B08_Solicitation_Clauses_(revised).docx

TABLE OF CONTENTS

PART I – The Schedule

52.246-12 Inspection of Construction

52.211-10 Commencement, Prosecution, and Completion of Work

52.211-13 Time Extensions

52.242-14 Suspension of Work

Notice to Contractors - Contractor Performance Assessment Reporting System

Electronic Invoicing and Payment Requirements – Invoice Processing Platform (IPP)

Special Clause 1: Key Personnel

1452.201-70 Authorities and Delegations

1452.204-70 Release of Claims

1452.203-70 Restriction on Endorsements—Department of the interior

1452.215-70 Examination of Records by the Department of the Interior

1452.228-70 Liability Insurance—Department of the Interior

1452.236-70 Prohibition Against Use of Lead-based Paint

1452.233-2 Service of Protest Department of the Interior (JUL 1996) (Deviation)

Wage Determination

PART II – Contract Clauses

52.202-1 Definitions

52.219-14 Limitations on Subcontracting (Jan 2017)

52.222-35 Equal Opportunity for Veterans

52.222-36 Equal Opportunity for Workers with Disabilities

52.223-9 Estimate of Percentage of Recovered Material Content for EPA- Designated Products

52.225-9 Buy American—Construction Materials

52.252-2 Clauses Incorporated by Reference

Clauses Incorporated by Reference:

52.203-3 Gratuities

52.203-5 Covenant Against Contingent Fees

52.203-7 Anti-Kickback Procedures

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity

52.203-12 Limitation on Payments to Influence Certain Federal Transactions

52.203-13 Contractor Code of Business Ethics and Conduct

52.203-14 Display of Hotline Poster(s)

52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights

52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper

52.204-9 Personal Identity Verification of Contractor Personnel

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards

52.204-13 System for Award Management Maintenance

52.204-14 Service Contract Reporting Requirements

52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

52.210-1 Market Research

52.215-2 Audit and Records—Negotiation

52.215-8 Order of Precedence—Uniform Contract Format

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data – Modifications

52.215-19 Notification of Ownership Changes

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns

52.219-6 Notice of Total Small Business Set-aside (Nov 2011)

52.219-8 Utilization of Small Business Concerns

52.219-28 Post-Award Small Business Program Rerepresentation

52.222-3 Convict Labor

52.222-4 Contract Work Hours and Safety Standards—Overtime Compensation

52.222-6 Construction Wage Rate Requirements

52.222-7 Withholding of Funds

52.222-8 Payrolls and Basic Records

52.222-9 Apprentices and Trainees

52.222-10 Compliance with Copeland Act Requirements

52.222-11 Subcontracts (Labor Standards)

52.222-12 Contract Termination—Debarment

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations

52.222-14 Disputes Concerning Labor Standards

52.222-15 Certification of Eligibility

52.222-21 Prohibition of Segregated Facilities

52.222-26 Equal Opportunity

52.222-27 Affirmative Action Compliance Requirements for Construction

52.222-37 Employment Reports on Veterans

52.222-40 Notification of Employee Rights Under the National Labor Relations Act

52.222-50 Combating Trafficking in Persons

52.222-54 Employment Eligibility Verification

52.222-55 Minimum Wages Under Executive Order 13658

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

52.223-3 Hazardous Material Identification and Material Safety Data—Alternate I

52.223-5 Pollution Prevention and Right-to-Know Information

52.223-6 Drug-Free Workplace

52.223-15 Energy Efficiency in Energy-Consuming Products

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving

52.224-1 Privacy Act Notification

52.224-2 Privacy Act

52.225-13 Restrictions on Certain Foreign Purchases

52.227-1 Authorization and Consent

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement

52.227-4 Patent Indemnity—Construction Contracts

52.228-2 Additional Bond Security

52.228-5 Insurance—Work on a Government Installation

52.228-11 Pledges of Assets

52.228-12 Prospective Subcontractor Requests for Bonds

52.228-14 Irrevocable Letter of Credit

52.228-15 Performance and Payment Bonds—Construction

52.229-3 Federal, State, and Local Taxes

52.232-5 Payments under Fixed-Price Construction Contracts

52.232-23 Assignment of Claims

52.232-27 Prompt Payment for Construction Contracts

52.232-33 Payment by Electronic Funds Transfer—System for Award Management

52.232-39 Unenforceability of Unauthorized Obligations

52.232-40 Providing Accelerated Payments to Small Business Subcontractors

52.233-1 Disputes—Alternate I

52.233-3 Protest after Award

52.233-4 Applicable Law for Breach of Contract Claim

52.236-2 Differing Site Conditions

52.236-3 Site Investigation and Conditions Affecting the Work

52.236-5 Material and Workmanship

52.236-6 Superintendence by the Contractor

52.236-7 Permits and Responsibilities

52.236-8 Other Contracts

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

52.236-10 Operations and Storage Areas

52.236-11 Use and Possession Prior to Completion

52.236-12 Cleaning Up

52.236-13 Accident Prevention

52.236-14 Availability and Use of Utility Services

52.236-15 Schedules for Construction Contracts

52.236-16 Quantity Surveys

52.236-21 Specifications and Drawings for Construction

52.236-26 Preconstruction Conference

52.242-13 Bankruptcy

52.243-4 Changes

52.244-6 Subcontracts for Commercial Items

52.246-21 Warranty of Construction

52.248-3 Value Engineering—Construction

52.249-2 Termination for Convenience of the Government (Fixed-Price)—Alternate I

52.249-10 Default (Fixed-Price Construction)

52.253-1 Computer Generated Forms

PART III – List of Documents, Exhibits, and Other Attachments

PART IV – Representations and Instructions

52.204-8 Annual Representations and Certifications

52.204-19 Incorporation by Reference of Representations and Certifications (Dec 2014)

52.209-5 Certification Regarding Responsibility Matters

52.209-7 Information Regarding Responsibility Matters

52.215-1 Instructions to Offerors—Competitive

Instructions for the Submission of Offers and Other Information

52.204-7 System for Award Management

52.211-6 Brand Name or Equal

1452.215-71 Use and Disclosure of Proposal Information – Department of Interior

52.216-1 Type of Contract

52.222-5 Construction Wage Rate Requirements—Secondary Site of the Work

52.222-23 Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for Construction

52.225-10 Notice of Buy American Requirement—Construction Materials

52.228-1 Bid Guarantee

52.236-27 Site Visit (Construction)

52.236-28 Preparation of Proposals—Construction

52.252-5 Authorized Deviations in Provisions

Significant Factors and Sub-factors

Solicitation 140P30-18-R-0002

ANTI Burnside Bridge Walkway

SECTION B – SUPPLIES OR SERVICES AND PRICES

PRICE SCHEDULE

DATE:

COMPANY NAME:

DUNS #:

CONTACT NAME:

PHONE:

E-MAIL:

Burnside Bridge Walkway

LS

PRICE SCHEDULE GENERAL NOTES

1. Offerors shall submit a lump sum price above and a price for all line items listed on the Price Schedule attachment; failure to do so may render the offer unacceptable.

2. Refer to attached project specifications for definitions of the line items.

3. On lump-sum line items, provide total price only.

4. If no item exists for a portion of the work, include the price in a related line item.

5. In accordance with Federal Acquisition Regulations only the Contracting Officer has authority to change the scope of work, project schedule or the contract price. The contractor shall notify the Contracting Officer immediately if they believe they have been given direction which changes the scope of work, project schedule or contract price.

SECTION C – DESCRIPTIONS/SPECIFICATIONS/STATEMENT OF WORK

The Statement of Work (SOW) consists of the documents listed in section "J". In addition the full project scope includes the terms and conditions as noted in sections B through J.

This acquisition is being conducted per the procedures authorized in Part 15 of the Federal Acquisition Regulations. The term "bid" and "bidders" shall mean "offer" and "offeror".

SECTION D – PACKAGING AND MARKING

This section is not used.

SECTION E – INSPECTION AND ACCEPTANCE

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

(a) Definition. “Work” includes, but is not limited to, materials, workmanship, and manufacture and fabrication of components.

(b) The Contractor shall maintain an adequate inspection system and perform such inspections as will ensure that the work performed under the contract conforms to contract requirements. The Contractor shall maintain complete inspection records and make them available to the Government. All work shall be conducted under the general direction of the Contracting Officer and is subject to Government inspection and test at all places and at all reasonable times before acceptance to ensure strict compliance with the terms of the contract.

(c) Government inspections and tests are for the sole benefit of the Government and do not— (1) Relieve the Contractor of responsibility for providing adequate quality control measures;

(2) Relieve the Contractor of responsibility for damage to or loss of the material before acceptance; (3) Constitute or imply acceptance; or

(4) Affect the continuing rights of the Government after acceptance of the completed work under paragraph (i) of this section.

(d) The presence or absence of a Government inspector does not relieve the Contractor from any contract requirement, nor is the inspector authorized to change any term or condition of the specification without the Contracting Officer’s written authorization.

(e) The Contractor shall promptly furnish, at no increase in contract price, all facilities, labor, and material reasonably needed for performing such safe and convenient inspections and tests as may be required by the Contracting Officer. The Government may charge to the Contractor any additional cost of inspection or test when work is not ready at the time specified by the Contractor for inspection or test, or when prior rejection makes re-inspection or retest necessary. The Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.

(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.

(g) If the Contractor does not promptly replace or correct rejected work, the Government may—

(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or

(2) Terminate for default the Contractor’s right to proceed.

(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.

(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.

(End of clause)

SECTION F – DELIVERIES OR PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than March 30, 2018. Period of performance is 180 days after Notice to Proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-13 TIME EXTENSIONS (SEPT 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

52.242-14 SUSPENSION OF WORK (APR 1984)

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer’s failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed—

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

SECTION G – CONTRACT ADMINISTRATION DATA

NOTICE TO CONTRACTORS - CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM (December 2015)

1. FAR 42.1502 directs all Federal agencies to collect past performance information on contracts. The Department of the Interior (DOI) has implemented the Contractor Performance Assessment Reporting System (CPARS) to comply with this regulation. One or more past performance evaluations will be conducted in order to record your contract performance as required by FAR 42.15.

2. The past performance evaluation process is a totally paperless process using CPARS. CPARS is a web-based system that allows for electronic processing of the performance evaluation report. Once the report is processed, it is available in the Past Performance Information Retrieval System (PPIRS) for Government use in evaluating past performance as part of a source selection action.

3. We request that you furnish the Contracting Officer (CO) with the name, position title, phone number, and email address for each person designated to have access to your firm's past performance evaluation(s) for the contract no later than 30 days after award. Each person granted access will have the ability to provide comments in the Contractor portion of the report and state whether or not the Contractor agrees with the evaluation, before returning the report to the Assessing Official (AO). Information in the report must be protected as source selection sensitive information not releasable to the public.

4. When your Contractor Representative(s) are registered in CPARS, they will receive an automatically generated email with detailed login instructions. Further details, systems requirements, and training information for CPARS is available at https://www.cpars.gov/.

5. Within 60 days after the end of a performance period, the AO will complete an interim or final past performance evaluation, and the report will be accessible at https://www.cpars.gov/.

a. Contractor Representatives may then provide comments in response to the evaluation, or return the evaluation without comment.

b. Your comments should focus on objective facts in the AO's narrative and should provide your views on the causes and ramifications of the assessed performance.

c. All information provided should be reviewed for accuracy prior to submission.

d. If you elect not to provide comments, please acknowledge receipt of the evaluation by indicating "No comment" in the space provided, and then selecting “Accept the Ratings and Close the Evaluation”.

e. Your response is due within 60 calendar days after receipt of the CPAR. On day 15, the evaluation will become available in PPIRS-RC marked as “Pending” with or without comments and whether or not it has been closed.

f. If you do not sign and submit the CPAR within 60 days, it will automatically be returned to the Government and will be annotated: "The report was delivered/received by the contractor on (date). The contractor neither signed nor offered comment in response to this assessment."

6. The following guidelines apply concerning your use of the past performance evaluation:

a. Protect the evaluation as source selection information. After review, transmit the evaluation by completing and submitting the form through CPARS. If for some reason you are unable to view and/or submit the form through CPARS, contact the CO for instructions.

b. Strictly control access to the evaluation within your organization. Ensure the evaluation is never released to persons or entities outside of your control.

c. Prohibit the use of or reference to evaluation data for advertising, promotional material, pre-award surveys, responsibility determinations, production readiness reviews, or other similar purposes.

7. If you wish to discuss a past performance evaluation, you should request a meeting in writing to the CO no later than seven days following your receipt of the evaluation. The meeting will be held in person or via telephone or other means during your 60-day review period.

8. A copy of the completed past performance evaluation will be available in CPARS for your viewing and for Government use supporting source selection actions after it has been finalized.

(End of Notice)

Electronic Invoicing and Payment Requirements - Invoice Processing Platform (IPP) (April 2013)

Payment requests must be submitted electronically through the U. S. Department of the Treasury's Invoice Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions - Commercial Items included in commercial item contracts. The IPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice:

1. Contractor’s Payment Application / Invoice

2. Updated Schedule of Values

The Contractor must use the IPP website to register access and use IPP for submitting requests for payment. The Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) within 3 - 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP Production Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the Contractor must submit a waiver request in writing to the Contracting Officer with its proposal or quotation.

(End of Local Clause)

SECTION H – SPECIAL CONTRACT REQUIREMENTS

SPECIAL CLAUSE 1: KEY PERSONNEL

(a) The Contractor shall assign to this contract the following key personnel:

Project Manager:

Job-site Superintendent:

Quality Control Supervisor: _______

(b) During the first 90 days of performance after Notice to Proceed, the Contractor shall make no substitutions of key personnel unless the substitution is necessitated by illness, death, or termination of employment. The Contractor shall notify the Contracting Officer within 15 calendar days after the occurrence of any of these events and provide the information required by paragraph (c) below. After the 90-day period, the Contractor shall submit the information required by paragraph (c) to the Contracting Officer at least 15 days prior to making any permanent substitutions.

(c) The Contractor shall provide a detailed explanation of the circumstances necessitating the proposed substitutions, complete resumes for the proposed substitutes, and any additional information requested by the Contracting Officer. Proposed substitutes should have comparable qualifications to those of the persons being replaced. The Contracting Officer will notify the Contractor within 15 calendar days after receipt of all required information of the decision on substitutions. This clause will be modified to reflect any approved changes of key personnel.

1452.201-70 AUTHORITIES AND DELEGATIONS (SEPT 2011)

(a) The Contracting Officer is the only individual authorized to enter into or terminate this contract, modify any term or condition of this contract, waive any requirement of this contract, or accept nonconforming work.

(b) The Contracting Officer will designate a Contracting Officer's Representative (COR) at time of award. The COR will be responsible for technical monitoring of the contractor's performance and deliveries. The COR will be appointed in writing, and a copy of the appointment will be furnished to the Contractor. Changes to this delegation will be made by written changes to the existing appointment or by issuance of a new appointment.

(c) The COR is not authorized to perform, formally or informally, any of the following actions:

(1) Promise, award, agree to award, or execute any contract, contract modification, or notice of intent that changes or may change this contract;

(2) Waive or agree to modification of the delivery schedule;

(3) Make any final decision on any contract matter subject to the Disputes Clause; (4) Terminate, for any reason, the Contractor's right to proceed;

(5) Obligate in any way, the payment of money by the Government.

(d) The Contractor shall comply with the written or oral direction of the Contracting Officer or authorized representative(s) acting within the scope and authority of the appointment memorandum. The Contractor need not proceed with direction that it considers to have been issued without proper authority. The Contractor shall notify the Contracting Officer in writing, with as much detail as possible, when the COR has taken an action or has issued direction (written or oral) that the Contractor considers to exceed the COR's appointment, within 3 days of the occurrence. Unless otherwise provided in this contract, the Contractor assumes all costs, risks, liabilities, and consequences of performing any work it is directed to perform that falls within any of the categories defined in paragraph (c) prior to receipt of the Contracting Officer's response issued under paragraph (e) of this clause.

(e) The Contracting Officer shall respond in writing within 30 days to any notice made under paragraph (d) of this clause. A failure of the parties to agree upon the nature of a direction, or upon the contract action to be taken with respect thereto, shall be subject to the provisions of the Disputes clause of this contract.

(f) The Contractor shall provide copies of all correspondence to the Contracting Officer and the COR.

(g) Any action(s) taken by the Contractor, in response to any direction given by any person acting on behalf of the Government or any Government official other than the Contracting Officer or the COR acting within his or her appointment, shall be at the Contractor's risk.

1452.204-70 RELEASE OF CLAIMS—DEPARTMENT OF THE INTERIOR (JUL 1996)

After completion of work and prior to final payment, the Contractor shall furnish the Contracting Officer with a release of claims against the United States relating to this contract. The Release of Claims form (DI–137) shall be used for this purpose. The form provides for exception of specified claims from operation of the release.

(End of clause)

1452.203-70 RESTRICTIONS ON ENDORSEMENTS (JUL 1996)

The Contractor shall not refer to contracts awarded by the Department of the Interior in commercial advertising, as defined in FAR 31.205–1, in a manner which states or implies that the product or service provided is approved or endorsed by the Government, or is considered by the Government to be superior to other products or services. This restriction is intended to avoid the appearance of preference by the Government toward any product or service. The Contractor may request the Contracting Officer to make a determination as to the propriety of promotional material.

(End of clause)

1452.215-70 EXAMINATION OF RECORDS BY THE DEPARTMENT OF THE INTERIOR (APR

1984)

For purposes of the Examination of Records by the Comptroller General clause of this contract (FAR 52.215–2(d)), the Secretary of the Interior, the Inspector General, and their duly authorized representative(s) from the Department of the Interior shall have the same access and examination rights as the Comptroller General of the United States.

1452.228-70 LIABILITY INSURANCE—DEPARTMENT OF THE INTERIOR (JUL 1996)

(a) The Contractor shall procure and maintain during the term of this contract and any extension thereof liability insurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer. The named insured parties under the policy shall be the Contractor and the United States of America. The amounts of the insurance shall be not less than as follows:

(i) Workers' compensation and employer's liability. Contractors are required to comply with applicable Federal and State workers' compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy. Employer's liability coverage of at least $100,000 is required.

(ii) General liability: $1,000,000

(iii) Automobile liability. The contractor is required to obtain automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage.

(iv) The amount of liability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

(b) Each policy shall have a certificate evidencing the insurance coverage. The insurance company shall provide an endorsement to notify the Contracting Officer 30 days prior to the effective date of cancellation or termination of the policy or certificate; or modification of the policy or certificate which may adversely affect the interest of the Government in such insurance. The certificate shall identify the contract number, the name and address of the Contracting Officer, as well as the insured, the policy number and a brief description of contract services to be performed. The contractor shall furnish the Contracting Officer with a copy of an acceptable insurance certificate prior to beginning the work.

(End of clause)

1452.236-70 PROHIBITION AGAINST USE OF LEAD-BASED PAINT (JUL 1996)

Paint containing more than .06 percent by weight of lead in paint, or the equivalent measure of lead in the dried film of paint already applied, shall not be used in the construction or rehabilitation of residential structures under this contract or any resulting subcontracts.

(End of clause) 1452.233-2 SERVICE OF PROTEST DEPARTMENT OF THE INTERIOR (SEPT 2006) (DEVIATION) (JUL 1996)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from

National Park Service Office of Acquisition, Financial Assistance and Property Management Attention: Stacey Rickard Contracting Officer 1100 Ohio Drive, SW Washington, DC 20242

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the

GAO.

(c) A copy of the protest served on the Contracting Officer shall be simultaneously furnished by the protester to the Department of the Interior Assistant Solicitor, Acquisitions and Intellectual Property, 1849 C Street, NW, Room 6511, Washington, DC 20240.

(End of provision)

CONSTRUCTION WAGE DECISION:

General Decision Number: MD170036 dated 07/14/2017 MD36 Superseded General Decision Number: MD20160036 Maryland

SECTION I – CONTRACT CLAUSES

52.202-1 DEFINITIONS (NOV 2013)

When a solicitation provision or contract clause uses a word or term that is defined in the Federal Acquisition Regulation (FAR), the word or term has the same meaning as the definition in FAR 2.101 in effect at the time the solicitation was issued, unless—

(a) The solicitation, or amended solicitation, provides a different definition; (b) The contracting parties agree to a different definition;

(c) The part, subpart, or section of the FAR where the provision or clause is prescribed provides a different meaning; or

(d) The word or term is defined in FAR Part 31, for use in the cost principles and procedures.

(End of clause)

52.219-14 LIMITATIONS ON SUBCONTRACTING (JAN 2017)

(a) This clause does not apply to the unrestricted portion of a partial set-aside.

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside or reserved for small business concerns or 8(a) participants;

(2) Part or parts of a multiple-award contract that have been set aside for small business concerns or 8(a) participants; and

(3) Orders set aside for small business or 8(a) participants under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F).

(c) By submission of an offer and execution of a contract, the Offeror/Contractor agrees that in performance of the contract in the case of a contract for --

(1) Services (except construction). At least 50 percent of the cost of contract performance incurred for personnel shall be expended for employees of the concern.

(2) Supplies (other than procurement from a nonmanufacturer of such supplies). The concern shall perform work for at least 50 percent of the cost of manufacturing the supplies, not including the cost of materials.

(3) General construction. The concern will perform at least 15 percent of the cost of the contract, not including the cost of materials, with its own employees.

(4) Construction by special trade contractors. The concern will perform at least 25 percent of the cost of the contract, not including the cost of materials, with its own employees.

(End of Clause)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (OCT 2015)

(a) Definitions. As used in this clause-- “Active duty wartime or campaign badge veteran,” “Armed Forces service medal veteran,” “disabled veteran,” “protected veteran,” “qualified disabled veteran,’ and “recently separated veteran” have the meanings given at FAR 22.1301.

(b) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-300.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified protected veterans, and requires affirmative action by the Contractor to employ and advance in employment qualified protected veterans.

(c) Subcontracts. The Contractor shall insert the terms of this clause in subcontracts of $150,000 or more unless exempted by rules, regulations, or orders of the Secretary of Labor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate of identify properly the parties and their undertakings.

(End of Clause)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUL 2014)

(a) Equal opportunity clause. The Contractor shall abide by the requirements of the equal opportunity clause at 41 CFR 60-741.5(a), as of March 24, 2014. This clause prohibits discrimination against qualified individuals on the basis of disability, and requires affirmative action by the Contractor to employ and advance in employment qualified individuals with disabilities.

(b) Subcontracts. The Contractor shall include the terms of this clause in every subcontract or purchase order in excess of $15,000 unless exempted by rules, regulations, or orders of the Secretary, so that such provisions will be binding upon each subcontractor or vendor. The Contractor shall act as specified by the Director, Office of Federal Contract Compliance Programs of the U.S. Department of Labor, to enforce the terms, including action for noncompliance. Such necessary changes in language may be made as shall be appropriate to identify properly the parties and their undertakings.

(End of clause)

52.223-9 ESTIMATE OF PERCENTAGE OF RECOVERED MATERIAL CONTENT FOR EPA- DESIGNATED PRODUCTS (MAY 2008)

(a) Definitions. As used in this clause— “Postconsumer material” means a material or finished product that has served its intended use and has been discarded for disposal or recovery, having completed its life as a consumer item. Postconsumer material is a part of the broader category of “recovered material.”

“Recovered material” means waste materials and by-products recovered or diverted from solid waste, but the term does not include those materials and by-products generated from, and commonly reused within, an original manufacturing process.

(b) The Contractor, on completion of this contract, shall—

(1) Estimate the percentage of the total recovered material content for EPA-designated item(s) delivered and/or used in contract performance, including, if applicable, the percentage of post-consumer material content; and

(2) Submit this estimate to Contracting Officer’s Representative. (End of clause)

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause— “Commercially available off-the-shelf (COTS) item”—

(1) Means any item of supply (including construction material) that is—

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101); (ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4), such as agricultural products and petroleum products.

“Component” means an article, material, or supply incorporated directly into a construction material.

“Construction material” means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site. Materials purchased directly by the Government are supplies, not construction material.

“Cost of components” means—

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

“Domestic construction material” means—

(1) An unmanufactured construction material mined or produced in the United States; (2) A construction material manufactured in the United States, if—

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

“Foreign construction material” means a construction material other than a domestic construction material.

“United States” means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows: None

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that—

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American statute is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American statute to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American statute.

(1)

(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including—

(A) A description of the foreign and domestic construction materials; (B) Unit of measure;

(C) Quantity; (D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

FOREIGN AND DOMESTIC CONSTRUCTION MATERIALS PRICE COMPARISON

Construction Material Description Unit of Measure Quantity Price (Dollars)* Item 1:

Foreign construction material Domestic construction material

Item 2:

Foreign construction material Domestic construction material [List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.] [Include other applicable supporting information.] [* Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).]

52.252-2 – CLAUSES INCORPORATED BY REFERENCE (FEB 1998).

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these addresses:

http://farsite.hill.af.mil https://www.acquisition.gov/ (End of Clause)

CLAUSES INCORPORATED BY REFERENCE

52.203-3 Gratuities (APR 1984)

52.203-5 Covenant Against Contingent Fees (MAY 2014)

52.203-7 Anti-Kickback Procedures (MAY 2014)

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity (MAY 2014)

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity (MAY 2014)

52.203-12 Limitation on Payments to Influence Certain Federal Transactions (OCT 2010)

52.203-13 Contractor Code of Business Ethics and Conduct (OCT 2015)

52.203-14 Display of Hotline Poster(s) (OCT 2015)

52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform Employees of Whistleblower Rights (APR 2014)

52.204-4 Printed or Copied Double-sided on Postconsumer Fiber Content Paper (MAY 2011)

52.204-9 Personal Identity Verification of Contractor Personnel (JAN 2011)

52.204-10 Reporting Executive Compensation and First-tier Subcontract Awards (OCT 2015)

52.204-13 System for Award Management Maintenance (JUL 2013)

52.204-14 Service Contract Reporting Requirements (JAN 2014)

52.209-6 Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment (OCT 2015)

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters (JUL 2013)

52.210-1 Market Research (APR 2011)

52.215-2 Audit and Records--Negotiation (OCT 2010)

52.215-8 Order of Precedence—Uniform Contract Format (OCT 1997)

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data--Modifications (AUG 2011)

52.215-19 Notification of Ownership Changes (OCT 1997)

52.219-4 – Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT 2014)

52.219-6 Notice of Total Small Business Set-aside (NOV 2011)

52.219-7 Notice of Partial Small Business Set-Aside (June 2003)

52.219-8 Utilization of Small Business Concerns (OCT 2014)

52.219-28 Post-Award Small Business Program Rerepresentation (JUL 2013)

52.222-3 Convict Labor (JUN 2003)

52.222-4 Contract Work Hours and Safety Standards—Overtime Compensation (MAY 2014)

52.222-6 Construction Wage Rate Requirements (MAY 2014)

52.222-7 Withholding of Funds (MAY 2014)

52.222-8 Payrolls and Basic Records (MAY 2014)

52.222-9 Apprentices and Trainees (JUL 2005)

52.222-10 Compliance with Copeland Act Requirements (FEB 1988)

52.222-11 Subcontracts (Labor Standards) (MAY 2014)

52.222-12 Contract Termination--Debarment (MAY 2014)

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations (MAY 2014)

52.222-14 Disputes Concerning Labor Standards (FEB 1988)

52.222-15 Certification of Eligibility (MAY 2014)

52.222-21 Prohibition of Segregated Facilities (APR 2015)

52.222-26 Equal Opportunity (APR 2015)

52.222-27 Affirmative Action Compliance Requirements for Construction (FEB 1999)

52.222-37 Employment Reports on Veterans (FEB 2016)

52.222-40 Notification of Employee Rights Under the National Labor Relations Act (DEC 2010)

52.222-50 Combating Trafficking in Persons (MAR 2015)

52.222-54 Employment Eligibility Verification (OCT 2015)

52.222-55 – Minimum Wages Under Executive Order 13658 (DEC 2015)

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction (SEP 2013)

52.223-3 Hazardous Material Identification and Material Safety Data (JAN

1997)—ALTERNATE I (JAN 1995)

52.223-5 Pollution Prevention and Right-to-Know Information (MAY 2011)

52.223-6 Drug-Free Workplace (MAY 2001)

52.223-15 Energy Efficiency in Energy-Consuming Products (DEC 2007)

52.223-17 Affirmative Procurement of EPA-designated Items in Service and Construction Contracts (MAY 2008)

52.223-18 Encouraging Contractor Policies to Ban Text Messaging While Driving (AUG 2011)

52.224-1 Privacy Act Notification (APR 1984)

52.224-2 Privacy Act (APR 1984)

52.225-13 Restrictions on Certain Foreign Purchases (JUN 2008)

52.227-1 Authorization and Consent (DEC 2007)

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement (DEC 2007)

52.227-4 Patent Indemnity—Construction Contracts (DEC 2007)

52.228-2 Additional Bond Security (OCT 1997)

52.228-5 Insurance—Work on a Government Installation (JAN 1997)

52.228-11 Pledges of Assets (JAN 2012)

52.228-12 Prospective Subcontractor Requests for Bonds (MAY 2014)

52.228-14 Irrevocable Letter of Credit (MAY 2014)

52.228-15 Performance and Payment Bonds--Construction (OCT 2010)

52.229-3 Federal, State, and Local Taxes (FEB 2013)

52.232-5 Payments Under Fixed-Price Construction Contracts (MAY 2014)

52.232-23 Assignment of Claims (MAY 2014)

52.232-27 Prompt Payment for Construction Contracts (MAY 2014)

52.232-33 Payment By Electronic Funds Transfer—System for Award Management (JUL 2013)

52.232-39 Unenforceability of Unauthorized Obligations (JUN 2013)

52.232-40 Providing Accelerated Payments to Small Business Subcontractors (DEC 2013)

52.233-1 Disputes (MAY 2014)—ALTERNATE I (DEC 1991)

52.233-3 Protest After Award (AUG 1996)

52.233-4 Applicable Law for Breach of Contract Claim (OCT 2004)

52.236-2 Differing Site Conditions (APR 1984)

52.236-3 Site Investigation and Conditions Affecting the Work (APR 1984)

52.236-5 Material and Workmanship (APR 1984)

52.236-6 Superintendence by the Contractor (APR 1984)

52.236-7 Permits and Responsibilities (NOV 1991)

52.236-8 Other Contracts (APR 1984)

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities and Improvements (APR 1984)

52.236-10 Operations and Storage Areas (APR 1984)

52.236-11 Use and possession Prior to Completion (APR 1984)

52.236-12 Cleaning Up (APR 1984)

52.236-13 Accident Prevention (NOV 1991)

52.236-14 Availability and Use of Utility Services (APR 1984)

52.236-15 Schedules for Construction Contracts (APR 1984)

52.236-16 Quantity Surveys (APR 1984)

52.236-21 Specifications and Drawings for Construction (FEB 1997)

52.236-26 Preconstruction Conference (FEB 1995)

52.242-13 Bankruptcy (JUL 1995)

52.243-4 Changes (JUN 2007)

52.244-6…