Sol_140P5219B0001.pdf

SOLICITATION, OFFER,

AND AWARD

2. TYPE OF SOLICITATION

6. PROJECT NO. 4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO.

PAGE OF PAGES

7. ISSUED BY CODE 8. ADDRESS OFFER TO

SOLICITATION

(Construction, Alteration, or Repair)

1. SOLICITATION NO. 3. DATE ISSUED

IMPORTANT -- The "offer" section on the reverse must be fully completed by offeror.

9.

INFORMATION

a. NAME b. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder."

CALL:

FOR

SEALED BID (IFB)

NEGOTIATED (RFP)

0040431943

NPS, SER - West MABO

Gulf Islands National Seashore

Park Headquarters 1801 Gulf Breeze Parkway

PSW

Attn: Contracting Officer

Gulf Breeze FL 32563

DOI - NPS - SER - WEST MABO

VIA ELECTRONIC COMMERCE

FEDCONNECT OR

EMAIL: andre_ward@nps.gov

Evans Ward 850-934-2614

PMIS 210394

x

05/02/2019

140P5219B0001

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date)

Replace Boat Ramp and Piers at Davis Bayou Public Boat Launch

Contractor shall furnish all labor, equipment, supplies, and materials required to remove the existing structures and reconstruct boat ramp and finger piers at the

Davis Bayou boat launch area of Gulf Islands National Seashore, Ocean Springs, Jackson County, Mississippi.

List of Attachments:

1) Project Specifications SOW (dated 2/28/20198).....9-pages

2) Wage Determination (dated 1/04/2019)..............3-pages

List of Exhibits:

1) Photos of Public Boat Launch .....................4-pages

2) MAPs .............................................2-page

THIS IS A 100% SET-ASIDE FOR SMALL BUSINESS CONCERNS.

Magnitude of Construction price range is between $250,000.00 and $500,000.00

NAICS Code: 237990

Size Standard: $36.5M

Continued ...

11. The Contractor shall begin performance

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

award, notice to proceed. The performance period is mandatory negotiable. (See ________________________________________________.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and is not required.is, b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

d. Offers providing less than

12b. CALENDAR DAYSYES NO

(If "YES", indicate within how many calendar days after award in Item 12b.)

5 120 calendar days and complete it within ________________ ________________ calendar days after receiving

Section E clause FAR 52.211-10

05/31/2019

NSN 7540-01-155-3212

x x x x copies to perform the work required are due at the place specified in Item 8 by _____________ ___________________ (hour) local time calendar days for Government acceptance after the date offers are due will not be considered and will be rejected . _________________

STANDARD FORM 1442 (Rev. 4-85)

Prescribed by GSA

FAR(48 CFR) 53.236-1(d)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ____________________ calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in item 13d. Failure to insert any number means the offeror accepts the minimum in item 13d.)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than item 14.)

CODE FACILITY CODE

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

OFFER (Must be fully completed by offeror)

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE.

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20b. SIGNATURE 20c. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this document and return (Contractor is not required to sign this document.)

Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award.

No further contractual document is necessary.

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print) 31a. NAME OF CONTRACTING OFFICER (Type or print)

30b. SIGNATURE 30c. DATE 31b. UNITED STATES OF AMERICA 31c. DATE

BY

2PAGE OF

NPS, SER - West MABO Gulf Islands National Seashore

Park Headquarters 1801 Gulf Breeze Parkway

PSW

Attn: Contracting Officer

Gulf Breeze FL 32563

Evans Ward

28. NEGOTIATED AGREEMENT 29. AWARD

Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, copies to issuing office.)

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

STANDARD FORM 1442 (REV. 4-85) BACK

Continued...

ITEM NO.

(A)

SUPPLIES/SERVICES

(B)

QUANTITY

(C)

UNIT

(D)

UNIT PRICE

(E)

AMOUNT

(F)

NAME OF OFFEROR OR CONTRACTOR

3 40

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

140P5219B0001

Delivery: 120 Days After Notice to Proceed

Delivery Location Code: 0009060348

NPS, Gulf Islands NS

3500 Park Road

Ocean Springs MS 39564-9709 US

Period of Performance: 06/24/2019 to 10/21/2019

GUIS R5323190016

00010 RECONSTRUCT BOAT RAMP AND PIERS (DAVIS BAYOU AREA)

This job will consist of demolition of existing finger piers and concrete slabs. Contractor shall furnish all labor, materials, equipment, supplies and supervision to reconstruct.

FIRM-FIXED PRICE $_______________________________

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

A - Solicitation/Contract Form Clauses

B - Supplies or Services/Prices Clauses

C - Description/Specifications Clauses

D - Packaging and Marking Clauses

E - Inspection and Acceptance Clauses

F - Deliveries or Performance Clauses

G - Contract Administration Data Clauses

H - Special Contract Requirements Clauses

I - Contract Clauses Clauses

J - List of Documents, Exhibits and Other Attachments List of Documents, Exhibits, and Other Attachments Clauses

K - Representations, Certifications, and Other Statements of Bidders Clauses

L - Instructions,Conditions, and Notices to Bidders Clauses

M - Evaluation Factors for Award Clauses

A - Solicitation/Contract Form

Clauses

Part I¿The Schedule.

Refer to Standard Form 1442, Solicitation, Offer and Award, Pages 1 through 3 of this Package.

B - Supplies or Services/Prices

Clauses

BID SCHEDULE

POINT OF CONTACT: ______________________________________________________

COMPANY: ________________________________________________________________

PHONE: ___________________________________________________________________

EMAIL: ___________________________________________________________________

DUNS #: ___________________________________________________________________

Each Bid item shall include all cost for materials, labor, expenses, fees, and taxes plus permitting costs, overhead and profit associated with each bid item to construct the following areas of work in accordance with the contact documents. The unit costs shall include the costs for all construction disciplines (civil, structural, mechanical, electrical, control work, etc) associated with the work area. .

Bid

Item

No. Description Qty Unit Price_____

001A Mobilization/Demobilization: 1 Job $_____________

001B Demo and dispose existing piers and concrete slab: 1 Job $_____________

001C Install and remove cofferdam: 1 Job $_____________

001D Install new poured in place boat ramp slabs: 1 Job $_____________

001E Install new pilings and piers: 1 Job $_____________

001F Bonding & Insurance: 1 LS $_____________

001G Material Purchase Certificate (MPC): 1 LS $_____________ (3.5% Sales and Use Tax)

Total BASE Price $

- END OF BID SCHEDULE -

C - Description/Specifications

STATEMENT OF WORK: Replace Boat Ramp and Finger Piers at DB Boat Launch is incorporated into Section J, Attachment 1.

This job will consist of demolition of the existing finger piers and concrete slabs.

Contractor shall furnish all labor, materials, equipment, supplies and supervision .to perform the following TASKS:

Mobilization/Demobilization Demo and remove existing three piers and concrete slab o Remove existing piers and piling o Remove old broken slab o Dispose of or recycle removed material in approved facility Install and remove cofferdam o Approximately 178 LF o Recommend PZ-27 or equal steel sheeting Utilize 30 LF sheeting on front face Utilize 20-25 LF sheeting on side walls Brace with H beam whaler and 30 LF H-beam piling for support o Dewater of cofferdam cell Supply pumps and manning to dewater cofferdam area Install well sump areas Install new poured in place boat ramp slab o Prep slab area and place a geogrid (Tensar BX1200 or equal) liner o Install a 24" layer of compacted 610 limestone o Construct two slab areas 20'x50' each on top of prepared area Install top 24"x30" footer area with rebar a #5 rebar cage Install bottom 24"x30" footer area with a #5 rebar cage Install a 8" thick main slab area with side footers 18" thick with #4 rebar grid on 12" centers Pour 4000 psi concrete Build new piers (3 each) o Drive new 12"x25 LF piling treated to 2.5 cca o Install new headers and stringers o Install new grid walk mini mesh FRP grating for top decking

DELIVERABLES:

Before notice to proceed Provide product submittals for materials to be installed for approval by project manager.

Provide a written narrative summary of how the contractor will execute the project with a timeline. This document will be referred to as the implementation plan.

Provide safety plan as identified in SOW Section 9.

Provide Safety Data Sheets for each hazardous chemical, if applicable.

Before contract close out Provide DI-137 Form Release of Claims Provide Warranty documentation on Company Letterhead.

Refer to Attachment 1 SOW for more details.

D - Packaging and Marking

E - Inspection and Acceptance

Clauses

52.242-14 Suspension of Work. (APR 1984)

52.246-12 Inspection of Construction. (AUG 1996)

52.246-21 Warranty of Construction. (APR 1984) - Alternate I (APR 1984)

F - Deliveries or Performance

Clauses

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [Contracting Officer insert number] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than [* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date]. The time stated for completion shall include final cleanup of the premises.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

52.211-10 Commencement, Prosecution, and Completion of Work. (APR 1984) - Alternate I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 120. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 06/19/2019. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

G - Contract Administration Data

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor.

To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is:

https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice [Contractor's Invoice or Voucher supported by Schedule of Values itemized by material delivered, bond premiums, work completed satisfactory long with requite Certification (progress) and or Release of Claims (final) documentation as required under this contract:

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

H - Special Contract Requirements

Clauses

52.222-23 Notice of Requirement for Affirmative Action To Ensure Equal Employment Opportunity for Construction. (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

SMSA Counties MS Jackson.: 6026 Pascagoula - Moss, Point MS__________16.9 %

Goals for female participation for each trade

Nationwide Goal_____________________________________________________6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area.

If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled Affirmative Action Compliance Requirements for Construction, and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the-

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the covered area is Mississippi (state), Jackson (county), Ocean Springs (nearest city)..

(End of provision)

52.222-27 Affirmative Action Compliance Requirements for Construction. (APR 2015)

52.236-1 Performance of Work by the Contractor. (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 15 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

52.236-13 Accident Prevention. (NOV 1991) - Alternate I (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will (1) safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities; (2) avoid interruptions of Government operations and delays in project completion dates; and (3) control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall -

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR part 1926 and 29 CFR part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(f) Before commencing the work, the Contractor shall -

(1) Submit a written proposed plan for implementing this clause. The plan shall include an analysis of the significant hazards to life, limb, and property inherent in contract work performance and a plan for controlling these hazards; and

(2) Meet with representatives of the Contracting Officer to discuss and develop a mutual understanding relative to administration of the overall safety program.

(End of clause)

52.236-15 Schedules for Construction Contracts. (APR 1984)

1452.204-70 Release of Claims (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI-

137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

PRESERVATION OF HISTORICAL AND ARCHEOLOGICAL DATA (NOV 2007)

(a) The Historic and Archeological Data Preservation Act of 1974, provides for the preservation of historical and archeological data that might otherwise be lost as the result of alterations to the terrain caused by a federal or federally licensed activity or program.

(b) If, in connection with operations under this contract, the Contractor, subcontractors, or the employees of any of them, discovers, encounters or becomes aware of any possible historical or archeological data, objects or sites of cultural value on the project area, such as historical ruins, graves or grave markers, fossils, or artifacts, the Contractor shall immediately suspend all operations in the vicinity of the cultural value and shall notify the Contracting Officer in writing, giving the location and nature of the findings. No objects of cultural resource value may be removed.

(c) Where appropriate by reason of discovery, the Contracting Officer may order delays in the time of performance and/or changes in the work. If such delays and/or changes are ordered, the time of performance and contract price shall be adjusted in accordance with the Changes clause.

(d) The Contractor will be responsible for protecting the cultural resources within the effected area from damage. In addition, the contractor will be liable for all damage to the identified cultural resources caused by their actions or the actions of their agents or representatives. The Contractor shall immediately notify the Contracting Officer or his representative if any damage occurs to any cultural resource and immediately suspend work in the area in which damage has occurred until authorized to proceed.

(e) The Contractor agrees to insert this paragraph in all subcontracts that involve the performance of work on the terrain of the site.

Alternate 1:

Insert the following paragraph (f) if the work is being performed on tribal lands:

(f) If the discovery occurs on tribal lands, the Contractor shall immediately orally notify the responsible tribal official and the Contracting Officer, and follow with written confirmation within 2 days to the responsible tribal official and the Contracting Officer. The contact information for the tribal official may be obtained at: http://web.cast.uark.edu/other/nps/nacd.

(End of Clause)

AUTHORITIES AND DELEGATIONS (SEPT 2011)

Authorities and Delegations (SEP 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting

Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause;

(4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum.

The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph

(d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

(End of clause)

I - Contract Clauses

Clauses

52.203-3 Gratuities. (APR 1984)

52.203-5 Covenant Against Contingent Fees. (MAY 2014)

52.203-7 Anti-Kickback Procedures. (MAY 2014)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity. (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. (MAY 2014)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions. (OCT 2010)

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights. (APR 2014)

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper. (MAY 2011)

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (OCT 2018)

52.204-12 Unique Entity Identifier Maintenance. (OCT 2016)

52.204-13 System for Award Management Maintenance. (OCT 2018)

52.204-22 Alternative Line Item Proposal. (JAN 2017)

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror's practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation.

However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable.

(End of provision)

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment. (OCT 2015)

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations. (NOV 2015)

52.214-29 Order of Precedence - Sealed Bidding. (JAN 1986)

52.216-24 Limitation of Government Liability. (APR 1984)

(a) In performing this contract, the Contractor is not authorized to make expenditures or incur obligations exceeding Not Applicabledollars.

(b) The maximum amount for which the Government shall be liable if this contract is terminated is Not Applicabledollars.

(End of clause)

52.216-25 Contract Definitization. (OCT 2010)

(a) A clause inapplicable to FFP definitive contract is contemplated. The Contractor agrees to begin promptly negotiating with the Contracting Officer the terms of a definitive contract that will include (1) all clauses required by the Federal Acquisition Regulation (FAR) on the date of execution of the letter contract, (2) all clauses required by law on the date of execution of the definitive contract, and (3) any other mutually agreeable clauses, terms, and conditions. The Contractor agrees to submit a [insert specific type of proposal (e.g., fixed-price or cost-and-fee)] proposal, including data other than certified cost or pricing data, and certified cost or pricing data, in accordance with FAR 15.408, Table 15-2, supporting its proposal.

(b) The schedule for definitizing this contract is: [insert target date for definitization of the contract and dates for submission of proposal, beginning of negotiations, and, if appropriate, submission of make-or-buy and subcontracting plans and certified cost or pricing data]

(c) If agreement on a definitive contract to supersede this letter contract is not reached by the target date in paragraph (b) above, or within any extension of it granted by the Contracting Officer, the Contracting Officer may, with the approval of the head of the contracting activity, determine a reasonable price or fee in accordance with subpart 15.4 and part 31 of the FAR, subject to Contractor appeal as provided in the Disputes clause. In any event, the Contractor shall proceed with completion of the contract, subject only to the Limitation of Government Liability clause.

(1) After the Contracting Officer's determination of price or fee, the contract shall be governed by-

(i) All clauses required by the FAR on the date of execution of this letter contract for either fixed-price or cost-reimbursement contracts, as determined by the Contracting Officer under this paragraph (c);

(ii) All clauses required by law as of the date of the Contracting Officer's determination; and

(iii) Any other clauses, terms, and conditions mutually agreed upon.

(2) To the extent consistent with subparagraph (c)(1) above, all clauses, terms, and conditions included in this letter contract shall continue in effect, except those that by their nature apply only to a letter contract.

(End of clause)

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (OCT 2014)

(a) Definitions. See 13 CFR 125.6(e) for definitions of terms used in paragraph (d).

(b) Evaluation preference. (1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(2) The factor of 10 percent shall be applied on a line item basis or to any group of items on which award may be made. Other evaluation factors described in the solicitation shall be applied before application of the factor.

(3) When the two highest rated offerors are a HUBZone small business concern and a large business, and the evaluated offer of the HUBZone small business concern is equal to the evaluated offer of the large business after considering the price evaluation preference, award will be made to the HUBZone small business concern.

(c) Waiver of evaluation preference. A HUBZone small business concern may elect to waive the evaluation preference, in which case the factor will be added to its offer for evaluation purposes.

The agreements in paragraphs (d) and (e) of this clause do not apply if the offeror has waived the evaluation preference.

[ ] Offeror elects to waive the evaluation preference.

(d) Agreement. A HUBZone small business concern agrees that in the performance of the contract, in the case of a contract for

(1) Services (except construction), at least 50 percent of the cost of personnel for contract performance will be spent for employees of the concern or employees of other HUBZone small business concerns;

(2) Supplies (other than procurement from a nonmanufacturer of such supplies), at least 50 percent of the cost of manufacturing, excluding the cost of materials, will be performed by the concern or other HUBZone small business concerns;

(3) General construction. (i) At least 15 percent of the cost of contract performance to be incurred for personnel will be spent on the prime contractor's employees;

(ii) At least 50 percent of the cost of the contract performance to be incurred for personnel will be spent on the prime contractor's employees or on a combination of the prime contractor's employees and employees of HUBZone small business concern subcontractors;

(iii) No more than 50 percent of the cost of contract performance to be incurred for personnel will be subcontracted to concerns that are not HUBZone small business concerns; or

(4) Construction by special trade contractors. (i) At least 25 percent of the cost of contract performance to be incurred for personnel will be spent on the prime contractor's employees;

(ii) At least 50 percent of the cost of the contract performance to be incurred for personnel will be spent on the prime contractor's employees or on a combination of the prime contractor's employees and employees of HUBZone small business concern subcontractors;

(iii) No more than 50 percent of the cost of contract performance to be incurred for personnel will be subcontracted to concerns that are not HUBZone small business concerns.

(e) A HUBZone joint venture agrees that the aggregate of the HUBZone small business concerns to the joint venture, not each concern separately, will perform the applicable percentage of work requirements.

(f)(1) When the total value of the contract exceeds $25,000, a HUBZone small business concern nonmanufacturer agrees to furnish in performing this contract only end items manufactured or produced by HUBZone small business concern manufacturers.

(2) When the total value of the contract is equal to or less than $25,000, a HUBZone small business concern nonmanufacturer may provide end items manufactured by other than a HUBZone small business concern manufacturer provided the end items are produced or manufactured in the United States.

(3) Paragraphs (f)(1) and (f)(2) of this section do not apply in connection with construction or service contracts.

(g) Notice. The HUBZone small business offeror acknowledges that a prospective HUBZone awardee must be a HUBZone small business concern at the time of award of this contract. The HUBZone offeror shall provide the Contracting Officer a copy of the notice required by 13 CFR

126.501 if material changes occur before contract award that could affect its HUBZone eligibility.

If the apparently successful HUBZone offeror is not a HUBZone small business concern at the time of award of this contract, the Contracting Officer will proceed to award to the next otherwise successful HUBZone small business concern or other offeror.

(End of clause)

52.219-6 Notice of Total Small Business Set-Aside. (NOV 2011)

52.219-8 Utilization of Small Business Concerns. (OCT 2018)

52.219-14 Limitations on Subcontracting. (JAN 2017)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside or reserved for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; and

(3) Orders set aside for small business or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).

(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for-

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a non-manufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.

(End of clause)

52.219-28 Post-Award Small Business Program Rerepresentation. (JUL 2013)

(a) Definitions. As used in this clause-

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause. Such a concern is "not dominant in its field of operation" when it does not exercise a controlling or major influence on a national basis in a kind of business activity in which a number of business concerns are primarily engaged. In determining whether dominance exists, consideration shall be given to all appropriate factors, including volume of business, number of employees, financial resources, competitive status or position, ownership or control of materials, processes, patents, license agreements, facilities, sales territory, and nature of business activity.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts-

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the date specified in the contract for exercising any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/content/table-small-business-size-standards.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the representation required by paragraph (b) of this clause by validating or updating all its representations in the Representations and Certifications section of the System for Award Management (SAM) and its other data in SAM, as necessary, to ensure that they reflect the Contractor's current status. The Contractor shall notify the contracting office in writing within the timeframes specified in paragraph (b) of this clause that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in SAM, or does not have a representation in SAM for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it [ ] is, [ ] is not a small business concern under NAICS Code [insert NAICS Code] assigned to contract number [insert contract number]. (Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.222-3 Convict Labor. (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards - Overtime Compensation. (MAY 2018)

(a) Overtime requirements. No Contractor or subcontractor employing laborers or mechanics (see Federal Acquisition Regulation 22.300) shall require or permit them to work over 40 hours in any workweek unless they are paid at least 1 and 1/2 times the basic rate of pay for each hour worked over 40 hours.

(b) Violation; liability for unpaid wages; liquidated damages. The responsible Contractor and subcontractor are liable for unpaid wages if they violate the terms in paragraph (a) of this clause.

In addition, the Contractor and subcontractor are liable for liquidated damages payable to the Government. The Contracting Officer will assess liquidated damages at the rate specified at 29 CFR 5.5(b)(2) per affected employee for each calendar day on which the employer required or permitted the employee to work in excess of the standard workweek of 40 hours without paying overtime wages required by the Contract Work Hours and Safety Standards statute (found at 40 U.S.C. chapter 37). In accordance with the Federal Civil Penalties Inflation Adjustment Act of 1990 (28 U.S.C. 2461 Note), the Department of Labor adjusts this civil monetary penalty for inflation no later than January 15 each year.

(c) Withholding for unpaid wages and liquidated damages. The Contracting Officer will withhold from payments due under the contract sufficient funds required to satisfy any Contractor or subcontractor liabilities for unpaid wages and liquidated damages. If amounts withheld under the contract are insufficient to satisfy Contractor or subcontractor liabilities, the Contracting Officer will withhold payments from other Federal or Federally assisted contracts held by the same Contractor that are subject to the Contract Work Hours and Safety Standards statute.

(d) Payrolls and basic records. (1) The Contractor and its subcontractors shall maintain payrolls and basic payroll records for all laborers and mechanics working on the contract during the contract and shall make them available to the Government until 3 years after contract completion.

The records shall contain the name and address of each employee, social security number, labor classifications, hourly rates of wages paid, daily and weekly number of hours worked, deductions made, and actual wages paid. The records need not duplicate those required for construction work by Department of Labor regulations at 29 CFR 5.5(a)(3) implementing the Construction Wage Rate Requirements statute.

(2) The Contractor and its subcontractors shall allow authorized representatives of the Contracting Officer or the Department of Labor to inspect, copy, or transcribe records maintained under paragraph (d)(1) of this clause. The Contractor or subcontractor also shall allow authorized representatives of the Contracting Officer or Department of Labor to interview employees in the workplace during working hours.

(e) Subcontracts. The Contractor shall insert the provisions set forth in paragraphs (a) through (d) of this clause in subcontracts that may require or involve the employment of laborers and mechanics and require subcontractors to include these provisions in any such lower tier subcontracts. The Contractor shall be responsible for compliance by any subcontractor or lower-tier subcontractor with the provisions set forth in paragraphs (a) through (d) of this clause.

(End of clause)

52.222-6 Construction Wage Rate Requirements. (AUG 2018)

(a) Definition- Site of the work-(1) Means-

(i) The primary site of the work. The physical place or places where the construction called for in the contract will remain when work on it is completed;

and

(ii) The secondary site of the work, if any. Any other site where a significant portion of the building or work is constructed, provided that such site is-

(A) Located in the United States; and

(B) Established specifically for the performance of the contract or project;

(2) Except as provided in paragraph (3) of this definition, includes any fabrication plants, mobile factories, batch plants, borrow pits, job headquarters, tool yards, etc., provided-

(i) They are dedicated exclusively, or nearly so, to performance of the contract or project; and

(ii) They are adjacent or virtually adjacent to the "primary site of the work" as defined in paragraph (a)(1)(i), or the "secondary site of the work" as defined in paragraph (a)(1)(ii) of this definition;

(3) Does not include permanent home offices, branch plant establishments, fabrication plants, or tool yards of a Contractor or subcontractor whose locations and continuance in operation are determined wholly without regard to a particular Federal contract or project. In addition, fabrication plants, batch plants, borrow pits, job headquarters, yards, etc., of a commercial or material supplier which are established by a supplier of materials for the project before opening of bids and not on the Project site, are not included in the "site of the work." Such permanent, previously established facilities are not a part of the "site of the work" even if the operations for a period of time may be dedicated exclusively or nearly so, to the performance of a contract.

(b)(1) All laborers and mechanics employed or working upon the site of the work will be paid unconditionally and not less often than once a week, and without subsequent deduction or rebate on any account (except such payroll deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents thereof) due at time of payment computed at rates not less than those contained in the wage determination of the Secretary of Labor which is attached hereto and made a part hereof, or as may be incorporated for a secondary site of the work, regardless of any contractual relationship which may be alleged to exist between the Contractor and such laborers and mechanics. Any wage determination incorporated for a secondary site of the work shall be effective from the first day on which work under the contract was performed at that site and shall be incorporated without any adjustment in contract price or estimated cost. Laborers employed by the construction Contractor or construction subcontractor that are transporting portions of the building or work between the secondary site of the work and the primary site of the work shall be paid in accordance with the wage determination applicable to the primary site of the work.

(2) Contributions made or costs reasonably anticipated for bona fide fringe benefits under section 1(b)(2) of the Construction Wage Rate Requirements statute on behalf of laborers or mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of paragraph (e) of this clause; also, regular contributions made or costs incurred for more than a weekly period (but not less often than quarterly) under plans, funds, or programs which cover the particular weekly period, are deemed to be constructively made or incurred during such period.

(3) Such laborers and mechanics shall be paid not less than the appropriate wage rate and fringe benefits in the wage determination for the classification of work actually performed, without regard to skill, except as provided in the clause entitled Apprentices and Trainees. Laborers or mechanics performing work in more than one classification may be compensated at the rate specified for each classification for the time actually worked therein; provided that the employer's payroll records accurately set forth the time spent in each classification in which work is performed.

(4) The wage determination (including any additional classifications and wage rates conformed under paragraph (c) of this clause) and the Construction Wage Rate Requirements (Davis-Bacon Act) poster…