Amendment 00001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 1

2.AMENDMENT/MODIFICATION NO.

00001

3. EFFECTIVE DATE

02/18/2019

4. REQUISITION/PURCHASE REQ. NO.

5. PROJECT NO. (If applicable)

4C9L

6. ISSUED BY CODE BFAO CODE RCH

Federal Bureau of Prisons Field Acquisition Office U.S. Armed Forces Reserve Complex 346 Marine Forces Drive

Grand Prairie, TX 75051

7. ADMINISTERED BY (If other than Item 6)

Federal Bureau of Prisons FMC Rochester 2110 East Center Street Rochester, MN 55904

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION 1541220B00000001

9B. DATED (SEE ITEM 11)

01/29/2020

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

The purpose of Amendment 00001 is to incorporate the attached:

1. Site Visit Meeting Minutes and

2. General Wage Decision Number: MN20200123 dated 2/14/2020

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

NSN 7540-01-152-8070

Previous edition unusable

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

10-83)

X x x

PRE-BID CONFERENCE MEETING MINUTES

15B41220B00000001 – Replace Outer Fence

FMC Rochester – PROJECT 4C9L

1 | P a g e

DATE: 9:30 am, Tuesday, Feb 18, 2020 Place: FMC Rochester Business Office

CONTRACTING OFFICER (Gregory Visser):

I. INTRODUCTIONS:

Introductions were made.

II. PURPOSE OF MEETING:

Greg identified the project(15B41220B00000001), Replace Outer Fence at the Federal Medical Center located in Rochester, MN. Greg indicated that the purpose of this meeting is to familiarize the contractor with the Bureau of Prisons policies and procedures to be observed during the performance of work and the unique circumstances and requirements surrounding a correctional setting. This meeting is also to explain the solicitation, as issued, and not to furnish additional information.

Greg stated that questions will NOT be answered at the site visit and that only written questions will be accepted and answered. Written questions must be submitted to Michelle Morgan at mrmorgan@bop.gov. The deadline for receipt of written questions is Thursday February 20, 2020 at 10:00a.m. Central Standard Time.

Greg stated that nothing said here shall be interpreted as a change to the solicitation without the issuance of a formal amendment through the Contracting Officer, Michelle Morgan. Only the Contracting Officer has the authority to enter into, administer, and/or terminate a contractual action on behalf of the United States.

III. MINUTES:

Greg pointed out that minutes of this meeting will be recorded and distributed via Beta Sam.Gov at https://beta.sam.gov/

IV. SITE VISIT INFORMATION:

Greg advised that at the conclusion of the meeting the contractor will be able to visit the selected work site.

V. FRONT COVER PAGE FORMS AND INSTRUCTIONS:

Greg noted that the instructions for submitting quotes are detailed in the “Instruction to Bidders” section in the Solicitation and all bids sent by mail shall be addressed to:

FEDERAL BUREAU OF PRISONS FIELD ACQUISITION OFFICE

U.S. ARMED FORCES RESERVE COMPLEX

ATTN: MICHELLE MORGAN

346 MARINE FORCES DRIVE

GRAND PRAIRIE, TX 75051

FMC Rochester – PROJECT 4C9L

2 | P a g e

VI. TIME FRAMES AND LOCATION FOR SUBMISSION OF BIDS:

Greg stated that the deadline for submission of bids for this project is March 10, 2020 by 2:00 P.M. CST.

This due date is strictly enforced. Late bids will be rejected.

VII. GENERAL TOPICS:

Greg addressed the following submission/completion items:

1. From the solicitation, each bidder SHALL complete and submit the following forms, clauses, and statements with his/her bid. Failure to do so may cause your bid to be considered as non-responsive:

STANDARD FORM 1442 Pages 1 & 2: Please include DUNS number and Tax ID# and e-mail address where indicated in block 10 and complete blocks 14-20c. If your company has a “doing business as” name reflected in you SAM registration, include this name as well in Block 14.

Ensure the address typed in block 14 matches the address in your SAM registration.

PAST PERFORMANCE SUBMISSION: Please ensure the “Instruction to Bidders” is reviewed and complied with its entirety. References and banking submissions must be submitted in advance to the bid opening directly to Mrs. Morgan via email.

BID GUARANTEE: See Page 4 of the solicitation. A bid bond must be submitted in original (ink signatures) with your solicitation. The penal sum of the bond must be at least 20% of the bid price, not to exceed $3 million, whichever is less. A blank bid bond was included in the solicitation. The bid bond must be from a Government approved surety. A list of approved sureties can be located on the Department of Treasury, Bureau of the Fiscal Service website.

REPRESENTATIONS AND CERTIFICATIONS: All contractors submitting a bid must be registered in the System for Award Management (SAM) at www.sam.gov with the North American Industry Classification Standard code (NAICS) 238990 which is applicable to this acquisition.

FAR PROVISION 52.204-8: Pursuant to the section (b) (1) of this provision, provision 52.204-7 is included in this solicitation. Bidders should not mark either of the two options under section (b) (2).

Leave these options unmarked.

FAR PROVISION 52.209-13: Bidders should check either (1) or (2) under section (b).

AMENDMENTS: Amendments (if any) must be acknowledged and submitted with the bid by one of the methods as described in item eleven of the Standard Form 30.

FMC Rochester – PROJECT 4C9L

3 | P a g e

2. Greg also addressed the following items:

DAVIS BACON ACT: This contract is subject to the Davis Bacon Act. Wage Decision MN123 is applicable for this area. All applicable workers must be paid according to the terms of the wage decision.

HIRING GOALS: Hiring goals for this project are 1.4% for minorities and 6.9% for females – A “Good Faith” effort should be put forth by the contractor to achieve these goals.

LICENSING AND PERMITS: All required licensing and permits are required to be obtained by the contractor who receives contract award.

MAGNITUDE: The magnitude of the project is between $1,000,000.00 and $5,000,000.00.

WORK HOURS: Per SOW Section 1.2 Contractor Use of Premises: Work hours within the secure perimeter shall be between 7:30 am and 3:00 pm Monday through Friday excluding federal holidays.

COR: The Contracting Officer’s Representative (COR) is Tara Jensen, Engineering Technician at FMC Rochester.

PERIOD OF PERFORMANCE: The completion period is 934 calendar days after issuance of notice to proceed.

TIME EXTENSIONS: Time extensions for inclement weather will not be granted unless the weather is unusually severe and abnormal in comparison to prior years.

LIQUIDATED DAMAGES: Liquidated damages for this project are in the amount of $794.62 per calendar day of delay after scheduled completion.

PRE-CONSTRUCTION CONFERENCE: A Pre-Construction conference is required after the contract is awarded and will be scheduled accordingly.

PROGRESS SCHEDULE: A copy of the progress schedule is to be provided to the Contracting Officer and Contracting Officer’s Representative as soon as possible. Each time the progress schedule is changed, it must be provided to both the Contracting Officer and COR. It is suggested an updated document be provided by the Prime Contractor at the mandatory monthly progress meeting.

PROGRESS MEETINGS: Progress meetings are mandatory and will be scheduled monthly.

PAYMENT REQUESTS: Application for payments are to be submitted on AIA G702 and AIAG703(Continuation) or the contractors own form as long as the information is similar to the

FMC Rochester – PROJECT 4C9L

4 | P a g e

G702. Contactors can get these forms from the following website www.aiabookstore.com. The contractor will also be required to submit a Contractor Certification (FAR 52.232-5(c)), and a Progress Payments – Subcontractor Itemization with all application for payments.

QUESTIONS: All questions will be posed to Mrs. Morgan no later than Thursday, February 20, 2020, 10:00 a.m. CST.

COR: Tara Jensen addressed the following topics:

OVERVIEW OF PROJECT: provide a summary of the work to be completed under this project.

ACCESS TO SITE/PARKING OF VEHICLES: Work outside of the secure perimeter of the institution will be allowed between the hours of 7:30 a.m. and 3:00 p.m. Parking will be provided for employee vehicles and contractor work vehicles.

STORAGE OF MATERIALS: Storage of materials will be coordinated with the Contracting Officer’s Representative.

CONTRACTOR TEMPORARY OFFICE: No temporary office space will be provided.

INSPECTIONS: "Punch List" items generated by inspections will be corrected and discrepancy items re-inspected and approved before contract closure takes place. Should any work be covered without proper notification, the contractor shall uncover that work for inspection at his own expense.

SAFETY MANAGER: Bernie Richards addressed the following safety concerns.

3. SAFETY POINTS:

The contractor is responsible for providing required protective gear to all contractor workers, should it be required. Contractor will ensure that all workers have proper safety gear at all times.

Contractor is responsible for the prevention of accidents on the project site and has spill kit onsite and containment procedures. OSHA requirements will be adhered to.

The Contractor will have a Safety Representative on site at all times during the completion of this project.

Proper storage of any chemicals with SDS present.

CAPTAIN: Acting Captain Dan Nelson addressed the following security concerns

4. SECURITY

FMC Rochester – PROJECT 4C9L

5 | P a g e

ADVERSE WEATHER: Whenever adverse weather conditions or other institution emergency contingencies are in effect, contract workers will not be permitted passage into the secure institution. Should emergency conditions be implemented while contract workers are inside the secure perimeter, they will be required to secure their tools, remove vehicles and equipment, and leave the institution grounds until the emergency situation has been resolved.

Depending upon the nature of the emergency, this normally will not affect any construction outside of the secure perimeter.

SECURITY CLEARANCES: Contract workers are subject to security investigative procedures.

Please refer to the contract for details. Please refer to FAO-0009(Page 6) and BOP 52.24-403-70(Page 16 - 17) of the solicitation.

EMPLOYEE IDENTIFICATION: Contractor personnel working on project site must bring valid photo identification to the institution each day. The identification will be surrendered upon entry to, and returned upon exit from institution property.

TOOL ACCOUNTABILITY: Strict accountability and control of all contractor tools and hazardous materials must be maintained at all times. All contractor tools to be used inside the secure perimeter must be inventoried and accounted for at the conclusion of the work day Contractor tools may not be stored on-site overnight. The contractor should provide for enough time at the conclusion of the work day for the return and accounting of all tools issued during the work day.

Lost or missing tools must be reported to the COR the Captain immediately.

ILLEGAL ITEMS ON FEDERAL PROPERTY: Firearms, ammunition, knives, other weapons, drugs, narcotics, and alcoholic beverages are not permitted inside/outside the secure perimeter or anywhere else on Federal property at any time. This includes the private vehicles of contract workers. Violators will be subject to criminal prosecution. All persons, vehicles, and equipment are subject to search by institution authorities at any time.

NO CONTACT WITH INMATES: Contract workers are not to have any contact with inmates at any time. No photographs may be taken of inmates.

CONTRACTOR EMPLOYEE WORK DRESS: Green or khaki-colored clothing is not allowed, as inmates wear these colors.

PHOTOGRAPHS: The institution’s Facilities Department maintains a digital camera that will be utilized by FBOP staff to document the project work. The Contractor may request copies of these photos, and may request that photos be taken for specific conditions. Cellular telephones equipped with photographic capabilities are prohibited on the project construction site.

20. Additional Topics: There were no additional topics to address.

FMC Rochester – PROJECT 4C9L

6 | P a g e

VIII. ADDITIONAL NOTES:

None.

Upon completion of the meeting the contractor was escorted to the job site. The meeting concluded at 10:00am.

Meeting minutes recorded by:

Greg Visser, Supervisory Contract Specialist FMC Rochester

NOTICE:

MEETING MINUTES ARE PROVIDED FOR INFORMATIONAL PURPOSES ONLY. THEY ARE NOT

INTENDED TO CHANGE ANY SPECIFICATIONS, TERMS OR CONDITIONS OF THE

SOLICITATION. ANY AND ALL CHANGES TO THE SOLICITATION SHALL BE ISSUED IN

SUBSEQUENT AMENDMENTS ISSUED BY THE CONTRACTING OFFICER ON A STANDARD

FORM 30 (SF-30).

GREGORY VISSER

Digitally signed by GREGORY

VISSER

Date: 2020.02.18 10:23:45 -06'00'

Project 4C9L Replace Perimeter Fence FMC Rochester Sign In Sheet

"General Decision Number: MN20200123 02/14/2020

Superseded General Decision Number: MN20190123

State: Minnesota

Construction Type: Building

County: Olmsted County in Minnesota.

BUILDING CONSTRUCTION PROJECTS (does not include single family homes or apartments up to and including 4 stories).

Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.80 for calendar year 2020 applies to all contracts subject to the DavisBacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.80 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2020. If this contract is covered by the EO and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must pay workers in that classification at least the wage rate determined through the conformance process set forth in 29 CFR 5.5(a)(1)(ii) (or the EO minimum wage rate,if it is higher than the conformed wage rate). The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the abovementioned types of contracts entered into by the federal government that are subject to the DavisBacon Act itself, but it does not apply to contracts subject only to the DavisBacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/03/2020 1 02/14/2020

ASBE0034001 06/01/2019

Rates Fringes

ASBESTOS WORKER/HEAT & FROST

INSULATOR........................$ 38.15 33.40

BOIL0647008 03/01/2018

Rates Fringes

BOILERMAKER......................$ 37.22 27.14

BRMN0001015 05/01/2018

Rates Fringes

BRICKLAYER.......................$ 38.75 20.78

BRMN0001024 05/01/2018

Rates Fringes

TILE FINISHER....................$ 25.13 5.54

TILE SETTER......................$ 33.55 24.64

* CARP0068008 05/01/2019

Rates Fringes

SOFT FLOOR LAYER.................$ 34.92 18.38

* CARP1382004 04/29/2019

Rates Fringes

CARPENTER (Includes Acoustical Ceiling Installation, Batt Insulation, Drywall Hanging, and Form Work, and Excludes Soft Floor Layer)................$ 32.63 20.77

ELEC0343006 07/01/2019

Rates Fringes

ELECTRICIAN......................$ 39.53 21.41

* ELEV0009007 01/01/2020

Rates Fringes

ELEVATOR MECHANIC................$ 51.55 34.765

ENGI0049014 05/01/2019

Rates Fringes

POWER EQUIPMENT OPERATOR

Bulldozer...................$ 40.08 20.55 Crane.......................$ 41.84 20.55 Drill.......................$ 40.08 20.55 Forklift....................$ 40.08 20.55 Oiler.......................$ 37.45 20.55 Roller......................$ 40.08 20.55

IRON0512029 06/03/2019

IRONWORKER (Reinforcing and

Structural)......................$ 37.60 29.40

LABO0405017 05/01/2019

Rates Fringes

LABORER

Common or General...........$ 28.70 17.52 Concrete Saw (Handheld/Walk Behind)......$ 28.70 17.52 Mason Tender Brick/Cement/Concrete.......$ 28.70 17.52

LABO0563061 05/01/2018

Rates Fringes

LABORER (Pipelayer)..............$ 36.45 17.34

PAIN0681005 05/01/2018

Rates Fringes

DRYWALL FINISHER/TAPER...........$ 29.01 17.55

PAIN0681008 05/01/2018

Rates Fringes

PAINTER (Brush and Roller).......$ 29.66 16.94

PAIN1324001 06/04/2018

Rates Fringes

GLAZIER..........................$ 41.19 18.64

PLAS0633007 05/01/2019

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 42.06 10.63

PLUM0006004 05/01/2019

Rates Fringes

PLUMBER (Excluding HVAC Installation)....................$ 41.11 22.23

SFMN0669004 04/01/2019

Rates Fringes

SPRINKLER FITTER (Fire Sprinklers)......................$ 37.79 21.04

SHEE0010044 05/01/2018

SHEET METAL WORKER (HVAC Duct Installation Only)...............$ 35.18 22.84

* UAVGMN0021 01/01/2019

Rates Fringes

OPERATOR: Loader................$ 35.46 20.30

* UAVGMN0022 01/01/2019

Rates Fringes

PAINTER: Spray..................$ 32.18 17.93

SUMN2015058 06/22/2018

Rates Fringes

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 30.25 14.51

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 32.03 14.80

PIPEFITTER.......................$ 35.96 25.48

ROOFER...........................$ 24.80 9.73

SHEET METAL WORKER (Excluding HVAC Duct Installation)..........$ 36.18 22.25

TRUCK DRIVER: Dump Truck........$ 23.43 12.33

WELDERS Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the DavisBacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other healthrelated needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other healthrelated needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and nonunion rates. Example: SULA2012007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVGOH0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the DavisBacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

Wage Determination