191BWC19R0003.pdf

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24 & 30

1. REQUISITION NUMBER

9309R3281025B

5. SOLICITATION NUMBER

191BWC19R0003

2. CONTRACT NO. 3. AWARD/EFFECTIVE DATE 4. ORDER NUMBER 6. SOLICITATION ISSUE

DATE

03/01/2016

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME Philip Johnson

b. TELEPHONE NUMBER (No collect calls)

c. EMAIL johnsonpk@state.gov

8. OFFER DUE DATE / LOCAL

TIME

04/01/2019 03:00:pm

CODE IBWC_

International Boundary and Water Commission (IBWC)

USIBWC - ACQUISITIONS DIV

4171 NORTH MESA, STE. C100

EL PASO, TX 79902-1441

9. ISSUED BY UNRESTRICTED OR X SET ASIDE: 100.00 % FOR

X SMALL BUSINESS

HUBZONE SMALL

BUSINESS

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS (WOSB)

ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

8(A)

NAICS: 562111

SIZE STANDARD: $0

10. THE ACQUISITION IS

SEE

SCHEDULE

11. DELIVERY FOR FOB DESTINATION

UNLESS BLOCK IS MARKED

12. DISCOUNT TERMS

13a. THIS CONTRACT IS

RATED ORDER UNDER DPAS

13b. RATING

X RFQ IFB RFP

14. METHOD OF SOLICITATION

IBWC_CODE15. DELIVER TO

Lorenzo Ortiz International Boundary and Water Commission (IBWC)

865 RIO RICO INDUSTRIAL PARK

INTERNATIONAL BOUNDARY AND WATER

COMMISSION

RIO RICO, AZ 85648-4063

CODE IBWC_16. ADMINISTERED BY

International Boundary and Water Commission (IBWC)

USIBWC - ACQUISITIONS DIV

4171 NORTH MESA, STE. C100

EL PASO, TX 79902-1441

FACILITY CODECODE

Contact Duns Telephone No.

17a. CONTRACTOR/OFFEROR IBWC_CODE18a. PAYMENT WILL BE MADE BY

International Boundary and Water Commission (IBWC)

USIBWC - FINANCIAL SERVICES DIV

4171 NORTH MESA, STE. C100

EL PASO, TX 79902-1441

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER SEE ADDENDUM

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW IS

CHECKED

19. ITEM NO. 20. SCHEDULE OF SUPPLIES/SERVICES

(Use Reverse and/or Attach Additional Sheets as Necessary)

21. QUANTITY 22. UNIT 23. UNIT PRICE 24. AMOUNT

See Line Items Section

25. ACCOUNTING AND APPROPRIATION DATA

See Line Item Detail

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

X 27a. SOLICITATION INCORPORATES BY REFERENCES FAR 52.212-1, 52.212-4, FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA ARE X ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4, 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN __1__ COPIES TO

ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER ALL ITEMS SET FORTH

OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL SHEETS SUBJECT TO THE

TERMS AND CONDITIONS SPECIFIED.

29. AWARD OF CONTRACT: REF. OFFER DATED . YOUR OFFER ON

SOLICITATION (BLOCK 5) INCLUDING ANY ADDITIONS OR CHANGES WHICH

ARE SET FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30b. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 30c. DATE SIGNED 31b. NAME OF THE CONTRACTING OFFICER (TYPE OR PRINT)

Philip Johnson 31c. DATE SIGNED

08/18/2016

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

STANDARD FORM 1449 (REV. 02/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

191BWC19R0003

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED: _________________________________

32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32c. DATE 32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT

REPRESENTATIVE

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE 32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

PARTIAL FINAL

33. SHIP NUMBER 34. VOUCHER NUMBER 35. AMOUNT VERIFIED

CORRECT FOR

COMPLETE PARTIAL FINAL

36. PAYMENT 37. CHECK NUMBER

38. S/R ACCOUNT NUMBER 39. S/R VOUCHER NUMBER 40. PAID BY

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT 42a. RECEIVED BY (Print)

41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER 41c. DATE

42b. RECEIVED AT (Location)

42c. DATE REC'D (YY/MM/DD) 42d. TOTAL CONTAINERS

STANDARD FORM 1449 (REV. 02/2012) BACK

001 Sludge Removal from filter press to landfill in accordance with the attached Scope of Work.

Period of Performance - 05/01/19 - 09/30/19. Base Year

5.00 MO

Doc Ref No: 9309R3281025B FOB:Delivery Date

Destination

002 5.00 MOLandfill Fee (estimated amount $337,500.00). Landfill fees are required by the landfill for receipt of sludge and the actual amount is dependent upon the actual quantities received and accepted. Landfill fees will be reimbursed on a monthly basis.

landfill fees are required to be supported by legible landfill receipts. Period of performance 05-01-19 -09/30/19 (Base Year) Doc Ref No: 9309R3281025B

FOB:Delivery Date Destination

003 Sludge Removal from filter press to landfill in accordance with the attached Scope of Work.

Period of Performance - 10/01/19 - 09/30/20. Option Year One (1)

12.00 MO

Doc Ref No: 9309R3281025B FOB:Delivery Date

Destination

004 12.00 MOLandfill Fee (estimated amount $864,000.00). Landfill fees are required by the landfill for receipt of sludge and the actual amount is dependent upon the actual quantities received and accepted. Landfill fees will be reimbursed on a monthly basis.

Landfill fees are required to be supported by legible landfill receipts. Period of performance 10-01-19 -09/30/20 (Option Year One (1) Doc Ref No: 9309R3281025B

FOB:Delivery Date Destination

005 Sludge Removal from filter press to landfill in accordance with the attached Scope of Work.

Period of Performance - 10/01/20 - 09/30/21. Option Year Two (2)

12.00 MO

Doc Ref No: 9309R3281025B FOB:Delivery Date

Destination

006 12.00 MOLandfill Fee (estimated amount $918,000.00). Landfill fees are required by the landfill for receipt of sludge and the actual amount is dependent upon the actual quantities received and accepted. Landfill fees will be reimbursed on a monthly basis.

Landfill fees are required to be supported by legible landfill receipts. Period of performance 10-01-20 -09/30/21 (Option Year Two (2) Doc Ref No: 9309R3281025B

FOB:Delivery Date Destination

007 Sludge Removal from filter press to landfill in accordance with the attached Scope of Work.

Period of Performance - 10/01/21 - 09/30/22. Option Year Three (3)

12.00 MO

Doc Ref No: 9309R3281025B

191BWC19R0003

Line Item Summary

Solicitation Number:

191BWC19R0003

Contract Number: Title: Sludge Removal Press to Landfill

Date of Solicitation:

09/19/2016

Line Item No. Description Quantity Unit Unit Price Total Cost

Delivery Date FOB:

Destination

008 12.00 MOLandfill Fee (estimated amount $972,000.00). Landfill fees are required by the landfill for receipt of sludge and the actual amount is dependent upon the actual quantities received and accepted. Landfill fees will be reimbursed on a monthly basis.

Landfill fees are required to be supported by legible landfill receipts. Period of performance 10-01-21 -09/30/22 (Option Year Three (3) Doc Ref No: 9309R3281025B

FOB:Delivery Date Destination

009 Sludge Removal from filter press to landfill in accordance with the attached Scope of Work.

Period of Performance - 10/01/22 - 09/30/23. Option Year Four (4)

12.00 MO

Doc Ref No: 9309R3281025B FOB:Delivery Date

Destination

010 12.00 MOLandfill Fee (estimated amount $1,026,000.00). Landfill fees are required by the landfill for receipt of sludge and the actual amount is dependent upon the actual quantities received and accepted. Landfill fees will be reimbursed on a monthly basis.

Landfill fees are required to be supported by legible landfill receipts. Period of performance 10-01-22 -09/30/23 (Option Year Four (4) Doc Ref No: 9309R3281025B

FOB:Delivery Date Destination

Identifier Title Date Number of Pages

1 QASP-Sludge to Landfill.docx 02/28/2019 13 2 Statement of Equipment _.pdf 02/28/2019 1 3 SOW Sludge.pdf 02/28/2019 11

4 WD 15-5481 02/28/2019 11

2.1 Contracting Officer

“Contracting Officer” (CO) means a person with the authority to enter into, administer, and/or terminate contracts and make related determinations and findings. The scope of the CO’s authority is defined by FAR 1.602-1, the CO’s Warrant, and other applicable fed-eral laws. The term includes certain authorized representation of the CO within the limits of their authority as delegated by the CO.

2.2 Designation of Contracting Officer/Contract Specialist

The Contracting Officer for this contract is:

Name: Philip Johnson Address: International Boundary & Water Commission, United States & Mexico (USIBWC) 4171 N Mesa, Suite C-100

191BWC19R0003

Line Item Summary

Solicitation Number:

191BWC19R0003

Contract Number: Title: Sludge Removal Press to Landfill

Date of Solicitation:

09/19/2016

Line Item No. Description Quantity Unit Unit Price Total Cost

El Paso, TX 79902 Telephone: 915-832-4714 Fax: 915-493-5664 Email: Philip.Johnson@ibwc.gov

Any change to the CO will be made in writing.

2.3 Contracting Officer's Representative USIBWC

The Contracting Officer shall designate a technical representative to act for the Contracting Officer during the contract period. The Contracting Officer’s Representative (COR) will act for the Contracting Officer only in technical matters and will not be authorized to commit the Government on any contract terms, conditions, or changes in unit price, total price, quantity, or delivery schedule. Any changes to the contract in unit price, total contract price, quantity, quality, or delivery schedule will be made only by the Contracting Officer by executed modification to the contract.

The Contracting Officer’s Representative will be appointed in writing after contract award.

2.4 Notification to the Government of Delays

In the event the contractor encounters difficulty in meeting performance requirements, or anticipates difficulty in complying with the contract delivery schedule or dates, or whenever the Contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, the Contractor shall immediately notify the Contracting Officer and the COR in writing, giving pertinent details.

NOTE: This data shall not be construed as a waiver by the Government of any delivery schedule or dates or of any rights or remedies provided by law or under this Contract.

2.5 Compensation and Liability Insurance

The Contractor shall within ten (10) calendar days after award of contract provide and maintain minimum insur-ance as follows:

(a) General Liability Insurance for bodily injury and property damage with minimum limits $500,000 each occurrence with an aggregate of $1,000,000.

(b) Automobile Liability for bodily injury and property damage with minimum of $250,000 for injury to or death of any one (1) person, $500,000 each accident or occurrence for bodily injury, and $100,000 for each ac-cident or occurrence for property damage liability.

(c) Worker's Compensation Insurance for all labor employed on the project who may come within the pro-tection of workers' compensation laws and Employers General Liability with minimum limits of $100,000 each accident, bodily injury by disease $100,000 each employee, $500,000 aggregate.

In every case the insurance coverage shall amount to at least the limits stated above. However, where the Financial Responsibility Compulsory Insurance Law of the State in which the project is located requires higher limits, the Automobile Liability Insurance Policy shall provide coverage of at least those limits required by State law.

The insurance obtained by the Contractor must (1) be effective for the term of the contract and (2) must name both the

United States of America by and through the United States Section of the International Boundary and Water Commission, United States and Mexico, as additionally insured. The requirement for naming the United States of America as an additional insured does not apply to Worker's Compensation Insurance.

Before commencing work under this contract, the Contractor shall certify to the Contracting Officer in writing that the required insurance has been obtained.

The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective (1) for such period as the laws of the State in which this contract is to be performed prescribe or (2) until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer. The Contractor's writ-ten certification shall be accompanied by either a Certificate issued by the insurer or photocopies of the insur-ance policies which reflect that the cancellation/change provisions of this contract have been met.

The Contractor shall insert the substance of this clause including this paragraph in subparagraphs under this contract and shall require subcontractors to provide and maintain the same limits.

At least 5 days prior to each such subcontractor's personnel commencing work on this project, the Con-tractor shall furnish (or ensure that there has been furnished) to the Contracting Officer a current Certificate of Insurance meeting the requirements as stated above.

[End of Clause]

2.6 Payment & Invoicing

Payment shall be made in accordance with Contract Clause 52.212-4 and the Contractor's payment scheduled which correlates with completed work.

Invoices shall be submitted to the USIBWC's Finance and Accounting Division (FAD) by email to invoices@ibwc.gov with a copy to the CO and the COR.

Clause Title 52.246-4 Inspection of Services - Fixed-Price (Aug 1996)

Clause Title 52.204-7 System for Award Management (Jul 2013)

52.204-13 System for Award Management Maintenance (JUL 2013)

52.223-5 Pollution Prevention and Right-to-Know Information (May 2011)

52.228-5 Insurance - Work on a Government Installation (Jan 1997)

52.229-3 Federal, State and Local Taxes (Feb 2013)

52.232-17 Interest (May 2014)

52.232-23 Assignment of Claims (May 2014)

52.232-39 Unenforceability of Unauthorized Obligations (Jun 2013)

52.212-4 Contract Terms and Conditions--Commercial Items (May 2015)

52.202-1 Definitions (Nov 2013)

Clause Title 52.203-3 Gratuities (Apr 1984)

52.203-12 Limitation On Payments To Influence Certain Federal Transactions (Oct 2010)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

(Apr 2014)

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011)

52.209-10 Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

52.223-6 Drug Free Workplace (May 2001)

52.232-18 Availability Of Funds (Apr 1984)

52.237-2 Protection Of Government Buildings, Equipment, And Vegetation (Apr 1984)

52.237-3 Continuity Of Services (Jan 1991)

52.242-13 Bankruptcy (July 1995)

52.204-9 Personal Identity Verification of Contractor Personnel (Jan 2011)

(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24 and Federal Information Processing Standards Publication (FIPS PUB) Number 201.

(b) The Contractor shall account for all forms of Government-provided identification issued to the Contractor employees in connection with performance under this contract. The Contractor shall return such identification to the issuing agency at the earliest of any of the following, unless otherwise determined by the Government:

(1) When no longer needed for contract performance.

(2) Upon completion of the Contractor employee’s employment.

(3) Upon contract completion or termination.

(c) The Contracting Officer may delay final payment under a contract if the Contractor fails to comply with these requirements.

(d) The Contractor shall insert the substance of this clause, including this paragraph (d), in all subcontracts when the subcontractor‘s employees are required to have routine physical access to a Federally-controlled facil-ity and/or routine access to a Federally-controlled information system. It shall be the responsibility of the prime Contractor to return such identification to the issuing agency in accordance with the terms set forth in paragraph

(b) of this section, unless otherwise approved in writing by the Contracting Officer.

(End of clause)

52.217-9 Option to Extend the Term of the Contract (Mar 2000)

(a) The Government may extend the term of this contract by written notice to the Contractor within 1; provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least 30 days [60 days unless a different number of days is inserted] before the contract expires. The preliminary notice does not commit the Government to an extension.

(b) If the Government exercises this option, the extended contract shall be considered to include this option clause.

(c) The total duration of this contract, including the exercise of any options under this clause, shall not exceed 2 years (months)(years).

(End of clause)

52.252-2 Clauses Incorporated by Reference (Feb 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were giv-en in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this / these address(es):

www.acquisition.gov [Insert one or more Internet addresses] [Insert one or more Internet addresses]

(End of clause)

52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders--Commercial Items (June 2016)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to ac-quisitions of commercial items:

(1) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015)

(2) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(3) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004)(Public Laws 108-77 and 108-78 (19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting Officer has in-dicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

XX (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Sept 2006), with Alternate I (Oct 1995) (41 U.S.C. 4704 and 10 U.S.C. 2402).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (June 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Rein-vestment Act of 2009.)

XX (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Oct 2015) (Pub. L.

109-282) (31 U.S.C. 6101 note).

__ (5) [Reserved].

XX (6) 52.204-14, Service Contract Reporting Requirements (Jan 2014) (Pub. L. 111-117, section 743 of Div.

C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Jan 2014) (Pub.

L. 111-117, section 743 of Div. C).

XX (8) 52.209-6, Protecting the Government's Interest When Subcontracting with Contractors Debarred, Sus-pended, or Proposed for Debarment. (Oct 2015) (31 U.S.C. 6101 note).

XX (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Jul 2013) (41 U.S.C. 2313).

__ (10) [Reserved].

__ (11)(i) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Nov 2011) (15 U.S.C. 657a).

__ (ii) Alternate I (Nov 2011) of 52.219-3.

__ (12)(i) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2014) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

__ (ii) Alternate I (Jan 2011) of 52.219-4.

__ (13) [Reserved]

XX (14)(i) 52.219-6, Notice of Total Small Business Set-Aside (Nov 2011) (15 U.S.C. 644).

__ (ii) Alternate I (Nov 2011).

__ (iii) Alternate II (Nov 2011).

__ (15)(i) 52.219-7, Notice of Partial Small Business Set-Aside (June 2003) (15 U.S.C. 644).

__ (ii) Alternate I (Oct 1995) of 52.219-7.

__ (iii) Alternate II (Mar 2004) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)).

XX (17)(i) 52.219-9, Small Business Subcontracting Plan (Oct 2015) (15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (Oct 2001) of 52.219-9.

__ (iii) Alternate II (Oct 2001) of 52.219-9.

__ (iv) Alternate III (Oct 2015) of 52.219-9.

__ (18) 52.219-13, Notice of Set-Aside of Orders (Nov 2011) (15 U.S.C. 644(r)).

XX (19) 52.219-14, Limitations on Subcontracting (Nov 2011) (15 U.S.C. 637(a)(14)).

__ (20) 52.219-16, Liquidated Damages--Subcon-tracting Plan (Jan 1999) (15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (Nov 2011) (15 U.S.C. 657 f).

XX (22) 52.219-28, Post Award Small Business Program Rerepresentation (Jul 2013) (15 U.S.C. 632(a)(2)).

__ (23) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women- Owned Small Business Concerns (Dec 2015) (15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Dec 2015) (15 U.S.C. 637(m)).

XX (25) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

XX (26) 52.222-19, Child Labor--Cooperation with Authorities and Remedies (Feb 2016) (E.O. 13126).

XX (27) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

XX (28) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

XX (29) 52.222-35, Equal Opportunity for Veterans (Oct 2015)(38 U.S.C. 4212).

XX (30) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

XX (31) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212).

XX (32) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496).

XX (33)(i) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O. 13627).

__ (34) 52.222-54, Employment Eligibility Verification (Oct 2015). (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial items as prescribed in 22.1803.)

__ (35)(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA-Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of com-mercially available off-the-shelf items.)

__ (36) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (June 2016) (E.O. 13693).

__ (37) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (June 2016) (E.O. 13693).

__ (38)(i) 52.223-13, Acquisition of EPEAT®-Registered Imaging Equipment (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Oct 2015) of 52.223-13.

__ (39)(i) 52.223-14, Acquisition of EPEAT®-Registered Televisions (Jun 2014) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-14.

__ (40) 52.223-15, Energy Efficiency in Energy-Consuming Products (Dec 2007) (42 U.S.C. 8259b).

__ (41)(i) 52.223-16, Acquisition of EPEAT®-Registered Personal Computer Products (Oct 2015) (E.O.s 13423 and 13514).

__ (ii) Alternate I (Jun 2014) of 52.223-16.

XX (40) 52.223-18, Encouraging Contractor Policies to Ban Text Messaging While Driving (Aug 2011) (E.O.

13513).

__ (43) 52.223-20, Aerosols (June 2016) (E.O. 13693).

__ (44) 52.223-21, Foams (June 2016) (E.O. 13693).

__ (45) 52.225-1, Buy American--Supplies (May 2014) (41 U.S.C. chapter 83).

__ (46)(i) 52.225-3, Buy American--Free Trade Agreements--Israeli Trade Act (May 2014) (41 U.S.C. chapter 83, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, Pub. L. 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I (May 2014) of 52.225-3.

__ (iii) Alternate II (May 2014) of 52.225-3.

__ (iv) Alternate III (May 2014) of 52.225-3.

__ (47) 52.225-5, Trade Agreements (Feb 2016) (19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

XX (48) 52.225-13, Restrictions on Certain Foreign Purchases (June 2008) (E.O.'s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (49) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302

Note).

__ (50) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C. 5150).

__ (51) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C.

5150).

__ (52) 52.232-29, Terms for Financing of Purchases of Commercial Items (Feb 2002) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

__ (53) 52.232-30, Installment Payments for Commercial Items (Oct 1995) (41 U.S.C. 4505, 10 U.S.C.

2307(f)).

XX (54) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (55) 52.232-34, Payment by Electronic Funds Transfer--Other than System for Award Management (Jul 2013) (31 U.S.C. 3332).

__ (56) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

__ (57) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

__ (58)(i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C.

Appx. 1241(b) and 10 U.S.C. 2631).

__ (ii) Alternate I (Apr 2003) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement pro-visions of law or Executive orders applicable to acquisitions of commercial items:

[Contracting Officer check as appropriate.]

__ (1) 52.222-17, Nondisplacement of Qualified Workers (May 2014)(E.O. 13495).

XX (2) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

XX (3) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C. 206 and 41 U.S.C.

chapter 67).

XX (4) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards-Price Adjustment (Multiple Year and Option Contracts) (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (5) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards--Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

__ (6) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Main-tenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

__ (7) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain

Services--Requirements (May 2014) (41 U.S.C. chapter 67).

XX (8) 52.222-55, Minimum Wages Under Executive Order 13658 (Dec 2015).

__ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

__ (10) 52.237-11, Accepting and Dispensing of $1 Coin (Sept 2008) (31 U.S.C. 5112(p)(1)).

(d) Comptroller General Examination of Record. The Contractor shall comply with the provisions of this para-graph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, and does not contain the clause at 52.215-2, Audit and Records--Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor's directly pertinent records involving transac-tions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR Subpart 4.7, Contractor Records Retention, of the other clauses of this contract.

If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the dis-putes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c), and (d) of this clause, the Con-tractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial items. Unless otherwise indicated below, the extent of the flow down shall be as required by the clause--

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Oct 2015) (41 U.S.C. 3509).

(ii) 52.219-8, Utilization of Small Business Concerns (Oct 2014) (15 U.S.C. 637(d)(2) and (3)), in all subcon-tracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds $700,000 ($1.5 million for construction of any public facility), the subcontractor must in-clude 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(iii) 52.222-17, Nondisplacement of Qualified Workers (May 2014) (E.O. 13495). Flow down required in ac-cordance with paragraph (l) of FAR clause 52.222-17.

(iv) 52.222-21, Prohibition of Segregated Facilities (Apr 2015)

(v) 52.222-26, Equal Opportunity (Apr 2015) (E.O. 11246).

(vi) 52.222-35, Equal Opportunity for Veterans (Oct 2015) (38 U.S.C. 4212).

(vii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jul 2014) (29 U.S.C. 793).

(viii) 52.222-37, Employment Reports on Veterans (Feb 2016) (38 U.S.C. 4212)

(ix) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O.

13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(x) 52.222-41, Service Contract Labor Standards (May 2014) (41 U.S.C. chapter 67).

(xi) __(A) 52.222-50, Combating Trafficking in Persons (Mar 2015) (22 U.S.C. chapter 78 and E.O 13627).

__(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 and E.O 13627).

(xii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Mainten-ance, Calibration, or Repair of Certain Equipment-Requirements (May 2014) (41 U.S.C. chapter 67).

(xiii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Requirements (May 2014) (41 U.S.C. chapter 67).

(xiv) 52.222-54, Employment Eligibility Verification (Oct 2015) (E.O. 12989).

(xv) 52.222-55, Minimum Wages Under Executive Order 13658 (Mar 2016).

(xvi) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Jul 2013) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xvii) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations (May 2014) (42 U.S.C. 1792).

Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xviii) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (Feb 2006) (46 U.S.C. Appx.

1241(b) and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

(End of clause)

52.217-8 Option to Extend Services (Nov 1999)

The Government may require continued performance of any services within the limits and at the rates specified in the contract. These rates may be adjusted only as a result of revisions to prevailing labor rates provided by the Secretary of Labor. The option provision may be exercised more than once, but the total extension of per-formance hereunder shall not exceed 6 months. The Contracting Officer may exercise the option by written no-tice to the Contractor within 1 day.

(End of clause)

Clause Title 52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.203-11 Certification And Disclosure Regarding Payments To Influence Certain Federal Transactions (Sept 2007)

52.209-5 Certification Regarding Responsibility Matters (Oct 2015)

(a)(1) The Offeror certifies, to the best of its knowledge and belief, that--

(i) The Offeror and/or any of its Principals--

(A) Are __ are not __ presently debarred, suspended, proposed for debarment, or declared ineligible for the award of contracts by any Federal agency;

(B) Have __ have not __, within a three-year period preceding this offer, been convicted of or had a civil judg-ment rendered against them for: commission of fraud or a criminal offense in connection with obtaining, at-tempting to obtain, or performing a public (Federal, State, or local) contract or subcontract; violation of Federal or State antitrust statutes relating to the submission of offers; or commission of embezzlement, theft, forgery, bribery, falsification or destruction of records, making false statements, tax evasion, violating Federal criminal tax laws, or receiving stolen property (if offeror checks "have", the offeror shall also see 52.209-7, if included in this solicitation);

(C) Are __ are not __ presently indicted for, or otherwise criminally or civilly charged by a governmental entity with, commission of any of the offenses enumerated in paragraph (a)(1)(i)(B) of this provision;

(D) Have __, have not __, within a three-year period preceding this offer, been notified of any delinquent Feder-al taxes in an amount that exceeds $3,500 for which the liability remains unsatisfied.

(1) Federal taxes are considered delinquent if both of the following criteria apply:

(i) The tax liability is finally determined. The liability is finally determined if it has been assessed. A liability is not finally determined if there is a pending administrative or judicial challenge. In the case of a judicial chal-lenge to the liability, the liability is not finally determined until all judicial appeal rights have been exhausted.

(ii) The taxpayer is delinquent in making payment. A taxpayer is delinquent if the taxpayer has failed to pay the tax liability when full payment was due and required. A taxpayer is not delinquent in cases where enforced col-lection action is precluded.

(2) Examples.

(i) The taxpayer has received a statutory notice of deficiency, under I.R.C. § 6212, which entitles the taxpayer to seek Tax Court review of a proposed tax deficiency. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek Tax Court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(ii) The IRS has filed a notice of Federal tax lien with respect to an assessed tax liability, and the taxpayer has been issued a notice under I.R.C. § 6320 entitling the taxpayer to request a hearing with the IRS Office of Ap-peals contesting the lien filing, and to further appeal to the Tax Court if the IRS determines to sustain the lien filing. In the course of the hearing, the taxpayer is entitled to contest the underlying tax liability because the tax-payer has had no prior opportunity to contest the liability. This is not a delinquent tax because it is not a final tax liability. Should the taxpayer seek tax court review, this will not be a final tax liability until the taxpayer has exercised all judicial appeal rights.

(iii) The taxpayer has entered into an installment agreement pursuant to I.R.C. § 6159. The taxpayer is making timely payments and is in full compliance with the agreement terms. The taxpayer is not delinquent because the taxpayer is not currently required to make full payment.

(iv) The taxpayer has filed for bankruptcy protection. The taxpayer is not delinquent because enforced collec-tion action is stayed under 11 U.S.C. 362 (the Bankruptcy Code).

(ii) The Offeror has __ has not __, within a three-year period preceding this offer, had one or more contracts ter-minated for default by any Federal agency.

(2) "Principal," for the purposes of this certification, means an officer, director, owner, partner, or a person hav-ing primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

This Certification Concerns a Matter Within the Jurisdiction of an Agency of the United States and the Making of a False, Fictitious, or Fraudulent Certification May Render the Maker Subject to Prosecution Under Section 1001, Title 18, United States Code.

(b) The Offeror shall provide immediate written notice to the Contracting Officer if, at any time prior to con-tract award, the Offeror learns that its certification was erroneous when submitted or has become erroneous by reason of changed circumstances.

(c) A certification that any of the items in paragraph (a) of this provision exists will not necessarily result in withholding of an award under this solicitation. However, the certification will be considered in connection with a determination of the Offeror's responsibility. Failure of the Offeror to furnish a certification or provide such additional information as requested by the Contracting Officer may render the Offeror nonresponsible.

(d) Nothing contained in the foregoing shall be construed to require establishment of a system of records in or-der to render, in good faith, the certification required by paragraph (a) of this provision. The knowledge and in-formation of an Offeror is not required to exceed that which is normally possessed by a prudent person in the ordinary course of business dealings.

(e) The certification in paragraph (a) of this provision is a material representation of fact upon which reliance was placed when making award. If it is later determined that the Offeror knowingly rendered an erroneous certi-fication, in addition to other remedies available to the Government, the Contracting Officer may terminate the contract resulting from this solicitation for default.

(End of provision)

52.209-7 Information Regarding Responsibility Matters (Jul 2013)

(a) Definitions. As used in this provision --

“Administrative proceeding” means a non-judicial process that is adjudicatory in nature in order to make a de-termination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This in-cludes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

“Federal contracts and grants with total value greater than $10,000,000” means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

“Principal” means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror __ has __ does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the follow-ing information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provi-sion, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via ht-tps://www.acquisition.gov. (see 52.204-7).

(End of provision)

52.212-3 Offeror Representations and Certifications--Commercial Items (Apr 2016)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual repres-entations and certification electronically via the System for Award Management (SAM) website accessed through http://www.acquisition.gov. If the Offeror has not completed the annual representations and certifica-tions electronically, the Offeror shall complete only paragraphs (c) through (r) of this provision.

(a) Definitions. As used in this provision--

"Economically disadvantaged women-owned small business (EDWOSB) concern" means a small business con-cern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

"Forced or indentured child labor" means all work or service--

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accom-plished by process or penalties.

"Highest-level owner" means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

"Immediate owner" means an entity, other than the offeror, that has direct control of the offeror. Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employ-ees.

"Inverted domestic corporation", means a foreign incorporated entity that meets the definition of an inverted do-mestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C.

395(c).

"Manufactured end product" means any end product in product and service codes (PSCs) 1000-9999, except--

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

"Place of manufacture" means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

"Predecessor" means an entity that is replaced by a successor and includes any predecessors of the predecessor.

"Restricted business operations" means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174). Restricted business opera-tions do not include business operations that the person (as that term is defined in Section 2 of the Sudan Ac-countability and Divestment Act of 2007) conducting the business can demonstrate--

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Depart-ment of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

"Sensitive technology"--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used spe-cifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

"Service-disabled veteran-owned small business concern"--

(1) Means a small business concern--

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-dis-abled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled vet-erans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

"Small business concern" means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

"Small disadvantaged business concern", consistent with 13 CFR 124.1002, means a small business concern un-der the size standard applicable to the acquisition, that--

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by--

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR 124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

"Subsidiary" means an entity in which more than 50 percent of the entity is owned--

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

"Successor" means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term "successor" does not in-clude new offices/divisions of the same company or a company that only changes its name. The extent of the re-sponsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

"Veteran-owned small business concern" means a small business concern--

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at 38 U.S.C.