.

B. Prior to final inspection, the ductwork or parts used which show wear and tear beyond normal, shall be replaced with identical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the Mechanical

Specification requirements.

1.10 TEMPORARY USE OF EXISTING ELEVATORS

A. Use of existing elevators for handling building materials and

Contractor's personnel will be permitted subject to following provisions:

1. Contractor makes all arrangements with the COR for use of elevators.

The COR will ascertain that elevators are in proper condition.

Contractor may use elevators for daily use and for special nonrecurring time intervals when permission is granted. Personnel for operating elevators will not be provided by the Department of

Veterans Affairs.

2. Contractor covers and provides maximum protection of following elevator components:

a. Entrance jambs, heads soffits and threshold plates.

b. Entrance columns, canopy, return panels and inside surfaces of car enclosure walls.

01 00 00 - 7

c. Finish flooring.

1.11 TEMPORARY TOILETS

A. Contractor may have for use of Contractor's workmen, such toilet accommodations as may be assigned to Contractor by Medical Center.

Contractor shall keep such places clean and be responsible for any damage done thereto by Contractor's workmen. Failure to maintain satisfactory condition in toilets will deprive Contractor of the privilege to use such toilets.

1.12 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably required amounts of utilities available to the Contractor from existing outlets and supplies, as specified in the Contract. The Contractor shall carefully conserve any utilities furnished without charge.

B. Electricity (for Construction): Furnish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system is available at no cost to the Contractor.

C. Water (for Construction): Furnish temporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Water is available at no cost to the Contractor.

1.13 INSTRUCTIONS

A. Contractor shall furnish Maintenance manuals (hard copies and electronic) and verbal instructions when required by the various sections of the Specifications and as hereinafter specified.

B. Manuals: Maintenance manuals and one compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidental with the delivery of materials to the job site. Manuals shall be complete, detailed guides for the maintenance.

OSHA Requirements and Safety and Health Regulations

PART 1 - OSHA Requirements

1.1 General

A. Contractors are required to comply with the Occupational Safety and Health Act of 1970.

This will include the safety and health standard found in Code of Federal Regulations (CFR)

1910 and 1926. Copies of those standards can be obtained from the Superintendent of

Documents, U.S. Government Printing Office, Washington, D.C., 20420.

B. In addition, Contractor will be required to comply with other applicable Medical Center policies and safety regulations. These policies and regulations will be presented to the

Contractor at the pre-construction meeting. Each of the Contractor’s employees will be required to read the statement of policies and regulations, and sign an acknowledgment that such policies and regulations are understood. Signed acknowledgment will be returned to the

Contract Officer Technical Representative.

C. Contractors involved with the removal, alteration or disturbance of asbestos-type insulation or materials or lead paint will be required to comply strictly with the regulations found in

CFR 1910.1001 and the appropriate Environmental Protection Agency (EPA) lead regulations regarding disposal of asbestos or lead paint. Assistance in identifying asbestos or lead can be requested from the Medical Center’s Industrial Hygienist and the COR.

D. Contractors entering locations of asbestos contamination or lead paint residue (i.e., pipe, basements, walls, windows) shall be responsible for providing respiratory protection to their employees and ensuring respirators are worn in accordance with the Occupational Safety and

Health Administration (OSHA) [CFR 1910.1001(g)]. Asbestos-or lead paint-contaminated areas shall be defined on project drawings. The minimum equipment requirements will be a half-mask air-purifying respirator equipped with high efficiency filters and disposable coveralls, or as determined by air monitoring results.

E. Contractor, along with other submittals and at least two weeks prior to bringing any materials on-site, must submit a complete list of chemicals the Contractor will use and Material Safety

Data Sheets (MEDS) for all hazardous materials as defined in OSHA 1910.1200(d), Hazard

Determination. Contracting Officer shall have final approval of all materials brought on site.

F. The Contractor will be held solely responsible for the safety and health of their employees.

The contractor will also be held responsible for protecting the health and safety of the VA

Community (patients, staff, and visitors) from the unwanted effects of construction. VA staff will monitor the Contractor's performance in complying with all safety and health aspects of the project. Severe or constant violations may result in an immediate work stoppage or request for a Compliance Officer from the Occupational Safety and Health

Administration.

G. During all phases of demolition, construction and alterations, Contractors are required to understand and strictly follow National Fire Protection Association (NFPA) 241, Standard

OSHA Requirements and Safety and Health Regulations - Attachment 1 for Safeguarding Construction, Alteration and Demolition Operations. The Medical Center’s

Safety and Occupational Health Specialist or Industrial Hygienist will closely monitor the work area for compliance. Appropriate action will be taken for non-compliance.

PART 2 - Specific VA Medical Center Fire and Safety Policies, Procedures and Regulations

2.1 Introduction.

A. The safety and fire protection of patients, employees, members of the public and government is one of continuous concern to this Medical Center.

B. Contractors, their supervisors and employees are required to comply with Medical Center policies to ensure the occupational safety and health of all. Failure to comply may result in work stoppage.

C. While working at this Medical Center, contractors are responsible for the occupational safety and health of their employees. Contractors are required to comply with the applicable OSHA standards found in 29 CFR 1910 for general industry and 29 CFR 1926 for construction.

Failure to comply with these standards may result in work stoppage and a request to the Area

Director of OSHA for a Compliance Officer to inspect your work site.

D. Contractors are to comply with the requirements found in the National Fire Protection

Association (NFPA) 241, Building Construction and Demolition Operation, and NFPA 51B, Fire Prevention in Use of Cutting and Welding Processes.

E. Questions regarding occupational safety and health issues can be addressed to the Medical

Center Safety and Occupational Health Specialist (ext. 4172) or Industrial Hygienist (ext.

4628).

F. Smoking is not permitted in any interior areas of the Medical Center, including all interior stairwells, tunnels, construction and/or service/maintenance sites. Compliance with this policy by your direct and subcontracted labor force is required.

2.2 Hazard Communication

A. Contractors shall comply with OSHA Standard 29 CFR 1926.59, Hazard Communication.

B. Contractors shall submit to the VA Safety Officer, copies of MSDS covering all hazardous materials to which the Contractor and VA employees are exposed.

C. Contractors shall inform the Safety Officer of the hazards to which VA personnel and patients may be exposed.

D. Contractors shall have a written Hazard Communication Program available at the construction site, which details how the Contractor will comply with 29 CFR 1926.59.

2.3 Fires

OSHA Requirements and Safety and Health Regulations - Attachment 1

A. All fires must be reported. In the event of a fire in your work area, use the nearest pull box station, and also notify Medical Center staff in the immediate area. Emergency notification can also be accomplished by dialing ext. 2222.

B. Be sure to give the exact location from where you are calling and the nature of the emergency. If a Contractor experiences a fire that was rapidly extinguished by your staff, you still must notify the Construction Safety Officer (ext. 4172) within an hour of the event so that an investigation of the fire can be accomplished.

2.4 Fire Alarms, Smoke Detection and Sprinkler System

If the nature of your work requires the deactivation of the fire alarm, smoke detection or sprinkler system, you must notify the Safety Office. Notification must be made well in advance so that ample time can be allowed to deactivate the system and provide alternative measures for fire protection. Under no circumstance is a Contractor allowed to deactivate any of the fire protection systems in this Medical Center.

2.5 Smoke Detectors

False alarms will not be tolerated. You are required to be familiar with the location of the smoke detectors in your work area. When performing cutting, burning or welding or any other operations that may cause smoke or dust, you must take steps to temporarily cover smoke detectors in order to prevent false alarms. Failure to take the appropriate action will result in the Contracting Officer assessing actual costs for government response for each false alarm that is preventable. Prior to covering the smoke detectors, the Contractor will notify the

Safety Officer, who will also be notified when the covers are removed.

2.6 Hot Work Permit

A. Hot work is defined as operations including, but not limited to, cutting, welding, thermal welding, brazing, soldering, grinding, thermal spraying, thawing pipes or any similar situation. If such work is required, whenever possible the Contractor must notify the COR no less than one day in advance of such work. The Competent Hot Work Supervisor

(CHWS) will inspect the work area and issue a Hot Work Permit, authorizing the performance of such work.

B. All hot work will be performed in compliance with the Engineering Service Policy 138-047 regarding Hot Work Permits and NFPA 241, Safeguarding Construction, Alternation and

Demolition Operations; and NFPA 51B, Fire Prevention in Use of Cutting and Welding

Processes; and applicable OSHA standard. A hot work permit will only be issued to individuals familiar with these regulations.

C. A Hot Work Permit will be issued only for the period necessary to perform such work. In the event the time necessary will exceed one day, a Hot Work Permit may be issued for the period needed; however, the CHWS will inspect the area daily. Hot Work Permit will apply only to the location identified on the permit. If additional areas involve hot work, then additional permits must be requested.

D. Contractors will not be allowed to perform hot work processes without the appropriate permit.

E. Any work involving the Medical Center’s fire protection system will require advance notification. Under no circumstance will the Contractor or employee attempt to alter or tamper with the existing fire protection system.

F. Thirty minutes following completion of the hot work, the Fire Watch will perform an inspection of the area to confirm that sparks or drops of hot metal are not present.

2.7 Temporary Enclosures

Only non-combustible materials will be used to construct temporary enclosures or barriers at this

Medical Center. Plastic materials and fabrics used to construct dust barriers must conform to

NFPA 701, Standard Methods of Fire Tests for Flame-Resistant Textiles and Films.

2.8 Flammable Liquids

All flammable liquids will be kept in approved safety containers. Only the amount necessary for your immediate work will be allowed in the building. Flammable liquids must be removed from the building at the end of each day.

2.9 Compressed Gas Cylinders

Compressed gas shall be secured in an upright position at all times. A suitable cylinder cart will be used to transport compressed gas cylinders. Only those compressed gas cylinders necessary for immediate work will be allowed in occupied buildings. All other compressed gas cylinders will be stored outside of buildings in a designated area. Contractors will comply with applicable standards compressed gas cylinders found in 29 CFR 1910 and 1926 (OSHA).

2.10 Internal Combustion Engine-Powered Equipment

Equipment powered by an internal combustion engine (such as saws, compressors, generators, etc.)

will not be used in an occupied building. Special consideration may be given for unoccupied buildings only if the OSHA and NFPA requirements have been met.

2.11 Powder-Activated Tools

The operator of powder-activated tools must be trained and certified to use them. Powder-activated tools will be kept secured at all times. When not in use, the tools will be locked up.

When in use, the operator will have the tool under his immediate control.

2.12 Tools

A. Under no circumstances will equipment, tools and other items of work to be left unattended for any reason. All tools, equipment and items of work must be under the immediate control of your employee.

01 00 00 - 5

B. If for some reason a work area must be left unattended, then tools and other equipment must be placed in an appropriate box or container and locked. All tool boxes, containers or any other device used for the storage of tools and equipment will be provided with a latch and padlock, and will be kept locked at all times, except for putting in and removing tools.

C. All doors to work areas will be closed and locked when room is left unattended. Failure to comply with this policy will be considered a violation of VA Regulations 1.218(b), Failure to comply with signs of a directive and restrictive nature posted for safety purposes, and subject to a $50.00 fine. Subsequent similar violations may result in both imposition of such a fine as well as the Contracting Officer taking action under the contract’s Accident Prevention Clause [Federal Acquisition Regulation

(FAR) 52.236-13] to suspend all contract work until violations may be satisfactorily resolved, or under FAR 52.236-5, Material and Workmanship Clause, to remove from the worksite any personnel deemed by the Contracting Officer to be careless to the point of jeopardizing the welfare of facility patients or staff.

D. You must report any tools or equipment that are missing to the VA Police Department.

E. Tools and equipment found unattended will be confiscated and removed from the work area.

2.13 Ladders

Ladders must not be left unattended in an upright position. Ladders must be attended at all times or taken down, and chained securely to a stationary object.

2.14 Scaffolds

All scaffolds will be attended at all times. When not in use, an effective barricade (fence) will be erected around the scaffold to prevent use by unauthorized personnel (Reference OSHA 1926, Subpart L).

2.15 Excavations

The contractor shall comply with OSHA 1926, Subpart P. An OSHA Competent Person must be on site during the excavation. The contractor shall coordinate with the COR and utility companies prior to the excavation to identify underground utilities tanks, etc. All excavations left unattended will be provided with a barricade suitable to prevent entry by unauthorized persons.

2.16 Storage

You must make prior arrangements with the COR for the storage of building materials. Storage will not be allowed to accumulate in the Medical Center buildings.

2.17 Trash and Debris

01 00 00 - 6

OSHA Requirements and Safety and Health Regulations - Attachment 1

You must remove all trash and debris from the work area on a daily basis. Trash and debris will not be allowed to accumulate inside or outside of the buildings. You are responsible for making arrangements for removal of trash from the Medical Center facility.

2.18 Protection of Floors

It may be necessary at times to take steps to protect floors from dirt, debris, paint, etc. A tarp or other protective covering may be used. However, you must maintain a certain amount of floor space for the safe passage of pedestrian traffic. Common sense must be used in this matter.

2.19 Signs

Signs must be placed at the entrance to work areas warning people of your work. Signs must be suitable for the condition of the work. Small pieces of paper with printing or writing are not acceptable. The VA Medical Center (VAMC) Safety Officer or COR can be consulted in this matter.

2.20 Accidents and Injuries

Contractors must report all accidents and injuries involving their employees.

2.21 Infection Control

Contractors must control the generation of dust and the contamination of patient care surfaces, supplies and equipment. During demolition phases of the construction:

A. The construction area shall be under negative pressure, ensuring there is an appreciable flow of clean air from the VA-occupied portion of the facility into the construction area. The airflow shall be sufficiently strong enough to draw in the plastic door flaps commonly located at the construction entrance or at the specific site within the construction area.

B. Construction debris being transported through the VA-occupied portion of the facility shall be covered and/or whetted.

C. Construction employees shall remove dust-laden clothing before entering the VA-occupied portion of the facility.

D. Carpet/sticky mats shall be placed at all construction entrances, and be satisfactorily maintained so as to minimize the tracking of dust into the VA-occupied portion of the facility.

E. Dry sweeping of dust and debris is not to be performed.

(Control measures B - E above must be practiced during the construction phase.)

2.22 Confined Space Entry

01 00 00 - 7

OSHA Requirements and Safety and Health Regulations - Attachment 1

A. Contractor will be informed that the workplace contains permit-required confined space, and that permit-space entry is allowed only through compliance with a permit space program meeting the requirements of 29 CFR 1910.146 and 1926.21(b)(6).

B. Contractor will be apprised of the elements including the hazards identified and the Medical

Center’s (last employer) experience with the space that makes the space in question a permit space.

C. Contractor will be apprised of any precautions or procedures that the Medical Center has implemented for the protection of employees in or near permit space where Contractor personnel will be working.

D. Medical Center and Contractor will coordinate entry operations when both Medical Center personnel and Contractor personnel will be working in or near permit spaces as required by

29 CFR 1910.146(d)(ii) and 1926.21(b)(6).

E. Contractor will obtain any available information regarding permit space hazards and entry operation from the Medical Center.

F. At the conclusion of the entry operations, the Medical Center and Contractor will discuss any hazards confronted or created in permit spaces.

G. The Contractor is responsible for complying with 29 CFR 1910.246(d) through (g) and

1926.21(b)(6). The Medical Center, does not provide rescue and emergency services required by 29 CFR 1910.246(k) and 1926.21(b)(6).

2.23 Contractor Parking and Material Delivery

There is no Contractor parking on Medical Center property unless the contract drawings show a designated staging area that is under the Contractor’s control.

Contractor's delivery of building materials tools, etc., must be pre-arranged with the Project

Manager.

Safety and Health During Construction Activities - Attachment 2

Pre Construction Risk Assessment (PCRA)

Project: _______________________________ Project/Contract #: ________________

This form may be used for projects or activities to determine if a Site Specific Safety Plan (SSSP) is necessary. If the contractor or vendor is not working independently (VAMC Supervisor is present and in control of the contractor) and the job is short duration (less than five working days) and the hazard analysis does not include any high risk activities, then Occupational Health and Safety may allow work without submitting a SSSP.

Activity Yes High Risk

1. Respiratory protection is required for the work being conducted

List specifics: (activity being preformed, PPE Being used, Training, Fit testing).

2. Hearing protection is required for the work being conducted

List specifics: (Type of noise; impact, constant, start up).

3. Other personal protective equipment is required for the work being conducted, what activity? ________________________________

List specifics: (Gloves, safety Glasses, hard hat, steel toes, overalls).

4. Are there overhead hazards associated with the activity being conducted?

Wires, power, communication, grounding, location(s), signage.

List specifics:

Yes

5. Work is being conducted in a confined space. Permit required? Training?

List specifics: Tanks, sewer, tunnels, Rescue Team notification.

PRCS

Only

6. Ladders will be necessary for the work being conducted.

7. Scaffolding will be necessary for the work being conducted.

List specifics:

Greater than six feet

8. Other work platforms will be necessary for the work being conducted.

List specifics: Rails, toe boards, netting

Greater than six feet

9. Fall protection is required for the work being conducted.

Yes

Safety and Health During Construction Activities - Attachment 2

10. ASBESTOS Abatement

Exposure to asbestos may be associated with the work being conducted.

List specifics: Renovation, Demolition, Emergency Response

29 CFR 1910.1001.

unless approved by the

Asbestos

Manager

Activity Yes High Risk

11. Hazardous materials will be used.

MSDSs will be provided for known substances

List specifics: 29 CFR 1910.1200.

12. Hot work (Cutting, Welding, Brazing, etc).

Use of VAMC Cleveland Hot Work Policy (ECP 138-047) is required.

13. Additional ventilation will be necessary for the work being conducted.

List specifics: Reason for need of ventilation, confined space, foul odor, excessive heat.

14. Operation and maintenance of electric power generation, control, transformation, transmission, and distribution lines and equipment are necessary for the work being conducted.

List specifics:

Yes

15. Work will be conducted on energized equipment.

Use of VAMC Cleveland Working on Energized Equipment policy (138-

034) is required.

List specifics: list voltages in area, emergency procedures.

16. Other electrical work will be conducted.

17. Lock Out/Tag Out will be necessary for the work being conducted.

18. Cranes, derricks, or slings will be necessary for the work being conducted.

List specifics: Yes

19. Excavating will be necessary for work being conducted.

List site specifics:

Risk

20. Excavating or earthmoving equipment will be used.

21. Industrial trucks will be used.

22. Other motorized vehicles will be used.

23. Concrete and masonry construction operations will be necessary for work being conducted.

List specifics: % of recycled components

24. Steel erection activities will be necessary for the work being conducted.

New Steel % of recycled material,

25. Alteration, conversion, or improvement of existing electric transmission and distribution lines and equipment will be necessary for the work being conducted.

List specifics:

Yes

26. Hand and portable powered tools or other hand-held equipment will be used.

27. Compressed gas or compressed air equipment is necessary for work being conducted.

28. List all other hazardous activities that will be conducted or potentially hazardous equipment that will be used including vibration hazards.

Risk

29. Infection Control Risks identified. Infection Control Risk Assessment

(ICRA) required- refer to Enclosure (1).

unless approved by IC

30. Life Safety Risks identified.

Interim Life Safety Risk Assessment Form -Attachment (4) - must be completed and submitted.

31. Emergency Procedures Identified.

Fire, severe weather, utility failure, etc.

32. Demolition will be necessary for the work being conducted.

33. New Construction: Minimum __%__ of total project waste shall be diverted from landfill.

Recycled aggregate, Concrete, Steel.

34. Interior Remodeling: Minimum _%___ of total project waste shall be diverted from landfill.

a) Ceiling tile

b) Steel

c) Carpet

Submitted by (Contractor)________________________________ Date: ____________

Reviewed by (COR) ___________________________________ Date: ____________

Reviewed by (CSM) ____________________________________ Date: ___________

SSSP Required Yes No

Safety and Health During Construction Activities - Attachment 3

Construction Safety Poster – Cleveland VA

Project:

Project #:

VAMC Emergency Number – 2222

Infection Control Category:

Fire Extinguisher Locations:

Fire Alarm Location:

Safe Area of Refuge Location:

Evacuation Assembly Location:

MSDS Location:

COR:

Phone:

Safety and Health During Construction Activities - Attachment 4

Interim Life Safety Risk Assessment Form

Project:_______________________________________________ Date:__________________

Location: _____________________________________________________________________

Estimated completion Date ___________ Actual Completion Date ____________________

Life Safety Risk Assessment

Guidelines: Yes/

No

Comments ILSM

1. Will exit egress routes from occupied areas remain unchanged?

2. Will exit stairs remain unobstructed and fire separated?

3. Will fire and smoke compartments remain intact and unchanged?

4. Will fire alarm detection systems remain functional and unimpaired?

5. Will fire suppression systems remain function and unimpaired?

6. Will construction area be separated by noncombustible smoke tight partitions?

7. Will emergency access by fire department remain unobstructed?

8. Will normal distances to exits be maintained?

9. Will all hazardous areas be protected?

Interim Life Safety Measures (ISLM)

A. Ensure Egress H. Conduct 2 Fire Drills Per Shift in All Areas B. Emergency Forces Access I. Conduct 2 Fire Drills Per Shift in Local Area C. Fire Department Notification J. Increase Hazard Surveillance D. Ensuring Operational Life Safety Systems K. Compartmentation Training of Personnel E. Temporary Construction L. Conduct Organizational Training on Life Safety F. Additional Fire Fighting Equipment M. Conduct Additional Training on Incident Response G. Control Combustible Loading N. Institute a Fire Watch

Safety and Health During Construction Activities - Attachment 4

Life Safety Narrative:

Assessment Performed By:_______________________________________________________

Contracting Officer Technical Representative

Assessment Reviewed By:________________________________________________________

VAMC Cleveland Occupational Health and Safety

Safety and Health During Construction Activities - Attachment 5

Contractor Safety and Security Orientation

In order to promote safety in construction activities at VAMC Cleveland, all contract employees will receive orientation to communicate facility-specific safety concerns. This document provides examples of discussion points used to give contractors the necessary site-specific safety and procedural information. Refer to the Infection Control During Construction program for Infection Control Orientation discussion points.

Check all that apply:

Specific Items on the Hazardous Work Activity Checklist (Attachment 2)

Stop Work Authority

Confined Space Entry Requirements

Obtaining and Updating Hot Work Permits

Interim Life Safety Measures (Attachment 4)

.Job Site Security

Contractor ID Badge Requirements

Contractor Key Requirements

Contractor Parking Requirements

Process for Working Before or After Normal Hours

VA Daily Log

Request for Information

Other Not Previously Mentioned

Safety and Health During Construction Activities - Attachment 6

Job Safety Check Sheet

Project ID:__________________________ COR:_____________ Date:_________________

Location:__________________________

A. Personal Protective Equipment: No. Grade N/A COMMENTS –Note

Improvements Needed:

1. Hard hats in use by all personnel. A1 1 2 3 4 5 N/A

2. Eye protection in use by all personnel. A2 1 2 3 4 5 N/A

3. Hearing protection (engineering controls, double protection for high noise areas, rotation of employees).

A3 1 2 3 4 5 N/A

4. Proper footgear and protective clothing. A4 1 2 3 4 5 N/A

5. Fall protection in use. A5 1 2 3 4 5 N/A

6. Respirators/face masks in good condition and used as required

(medical evaluation and fit test).

A6 1 2 3 4 5 N/A

B. Tools and Equipment:

No. Grade N/A COMMENTS –Note

1. Tools and equipment in good condition. B1 1 2 3 4 5 N/A

2. All equipment properly guarded. B2 1 2 3 4 5 N/A

3. Electrical equipment connected properly, grounded and in good condition; GFCI; automatic magnetic cut-off for woodworking tools.

B3 1 2 3 4 5 N/A

4. Air/sandblast hoses in good condition and properly wired. B4 1 2 3 4 5 N/A

5. Compressors equipped with automatic shut-off. B5 1 2 3 4 5 N/A

6. Ladders in good condition; tied back; extended 3 ft. beyond landing.

B6 1 2 3 4 5 N/A

C. Scaffolding: o Suspended o Tubular o Other (Rope Falls Not

Permitted)

No. Grade N/A COMMENTS –Note

Improvements Needed:

1. Scaffold in good repair; guardrails; toe boards and wire mesh in place.

C1 1 2 3 4 5 N/A

2. Counterweights marked with weight and in proper ratio. C2 1 2 3 4 5 N/A

3. Scaffold tied back and tied in. C3 1 2 3 4 5 N/A

4. Passageways under scaffold blocked.

C4 1 2 3 4 5 N/A

D. Hazardous Chemicals/Air Contaminants:

No. Grade N/A COMMENTS –Note

1. Hazard Communication Right-To-Know poster / written program on job.

D1 Y N N/A

2. List of hazardous materials on job. D2 Y N N/A

3. Material Safety Data Sheets available. D3 Y N N/A

4. Employees are familiar with program. D4 1 2 3 4 5 N/A

5. Proper containers in use with correct labels. D5 1 2 3 4 5 N/A

Safety and Health During Construction Activities - Attachment 6

E. General:

No. Y N N/A COMMENTS –Note

1. Safe access to work area. E1 Y N N/A

2. Contractors wearing ID Badges. E2 Y N N/A

3. Job site security maintained E2 Y N N/A

4. Good housekeeping and material storage. E2 Y N N/A

5. Barricades/debris protection/warning signs in place. E3 Y N N/A

6. Floor and wall openings properly protected. E4 Y N N/A

7. Shoring properly installed E5 Y N N/A

8. Eye wash available. E6 Y N N/A

9. First aid: Kit and certified employees. E8 Y N N/A

10. Trucks: Safe/good condition; D.O.T. regulation compliance. E9 Y N N/A

F. Fire Safety (ILSM)

1. Exits & pathways clearly marked and unobstructed. F1 Y N N/A

2. Emergency services pathway is free and unobstructed. F2 Y N N/A

3. Fire extinguishers are in place and inspected. F3 Y N N/A

4. Smoke and fire alarms operational or ILSM taken F4 Y N N/A

5. Sprinkler system operational or ILSM taken. F5 Y N N/A

6. Hot Work Permits posted. F3 Y N N/A

7. Hot work sites inspected after hot work. F4 Y N N/A

8. Smoking Policy is followed. F5 Y N N/A

G. Paperwork and Other Postings:

1. OSHA poster/log. G1 Y N N/A

2. Emergency phone number card. G2 Y N N/A

3. Drug-Free Workplace Policy Summary and poster (if applicable).

G3 Y N N/A

4. Job logs and Job Safety Check Sheets. G4 Y N N/A

5. Site-Specific Safety Plan (if applicable). G5 Y N N/A

Additional Comments:

PROJECT SCHEDULES

01 32 16.15 - 1

SECTION 01 32 16.15

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Method (CPM) plan and schedule demonstrating fulfillment of the Contract requirements

(Project Schedule), and shall keep the Project Schedule up-to-date in accordance with the requirements of this section and shall utilize the plan for scheduling, coordinating and monitoring work under this

Contract (including all activities of Subcontractors, equipment vendors and suppliers). Conventional Critical Path Method (CPM) technique shall be utilized to satisfy both time and cost applications.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized representative responsible for the Project Schedule including preparation, review and progress reporting with and to the Contracting Officer's Representative (COTR).

B. The Contractor's representative shall have direct project control and complete authority to act on behalf of the Contractor in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the option of developing the project schedule within their organization or to engage the services of an outside consultant. If an outside scheduling consultant is utilized, Section 1.3 of this specification will apply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification proposal to the COTR, within 10 days of bid acceptance. The qualification proposal shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified in the preceding paragraph.

3. A representative sample of prior construction projects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

01 32 16.15 - 2

B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision within seven calendar days from receipt of the qualification proposal.

In case of disapproval, the Contractor shall resubmit another consultant within 10 calendar days for renewed consideration. The

Contractor shall have their scheduling consultant approved prior to submitting any schedule for approval.

1.4 COMPUTER PRODUCED SCHEDULES

A. The Contractor shall provide monthly, to the Department of Veterans

Affairs (VA), all computer-produced time/cost schedules and reports generated from monthly project updates. This monthly computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined reports of the scheduling software approved by the Contracting Officer; a hard copy listing of all project schedule changes, and associated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the Contractor’s monthly payment request and the signed look ahead report. The COTR shall identify the five different report formats that the Contractor shall provide.

B. The Contractor shall be responsible for the correctness and timeliness of the computer-produced reports. The Contractor shall also responsible for the accurate and timely submittal of the updated project schedule and all CPM data necessary to produce the computer reports and payment request that is specified.

C. The VA will report errors in computer-produced reports to the

Contractor’s representative within ten calendar days from receipt of reports. The Contractor shall reprocess the computer-produced reports and associated diskette(s), when requested by the Contracting Officer’s representative, to correct errors which affect the payment and schedule for the project.

1.5 THE COMPLETE PROJECT SCHEDULE SUBMITTAL

A. Within 30 calendar days after receipt of Notice to Proceed, the

Contractor shall submit for the Contracting Officer's review; three blue line copies of the interim schedule on sheets of paper 765 x 1070 mm (30 x 42 inches) and an electronic file in the previously approved

CPM schedule program. The submittal shall also include three copies of

01 32 16.15 - 3 a computer-produced activity/event ID schedule showing project duration; phase completion dates; and other data, including event cost.

Each activity/event on the computer-produced schedule shall contain as a minimum, but not limited to, activity/event ID, activity/event description, duration, budget amount, early start date, early finish date, late start date, late finish date and total float. Work activity/event relationships shall be restricted to finish-to-start or start-to-start without lead or lag constraints. Activity/event date constraints, not required by the Contract, will not be accepted unless submitted to and approved by the Contracting Officer.