12474018R0001.pdf

SEE ADDENDUMIS CHECKED

CODE 18a. PAYMENT WILL BE MADE BY

CODE

FACILITYCODE

17b. CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN OFFER

OFFEROR

USDA-AMS-33SM

FREDERICKSBURG VA 22406

SUITE 101

100 RIVERSIDE PARKWAY

USDA AMS C&T

CODE 16. ADMINISTERED BYCODE

X

X

X

561730

SIZE STANDARD:

% FOR:SET ASIDE:UNRESTRICTED ORUSDA-AMS-33SM

RFPIFB

10. THIS ACQUISITION ISCODE

RFQ

14. METHOD OF SOLICITATION

13b. RATING

NAICS:

SMALL BUSINESS

10/13/2017 1000 ET

09/26/20179

901-801-5173BEVERLY BROWN

(No collect calls)

INFORMATION CALL:

FOR SOLICITATION 8. OFFER DUE DATE/LOCAL TIMEb. TELEPHONE NUMBER a. NAME

4. ORDER NUMBER3. AWARD/ 6. SOLICITATION

12474018R0001

5. SOLICITATION NUMBER

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS 1. REQUISITION NUMBER PAGE OF

1 57 OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

TELEPHONE NO.

17a. CONTRACTOR/

Memphis TN 38133 3275 Appling Road

USDA, AMS, C&T PROGRAM

15. DELIVER TO

FREDERICKSBURG VA 22406

SUITE 101

100 RIVERSIDE PARKWAY

9. ISSUED BY

7.

2. CONTRACT NO.

EFFECTIVE DATE

$7.50

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

ISSUE DATE

DELIVERY FOR FOB DESTINA-

TION UNLESS BLOCK IS

MARKED

11.

SEE SCHEDULE

12. DISCOUNT TERMS

THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13a.

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

HUBZONE SMALL

BUSINESS

8(A)

USDA AMS C&T

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

EDWOSB

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

Tax ID Number: Not Available DUNS Number: Not Available Lawn Care - Memphis Complex Period of Performance: 11/01/2017 to 10/31/2022

001 Base Year: November 1, 2017 - October 31, 2018 12 MO Lawn Care - Memphis Complex Per SOW Product/Service Code: S208 Product/Service Description: HOUSEKEEPING- Continued ...

(Use Reverse and/or Attach Additional Sheets as Necessary)

HEREIN, IS ACCEPTED AS TO ITEMS:

DATED

BEVERLY S. BROWN

. YOUR OFFER ON SOLICITATION (BLOCK 5),

INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET FORTH

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND DELIVER

ARE

ARE

31c. DATE SIGNED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA

31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print)

ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY ADDITIONAL

SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED.

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

OFFER

STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

ARE NOT ATTACHED.

ARE NOT ATTACHED.

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION IS NOT USABLE

30b. NAME AND TITLE OF SIGNER (Type or print)

30a. SIGNATURE OF OFFEROR/CONTRACTOR

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN

25. ACCOUNTING AND APPROPRIATION DATA

29. AWARD OF CONTRACT:

REF.

32e. MAILING ADDRESS OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32c. DATE 32b. SIGNATURE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

ACCEPTED, AND CONFORMS TO THE CONTRACT, EXCEPT AS NOTED:

32a. QUANTITY IN COLUMN 21 HAS BEEN

RECEIVED INSPECTED

40. PAID BY39. S/R VOUCHER NUMBER38. S/R ACCOUNT NUMBER

37. CHECK NUMBER

FINALPARTIAL

36. PAYMENT

FINALPARTIAL

35. AMOUNT VERIFIED

CORRECT FOR

34. VOUCHER NUMBER33. SHIP NUMBER

COMPLETE

32g. E-MAIL OF AUTHORIZED GOVERNMENT REPRESENTATIVE

42d. TOTAL CONTAINERS42c. DATE REC'D (YY/MM/DD)

42b. RECEIVED AT (Location)

42a. RECEIVED BY (Print)

41c. DATE41b. SIGNATURE AND TITLE OF CERTIFYING OFFICER

41a. I CERTIFY THIS ACCOUNT IS CORRECT AND PROPER FOR PAYMENT

STANDARD FORM 1449 (REV. 2/2012) BACK

24.

AMOUNT

23.

UNIT PRICE

22.

UNIT

21.

QUANTITY

20.

SCHEDULE OF SUPPLIES/SERVICES

19.

ITEM NO.

LANDSCAPING/GROUNDSKEEPING

002 Option Year I: November 1, 2018 - October 31, 12 MO

Lawn Care - Memphis Complex

Per SOW

(Option Line Item)

09/15/2018

Product/Service Code: S208

Product/Service Description: HOUSEKEEPING-

LANDSCAPING/GROUNDSKEEPING

003 Option Year II: November 1, 2019 - October 31, 12 MO

Lawn Care - Memphis Complex

Per SOW

(Option Line Item)

09/15/2019

Product/Service Code: S208

Product/Service Description: HOUSEKEEPING-

LANDSCAPING/GROUNDSKEEPING

004 Option Year III: November 1, 2020 - October 31, 12 MO

Lawn Care - Memphis Complex

Per SOW

Continued ...

32f. TELEPHONE NUMBER OF AUTHORIZED GOVERNMENT REPRESENTATIVE

32d. PRINTED NAME AND TITLE OF AUTHORIZED GOVERNMENT REPRESENTATIVE

46 2 of

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

NAME OF OFFEROR OR CONTRACTOR

3 46

CONTINUATION SHEET

REFERENCE NO. OF DOCUMENT BEING CONTINUED PAGE OF

(A) (B) (C) (D) (E) (F)

12474018R0001

(Option Line Item)

09/15/2020

Product/Service Code: S208

Product/Service Description: HOUSEKEEPING-

LANDSCAPING/GROUNDSKEEPING

005 Option Year IV: November 1, 2021 - October 31, 12 MO

Lawn Care - Memphis Complex

Per SOW

(Option Line Item)

09/15/2021

Product/Service Code: S208

Product/Service Description: HOUSEKEEPING-

LANDSCAPING/GROUNDSKEEPING

NSN 7540-01-152-8067 OPTIONAL FORM 336 (4-86)

Sponsored by GSA

FAR (48 CFR) 53.110

1 | P a g e

STATEMENT OF WORK

GROUNDS MAINTENANCE CONTRACT

USDA, AMS, COTTON AND TOBACCO PROGRAMS

C.1 Scope

The USDA Cotton and Tobacco Program are requesting quotes for grounds maintenance contract to be provided at 3275 Appling Road in Memphis, TN 38133. The contractor shall provide all equipment, chemicals, plants, fertilizers, parts and supplies necessary to maintain the premises to the satisfaction of the USDA, Cotton and Tobacco Programs.

C.2 Specifications/Requirements:

1. General Compliance Report to Facilities Manager or designee upon site visit (if contractor visit occurs over the weekend, then the following business day.

Review work plan for that visit or upcoming visits.

Review ground maintenance check list to ensure compliance before any payments will be authorized.

2. Lawn services:

Close cutting (scalping) grass at beginning of spring Mowing weekly Trimming (weed eating) weekly Edging sidewalks, curbs, etc. weekly Fertilizer application as needed, a minimum of three times per year (spring, early summer, and late summer)

Notes:

Services performed so as to maintain a manicured and healthy green lawn that is “weed free”.

Service should include approximately 40 cuttings.

3. Weed control Pre-emergence Post-emergence Remove all weeds from parking and driveway surfaces

Notes:

Services performed as needed to maintain a “weed free” lawn and plant beds. This shall include prevention and elimination of weeds without damaging existing plants.)

All chemical applications must adhere to all applicable codes and labeling.

All chemical applications requiring certified applicators shall be performed according to all applicable codes and regulations.

Each chemical application should be recorded. Copies of when each application and what has been applied to the property are given to the USDA Designee.

4. Flowerbeds, shrubs and trees:

Planting and removal of seasonal flowers and plants in designated areas (A minimum of 30 flats

(cell package) shall be supplied within 1 week for the following months: April, June, August and October. The USDA designee shall approve the plant varieties used and the locations.

Maintaining brown mulch to a depth of 2 – 3 inches throughout the contract ( A minimum of 2 applications per year is suggested.) (Designee shall approve mulch before application)

Trimming of shrubs to be done a minimum of 2 times per month.

Tree pruning to be done in November.

2 | P a g e

Notes: Contractor shall collect and haul away all trimmings.

5. Watering system Control of water intervals to maintain a green and healthy landscape including grass, shrubs, flowers, trees, etc… Maintenance of existing water system according to manufacturer’s recommendations including setting watering times corresponding to the existing watering zones. The contractor shall be responsible for opening the water system at the beginning of the contract and for any repairs needed for the water system to work properly. The contractor shall be responsible for closing the water system at the end of the contract according to the manufacturer’s specifications. The contractor shall be responsible for any damage due to contractor negligence and shall incur all cost associated with the damage. USDA to provide facilities water system zones to contractor. USDA designee will provide assistance with the operation of water system.

6. Leaves and trash:

During the months of March - October, weekly removal of leaves and trash along all fence lines, parking lot, back lot, truck wells, picnic area, flowerbeds, foundations, etc...

During the months of November – February, Bi-Weekly removal of leaves and trash along all fence lines, parking lot, back lot, truck wells, picnic area, flowerbeds, foundations, etc…

7. Pest and disease control:

All lawn, shrub and tree pests shall be controlled.

Prevention and control of plant fungus and disease.

Notes: Each application should be recorded. Copies of when each application is performed and what has been applied to the property are given to the USDA designee.

8. Concrete Lined Drainage Ditch:

Remove sediment and debris when needed. (Usually two times per year – COR will provide the dates when needed.)

C.3 BIOBASED REQUIREMENTS

The Contractor must comply with Section 9002 of the Farm Security and Rural Investment Act of 2002 (FSRIA), Executive Order (EO) 13423, “Strengthening Federal Envoi mental Energy and Transportation Management,” and the Federal Acquisition Regulation to provide biobased products.

The Contractor shall utilize products and material made from biobased materials (e.g., biobased greases, biobased hydraulic fluids, biobased absorbents) to the maximum extent possible without jeopardizing the intended end use or detracting from the overall quality delivered to the end user. All supplies and materials shall be of a type and quality that conform to applicable Federal specifications and standards. All supplies and materials to be used in the performance of work described herein are subject to the approval of the Contracting Officer Representative (COR).

The following is an example list of products that may be used in this contract for the grounds maintenance services for which biobased products are available. The list is not all inclusive. It is desirable that vendors be able to supply the greatest number of biobased products listed meeting the health and environmental specifications.

Fertilizers Graffiti or Grease Removers Mulch and Compost Agricultural Spray Adjuvants Compost Activators Erosion Control

Dethatchers Foliar Sprays pH Neutralizing Products Plant Washes

3 | P a g e

Biobased products that are designated for preferred procurement under USDA’s BioPreferred program must meet the required minimum biobased content as stated in the USDA Final Rule available at www.biopreferred.gov. The Contractor should provide data for their biobased products such as biobased content.

In addition to the biobased products designated by the U.S. Department of Agriculture in the BioPreferred Program, the Contractor is encouraged to use other commercially available biobased products.

The Contractor shall submit with the initial proposal a complete list of biobased products, indicating the name of the manufacturer, cost of each material, and the intended use of each of the materials that are to be used in carrying out the requirements of the contract. Additionally, the winning Contractor on each anniversary date of the contract shall compile a complete list of biobased products , including the information above, purchased to carry out the contract requirements. The Contractor shall list volume to be used and total cost for each individual product. This information will be used for reporting purposes.

The Contractor shall comply with the provision at FAR 52.223-1, Biobased Product Certification.

The Contractor shall comply with the clause at FAR 52.223-2, Affirmative Procurement of Biobased Products Under Service and Construction Contracts.

Within thirty (30) days of contract award, the Contractor shall submit a Grounds Maintenance Plan. This submittal shall be approved by the COR in writing. The Contractor shall not commence work until this submittal is approved by the COR in writing.

The Plan must be reviewed and updated annually, and as required by the COR. The Plan must contain and define the following elements:

The Contractor’s written policy stating its commitment to the use of biobased products, employee health and safety, and sound environmental management practices.

Detail on how the Contractor intends to keep abreast of the development and increasing availability of designated and non-designated biobased products and how any new or improved products will be incorporated on an ongoing basis into contract performance.

Proposed biobased grounds maintenance products which must be selected in accordance with the criteria included above. At a minimum, the Plan must identify products by brand name for each of the product types.

NOTE: A Contractor may propose more than one product within a product category and/or propose a product or products addressing more than one product category.

The product guides which define standard operating procedures for instructing staff in the proper use, storage, and disposal of biobased products; proper maintenance of equipment; and other procedures/instructions to accomplish work under this contract.

The Contractor shall provide data on the quantity and dollar values of biobased products used in this contract. The data will be submitted to the COR quarterly.

A demonstration of proper use, an effective training program, and technical assistance are essential to the success of the purchase and use of some biobased products that may function differently than a conventional product. Therefore we will look for a Contractor who will 1) demonstrate products, and 2) when selected, offer any necessary training to all of the construction staff and 3) be available with technical assistance to trouble shoot problems.

Additional information may be found at http://www.biopreferred.gov/BioPreferred/ http://www.biopreferred.gov/BioPreferred/

4 | P a g e

C.4 Contractor Responsibilities:

1. Contractor shall check in with the Contracting Officer’s Representative (COR) when arriving on-site to complete work. COR is Mr. Walt Bryant. If COR is not available, check-in with Mr. Steve Grantham.

2. The contractor shall rectify any unsatisfactory work within 24 hours of notification. The USDA, AMS, Cotton and Tobacco Programs reserves the right for contract termination based upon non-compliance of the contractor to the contract specifications. Notification of termination shall be provided 15 days prior to termination.

3. Monthly invoices shall be presented for payment indicating the dates of services performed.

4. Any regular visit that does not occur as scheduled shall be rescheduled immediately with the COR or designee within 24 hours of missed appointment. Failure to reschedule or ensure performance will be documented as non-compliance.

5. A supervisor shall make routine visits to the property (at a minimum two per quarter) to ensure customer satisfaction and inspect product on site.

5 | P a g e

Clauses

D.1 FAR 52.212-1 Instructions to Offerors—Commercial Items (JAN 2017)

(a) North American Industry Classification System (NAICS) code and small business size standard. The NAICS code and small business size standard for this acquisition appear in Block 10 of the solicitation cover sheet (SF 1449). However, the small business size standard for a concern which submits an offer in its own name, but which proposes to furnish an item which it did not itself manufacture, is 500 employees.

(b) Submission of offers. Submit signed and dated offers to the office specified in this solicitation at or before the exact time specified in this solicitation. Offers may be submitted on the SF 1449, letterhead stationery, or as otherwise specified in the solicitation. As a minimum, offers must show—

(1) The solicitation number;

(2) The time specified in the solicitation for receipt of offers;

(3) The name, address, and telephone number of the offeror;

(4) A technical description of the items being offered in sufficient detail to evaluate compliance with the requirements in the solicitation. This may include product literature, or other documents, if necessary;

(5) Terms of any express warranty;

(6) Price and any discount terms;

(7) “Remit to” address, if different than mailing address;

(8) A completed copy of the representations and certifications at FAR 52.212-3 (see FAR 52.212-

3(b) for those representations and certifications that the offeror shall complete electronically);

(9) Acknowledgment of Solicitation Amendments;

(10) Past performance information, when included as an evaluation factor, to include recent and relevant contracts for the same or similar items and other references (including contract numbers, points of contact with telephone numbers and other relevant information); and

(11) If the offer is not submitted on the SF 1449, include a statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation. Offers that fail to furnish required representations or information, or reject the terms and conditions of the solicitation may be excluded from consideration.

(c) Period for acceptance of offers. The offeror agrees to hold the prices in its offer firm for 30 calendar days from the date specified for receipt of offers, unless another time period is specified in an addendum to the solicitation.

(d) Product samples. When required by the solicitation, product samples shall be submitted at or prior to the time specified for receipt of offers. Unless otherwise specified in this solicitation, these samples shall be submitted at no expense to the Government, and returned at the sender’s request and expense, unless they are destroyed during preaward testing.

(e) Multiple offers. Offerors are encouraged to submit multiple offers presenting alternative terms and conditions, including alternative line items (provided that the alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation), or alternative commercial items for satisfying the requirements of this solicitation. Each offer submitted will be evaluated separately.

(f) Late submissions, modifications, revisions, and withdrawals of offers.

(1) Offerors are responsible for submitting offers, and any modifications, revisions, or withdrawals, so as to reach the Government office designated in the solicitation by the time specified in the solicitation.

If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that offers or revisions are due.

https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/52_212_213.html#wp1179194 https://www.acquisition.gov/sites/default/files/current/far/html/52_212_213.html#wp1179194 https://www.acquisition.gov/sites/default/files/current/far/html/52_212_213.html#wp1179194 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284 https://www.acquisition.gov/sites/default/files/current/far/html/FormsStandard67.html#wp1189284

6 | P a g e

(2)(i) Any offer, modification, revision, or withdrawal of an offer received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and—

(A) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m.

one working day prior to the date specified for receipt of offers; or

(B) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(C) If this solicitation is a request for proposals, it was the only proposal received.

(ii) However, a late modification of an otherwise successful offer, that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(3) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the offer wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(4) If an emergency or unanticipated event interrupts normal Government processes so that offers cannot be received at the Government office designated for receipt of offers by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation or other notice of an extension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(5) Offers may be withdrawn by written notice received at any time before the exact time set for receipt of offers. Oral offers in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile offers, offers may be withdrawn via facsimile received at any time before the exact time set for receipt of offers, subject to the conditions specified in the solicitation concerning facsimile offers. An offer may be withdrawn in person by an offeror or its authorized representative if, before the exact time set for receipt of offers, the identity of the person requesting withdrawal is established and the person signs a receipt for the offer.

(g) Contract award (not applicable to Invitation for Bids). The Government intends to evaluate offers and award a contract without discussions with offerors. Therefore, the offeror’s initial offer should contain the offeror’s best terms from a price and technical standpoint. However, the Government reserves the right to conduct discussions if later determined by the Contracting Officer to be necessary. The Government may reject any or all offers if such action is in the public interest; accept other than the lowest offer; and waive informalities and minor irregularities in offers received.

(h) Multiple awards. The Government may accept any item or group of items of an offer, unless the offeror qualifies the offer by specific limitations. Unless otherwise provided in the Schedule, offers may not be submitted for quantities less than those specified. The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit prices offered, unless the offeror specifies otherwise in the offer.

(i) Availability of requirements documents cited in the solicitation.

(1)(i) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to—

GSA Federal Supply Service Specifications Section Suite 8100

7 | P a g e

470 East L’Enfant Plaza, SW Washington, DC 20407

Telephone (202) 619-8925 Facsimile (202) 619-8978.

(ii) If the General Services Administration, Department of Agriculture, or Department of Veterans Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (i)(1)(i) of this provision. Additional copies will be issued for a fee.

(2) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(i) ASSIST (https://assist.dla.mil/online/start/).

(ii) Quick Search (http://quicksearch.dla.mil/).

(iii) ASSISTdocs.com (http://assistdocs.com).

(3) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by—

(i) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(ii) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(iii) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA

19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

(4) Nongovernment (voluntary) standards must be obtained from the organization responsible for their preparation, publication, or maintenance.

(j) Unique entity identifier. (Applies to all offers exceeding $3,500, and offers of $3,500 or less if the solicitation requires the Contractor to be registered in the System for Award Management (SAM) database.) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror’s name and address. The Offeror also shall enter its Electronic Funds Transfer (EFT) indicator, if applicable.

The EFT indicator is a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the Offeror to establish additional SAM records for identifying alternative EFT accounts (see subpart 32.11) for the same entity. If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for unique entity identifier establishment directly to obtain one. The Offeror should indicate that it is an offeror for a Government contract when contacting the entity designated at www.sam.gov for establishing the unique entity identifier.

(k) System for Award Management. Unless exempted by an addendum to this solicitation, by submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance and through final payment of any contract resulting from this solicitation. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror. Offerors may obtain information on registration and annual confirmation requirements via the SAM database accessed through https://www.acquisition.gov.

(l) Debriefing. If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(1) The agency’s evaluation of the significant weak or deficient factors in the debriefed offeror’s offer.

(2) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

https://assist.dla.mil/online/start/ http://quicksearch.dla.mil/ http://assistdocs.com/ https://assist.dla.mil/wizard/index.cfm https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2032_11.html#wp1043964 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2032_11.html#wp1043964 https://www.acquisition.gov/sites/default/files/current/far/html/Subpart%2032_11.html#wp1043964 https://www.acquisition.gov/sites/default/files/current/far/html/www.sam.gov https://www.acquisition.gov/sites/default/files/current/far/html/www.sam.gov https://www.acquisition.gov/

8 | P a g e

(3) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(4) A summary of the rationale for award;

(5) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(6) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

D.2 FAR 52.212-2 Evaluation—Commercial Items (OCT 2014)

(a) The Government will award a contract resulting from this solicitation to the responsible offeror whose offer conforming to the solicitation will be most advantageous to the Government, price and other factors considered. The following factors shall be used to evaluate offers:

Relevant Experience Equipment Biobased Products Past Performance Price

Factors are listed in descending order of importance.

Relevant experience, equipment, biobased products, and past performance, when combined, are significantly more important than price.

(b) Options. The Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. The Government may determine that an offer is unacceptable if the option prices are significantly unbalanced. Evaluation of options shall not obligate the Government to exercise the option(s).

(c) A written notice of award or acceptance of an offer, mailed or otherwise furnished to the successful offeror within the time for acceptance specified in the offer, shall result in a binding contract without further action by either party. Before the offer’s specified expiration time, the Government may accept an offer (or part of an offer), whether or not there are negotiations after its receipt, unless a written notice of withdrawal is received before award.

(End of provision)

D.3 FAR 52.212-3 Offeror Representations and Certifications—Commercial Items (JAN 2017)

The Offeror shall complete only paragraph (b) of this provision if the Offeror has completed the annual representations and certification electronically via the System for Award Management (SAM) website located at https://www.sam.gov/portal. If the Offeror has not completed the annual representations and certifications electronically, the Offeror shall complete only paragraphs (c) through (u) of this provision.

https://www.sam.gov/portal

9 | P a g e

(a) Definitions. As used in this provision— “Administrative merits determination” means certain notices or findings of labor law violations issued by an enforcement agency following an investigation. An administrative merits determination may be final or be subject to appeal or further review. To determine whether a particular notice or finding is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Arbitral award or decision” means an arbitrator or arbitral panel determination that a labor law violation occurred, or that enjoined or restrained a violation of labor law. It includes an award or decision that is not final or is subject to being confirmed, modified, or vacated by a court, and includes an award or decision resulting from private or confidential proceedings. To determine whether a particular award or decision is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“Civil judgment” means–

(1) In paragraph (h) of this provision: A judgment or finding of a civil offense by any court of competent jurisdiction.

(2) In paragraph (s) of this provision: Any judgment or order entered by any Federal or State court in which the court determined that a labor law violation occurred, or enjoined or restrained a violation of labor law. It includes a judgment or order that is not final or is subject to appeal. To determine whether a particular judgment or order is covered by this definition, it is necessary to consult section II.B. in the DOL Guidance.

“DOL Guidance” means the Department of Labor (DOL) Guidance entitled: “Guidance for Executive Order 13673, ‘Fair Pay and Safe Workplaces’”. The DOL Guidance was initially published in the Federal Register on August 25, 2016, and significant revisions will be published for public comment in the Federal Register. The DOL Guidance and subsequent versions can be obtained from www.dol.gov/fairpayandsafeworkplaces.

“Economically disadvantaged women-owned small business (EDWOSB) concern” means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States and who are economically disadvantaged in accordance with 13 CFR part 127. It automatically qualifies as a women-owned small business eligible under the WOSB Program.

“Enforcement agency” means any agency granted authority to enforce the Federal labor laws. It includes the enforcement components of DOL (Wage and Hour Division, Office of Federal Contract Compliance Programs, and Occupational Safety and Health Administration), the Equal Employment Opportunity Commission, the Occupational Safety and Health Review Commission, and the National Labor Relations Board. It also means a State agency designated to administer an OSHA-approved State Plan, but only to the extent that the State agency is acting in its capacity as administrator of such plan. It does not include other Federal agencies which, in their capacity as contracting agencies, conduct investigations of potential labor law violations. The enforcement agencies associated with each labor law under E.O. 13673 are–

(1) Department of Labor Wage and Hour Division (WHD) for–

(i) The Fair Labor Standards Act;

(ii) The Migrant and Seasonal Agricultural Worker Protection Act;

(iii) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act;

(iv) 41 U.S.C. chapter 67, formerly known as the Service Contract Act;

(v) The Family and Medical Leave Act; and

(vi) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors);

(2) Department of Labor Occupational Safety and Health Administration (OSHA) for–

(i) The Occupational Safety and Health Act of 1970; and

(ii) OSHA-approved State Plans;

(3) Department of Labor Office of Federal Contract Compliance Programs (OFCCP) for– https://www.acquisition.gov/sites/default/files/current/far/html/www.dol.gov/fairpayandsafeworkplaces http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/

10 | P a g e

(i) Section 503 of the Rehabilitation Act of 1973;

(ii) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era

Veterans’ Readjustment Assistance Act of 1974; and

(iii) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity);

(4) National Labor Relations Board (NLRB) for the National Labor Relations Act; and

(5) Equal Employment Opportunity Commission (EEOC) for–

(i) Title VII of the Civil Rights Act of 1964;

(ii) The Americans with Disabilities Act of 1990;

(iii) The Age Discrimination in Employment Act of 1967; and

(iv) Section 6(d) of the Fair Labor Standards Act (Equal Pay Act).

“Forced or indentured child labor” means all work or service—

(6) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(7) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

“Highest-level owner” means the entity that owns or controls an immediate owner of the offeror, or that owns or controls one or more entities that control an immediate owner of the offeror. No entity owns or exercises control of the highest level owner.

“Immediate owner” means an entity, other than the offeror, that has direct control of the offeror.

Indicators of control include, but are not limited to, one or more of the following: ownership or interlocking management, identity of interests among family members, shared facilities and equipment, and the common use of employees.

“Inverted domestic corporation”, means a foreign incorporated entity that meets the definition of an inverted domestic corporation under 6 U.S.C. 395(b), applied in accordance with the rules and definitions of 6 U.S.C. 395(c).

“Labor compliance agreement” means an agreement entered into between a contractor or subcontractor and an enforcement agency to address appropriate remedial measures, compliance assistance, steps to resolve issues to increase compliance with the labor laws, or other related matters.

“Labor laws” means the following labor laws and E.O.s:

(1) The Fair Labor Standards Act.

(2) The Occupational Safety and Health Act (OSHA) of 1970.

(3) The Migrant and Seasonal Agricultural Worker Protection Act.

(4) The National Labor Relations Act.

(5) 40 U.S.C. chapter 31, subchapter IV, formerly known as the Davis-Bacon Act.

(6) 41 U.S.C. chapter 67, formerly known as the Service Contract Act.

(7) E.O. 11246 of September 24, 1965 (Equal Employment Opportunity).

(8) Section 503 of the Rehabilitation Act of 1973.

(9) The Vietnam Era Veterans’ Readjustment Assistance Act of 1972 and the Vietnam Era Veterans'

Readjustment Assistance Act of 1974.

(10) The Family and Medical Leave Act.

(11) Title VII of the Civil Rights Act of 1964.

(12) The Americans with Disabilities Act of 1990.

(13) The Age Discrimination in Employment Act of 1967.

(14) E.O. 13658 of February 12, 2014 (Establishing a Minimum Wage for Contractors).

(15) Equivalent State laws as defined in the DOL Guidance. (The only equivalent State laws implemented in the FAR are OSHA-approved State Plans, which can be found at www.osha.gov/dcsp/osp/approved_state_plans.html).

http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/ https://www.acquisition.gov/sites/default/files/current/far/html/www.osha.gov/dcsp/osp/approved_state_plans.html

11 | P a g e

“Labor law decision” means an administrative merits determination, arbitral award or decision, or civil judgment, which resulted from a violation of one or more of the laws listed in the definition of “labor laws”.

“Manufactured end product” means any end product in product and service codes (PSCs) 1000-9999, except—

(1) PSC 5510, Lumber and Related Basic Wood Materials;

(2) Product or Service Group (PSG) 87, Agricultural Supplies;

(3) PSG 88, Live Animals;

(4) PSG 89, Subsistence;

(5) PSC 9410, Crude Grades of Plant Materials;

(6) PSC 9430, Miscellaneous Crude Animal Products, Inedible;

(7) PSC 9440, Miscellaneous Crude Agricultural and Forestry Products;

(8) PSC 9610, Ores;

(9) PSC 9620, Minerals, Natural and Synthetic; and

(10) PSC 9630, Additive Metal Materials.

“Place of manufacture” means the place where an end product is assembled out of components, or otherwise made or processed from raw materials into the finished product that is to be provided to the Government. If a product is disassembled and reassembled, the place of reassembly is not the place of manufacture.

“Predecessor” means an entity that is replaced by a successor and includes any predecessors of the predecessor.

“Restricted business operations” means business operations in Sudan that include power production activities, mineral extraction activities, oil-related activities, or the production of military equipment, as those terms are defined in the Sudan Accountability and Divestment Act of 2007 (Pub. L. 110-174).

Restricted business operations do not include business operations that the person (as that term is defined in Section 2 of the Sudan Accountability and Divestment Act of 2007) conducting the business can demonstrate—

(1) Are conducted under contract directly and exclusively with the regional government of southern Sudan;

(2) Are conducted pursuant to specific authorization from the Office of Foreign Assets Control in the Department of the Treasury, or are expressly exempted under Federal law from the requirement to be conducted under such authorization;

(3) Consist of providing goods or services to marginalized populations of Sudan;

(4) Consist of providing goods or services to an internationally recognized peacekeeping force or humanitarian organization;

(5) Consist of providing goods or services that are used only to promote health or education; or

(6) Have been voluntarily suspended.

“Sensitive technology”—

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically—

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

“Service-disabled veteran-owned small business concern”—

(1) Means a small business concern— http://uscode.house.gov/ http://uscode.house.gov/ http://uscode.house.gov/

12 | P a g e

(i) Not less than 51 percent of which is owned by one or more service-disabled veterans or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more service-disabled veterans; and

(ii) The management and daily business operations of which are controlled by one or more service-disabled veterans or, in the case of a service-disabled veteran with permanent and severe disability, the spouse or permanent caregiver of such veteran.

(2) Service-disabled veteran means a veteran, as defined in 38 U.S.C. 101(2), with a disability that is service-connected, as defined in 38 U.S.C. 101(16).

“Small business concern” means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR Part 121 and size standards in this solicitation.

“Small disadvantaged business concern”, consistent with 13 CFR 124.1002, means a small business concern under the size standard applicable to the acquisition, that—

(1) Is at least 51 percent unconditionally and directly owned (as defined at 13 CFR 124.105) by—

(i) One or more socially disadvantaged (as defined at 13 CFR 124.103) and economically disadvantaged (as defined at 13 CFR 124.104) individuals who are citizens of the United States; and

(ii) Each individual claiming economic disadvantage has a net worth not exceeding $750,000 after taking into account the applicable exclusions set forth at 13 CFR 124.104(c)(2); and

(2) The management and daily business operations of which are controlled (as defined at 13.CFR

124.106) by individuals, who meet the criteria in paragraphs (1)(i) and (ii) of this definition.

“Subsidiary” means an entity in which more than 50 percent of the entity is owned—

(1) Directly by a parent corporation; or

(2) Through another subsidiary of a parent corporation.

“Veteran-owned small business concern” means a small business concern—

(1) Not less than 51 percent of which is owned by one or more veterans (as defined at

38 U.S.C. 101(2)) or, in the case of any publicly owned business, not less than 51 percent of the stock of which is owned by one or more veterans; and

(2) The management and daily business operations of which are controlled by one or more veterans.

“Successor” means an entity that has replaced a predecessor by acquiring the assets and carrying out the affairs of the predecessor under a new name (often through acquisition or merger). The term “successor” does not include new offices/divisions of the same company or a company that only changes its name. The extent of the responsibility of the successor for the liabilities of the predecessor may vary, depending on State law and specific circumstances.

“Women-owned business concern” means a concern which is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

“Women-owned small business concern” means a small business concern—

(1) That is at least 51 percent owned by one or more women; or, in the case of any publicly owned business, at least 51 percent of the stock of which is owned by one or more women; and

(2) Whose management and daily business operations are controlled by one or more women.

“Women-owned small business (WOSB) concern eligible under the WOSB Program” (in accordance with 13 CFR part 127), means a small business concern that is at least 51 percent directly and unconditionally owned by, and the management and daily business operations of which are controlled by, one or more women who are citizens of the United States.

Note to paragraph (a): By a court order issued on October 24, 2016, the following definitions in this paragraph (a) are enjoined indefinitely as of the date of the order: “Administrative merits determination”, “Arbitral award or decision”, paragraph (2) of “Civil judgment”, “DOL Guidance”, “Enforcement agency”, http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20 http://uscode.house.gov/uscode-cgi/fastweb.exe?getdoc+uscview+t37t40+200+2++%2838%29%20%20AND%20%28%2838%29%20ADJ%20USC%29%3ACITE%20%20%20%20%20%20%20%20%20

13 | P a g e

“Labor compliance agreement”, “Labor laws”, and “Labor law decision”. The enjoined definitions will become effective immediately if the court terminates the injunction. At that time, GSA, DoD and NASA will publish a document in the Federal Register advising the public of the termination of the injunction.

(b)(1) Annual Representations and Certifications. Any changes provided by the offeror in paragraph (b)(2) of this provision do not automatically change the representations and certifications posted on the SAM website.

(2) The offeror has completed the annual representations and certifications electronically via the SAM website accessed through http://www.acquisition.gov. After reviewing the SAM database information, the offeror verifies by submission of this offer that the representations and certifications currently posted electronically at FAR 52.212-3, Offeror Representations and Certifications—Commercial Items, have been entered or updated in the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201), except for paragraphs ______________.

[Offeror to identify the applicable paragraphs at (c) through (t) of this provision that the offeror has completed for the purposes of this solicitation only, if any.

These amended representation(s) and/or certification(s) are also…