Sol_140A2323Q0007_Amd_0001.pdf

(x)

140A2323Q0007 x x

1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

A23

Albuquerque NM 87104 Suite 352A 1011 Indian School Rd.

Indian Education Acquisition Office

12/27/20220001

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

12/27/2022

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

This amendment is issued to replace Solicitation 140A2323Q0007 to correct the page numbering of the solicitation.

Replace Solicitation Number 140A2323Q0007 with the attached Solicitation Number

140A2323Q0007.

Period of Performance: 01/30/2023 to 01/29/2024

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Dawn Sekayumptewa

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

SOLICITATION NO.: 140A2323Q0007

INSTALLATION OF BATHROOM TILE

B.5. Miscellaneous Work: The contractor shall not perform any of contingent sum work, until the Contracting Officer issues a contract modification authorizing performance of work in accordance with FAR Clause 52.243-04, Changes, and FAR Clause 52.243-05, Changes and Changed Conditions; and subject to availability of funds, FAR Clause

52.232-18, Availability of Funds.

The Contractor shall promptly notify the Contracting Officer, in writing, of subsurface or any physical conditions from those indicated in this contract or unknown unusual physical conditions at the site before proceeding with the work.

The change orders request shall be forwarded to the Contracting Officer by memorandum outlining the need and a justification for the change order. Upon receipt of a change order request, the Contracting Officer will request a cost proposal from the Contractor. All cost proposals shall be in detail and itemized, showing price breakdown in sufficient detail to permit an analysis of cost for material, labor, equipment, hours, taxes, insurance, bonds, overhead costs, profit, and complete description of work involved in the change order, including any time extension.

In an emergency, a telephone approval may be granted by the Contracting Officer, and immediately the Contractor shall follow through by submitting a written cost proposal to the

Contracting Officer. The Contracting Office will issue a contract modification to authorize the work for the "emergency".

INSTALLATION OF BATHROOM TILE

Statement of Work

Bathroom Ceramic Tile Floor & Wall Remodel

Flandreau Indian School, Flandreau, SD 57028

This contract will involve the furnishing and install tile over tile in four ( 4) bathrooms (2 boys, 2 girls) at the Flandreau Indian School building 86. This contract requires awardee is to furnish all materials and hardware to complete the project. The buildings are located at the Flandreau Indian School approximately forty-two ( 42) miles North of Sioux Falls

SO. (l-29N to SD-34 E to SD 13 N)

General:

The Contractor agrees to complete all the work in accordance with the Environmental

Protection Agency, National Electrical Code, Plumbing codes and ADA compliant.

General Site Maintenance:

a. The Contractor Awardee shall clean up, remove, and dispose of all debris associated with this work. Maintaining cleanliness of the work site property during the entirety of this c o n t r a c t .

b. All work, including startup of equipment, is to be performed during regular summer working hours (June - August) (7a -4p) (MF) or school hours 830am -

3:30pm (September - May). All work cannot begin without the consent of the

Point of Contact Jeremy Gourneau, Facility Manager/Flandreau Indian School.

Phone: 605-997-3773 Ext: 2123

c. It is the intent of this contract that all work performed by the Contractor A wardee is to be completed and functional in all respects meeting all applicable codes and requirements.

d. The Contractor is responsible for protecting the work of other trades from any damage caused by his/her own work forces.

General Responsibilities:

a. The contractor is responsible to familiarize himself/herself with the work site and point out any potential problems with the Point of Contact before starting any work.

b. The Contractor shall cooperate with others to ensure a smooth and safe flow of work. Provide a plan detailing/sequencing of work that is needs completion to the Point of Contact.

INSTALLATION OF BATHROOM TILE

c. The Contractor shall comply with all requirements for safety procedures, reports, and meetings in accordance with applicable regulations.

d. The Contractor agrees that the Flandreau Indian School is not responsible for fire, theft, loss and or vandalism of any of the Contractor tools, equipment, materials, supplies and/or work in progress.

Supply and Install:

• 12"x24" wall tile, wall tile will begin from the floor to approximately 6'7"or higher depending on where a full tile ends this standard will encompass the entire bathroom. Rounded cap for end points and outside comers.

• 12 "x24" floor tile rounded transitions from floor to wall.

• Demo/dispose floor and wall tile

• Patch and prep floors/walls for tile installation, walls and floor must be level and true for tile to be laid flat.

• ADA transition point for floor tile to VCT tile at the bathroom entrances.

• Remove all mirrors, toilets, sinks, and stall surrounds to perform the floor and wall tile work then reinstall mirrors, toilets, sinks, and stall surrounds back to functional order.

• 1st floor boys restroom (112) floor: 302 sf walls: 469 sf

• 1st floor girls restroom (114) floor: 317 sf walls: 553 sf

• 2nd floor boys restroom {206) floor: 226 sf walls: 595 sf

• 2nd floor girls rest room (210) floor 283 sf walls: 588 sf

Security Clearance:

All Contractors to the Bureau of Indian Education are subject to review of completed investigative forms, a subsequent background investigation and final adjudication of that background investigation in order to determine your suitability to provide Contractor service to the Bureau of Indian Education. Contractor employees must obtain and maintain a favorably adjudication background investigation at a level equal to that which would be required for a federal employee and are subject to the same standards, requirements, and provisions as federal employees.

Performance of this contract may require Contractor personnel to have a Federal

Government issued person identification card before being allowed unsupervised access to a facility. The Flandreau Indian School business Technician/Human Resources will be the sponsoring official and will make the arrangement with the Bureau of Indian

Education Personnel Security for personnel identity verification and card issue.

INSTALLATION OF BATHROOM TILE

The Contractor employees to whom these provisions. are applicable may begin work before the background investigation is complete; however, if the employees do not meet the clearance e-requirement, the contractor will identify replacement staff to meet the work requirement.

I 9 r?c, 206 l_

206 SF

RESTROOM

20 SF

RESTROOM

254 SF

OFFICE

211A

164 SF

OFFICE

158 SF

RESTROOM

SOLICITATION NO.: 140A2323Q0007

INSTALLATION OF BATHROOM TILE

II

�6 II

CLASSROOM,

GENERAL

n

EJ

966 SF

CLASSROOM,

GENERAL

92.3 SF

OFFICE

�:-� 1:J

103 SF

CLASSROOM,

GENERAL

HMP

STORAGE

· 139 SF

LOUNGE

.3.31 SF

Dt:"C:TOfV\IA

I 16

GENERAL

RE

S

TROOM

Q c::�

29 SF

COVERED

WALKWAY

11 lA

288 SF

CLASSROOM

GENERAL•

962 SF

CLASSROOM

GENERAL•

B

921 SF

srewurnr r

CLASSROOM

GENERAL•

CLASSROOM

GENERAL

618 SF

CLASSROOM

r:.P1'.WD AT •

927 SF

CUSTODIAL

CLOSET

SECTION F -- DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECTION, AND COMPLETION OF WORK APR1984

The Contractor shall be required to (a) commence work under this contract within on three (3) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than five (5) calendar days. The time stated for completion shall include final cleanup of the premises.

F.2 52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION SEPTEMBER 2000

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $100.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

F.3 52.211-18 VARIATION IN ESTIMATED QUANTITY APRIL 1984

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract.

Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

F.4 52.236-01 PERFORMANCE OFWORKBYTHE CONTRACTOR APRIL 1984

The Contractor shall perform on the site, and with its own organization, work equivalent to at least fifteen percent

(15%) of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the

Contracting Officer determines that the reduction would be to the advantage of the Government.

F.5 52.242-14 SUSPENSION OF WORK APRIL 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or anypart of the work of this contract for the period of time that the Contracting Officer determines appropriatefor the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2)by the Contracting

Officer's failure to act within the time specified in this contract ( or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly.

However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

( c) A claim under this clause shall not be allowed--

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

SECTION G: CONTRACT ADMINISTATION

G.l CONTRACT ADMINISTRATION - GOVERNMENTAll administrative questions shall be directed to:

(Please do not mail your solicitations, please email to the address below.)

Dawn Sekayumptewa, Contracting Officer BIB-Division of Acquisition Operations 1011 Indian School RD NW Albuquerque, New Mexico 87104 Telephone No.: (505) 803-4259 Email: dawn.sekayumptewa@bie.edu

G.2 CONTRACT ADMINISTRATION CONTRACTOR

Designate a person whom the Government may contact during the period of the contract forprompt action on matters pertaining to the administration of the contract. Authorized Administrator is:

Company Name:

POC: EMAi..,_,,·""""""""""""""""""""""""""""""""""""""""-

Address:

Telephone No.

G.3 CONTRACTING OFFICER'S REPRESENTATIVE

A. The Contracting Officer shall designate a Contracting Officer's Representative (COR) who will represent the Contracting Officer in the technical phase of the work. The COR's duties, responsibilities, and limitations of authority will be set forth in a written COR designation letter. A copy of the COR designation letter will be made available to the Contractor.

B. The COR is not authorized to make any changes to the terms and conditions of this contract.Only the

Contracting Officer is authorized to make any changes to the contract by a properly written signed modification to the contract.

C. The Contracting Officer is the only official who can legally commit or obligate theGovernment for expenditure of public funds.

G.4 INVOICE AND PAYMENT

Electronic Invoicing and Payment Requirements- Invoice Processing Platform (IPP)

(April 2013)

Payment requests must be submitted electronically through the U.S. Department oftheTreasury's Invoice

Processing Platform System (IPP).

"Payment request" means any request for contract financing payment or invoice payment by the Contractor. To constitute a proper invoice, the payment request must comply with the requirements identified in the applicable

Prompt Payment clause included in the contract, or the clause 52.212-4 Contract Terms and Conditions -

Commercial Items included in commercial item contracts. TheIPP website address is: https://www.ipp.gov.

Under this contract, the following documents are required to be submitted as an attachment to the IPP invoice

[CO to edit and include the documentation required under this contract]:

4 copy q_fthe contractor's invoice shall he include,l with the IPP invoice, lf no invoice is attached, the Invoice will he reiected.

The Contractor must use the IPP website to register access and use IPP for submitting requests forpayment. The

Contractor Government Business Point of Contact (as listed in SAM) will receive enrollment instructions via email from the Federal Reserve Bank of Boston (FRBB) prior to the contract award date, but no more than }- 5 business days of the contract award date. Contractor assistance with enrollment can be obtained by contacting the IPP

Production

Helpdesk via email ippgroup@bos.frb.org or phone (866) 973-3131.

If the Contractor is unable to comply with the requirement to use IPP for submitting invoices for payment, the

Contractor must submit a waiver request inwriting to the Contracting Officer with itsproposal or quotation.

(End of Local Clause)

SECTION H -- SPECIAL CONTRACT REQUIREMENTS

H.1 Tribal Taxes, Requirements and/or Restrictions

( a) Special attention is called to FAR Clause 52.236-7, Permits and Responsibilities and FAR Clause

52.229-3, Federal, State, and Local Taxes. Offerors are responsible for contacting the tribe or tribal organization involved with regard to any requirements regarding tribal taxes, royalties and/or other applicable tribal laws or ordinances. Any costs associated with this section shall be included in the contractor's bid.

H.2 Modification Proposal - Cost Breakdown

The Contractor, in connection with any proposal he makes for a contract modification, shall furnish a price breakdown, itemized as required by the Contracting Officer (CO). Unless otherwise directed, the breakdown shall be in sufficient detail to permit an analysis of all material, labor, equipment, subcontract,and overhead costs, as well as profit, and shall cover all work involved in the modification, whether such work was deleted, added, or changed. Any amount claimed for subcontractors shall be supported by a similar price breakdown. In addition, if the proposal includes a time extension, a justification thereof shallalso be furnished. The proposal, together with the price breakdown and time extension justification, shall be furnished by the date specified by the

Contracting Officer.

H.3 POST AW ARD CONFERENCES - Firm Fixed Price Contracts

The Contracting Officer shall conduct monthly post award meetings with the contractor and the Contracting

Officer's Technical Representative (COTR). Discussions at these meetings will center on the contractor's performance to determine if the contractor is meeting and performing in accordance with the contract terms and conditions. The Contracting Officer will ensure that minutes of the meetings are taken, and copies provided to attendees.

H.4 Changes

The contractor shall not perform any of contingent sum work, until the Contracting Officer issues a modification authorizing performance of work in accordance with FAR clause 52.243-04, Changes and 52.243-

5, Changes and Changed Conditions.

The Contractor shall promptly notify the Contracting Officer, in writing, of subsurface or any physical conditions for those indicated in this contract or unknown physical conditions at the site before proceeding with the work.

The change orders request shall be forward to the Contracting Officer by memorandum outlining the need and justification for the change order. Upon receipt of the change order request the Contracting Officer will request a cost proposal from the Contractor. All cost proposal shall be in detail and itemized, showing price breakdown in sufficient detail to permit and analysis of cost for material, labor, equipment

, hours, taxes, insurance, bonds, overhead costs, profit, and complete description of work involved in the change order, including any time extension.

In an emergency situation, the Contracting Officer may grant a telephone approval, and immediately the

Contractor shall follow through by submitting a written cost proposal to the Contracting Officer. The

Contracting Officer will issue a contract modification to authorize the work for the "emergency".

H.5 Determination and Extension of Contract Time

The calendar days, stated under Section F .1 - FAR 52.211-10, allowed for the performance of the contract is based upon the work to be performed and weather conditions that are normally anticipated inthe area that may prevent work. Request for time extensions because of weather conditions shall not be granted except in the case of unusually severe weather or "Act of Nature" unanticipated by this contract.

H.6 Contractor Safety Program Requirements

The Contractor shall establish a safety program, which is consistent off AR Clause 52.236-13 and also shall include at a minimum the following requirements.

A. Safety Program Submittal: Within 10 days following the awarding of a contract, the Contractor shall submit in writing to the Contracting Officer a proposed comprehensive safety program for approval.

The Contractor's safety program shall detail policies, procedures and plans that will be implemented to ensure the safety and health of employees and visitors at the job site. The Contractor shall prepare a list of major hazards associated with the contract work and provide in the safety program means to minimize the hazards.

B. Pre-Construction Safety Meeting: Representative of the Contractor shall meet with the Contracting Officer's Representative and the Contracting Officer prior to the start of construction to review the safety program and discuss implementation of the health and safety provisions pertinent to the work under this contract. The Contractor should be prepared to discuss, in detail, the measures to be taken to control the hazards associated with the major phases of the work under this contract. This meeting shall be devoted mainly to a discussion of the way the Contractor intends to administer the health and safety program, delegation of responsibility for implementing the program, and determination of what shall be presented in the written safety program.

C. Contractor Housekeeping Requirement: Good housekeeping, including provision and facilitiesfor routine scrap removal, shall be maintained in all areas within the Contractor's scope of operations. All garbage shall be stored and removed to an approved dumpsite as specified by the permitting Agency.

The construction yard(s) shall be restored to their natural condition or better as required by the permitting requirements and in accordance with Tribal, State, and Federal Law (i.e. applicable OSHA construction standards).

D. Contractor Contamination Requirement: Handling, storage, and disposal of toxic materials of any nature shall be carried out in a manner so as not to contaminate or pollute public and/or private property, water supplies, rivers, lakes, reservoirs, streams, or the atmosphere. Disposal of all materials, including waste, garbage, and sewage, shall comply with all local, tribal, state and federal regulations (i.e. Clean Air and Water Act).

H. 7 Payment to Contractor

See FAR Clause 52.232-27, Prompt Payment for Construction Contract. Payments to the Contractor shall be made within fourteen (14) calendar days after the CO approves each invoice. The Government will make payment according to the project schedule that is provided, and the percentage completed.

H.8 WORK OUTSIDE REGULAR WORK.HOURS

If the contractor desires to perform work under this contract outside regular work hours or on Saturdays, Sundays or holidays, he shall apply, in writing, to the Contracting Officer no less than 10 calendar days prior to the planned start of such work. Regular work hours are, for the purpose of this clause, those hours the activity or Command where the work is to be performed normally works on a day-by-day basis. Application by the Contractor does not imply consent by the Government. Each application will be considered, and a decision made, on the potential benefit of permitting such work. Approval of a Contractor's application under this clause will be, unless otherwise agreed in writing, at no additional cost to the Government.

H.9 DRAWINGS AND OTHER DATA TO BECOME PROPERTY OF GOVERNMENT

All designs, drawings, specifications, notes and other works developed in the performance of this contract shall become the sole property of the Government and may be used on any other design or construction without additional compensation to the Contractor. The Government shall be considered the "person for whom the work was prepared" for the purpose of authorship in any copyrightable work under 17 U.S.C. 201(b). With respect thereto, the Contractor agrees not to assert or authorize others to assert any rights nor establish any claim under the design patent or copyright laws.

H.10 REQUIRED INSURANCE

The contractor shall procure and maintain insurance for each task order during the entire period of performance consistent with FAR 52.228-5, DIAR 1452.228-70, and FAR 28.307, which states the following minimum amounts of liability:

(a) Workers' Compensation and Employer's Liability. Contractors are required to comply with applicable Federal and State worker's compensation and occupational disease statutes. If occupational diseases are not compensable under those statutes, they shall be covered under the employer's liability section of the insurance policy, except when contract operations are so commingled with a contractor's commercial operations that it would not be practical to require this coverage. Employer's liability coverage ofat least $100,000 shall be required, except in States with exclusive or monopolistic funds that do not permit workers' compensation to be written by private carriers. (See 28.305(c) for treatment of contracts subject to the Defense Base Act.)

(b) General Liability. (1) The contracting officer shall require bodily injury liability insurance coverage written on the comprehensive form of policy of at least $500,000 per occurrence.

( c) Property damage liability insurance shall be required only in special circumstances as determined by the agency.

(d) Automobile Liability. The Contracting Officer shall require automobile liability insurance written on the comprehensive form of policy. The policy shall provide for bodily injury and property damage liability covering the operation of all automobiles used in connection with performing the contract. Policies covering automobiles operated in the United States shall provide coverage of at least $200,000 per person and $500,000 per occurrence for bodily injury and $20,000 per occurrence for property damage. The amount ofliability coverage on other policies shall be commensurate with any legal requirements of the locality and sufficient to meet normal and customary claims.

H.11 VOLATILE ORGANIC COMPOUNDS (VOC) COMPLIANCE PLAN

(a) Contractor's are required to comply with local VOC laws and regulations and shall have an acceptable VOC compliance plan. The plan shall demonstrate that the use of paints, solvents, adhesives and cleaners comply with local VOC laws and regulations governing VOC materials, and that all required permits have been obtained or will be obtained prior to starting work involving VOC's, in the air quality district in which the work will be performed.

(b) The compliance plan shall be submitted by the Contractor to the Contracting Officer within five ( 5) calendar days after receipt of contract, and prior to the use of any "VOC" materials on the project site.

The Government will approve or disapprove the Contractor's compliance plan within five calendar days after receipt. Should the Government reject the compliance plan, the Contractor shall resubmit a revised compliance plan within three calendar days after receipt of the rejection notification. Failure on the part of the Contractor to submit an acceptable "VOC" plan, shall not be grounds for a time extension to the performance period.

( c) An acceptable compliance plan shall contain, as a minimum:

(i) A listing of each material subject to restrictions in the air quality managementdistrict in question;

(ii) The rule governing its use;

(iii) A description of the actions which the Contractor will use to comply with the laws and regulations, and plans to report to the Contracting Officer any changes in the status of compliance during the life of the contract.

(iv) Alternatively, if no materials are subject to the restrictions in the air quality management district where the work will be performed, or if there are no restrictions, the compliance plan shall so state.

H.12 WAGE RA TES

Applicable Construction Wage Rate Requirements are in effect at the time of contract and will apply.

Contractors will be provided with the wage determination prior to issuance of a task order for pricing purposes. If crafts or trades are required in the performance of this project for which no wage is listed in the Department of Labor Wage Decision, the Contracting Officer shall be notified in writing.

H.13 CERTIFICATION OF PAYMENTS-RELEASE OF CLAIM

The Contractor, prior to receiving a progress or final payment under this contract, shall submit to the Contracting Officer a certification that the Contractor has made payment from proceeds of prior payments, or that he will make timely payment from the proceeds of the progress or final payment then due him, to his subcontractors and suppliers in accordance with his contractual arrangements. The Contractor shall submit to the Contracting Officer, together with his request for final payment, a properly executed Contractor's Release form. Failure to submit this completed release shall result in delay of final payment.

H.14 SUBCONTRACTDATA

The Contractor shall submit an executed Statement and Acknowledgment Standard Form 1413, to the Contracting Officer for every subcontractor (including every subcontractor of the second or lower tier) that will be performing work at the construction site. This shall be done before the subcontractor begins work. This form provides an acknowledgment by the subcontractor that mandatory "flow-down" contract clauses have been included in his contract in accordance with FAR Clause 52.222-11. The Prime Contractors will be given copies of Form SF 1413 after award of a contract. Completing this form creates no contractual relationship between subcontractors and the Government.

H.15 CONTRACTOR SECURITY REQUIREMENTS

At the Pre-construction Conference [or prior to beginning work on the contract], the Contractor shall provide a list of all on-site personnel, including sub-contractors (including second and third-tier subcontractors) and suppliers, to the Contracting Officer. The contractor shall update this list when changes occur. Contractor personnel not listed may be denied access to the Coast Guard facility.

Contractor personnel will be restricted to designated working areas. Any personnel violating this policy may lose access to the facility. Contractor personnel shall have photo identification at all times while working on BIA facilities. Contractors shall provide the COR with 24 hours of advance notice of every delivery to the site (e.g., concrete, lumber, etc ... ) and provide the company name, delivery person, and phone number of the firm(s) making deliveries.

Otherwise access to the BIA facility may be denied. Special security provisions may apply to some task orders. Employees may be required to submit to a background check and be United States citizens.

H.16 REAL ID ACT OF2005

The Real ID Act of 2005 established minimum security standards for license issuance and production and prohibits Federal agencies from accepting for certain purposes driver's licenses and identification cards from states not meeting the Act's minimum standards. To this purpose there are five states that are not in compliance with the Act nor have they received an extension to come into compliance with the act. Those states are Illinois, Minnesota, Missouri, New Mexico and Washington State. Anyone under this contract, to include subcontractors, who holds a driver's license from any of states without approved licenses and require access to a military facility will be required to provide identification other than a driver's license to gain access. It is the responsibility of the Contractor to ensure that they are in accordance with the Real ID Act and any other requirements for base access. For the states of Washington and Minnesota an enhanced driver's license is acceptable to gain access. Other forms of identification that are acceptable for military facility access are included as an attachment to this modification.

Further information on the Real ID Act can be found here: http://www.dhs.gov/real-id-enforcement brief#

H.17 TEMPORARYFACILITIES

(a) STORAGE: The location for exterior stock piling of materials shall be arranged by the COR and Project Manager. The Contractor shall be responsible for protecting materials stockpiled against weather, damage, theft, and other risks of loss. The BIA assumes no responsibility for material or equipment left in the storage area.

(b) SANITARY FACILITIES: Toilet facilities may be available for Contractor use. The Contractor shall ensure the facilities remain clean. Contractors may be required to provide toilet facilities at some sites.

(c) WATER AND ELECTRICITY: Water and 120V electricity may be available at no cost to the Contractor.

Should water and electricity be available contractor, the Contractor will bear connection costs. Cost of these utility connections and disconnections is the responsibility of the Contractor.

H.18 EXISTINGUTILITIES

Utility locations when shown are approximate. The contractor shall field verify all utility locations before digging or trenching. This shall include but not be limited to the use of sonic, electronic or magnetic detection devices, by noting pull box and utility box locations at the surface, and by potholing.

Contractor shall be responsible for repairing any utilities damaged during construction at no additional cost to the Government.

H.19 COVID-19 GUIDELINES

The following guidelines will be adhered to at Southwestern Indian Polytechnic Institute as preventive health strategy in response to the COVID-19 health pandemic. These guidelines are based on the Centers for Disease Control and Prevention (CDC) and Occupational Safety and Health Administration (OSHA) best practices to minimize risk of coronavirus transmission as employees return to the workplace.

(a) COVID Symptoms. Any Contractor personnel, employees, subcontractors, partners, or workers who are experiencing symptoms of COVID-19, including but not limited to cough, shortness of breath or difficulty breathing, fever, chills, muscle pain, sore throat, new loss of taste or smell should not report to work. Employees may be allowed to return to work after 14 days of having no symptoms. Contractor's project managers and site superintendents are responsible to monitor employees for symptoms before and during work, and follow appropriate precautions in accordance with CDC Guidance -Safety Practices for Critical Infrastructure Workers. https://www.cdc.gov/coronavirus/2019-ncov/community/critical-workers/implementing-safety-practices.html. If a Contractor's employee is unsure if they are sick, they should consult their supervisor. Visitors exhibiting or reporting COVID-19 symptoms (i.e., cough or shortness of breath or difficulty breathing fever, chills, muscle pain, sore throat, new loss of taste or smell) should be encouraged through notice and signage to leave the facility and reschedule their meeting/visit for a future time when they are in good health.

(b) Face Covers. Contractor personnel are required to wear cloth face coverings while onsite. Cloth face coverings may prevent people who do not know they have the virus from transmitting it to others. CDC does not recommend the general public wear surgical masks or N-95 respirators to protect themselves from respiratory diseases, including coronavirus (COVID-19). N-95s and other filtering face piece respirators should continue to be reserved for those at increased risk of exposure including health care workers and other medical first responders, as recommended by current CDC guidance and a job hazard analysis. Appropriate Personal Protective Equipment (PPE). Cloth face coverings are not respirators and are not appropriate substitutes where filtering face piece respirators are required. Employees who are performing tasks at elevated risk requiring respirators as identified through the job hazards analysis will be provided with the appropriate Personal Protective Equipment (PPE) to perform their jobs safely.

( c) Social Distancing. The CDC guidance includes a primary objective of disease mitigation through good hygiene, staying home when sick, and social distancing. Social distancing is a set of actions taken to stop or slow the spread of a highly contagious disease. The CDC has determined that social distancing is an essential step in preventing the spread of COVID-19. The goal of social distancing is to limit face to-face contact to decrease the spread of illness among people in community settings. Employees should practice social distancing by putting space ( currently six feet) between themselves and others. Visitors that exceed the maximum occupancy for the space should not enter the space. Any waiting area should also be structured to limit aggregation of people to avoid crowding and maintain social distancing.

Waiting areas should have suitable floor markings to facilitate social distancing.

( d) Hygiene. Contractors will have an overall cleaning schedule that is consistent with CDC cleaning recommendations including using Environmental Protection Agency (EPA) recommended cleaning and disinfecting solutions (https://www .cdc.gov/coronavirus/2019-ncov/community / disinfecting-building facility .html). Additionally, the Contractor shall encourage and support frequent hand washing, hand sanitizing and wiping down of surfaces in high traffic, shared spaces ( e.g., elevator lobbies, community desk, pantry, nooks, meeting rooms, restrooms, phone booths). Workstation configurations and schedules should accommodate simplified cleaning measures wherever possible.

H.20 BACKGROUND INVESTIGATION

In accordance with 25 U.S.C. § 3201 et seq. (Pub. L. 101-630), the Indian Child Protection and Family Violence Prevention Act; 34 U.C.C. § 20351, et seq. (Pub. L. 101-647), the Crime Control Act of 1990, as amended; and 441 Departmental Manual, Personnel Security and Suitability Requirements, all positions with duties and responsibilities involving regular contact with or control over Indian children are subject to a background investigation and determination of suitability for employment.

Accordingly, all such positions require a favorable background screening by the Bureau of Indian Education (BIE), Personnel Security and Suitability Program and a favorable background investigation by the Defense Counterintelligence Service Agency (DCSA). The documentation required to initiate a background investigation shall be completed for any Contractor employee that will be onsite during the contract's performance or have access to Personally Identifiable Information (PII). The complete submittal of the background investigation paperwork to the BIA/BIE will be accomplished within 14 days after contract award for service contracts or, for construction contracts, before a Notice to Proceed (NTP) is issued by the Contracting Officer. Pending the successful completion of a background investigation by the BIA/BIE and/or DCSA, the Contractor who has been granted a favorable screening (applicant and suitability) determination must, at all times, remain within sight and under the supervision of a Government employee ( or other person designated by the Contracting Officer Representative (COR), who has successfully completed the background investigation. If an unfavorable screening (applicant and suitability) determination is made, an employee shall not be allowed onsite. If the Contractor's employees are found onsite, without the proper authorization, the employee will face legal liability and the Contractor may have their contract terminated for default. Additionally, the individual and/or the company who proposed to employ this individual may be determined to be non responsible if an unfavorable screening (applicant and suitability) determination is made and may be deemed ineligible for contract award. If an unfavorable final background investigation determination is made, the contract may be terminated and the employee in question shall not be authorized to provide service to the BIA/BIE if the services involve contact with or regular control over Indian children. It is solely the COR's responsibility to initiate background checks for all Contractors and their employees in the BIE BEARCUBS system, which includes but is not limited to appropriate investigative forms and/or inquiries about their previous investigation; and, obtain a screening (applicant and suitability) determination, and subsequent final background investigation.

The Contracting Officer will consult with the COR when questions arise as to whether or not the scope of work of a contract requires background investigations for contractor personnel. If the Contracting Officer or COR believes the scope of work performed by contract personnel should not require a background investigation, the Personnel Security Officer will be contacted for concurrence and has the final authority to determine if background investigation(s) are required.

END OF SECTION H - SPECIAL CONTRACT REQUIREMENTS

SECTION I -- CONTRACT CLAUSES

I.1 52.252-02 CLAUSES IN CORPORA TED BY REFERENCE

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address( es): https:/ /www.arnetlfar.gov

CLAUSES TITLE PATE

52.202-1 Definitions lTUN 2020 52.203-3 Gratuities �R 1984 52.203-5 Covenant Against Contingent Fees MAY2014 52.203-6 !Restrictions on Subcontractor Sales to the Government lTUN 2020 52.203-7 �ti-Kickback Procedures lTUN 2020 52.203-8 tancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity MAY2014 52.203-10 OC>rice or Fee Adjustment for Illegal or Improper Activity MAY2014 52.203-12 limitation on Payments to Influence Certain Federal Transactions lTUN2020 52.203-13 tontractor Code of Business Ethics and Conduct NOV 2021 52.203-17 Contractor Employee Whistleblower Rights and Requirement to Inform lTUN 2020

�mployees ofWhistleblower Rights 52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements and �AN2017

Statements 52.204-1 �pproval of Contract PEC 1989 52.204-4 Printed or Copied Double- Sided on Recycled Paper MAY2011 52.204-10 !Reporting Executive Compensation and First- Tier Subcontract Awards lTUN 2020 52.204-13 System for A ward Management Maintenance PCT 2018 52.204-14 Service Contract Reporting Requirement bCT2016 52.204-18 Commercial and Government Entity Code Maintenance �UG2020 52.204-19 OCncorporation by Reference of Representations and Certifications PEC 2014 52.204-25 OC>rohibition on Contracting for Certain Telecommunications and Video Nov 2021

Surveillance Services or Equipment 52.204-26 OC>rohibition on Contracting for Certain Telecommunications and Video Surveillance bCT 2020

52.209-6 Protecting the Government's Interest When Subcontracting with ContractorsDebarred, NOV 2021 Suspended, or Proposed for Debarment

52.209-9 !Updates of Publicly Available Information Regarding Responsibility Matters PCT 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations NOV 2015 52.211-13 Time Extensions SEPT2000 52.211-18 !Variation in Estimated Quantity �R 1984 52.215-1 OCnstructions to Offerors - Competitive Acquisition NOV 2021 52.215-2 k\.udit and Records - Negotiation lTUN 2020 52.215-8 Order Precedence - Uniform Contract Format PCT 1997 52.215-10 Price Reduction for Defective Cost or Pricing Data �UG 2011 52.215-11 OC>rice Reduction for Defective Cost or Pricing Data - Modifications lTUN 2020 52.215-12 Subcontractor Certified Cost or Pricing Data lTUN 2020 52.215-13 Subcontractor Certified Cost or Pricing Data - Modifications lTUN 2020 52.215-21 IR.equirements for Certified Cost or Pricing Data and Data Other Than CertifiedCost or Nov 2021

OC>ricing Data - Modifications 52.219-6 Notice of Total Small Business Set- Aside NOV2020 52.219-8 !Utilization of Small Business Concerns PCT2022 52.219-9 Small Business Subcontracting Plan Nov 2021 52.219-14 limitations on Subcontracting bCT2022

52.219-28 52.222-1 52.222-3 52.222-4 52.222-6 52.222-7 52.222-8 52.222-9 52.222-10 52.222-11 52.222-12 52.222-13 52-222-14 52.222-15 52.222-21 52.222-23

52.222-26 52.222-27 52.222-35 52.222-36 52.222-37 52.222-40 52.222-50 52.222-54 52.222-55 52.222-62 52.223-2 52.223-3 52.223-5 52.223-6 52.223-9 52.223-10 52.223-11 52.223-12 52.223-17 52.223-18 52.225-13 52.226-1 52.227-4 52.228-2 52.228-5 52.228-11 52.228-12 52.228-13 52.229-3 52.232-15 52.232-16 52.232-17 52.232-18 52.232-19 52.232-23

SOLICITATION NO.: 140A2322R0019

CONSTRUCTION OF PARKING LOT PAVEMENT

!Post-Award Small Business Program Representation SEP 2021 [Notice to the Government of Labor Disputes fEB 1997 K:;onvict Labor �2003 K::ontract Work Hours and Safety Standards-Overtime Compensation MAY 2018 K::onstruction Wage Rate Requirements AUG 2018 Kvithholding of Funds MAY2014 !Payrolls and Basic Records MY 2021 Apprentices and Trainees MY 2005 K::ompliance with Copeland Act Requirements fEB 1988 Subcontractors (Labor Standards) MAY2014 Contract Termination-Debarment MAY2014 Compliance with Construction Wage Rate Requirements and Related Regulations MAY2014 Disputes Concerning Labor Standards fEB 1988 Certification of Eligibility MAY2014 !Prohibition of Segregated Facilities APR 2015 [Notice of Requirement for Affirmative Action to Ensure Equal Employment Opportunity for fEB 1999 (::onstruction Equal Opportunity SEPT 2016 Affirmative Action Compliance Requirements for Construction APR 2015 �qual Opportunity for Veterans �2020 Affirmative Action for Workers with Disabilities �2020 �mployment Reports on Veterans �2020 !Notification of Employee Rights Under the National Labor Relations Act DEC 2010 Combating Trafficking in Persons [NOV 2021 �mployment Eligibility Verification [NOV 2021 Minimum Wages Under Executive Order 14026 �AN2022 !Paid Sick Leave Under Executive Order 13706 �AN 2022 Affirmative Procurement ofBiobased Products Under Service and Construction Contracts SEP 2013 !Hazardous Material Identification And Material Safety Data fEB 2021 rollution Prevention and Right to Know Information MAY 2011 Drug-Free Workplace MAY2001 Estimate of Percentage of Recovered Materials Content for EPA Designated Items. MAY2008 Waste Reduction Program MAY2011 bzone-Depleting Substance and High Global Warning Potential Hydrofluorocarbons roNE 2016 Maintenance, Service Repairs, or Disposal of Refrigeration Equipment and Air Conditioners �2016 Affirmative Procurement of EPA-designated Items in Services and Construction Contracts AUG 2018 Encouraging Contractor Policies to Ban Text Messaging While Driving �2020 !Restriction on Certain Foreign Purchases fEB 2021 !Utilization oflndian Organizations and Indian-Owned Economic Enterprises roNE 2000 ratent Indemnity-Construction Contracts DEC 2007 Additional Bond Security bCT 1997 fosurance - Work on a Government Installation �AN 1997 OCndividual Surety - Pledges of Assets fEB 2021 !Prospective Subcontractor Request for Bonds MAY2014 Alternatives Payment Protections MY 2000 Federal, State, and Local Taxes fEB 2013 !Progress Payment Not Included APR 1984 rrogress Payment [NOV 2021 [nterest MAY2014 Availability of Funds APR 1984 Availability of Funds for the Next Fiscal Year APR 1984 Assignment of Claims MAY2014

52.232-39 IUnenforceability of Unauthorized Obligations 52.233-3 Protest after A ward 52.236-4 Physical Data 52.236-19 Organization and Direction of the Work 52.243-1 Changes Fixed Price 52.249-2 irermination for Convenience of the Government (Fixed Price) 52.249-10 Default (Fixed-Price Construction) 52.252-4 Alterations in Contract 52.252-6 �uthorized Deviations in Clauses 1452.203-70 Restriction on Endorsements 1452.215-70 Examination of Records by the Department of the Interior 1452.224-1 Privacy Act Notification (July 1996) Deviation 1452.236-70 Prohibition Against Use of Lead-based Paint

CLAUSES INCORPORATED BY FULL TEXT

1452.228-70 Liability Insurance (JUL 1996)

JUN 2013

AUG 1996

APR 1984

APR 1984

AUG 1987

APR 2012

APR 1984

APR 1984

NOV2020

JULY 1996

APR 1984

JULY 1996

JULY 1996

The Contractor shall procure and maintain during the term of this contract and any extension thereof liabilityinsurance in form satisfactory to the Contracting Officer by an insurance company which is acceptable to the Contracting Officer.

The named insured parties under the policy shall be the Contractor and the United States ofAmerica. The amounts of the insurance shall be not less than as follows:

$100 each person* $100 each occurrence* $ 100 property damage* Each policy shall have a certificate evidencing the insurance…