36C25018B0802-004.pdf

SPECIFICATIONS

2/21/18

PHYSICAL SECURITY IMPROVEMENTS

Project Number 539-19-204

Cincinnati VAMC

Cincinnati, OH

Set 1 of 1

Prepared by

VA250-17-R-0241 539-19-204

PHYSICAL SECURITY PROJECT

00 01 10-1

DEPARTMENT OF VETERANS AFFAIRS

VHA MASTER SPECIFICATIONS

TABLE OF CONTENTS

Section 00 01 10

DIVISION 00 - SPECIAL SECTIONS DATE

00 01 15 List of Drawing Sheets 07-15

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 General Requirements 11-15 01 32 16.15 Project Schedules (Small Projects – Des ign/Bid/Build 04-13 01 33 23 Shop Drawings, Product Data, and Samples 05-17 01 35 26 Safety Requirements 02-17 01 42 19 Reference Standards 05-16 01 74 19 Construction Waste Management 09-13

DIVISION 02 – EXISTING CONDITIONS

02 41 00 Demolition 08-17

DIVISION 03 – CONCRETE

Not used

DIVISION 04 – MASONRY

Not Used

DIVISION 05 – METALS

Not Used

DIVISION 06 – WOOD,PLASTICS AND COMPOSITES

06 10 00 Rough Carpentry 10-15

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 84 00 Firestopping 02-16 07 92 00 Joint Sealants 10-15

DIVISION 08 - OPENINGS

Not Used

DIVISION 09 – FINISHES

09 91 00 Painting 01-16

DIVISION 10 – SPECIALTIES

Not Used

00 01 10-2

DIVISION 11 – EQUIPMENT

Not used

DIVISION 12 – FURNISHINGS

Not used

DIVISION 13 - SPECIAL CONSTRUCTION

Not used

DIVISION 14– CONVEYING EQUIPMENT

Not used

DIVISION 21- FIRE SUPPRESSION

Not used

DIVISION 22 – PLUMBING

Not used

DIVISION 23 – HEATING, VENTILATING, AND AIR

CONDITIONING (HVAC)

Not used

DIVISION 25 – INTEGRATED AUTOMATION

Not used

DIVISION 26 – ELECTRICAL

26 05 11 Requirements for Electrical Installations 01-16 26 05 19 Low-Voltage Electrical Power Conductors an d Cables 01-17 26 05 26 Grounding and Bonding for Electrical Syste ms 01-17 26 05 33 Raceway and Boxes for Electrical Systems 0 5-14 26 27 26 Wiring Devices 01-16

DIVISION 27 – COMMUNICATIONS

Not Used

DIVISION 28 – ELECTRONIC SAFETY AND SECURITY

28 05 00 Common Work Results for Electronic Safety and Security 09-11 28 05 13 Conductors and Cables for Electronic Safet y and

Security 09-11

28 05 28.33 Conduits and Backboxes for Electronic S afety and Security

09-11

28 08 00 Commissioning of Electronic Safety and Sec urity Systems 11-16 28 13 00 Physical Access Control System 10-11

DIVISION 31 – EARTHWORK

Not used

DIVISION 32 – EXTERIOR IMPROVEMENTS

00 01 10-3

DIVISION 33 – UTILITIES

Not Used

DIVISION 34 – TRANSPORTATION

Not used

DIVISION 48 – Electrical Power Generation

00 01 15 - 1

SECTION 00 01 15

LIST OF DRAWING SHEETS

The drawings listed below accompanying this specification form a part of the contract.

DRAWING

SHEET INDEX

Sheet

Number Sheet Name

GI001 COVER SHEET

EY100 BASEMENT FLOOR PLAN

EY101 FIRST FLOOR PLAN

EY102 SECOND FLOOR PLAN

EY103 THIRD FLOOR PLAN

EY104 FOURTH FLOOR PLAN

EY105 FIFTH FLOOR PLAN

EY106 SIXTH FLOOR PLAN

EY107 SEVENTH FLOOR PLAN

EY108 EIGHTH FLOOR PLAN

EY109 NINTH FLOOR PLAN

EY200 SECURITY SCHEDULE & DETAILS

EY300 ACCESS CONTROL SCHEMATICS

- - - END - - -

00 01 15 - 2 i

SECTION 01 00 00

GENERAL REQUIREMENTS

TABLE OF CONTENTS

1.1 SAFETY REQUIREMENTS

1.2 GENERAL INTENTION

1.3 STATEMENT OF BID ITEM(S)

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

1.5 CONSTRUCTION SECURITY REQUIREMENTS

1.6 OPERATIONS AND STORAGE AREAS

1.7 ALTERATIONS

1.8 DISPOSAL AND RETENTION

1.9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT,

UTILITIES, AND IMPROVEMENTS

1.10 RESTORATION

1.11 PHYSICAL DATA

1.12 PROFESSIONAL SURVEYING SERVICES

1.13 LAYOUT OF WORK

1.14 AS-BUILT DRAWINGS

1.15 USE OF ROADWAYS

1.16 PROJECT ENGINEER'S FIELD OFFICE

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

1.18 TEMPORARY USE OF EXISTING ELEVATORS

1.19 TEMPORARY USE OF NEW ELEVATORS

1.20 TEMPORARY TOILETS

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

1.22 NEW TELEPHONE EQUIPMENT

1.23 TESTS

1.24 INSTRUCTIONS

1.25 GOVERNMENT-FURNISHED PROPERTY

ii

1.26 RELOCATED EQUIPMENT AND ITEMS

1.27 STORAGE SPACE FOR DEPARTMENT OF VETERANS AFFAIRS EQUIPMENT

1.28 CONSTRUCTION SIGN

1.29 SAFETY SIGN

1.30 PHOTOGRAPHIC DOCUMENTATION

1.31 FINAL ELEVATION Digital Images

1.32 HISTORIC PRESERVATION

1.33 VA TRIRIGA CPMS

01 00 00 -1

SECTION 01 00 00

GENERAL REQUIREMENTS

1.1 SAFETY REQUIREMENTS

Refer to section 01 35 26, SAFETY REQUIREMENTS for safety and infection control requirements.

Refer to Above Ceiling Permit: The general contrac tor is required to obtain an “Above –The Ceiling Work Permit” from the project engineer for this project and must be responsible for all th at it requires. A copy of the permit and policy is attached at the en d of this specification section.

1.2 GENERAL INTENTION

A. Contractor shall completely prepare site for bui lding operations, including demolition and removal of existing struct ures, and furnish labor and materials and perform work for PHYSICAL S ECURITY PROJECT

IMPROVEMENTS 539-19-204 as required by drawings and specifications.

B. Offices of FFE, INC., as Architect-Engineers, wi ll render certain technical services during construction. Such servic es shall be considered as advisory to the Government and shall not be construed as expressing or implying a contractual act of the Gov ernment without affirmations by Contracting Officer or his duly aut horized representative.

C. All employees of general contractor and subcontr actors shall comply with VA security management program and obtain perm ission of the VA police, be identified by project and employer, and restricted from unauthorized access.

1.3 STATEMENT OF BID ITEM(S)

A. ITEM I, Renovate areas of Cincinnati VA in accor dance with the design documents to accommodate upgrading existing physica l security panels. Work includes but is not limited to replac ing obsolete panels, adding controllers to convert expander panels to in dependent control panels, refeeding access control cabling to ensure that card readers are fed from panels on the same floor, upgrading Gr aphical User

Interface and upgrading system firmware to 3.14 aft er panels are

01 00 00 -2 upgraded. All work shall be completed in 180 calen dar days from notice to proceed.

B. ALTERNATE NO.1: Same as base bid I, except delet e updating Graphical

User Interface upgrade. All work shall be complete d in 180 calendar days from notice to proceed.

C. ALTERNATE NO.2: Same as base bid I, delete alter nate I and delete upgrading system firmware to 3.14. All work shall be completed in 180 calendar days from notice to proceed.

1.4 SPECIFICATIONS AND DRAWINGS FOR CONTRACTOR

A. Drawings and contract documents may be obtained from the website where the solicitation is posted. Additional copies will be at Contractor's expense.

1.5 CONSTRUCTION SECURITY REQUIREMENTS

A. Security Plan:

1. The security plan defines both physical and admi nistrative security procedures that will remain effective for the entir e duration of the project.

2. The General Contractor is responsible for assuri ng that all sub-contractors working on the project and their employ ees also comply with these regulations.

B. Security Procedures:

1. General Contractor’s employees shall not enter t he project site without appropriate badge. They may also be subjec t to inspection of their personal effects when entering or leaving the project site.

2. Before starting work the General Contractor shal l give one week’s notice to the Contracting Officer so that security arrangements can be provided for the employees. This notice is separ ate from any notices required for utility shutdown described lat er in this section.

3. No photography of VA premises is allowed without written permission of the Contracting Officer.

4. VA reserves the right to close down or shut down the project site and order General Contractor’s employees off the pr emises in the

01 00 00 -3 event of a national emergency. The General Contrac tor may return to the site only with the written approval of the Cont racting Officer.

C. Key Control:

1. The General Contractor shall provide duplicate k eys and lock combinations to the Contracting officers representa tive (COR) for the purpose of security inspections of every area o f project including tool boxes and parked machines and take a ny emergency action.

2. The General Contractor shall turn over all perma nent lock cylinders to the VA locksmith for permanent installation. See Section 08 71

00, DOOR HARDWARE and coordinate.

D. Document Control:

1. Before starting any work, the General Contractor /Sub Contractors shall submit an electronic security memorandum desc ribing the approach to following goals and maintaining confide ntiality of

“sensitive information”.

2. The General Contractor is responsible for safeke eping of all drawings, project manual and other project informat ion. This information shall be shared only with those with a specific need to accomplish the project.

3. Certain documents, sketches, videos or photograp hs and drawings may be marked “Law Enforcement Sensitive” or “Sensitive Unclassified”.

Secure such information in separate containers and limit the access to only those who will need it for the project. Re turn the information to the Contracting Officer upon request .

4. These security documents shall not be removed or transmitted from the project site without the written approval of Co ntracting

Officer.

5. All paper waste or electronic media such as CD’s and diskettes shall be shredded and destroyed in a manner acceptable to the VA.

6. Notify Contracting Officer and Site Security Off icer immediately when there is a loss or compromise of “sensitive in formation”.

01 00 00 -4

7. All electronic information shall be stored in sp ecified location following VA standards and procedures using an Engi neering Document

Management Software (EDMS).

a. Security, access and maintenance of all project drawings, both scanned and electronic shall be performed and track ed through the

EDMS system.

b. “Sensitive information” including drawings and o ther documents may be attached to e-mail provided all VA encryptio n procedures are followed.

E. Motor Vehicle Restrictions

1. Vehicle authorization request shall be required for any vehicle entering the site and such request shall be submitt ed 24 hours before the date and time of access. Access shall be restricted to picking up and dropping off materials and supplies.

1.6 OPERATIONS AND STORAGE AREAS

A. The Contractor shall confine all operations (inc luding storage of materials) on Government premises to areas authoriz ed or approved by the Contracting Officer. The Contractor shall hold and save the

Government, its officers and agents, free and harml ess from liability of any nature occasioned by the Contractor's perfor mance.

B. Temporary buildings (e.g., storage sheds, shops, offices) and utilities may be erected by the Contractor only with the appr oval of the

Contracting Officer and shall be built with labor a nd materials furnished by the Contractor without expense to the Government. The temporary buildings and utilities shall remain the property of the

Contractor and shall be removed by the Contractor a t its expense upon completion of the work. With the written consent of the Contracting

Officer, the buildings and utilities may be abandon ed and need not be removed.

C. The Contractor shall, under regulations prescrib ed by the Contracting

Officer, use only established roadways, or use temp orary roadways constructed by the Contractor when and as authorize d by the Contracting

Officer. When materials are transported in prosecut ing the work, vehicles shall not be loaded beyond the loading cap acity recommended by the manufacturer of the vehicle or prescribed by an y Federal, State, or

01 00 00 -5 local law or regulation. When it is necessary to cr oss curbs or sidewalks, the Contractor shall protect them from d amage. The

Contractor shall repair or pay for the repair of an y damaged curbs, sidewalks, or roads.

(FAR 52.236-10)

D. Working space and space available for storing ma terials shall be as determined by the COR.

E. Workmen are subject to rules of Medical Center a pplicable to their conduct.

F. Execute work so as to interfere as little as pos sible with normal functioning of Medical Center as a whole, including operations of utility services, fire protection systems and any e xisting equipment, and with work being done by others. Use of equipmen t and tools that transmit vibrations and noises through the building structure, are not permitted in buildings that are occupied, during co nstruction, jointly by patients or medical personnel, and Contractor's personnel, except as permitted by COR where required by limited working space.

1. Do not store materials and equipment in other th an assigned areas.

2. Schedule delivery of materials and equipment to immediate construction working areas within buildings in use by Department of

Veterans Affairs in quantities sufficient for not m ore than two work days. Provide unobstructed access to Medical Center areas required to remain in operation.

3. Where access by Medical Center personnel to vaca ted portions of buildings is not required, storage of Contractor's materials and equipment will be permitted subject to fire and saf ety requirements.

G. Utilities Services: Where necessary to cut exist ing pipes, electrical wires, conduits, cables, etc., of utility services, or of fire protection systems or communications systems (excep t telephone), they shall be cut and capped at suitable places where sh own; or, in absence of such indication, where directed by COR. All such actions shall be coordinated with the COR or Utility Company involve d:

01 00 00 -6

1. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the c onstruction project, for such items as water, sewer, electricit y, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

H. Part of Bldg. 1 will be vacated by Government in accordance with above phasing beginning immediately after date of receipt of Notice to

Proceed and turned over to Contractor.

I. When a building and/or construction site is turn ed over to Contractor, Contractor shall accept entire responsibility inclu ding upkeep and maintenance therefore:

1. Contractor shall maintain a minimum temperature of 4 degrees C (40 degrees F) at all times, except as otherwise specif ied.

2. Contractor shall maintain in operating condition existing fire protection and alarm equipment. In connection with fire alarm equipment, Contractor shall make arrangements for p re-inspection of site with Fire Department or Company (Department of Veterans Affairs or municipal) whichever will be required to respond to an alarm from

Contractor's employee or watchman.

J. Utilities Services: Maintain existing utility se rvices for Medical

Center at all times. Provide temporary facilities, labor, materials, equipment, connections, and utilities to assure uni nterrupted services.

Where necessary to cut existing water, steam, gases , sewer or air pipes, or conduits, wires, cables, etc. of utility services or of fire protection systems and communications systems (incl uding telephone), they shall be cut and capped at suitable places whe re shown; or, in absence of such indication, where directed by COR.

1. No utility service such as water, gas, steam, se wers or electricity, or fire protection systems and communications syste ms may be interrupted without prior approval of COR. Electric al work shall be accomplished with all affected circuits or equipmen t de-energized.

When an electrical outage cannot be accomplished, w ork on any energized circuits or equipment shall not commence without a

01 00 00 -7 detailed work plan, the Medical Center Director’s p rior knowledge and written approval. Refer to specification Sectio ns 26 05 11, REQUIREMENTS FOR ELECTRICAL INSTALLATIONS, 27 05 11 REQUIREMENTS FOR

COMMUNICATIONS INSTALLATIONS and 28 05 00, COMMON W ORK RESULTS FOR

ELECTRONIC SAFETY AND SECURITY for additional requi rements.

2. Contractor shall submit a request to interrupt a ny such services to

COR, in writing, 14 days in advance of proposed int erruption.

Request shall state reason, date, exact time of, an d approximate duration of such interruption.

3. Contractor will be advised (in writing) of appro val of request, or of which other date and/or time such interruption w ill cause least inconvenience to operations of Medical Center. Inte rruption time approved by Medical Center may occur at other than Contractor's normal working hours.

4. Major interruptions of any system must be reques ted, in writing, at least 15 calendar days prior to the desired time an d shall be performed as directed by the COR.

5. In case of a contract construction emergency, se rvice will be interrupted on approval of COR. Such approval will be confirmed in writing as soon as practical.

6. Whenever it is required that a connection fee be paid to a public utility provider for new permanent service to the c onstruction project, for such items as water, sewer, electricit y, gas or steam, payment of such fee shall be the responsibility of the Government and not the Contractor.

K. Abandoned Lines: All service lines such as wires , cables, conduits, ducts, pipes and the like, and their hangers or sup ports, which are to be abandoned but are not required to be entirely re moved, shall be sealed, capped or plugged at the main, branch or pa nel they originate from. The lines shall not be capped in finished are as, but shall be removed and sealed, capped or plugged in ceilings, within furred spaces, in unfinished areas, or within walls or par titions; so that they are completely behind the finished surfaces.

L. To minimize interference of construction activit ies with flow of

Medical Center traffic, comply with the following:

01 00 00 -8

1. Keep roads, walks and entrances to grounds, to p arking and to occupied areas of buildings clear of construction m aterials, debris and standing construction equipment and vehicles.

M. Coordinate the work for this contract with other construction operations as directed by COR. This includes the sc heduling of traffic and the use of roadways, as specified in Article, U SE OF ROADWAYS.

1.7 ALTERATIONS

A. Survey: Before any work is started, the Contract or shall make a thorough survey with the COR, of areas of buildings in which alterations occur and areas which are anticipated r outes of access, and furnish a report, signed by both, to the Contractin g Officer. This report shall list by rooms and spaces:

1. Existing condition and types of resilient floori ng, doors, windows, walls and other surfaces not required to be altered throughout affected areas of building.

2. Existence and conditions of items such as plumbi ng fixtures and accessories, electrical fixtures, equipment, veneti an blinds, shades, etc., required by drawings to be either reu sed or relocated, or both.

3. Shall note any discrepancies between drawings an d existing conditions at site.

4. Shall designate areas for working space, materia ls storage and routes of access to areas within buildings where al terations occur and which have been agreed upon by Contractor and P roject Engineer

COR.

B. Any items required by drawings to be either reus ed or relocated or both, found during this survey to be nonexistent, o r in opinion of COR

, to be in such condition that their use is impossi ble or impractical, shall be furnished and/or replaced by Contractor wi th new items in accordance with specifications which will be furnis hed by Government.

Provided the contract work is changed by reason of this subparagraph B, the contract will be modified accordingly, under pr ovisions of clause

01 00 00 -9 entitled "DIFFERING SITE CONDITIONS" (FAR 52.236-2) and "CHANGES" (FAR

52.243-4 and VAAR 852.236-88).

C. Re-Survey: Thirty days before expected partial o r final inspection date, the Contractor and COR together shall make a thorough re-survey of the areas of buildings involved. They shall furn ish a report on conditions then existing, of resilient flooring, do ors, windows, walls and other surfaces as compared with conditions of s ame as noted in first condition survey report:

1. Re-survey report shall also list any damage caus ed by Contractor to such flooring and other surfaces, despite protectio n measures; and, will form basis for determining extent of repair wo rk required of

Contractor to restore damage caused by Contractor's workmen in executing work of this contract.

D. Protection: Provide the following protective mea sures:

1. Wherever existing roof surfaces are disturbed th ey shall be protected against water infiltration. In case of le aks, they shall be repaired immediately upon discovery.

2. Temporary protection against damage for portions of existing structures and grounds where work is to be done, ma terials handled and equipment moved and/or relocated.

3. Protection of interior of existing structures at all times, from damage, dust and weather inclemency. Wherever work is performed, floor surfaces that are to remain in place shall be adequately protected prior to starting work, and this protecti on shall be maintained intact until all work in the area is com pleted.

1.8 DISPOSAL AND RETENTION

A. Materials and equipment accruing from work remov ed and from demolition of buildings or structures, or parts thereof, shall be disposed of as follows:

1. Reserved items which are to remain property of t he Government are noted on drawings or in specifications as items to be stored. Items that remain property of the Government shall be rem oved or dislodged from present locations in such a manner as to preve nt damage which

01 00 00 -10 would be detrimental to re-installation and reuse. Store such items where directed by COR.

2. Items not reserved shall become property of the Contractor and be removed by Contractor from Medical Center.

3. Items of portable equipment and furnishings loca ted in rooms and spaces in which work is to be done under this contr act shall remain the property of the Government. When rooms and spac es are vacated by the Department of Veterans Affairs during the alter ation period, such items which are NOT required by drawings and s pecifications to be either relocated or reused will be removed by th e Government in advance of work to avoid interfering with Contracto r's operation.

1.10 RESTORATION

A. Remove, cut, alter, replace, patch and repair ex isting work as necessary to install new work. Except as otherwise shown or specified, do not cut, alter or remove any structural work, an d do not disturb any ducts, plumbing, steam, gas, or electric work witho ut approval of the

COR. Existing work to be altered or extended and th at is found to be defective in any way, shall be reported to the COR before it is disturbed. Materials and workmanship used in restor ing work, shall conform in type and quality to that of original exi sting construction, except as otherwise shown or specified.

B. Upon completion of contract, deliver work comple te and undamaged.

Existing work (walls, ceilings, partitions, floors, mechanical and electrical work, lawns, paving, roads, walks, etc.) disturbed or removed as a result of performing required new work , shall be patched, repaired, reinstalled, or replaced with new work, a nd refinished and left in as good condition as existed before commenc ing work.

C. At Contractor's own expense, Contractor shall im mediately restore to service and repair any damage caused by Contractor' s workmen to existing piping and conduits, wires, cables, etc., of utility services or of fire protection systems and communications sy stems (including telephone) which are not scheduled for discontinuan ce or abandonment.

D. Expense of repairs to such utilities and systems not shown on drawings or locations of which are unknown will be covered b y adjustment to

01 00 00 -11 contract time and price in accordance with clause e ntitled "CHANGES"

(FAR 52.243-4 and VAAR 852.236-88) and "DIFFERING S ITE CONDITIONS" (FAR

52.236-2).

1.13 LAYOUT OF WORK

A. The Contractor shall lay out the work from Gover nment established base lines and bench marks, indicated on the drawings, a nd shall be responsible for all measurements in connection with the layout. The

Contractor shall furnish, at Contractor's own expen se, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor sha ll be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer. The Contra ctor shall also be responsible for maintaining and preserving all stak es and other marks established by the Contracting Officer until author ized to remove them.

If such marks are destroyed by the Contractor or th rough Contractor's negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the repl acement from any amounts due or to become due to the Contractor.

(FAR 52.236-17)

1.14 AS-BUILT DRAWINGS

A. The contractor shall maintain two full size sets of as-built drawings which will be kept current during construction of t he project, to include all contract changes, modifications and cla rifications.

B. All variations shall be shown in the same genera l detail as used in the contract drawings. To insure compliance, as-built d rawings shall be made available for the COR review, as often as requ ested.

C. Contractor shall deliver two approved completed sets of as-built drawings in the electronic version (scanned PDF) to the Project

Engineer COR within 15 calendar days after each com pleted phase and after the acceptance of the project by the Project Engineer COR.

D. Paragraphs A, B, & C shall also apply to all sho p drawings.

01 00 00 -12

1.15 USE OF ROADWAYS

A. For hauling, use only established public roads a nd roads on Medical

Center property and, when authorized by the COR, su ch temporary roads which are necessary in the performance of contract work. Temporary roads shall be constructed and restoration performe d by the Contractor at Contractor's expense. When necessary to cross cu rbing, sidewalks, or similar construction, they must be protected by wel l-constructed bridges.

1.17 TEMPORARY USE OF MECHANICAL AND ELECTRICAL EQUIPMENT

A. Use of new installed mechanical and electrical e quipment to provide heat, ventilation, plumbing, light and power will b e permitted subject to written approval and compliance with the followi ng provisions:

1. Permission to use each unit or system must be gi ven by COR in writing. If the equipment is not installed and main tained in accordance with the written agreement and following provisions, the

COR will withdraw permission for use of the equipme nt.

2. Electrical installations used by the equipment s hall be completed in accordance with the drawings and specifications to prevent damage to the equipment and the electrical systems, i.e. tran sformers, relays, circuit breakers, fuses, conductors, motor controll ers and their overload elements shall be properly sized, coordina ted and adjusted.

Installation of temporary electrical equipment or d evices shall be in accordance with NFPA 70, National Electrical Cod e, (2014

Edition), Article 590, Temporary Installations. Voltage supplied to each item of equipment shall be verified to be corr ect and it shall be determined that motors are not overloaded. The e lectrical equipment shall be thoroughly cleaned before using it and again immediately before final inspection including vacuu m cleaning and wiping clean interior and exterior surfaces.

3. Units shall be properly lubricated, balanced, an d aligned.

Vibrations must be eliminated.

4. Automatic temperature control systems for prehea t coils shall function properly and all safety controls shall fun ction to prevent coil freeze-up damage.

01 00 00 -13

5. The air filtering system utilized shall be that which is designed for the system when complete, and all filter elemen ts shall be replaced at completion of construction and prior to testing and balancing of system.

6. All components of heat production and distributi on system, metering equipment, condensate returns, and other auxiliary facilities used in temporary service shall be cleaned prior to use; maintained to prevent corrosion internally and externally during use; and cleaned, maintained and inspected prior to acceptance by the Government.

Boilers, pumps, feedwater heaters and auxiliary equ ipment must be operated as a complete system and be fully maintain ed by operating personnel. Boiler water must be given complete and continuous chemical treatment.

B. Prior to final inspection, the equipment or part s used which show wear and tear beyond normal, shall be replaced with iden tical replacements, at no additional cost to the Government.

C. This paragraph shall not reduce the requirements of the mechanical and electrical specifications sections.

D. Any damage to the equipment or excessive wear du e to prolonged use will be repaired replaced by the contractor at the contr actor’s expense.

1.20 TEMPORARY TOILETS

A. Provide where directed, (for use of all Contract or's workmen) ample temporary sanitary toilet accommodations with suita ble sewer and water connections; or, when approved by COR, provide suit able dry closets where directed. Keep such places clean and free fro m flies, and all connections and appliances connected therewith are to be removed prior to completion of contract, and premises left perfec tly clean.

1.21 AVAILABILITY AND USE OF UTILITY SERVICES

A. The Government shall make all reasonably require d amounts of utilities available to the Contractor from existing outlets a nd supplies, as specified in the contract. The amount to be paid by the Contractor for chargeable electrical services shall be the prevail ing rates charged to the Government. The Contractor shall carefully cons erve any utilities furnished without charge.

01 00 00 -14

B. The Contractor, at Contractor's expense and in a workmanlike manner, in compliance with code and as satisfactory to the Con tracting Officer, shall install and maintain all necessary temporary connections and distribution lines, and all meters required to meas ure the amount of electricity used for the purpose of determining cha rges. Before final acceptance of the work by the Government, the Contr actor shall remove all the temporary connections, distribution lines, meters, and associated paraphernalia and repair restore the inf rastructure as required.

C. Contractor shall install meters at Contractor's expense and furnish the

Medical Center a monthly record of the Contractor's usage of electricity as hereinafter specified.

D. Heat: Furnish temporary heat necessary to preven t injury to work and materials through dampness and cold. Use of open sa lamanders or any temporary heating devices which may be fire hazards or may smoke and damage finished work, will not be permitted. Mainta in minimum temperatures as specified for various materials:

1. Obtain heat by connecting to Medical Center hea ting distribution system.

a. Steam is available at no cost to Contractor.

E. Electricity (for Construction and Testing): Furn ish all temporary electric services.

1. Obtain electricity by connecting to the Medical Center electrical distribution system. The Contractor shall meter and pay for electricity required for electric cranes and hoisti ng devices, electrical welding devices and any electrical heati ng devices providing temporary heat. Electricity for all other uses is available at no cost to the Contractor.

F. Water (for Construction and Testing): Furnish te mporary water service.

1. Obtain water by connecting to the Medical Center water distribution system. Provide reduced pressure backflow preventer at each connection as per code. Water is available at no co st to the

Contractor.

01 00 00 -15

2. Maintain connections, pipe, fittings and fixture s and conserve water-use so none is wasted. Failure to stop leakag e or other wastes will be cause for revocation (at COR discretion) of use of water from Medical Center's system.

G. Fuel: Natural and LP gas and burner fuel oil req uired for boiler cleaning, normal initial boiler-burner setup and ad justing, and for performing the specified boiler tests will be furni shed by the

Government. Fuel required for prolonged boiler-burn er setup, adjustments, or modifications due to improper desig n or operation of boiler, burner, or control devices shall be furnish ed and paid by the

Contractor at Contractor's expense.

1.22 NEW TELEPHONE EQUIPMENT

The contractor shall coordinate with the work of i nstallation of telephone equipment by others. This work shall be c ompleted before the building is turned over to VA.

1.23 TESTS

A. As per specification section 23 05 93 the contra ctor shall provide a written testing and commissioning plan complete wit h component level, equipment level, sub-system level and system level breakdowns. The plan will provide a schedule and a written sequence of what will be tested, how and what the expected outcome will be. This document will be submitted for approval prior to commencing work. The contractor shall document the results of the approved plan and submit for approval with the as built documentation.

B. Pre-test mechanical and electrical equipment and systems and make corrections required for proper operation of such s ystems before requesting final tests. Final test will not be cond ucted unless pre-tested.

C. Conduct final tests required in various sections of specifications in presence of an authorized representative of the Con tracting Officer.

Contractor shall furnish all labor, materials, equi pment, instruments, and forms, to conduct and record such tests.

D. Mechanical and electrical systems shall be balan ced, controlled and coordinated. A system is defined as the entire syst em which must be coordinated to work together during normal operatio n to produce results

01 00 00 -16 for which the system is designed. For example, air conditioning supply air is only one part of entire system which provide s comfort conditions for a building. Other related components are return air, exhaust air, steam, chilled water, refrigerant, hot water, contr ols and electricity, etc. Another example of a system which involves sev eral components of different disciplines is a boiler installation. Eff icient and acceptable boiler operation depends upon the coordi nation and proper operation of fuel, combustion air, controls, steam, feedwater, condensate and other related components.

E. All related components as defined above shall be functioning when any system component is tested. Tests shall be complete d within a reasonably period of time during which operating an d environmental conditions remain reasonably constant and are typic al of the design conditions.

F. Individual test result of any component, where r equired, will only be accepted when submitted with the test results of re lated components and of the entire system.

1.24 INSTRUCTIONS

A. Contractor shall furnish Maintenance and Operati ng manuals (hard copies and electronic) and verbal instructions when requir ed by the various sections of the specifications and as hereinafter s pecified.

B. Manuals: Maintenance and operating manuals and o ne compact disc (four hard copies and one electronic copy each) for each separate piece of equipment shall be delivered to the COR coincidenta l with the delivery of the equipment to the job site. Manuals shall be complete, detailed guides for the maintenance and operation of equipme nt. They shall include complete information necessary for starting , adjusting, maintaining in continuous operation for long period s of time and dismantling and reassembling of the complete units and sub-assembly components. Manuals shall include an index covering all component parts clearly cross-referenced to diagrams and illustrati ons. Illustrations shall include "exploded" views showing and identify ing each separate item. Emphasis shall be placed on the use of specia l tools and instruments. The function of each piece of equipmen t, component, accessory and control shall be clearly and thorough ly explained. All necessary precautions for the operation of the equi pment and the reason

01 00 00 -17 for each precaution shall be clearly set forth. Man uals must reference the exact model, style and size of the piece of equ ipment and system being furnished. Manuals referencing equipment simi lar to but of a different model, style, and size than that furnishe d will not be accepted.

C. Instructions: Contractor shall provide qualified , factory-trained manufacturers' representatives to give detailed tra ining to assigned

Department of Veterans Affairs personnel in the ope ration and complete maintenance for each piece of equipment. All such t raining will be at the job site. These requirements are more specifica lly detailed in the various technical sections. Instructions for differ ent items of equipment that are component parts of a complete sy stem, shall be given in an integrated, progressive manner. All instructo rs for every piece of component equipment in a system shall be availab le until instructions for all items included in the system h ave been completed.

This is to assure proper instruction in the operati on of inter-related systems. All instruction periods shall be at such t imes as scheduled by the COR and shall be considered concluded only when the COR is satisfied in regard to complete and thorough covera ge. The contractor shall submit a course outline with associated mater ial to the COR for review and approval prior to scheduling training to ensure the subject matter covers the expectations of the VA and the co ntractual requirements. The Department of Veterans Affairs r eserves the right to request the removal of, and substitution for, any i nstructor who, in the opinion of the COR, does not demonstrate suffic ient qualifications in accordance with requirements for instructors abo ve.

1.25 GOVERNMENT-FURNISHED PROPERTY

A. The Government shall deliver to the Contractor, the

Government-furnished property shown on the drawings .

B. Equipment furnished by Government to be installe d by Contractor will be furnished to Contractor at the Medical Center.

C. Notify Contracting Officer in writing, 60 days i n advance, of date on which Contractor will be prepared to receive equipm ent furnished by

Government. Arrangements will then be made by the G overnment for delivery of equipment.

01 00 00 -18

1. Immediately upon delivery of equipment, Contract or shall arrange for a joint inspection thereof with a representative of the Government.

At such time the Contractor shall acknowledge recei pt of equipment described, make notations, and immediately furnish the Government representative with a written statement as to its c ondition or shortages.

2. Contractor thereafter is responsible for such eq uipment until such time as acceptance of contract work is made by the Government.

D. Equipment furnished by the Government will be de livered in a partially assembled (knock down) condition in accordance with existing standard commercial practices, complete with all fittings, f astenings, and appliances necessary for connections to respective services installed under contract. All fittings and appliances (i.e., couplings, ells, tees, nipples, piping, conduits, cables, and the li ke) necessary to make the connection between the Government furnishe d equipment item and the utility stub-up shall be furnished and installe d by the contractor at no additional cost to the Government.

E. Completely assemble and install the Government f urnished equipment in place ready for proper operation in accordance with specifications and drawings.

F. Furnish supervision of installation of equipment at construction site by qualified factory trained technicians regularly employed by the equipment manufacturer.

1.26 RELOCATED EQUIPMENT AND ITEMS

A. Contractor shall disconnect, dismantle as necess ary, remove and reinstall in new location, all existing equipment a nd items indicated by symbol "R" or otherwise shown to be relocated by the Contractor.

B. Perform relocation of such equipment or items at such times and in such a manner as directed by the COR.

C. Suitably cap existing service lines, such as ste am, condensate return, water, drain, gas, air, vacuum and/or electrical, a t the main whenever such lines are disconnected from equipment to be re located. Remove abandoned lines in finished areas and cap as specif ied herein before under paragraph "Abandoned Lines".

01 00 00 -19

D. Provide all mechanical and electrical service co nnections, fittings, fastenings and any other materials necessary for as sembly and installation of relocated equipment; and leave such equipment in proper operating condition.

E. All service lines such as noted above for reloca ted equipment shall be in place at point of relocation ready for use befor e any existing equipment is disconnected. Make relocated existing equipment ready for operation or use immediately after reinstallation.

- - - E N D - - -

DEPARTMENT OF VETERANS AFFAIRS MEDICAL CENTER

Cincinnati – Fort Thomas Divisions

3200 Vine Street

Cincinnati, Ohio 45220

MEMORANDUM NO. 138-30

September 2010

ABOVE-THE-CEILING WORK PERMIT PROGRAM

1. PURPOSE: - To describe the policy and procedure for scheduling, and inspecting all work performed above acoustical tile suspended ceiling and gypsum wallboard or plaster ceiling systems in buildings owned by the Cincinnati/FTD VAMC. The walls and floors are to maintain their fire-resistance. Every opening, penetration, and joint must be properly sealed as applicable (see SOC life safety drawings to determine applicable rating) to prevent the escape of fire and smoke from the compartment.

2. POLICY: - All construction, maintenance, repair, installation, utility, and telecommunications work performed above the finished ceiling in any Cincinnati/FTD owned building will be completed and installed such that all building components and structural elements (i.e. walls, floor slabs, interstitial space decking, etc.) are restored to original smoke-tight or fire-rated condition in order to maintain compartmentalization.

To monitor and control this type of work, no such work will be performed in

Cincinnati/FTD-owned buildings until an Above-The-Ceiling Work Permit is issued to the person(s) coordinating the work activity.

3. RESPONSIBILITIES:

a. Service Chiefs must be aware of the requirements of this policy with respect to equipment installations that are coordinated within their assigned building space.

They shall be aware that anyone performing work that would result penetrations above ceiling should have an above-the-ceiling work permit.

b. Contracting Officer’s Technical Representatives (COTRs), Engineering Shops, Information Resource Management Service (IRMS) and other staff coordinating or performing work above the finished ceiling are responsible for implementation of the policy requirements.

c. Engineering Technician will issue permits and inspect all work performed above the finished ceiling in all VAMC-owned buildings at their respective facilities.

When Engineering Technician is unavailable, appropriate designee (Engineering

COTR, Industrial Hygiene and Safety (IH&S) staff, or Competent Person) shall complete the Engineering Technician responsibilities.

d. IH&S Staff will provide training and technical consultation as needed for the successful implementation of this program and use this program as a process to monitor the life safety status of any VAMC-owned building.

4. ACTIONS:

a. The COTR, Engineering Service Supervisor, IRMS Supervisor, or other staff coordinating and construction, maintenance, repair, installation, utility, and telecommunications work above the finished ceiling in any VAMC-owned building will contact the Engineering Technician prior to performing any such work. Applicable work may include, but is not limited to, phone/data cabling, signal and control cabling, cabling for networked medical equipment, electrical cabling/wiring, lighting systems, and heating, ventilation, and air conditioning

(HVAC).

b. The Engineering Technician will meet with the person(s) coordinating the work to review the location and scope of the work, and review any planned penetration(s) of horizontal and/or vertical building fire or smoke partition/barrier. This includes assuring that any planned penetrations(s) of a fire or smoke partition/barrier will be properly sleeved and/or fires-topped with Underwriters

Laboratories, Inc. (UL) approved system.

c. The Engineering Technician will issue an Above-The-Ceiling Work Permit (see

Attachment) upon approval of the planned work method.

d. Person(s) performing the above-the ceiling work will contact the Engineering

Technician Engineer when all work is concluded. The individual will remain in the area and accompany the Engineering Technician on an inspection to ensure that all work was completed according to plan and that no further fire safety deficiencies or hazards exist.

e. All permits will be maintained on file by the Engineering Technician.

5. REFERENCES:

a. The Joint Commission (TJC) Manual.

b. National Fire Protection Association NFPA 101.

6. RESPONSIBLE OFFICE: - The Chief, Facilities and Engineering Service (138/ENG) is responsible for the contents of this memorandum.

7. RESCISSIONS: - None.

8. REISSUE DATE: September 2013

LINDA. SMITH, FACHE

Medical Center Director

Attachment: Above-the-Ceiling Work Permit

Attachment

ABOVE-THE-CEILING WORK PERMIT

Contractor/Dept./Service:_____________________________________________________

Responsible Person: __________________________________________________________

Location of Penetrations: ____________________________________________________

Work Narrative:

Before issuing a Fire/Smoke Barrier Penetration Permit, the Engineering Technician will review the following Checklist with the responsible person.

Check List Items Yes No N/A Did the responsible person obtain prints from Engin eering Service Supervisor/Project Section detailing hourly-rated w alls and identifying the scope of work for fire stop?

Is manufacturer’s product (fire sealant) applicatio n guide containing UL-listed fire stop systems available an d approved?

Are trained individuals actually performing work?

Has the responsible person prepared an itemized sch edule/marked up drawings of fire/smoke walls to be penetrated?

Materials utilized in repair:

Firestopping _________________________________ Wall Board _________________________________ Other _________________________________

Engineering Technician: ____________________________ Issue Date: ____________________________________________________

After penetrations are sealed, the Engineering Technician along with the responsible person will inspect to ensure compliance with the required standards.

Inspected By: __________________________________________________________________

Signature: _____________________________________________________________________

Signature: ___________________________________ Inspection Date: ________________

01 32 16.15 - 1

SECTION 01 32 16.15

PROJECT SCHEDULES

(SMALL PROJECTS – DESIGN/BID/BUILD)

PART 1- GENERAL

1.1 DESCRIPTION:

A. The Contractor shall develop a Critical Path Met hod (CPM) plan and schedule demonstrating fulfillment of the contract requirements

(Project Schedule), and shall keep the Project Sche dule up-to-date in accordance with the requirements of this section an d shall utilize the plan for scheduling, coordinating and monitoring wo rk under this contract (including all activities of subcontractor s, equipment vendors and suppliers). Conventional Critical Path Method ( CPM) technique shall be utilized to satisfy both time and cost applicati ons.

1.2 CONTRACTOR'S REPRESENTATIVE:

A. The Contractor shall designate an authorized rep resentative responsible for the Project Schedule including preparation, rev iew and progress reporting with and to the Contracting Officer's Rep resentative (COR).

B. The Contractor's representative shall have direc t project control and complete authority to act on behalf of the Contract or in fulfilling the requirements of this specification section.

C. The Contractor’s representative shall have the o ption of developing the project schedule within their organization or to en gage the services of an outside consultant. If an outside scheduling co nsultant is utilized, Section 1.3 of this specification will ap ply.

1.3 CONTRACTOR'S CONSULTANT:

A. The Contractor shall submit a qualification prop osal to the COR, within

10 days of bid acceptance. The qualification propos al shall include:

1. The name and address of the proposed consultant.

2. Information to show that the proposed consultant has the qualifications to meet the requirements specified i n the preceding paragraph.

3. A representative sample of prior construction pr ojects, which the proposed consultant has performed complete project scheduling services. These representative samples shall be of similar size and scope.

B. The Contracting Officer has the right to approve or disapprove the proposed consultant, and will notify the Contractor of the VA decision within seven calendar days from receipt of the qual ification proposal.

In case of disapproval, the Contractor shall resubm it another consultant within 10 calendar days for renewed cons ideration. The

01 32 16.15 - 2

Contractor shall have their scheduling consultant a pproved prior to submitting any schedule for approval.

1.4 COMPUTER PRODUCED SCHEDULES

A. The contractor shall provide monthly, to the Dep artment of Veterans

Affairs (VA), all computer-produced time/cost sched ules and reports generated from monthly project updates. This monthl y computer service will include: three copies of up to five different reports (inclusive of all pages) available within the user defined rep orts of the scheduling software approved by the Contracting Off icer; a hard copy listing of all project schedule changes, and associ ated data, made at the update and an electronic file of this data; and the resulting monthly updated schedule in PDM format. These must be submitted with and substantively support the contractor’s monthly payment request and the signed look ahead report. The COR shall identif y the five different report formats that the contractor shall provide.

B. The contractor shall be responsible for the corr…