P00004 P15PC00811: REMOVE AND REPLACE CONCRETE PREST PAVERS AT CASTLE CLINTON NATIONAL MONUMENT, NEW YORK, NY THE PURPOSE OF THIS MODIFICATION IS TO: 1. CLOSEOUT AND DE-OBLIGATE FUNDS IN THE AMOUNT OF $.05 FROM CONTRACT LINE ITEM NUMBER (CLIN) 10. Funding Only Action 0$ 3/20/20 3 P14PC00811: REMOVE AND REPLACE CONCRETE PREST PAVERS AT CASTLE CLINTON NATIONAL MONUMENT, NEW YORK, NY THIS MODIFICATION IS HEREBY ISSUED FOR THE FOLLOWING REASON(S): 1. DUE TO DIFFERING SITE CONDITIONS, THE ABOVE SUBJECT CONTRACT IS HEREBY MODIFIED TO PROCURE SUPPLIES TO CORRECT WATERPROOFING AND STRUCTURAL DEFICIENCIES UNEARTHED DURING THE PROJECT IN ACCORDANCE WITH STATEMENT OF WORK AND THE CONTRACTOR'S PROPOSAL DATED 6 JUNE 2016. THE CONTRACTOR SHALL PROVIDE ALL NECESSARY LABOR, MATERIAL, EQUIPMENT AND SUPERVISION TO PROVIDE MODIFICATIONS IN ACCORDANCE WITH THE ATTACHED STATEMENT OF WORK. THIS CHANGE ORDER REQUIRES AN EXTENSION OF 15 DAYS. IN ADDITION, THE CONTRACTOR HAS REQUESTED A NO COST TIME EXTENSION OF 30 DAYS DUE TO FLASHING MATERIALS SHIPPING DELAY. IN CONSIDERATION FOR GRANTING THE NO COST TIME EXTENSION OF 30 DAYS, THE CONTRACTOR AGREES TO FOREGO THE LABOR COSTS AND PERFORM THE CHANGE ORDER FOR THE MATERIALS COSTS ONLY OF $5,000.00. 2. AS A RESULT OF THIS MODIFICATION, THE CONTRACT COMPLETION DATE IS EXTENDED AN ADDITIONAL 45 DAYS FROM 15 JUNE 2016 TO 29 JULY 2016. 3. AS A RESULT OF THIS MODIFICATION, THE CONTRACT AMOUNT IS INCREASED BY $5,000.00 FROM $151,625.00 TO $156,625.00. 4. ACCEPTANCE OF THIS MODIFICATION BY THE CONTRACTOR CONSTITUTES AN ACCORD AND SATISFACTION AND REPRESENTS PAYMENT IN FULL FOR BOTH TIME AND MONEY AND FOR ANY AND ALL COSTS, IMPACT EFFECT, AND OR FOR DELAYS AND DISRUPTIONS ARISING OUT OF, OR INCIDENTAL TO, THE WORK AS HEREIN REVISED. Change Order $5.0k 8/4/16 2 P14PC00811: REMOVE AND REPLACE CONCRETE PREST PAVERS AT CASTLE CLINTON NATIONAL MONUMENT, NEW YORK, NY THE SUBJECT CONTRACT IS HEREBY FOR THE FOLLOWING: A. THE PURPOSE OF THIS MODIFICATION IS TO CHANGE THE CONTRACTING OFFICER DUE TO AN INTERNAL RE-ORGANIZATION OF THE NORTHEAST REGION NATIONAL PARK SERVICE CONTRACTING OFFICES. CONTRACTING OFFICER CHANGED FROM YENY BRETON TO KAREN UMSTOT B. ALL OTHER TERMS AND CONDITIONS REMAIN UNCHANGED. Other Administrative Action $0 6/10/16 1 P14PC00811: REMOVE AND REPLACE CONCRETE PREST PAVERS AT CASTLE CLINTON NATIONAL MONUMENT, NEW YORK, NY THE SUBJECT CONTRACT IS HEREBY MODIFIED AS FOLLOWS: 1. BY MUTUAL AGREEMENT OF THE PARTIES AND AT NO COST TO THE GOVERNMENT, THE CONTRACT COMPLETION DATE IS EXTENDED 144 DAYS FROM 01/26/2016 TO 06/17/2016, DUE TO THE FURTHER SPECIFICATIONS OF THE MANUFACTURER OF ADHERENCE TO TEMPERATURES OF FORTY DEGREES FARENHEIT (40F) FOR SPECIFIED ROOFING MATERIALS IN ADDITION TO THE REQUIREMENTS OUTLINED FOR INSTALLATION SET IN THE PROJECT SCOPE. THESE TEMPERATURES CANNOT BE ATTAINED DURING THE MONTHS OF JANUARY, FEBRUARY AND MARCH. 2. ACCEPTANCE OF THIS MODIFICATION BY THE CONTRACTOR CONSTITUTES AN ACCORD AND SATISFACTION AND REPRESENTS PAYMENT IN FULL FOR BOTH TIME AND MONEY AND FOR ANY AND ALL COSTS, IMPACT EFFECT, AND OR FOR DELAYS AND DISRUPTIONS ARISING OUT OF, OR INCIDENTAL TO, THE WORK AS HEREIN REVISED. Change Order $0 2/3/16 Not listed P15PC00811: REMOVE AND REPLACE CONCRET PREST PAVERS AT CASTLE CLINTON NATIONAL MONUMENT, NEW YORK, NY Not listed $151.6k 9/23/15