Computer, digital, in repair/modification of

TEARDOWN, EVALUATE, REPAIR AND/OR MODIFY
0001 NSN 7HH 7021-01-548-0358
COMPUTER,DIGITAL

0001AA N00104-21-U-0483 SW3117 9 EA
M/F: "A" CONDITION STOCK
TP: 3
0001AB OPTION QTY UP TO 100% OF ITEM 0001

SOLICITATION NOTES:
** Accelerated delivery is encouraged and accepted before the delivery date(s)
listed in the schedule. **
All freight is FOB Origin.
This RFQ is for repair. The resultant award of this solicitation will be
issued bilaterally, requiring the contractors written acceptance prior to
execution.. Verify nomenclature, part number, and NSN prior to responding.
Required Repair Turnaround Time (RTAT): 145 days
Quotes not meeting the required RTAT may not be considered for award.
Government source inspection is required.
Please note freight is handled by Navy CAV or Proxy CAV as stated in
NAVSUPWSSFA24 or NAVSUPWSSFA25.
Your quote should include the following information for justification
purposes:
*Firm-fixed-price per unit:___________
*New unit price:__________
*New unit delivery lead-time:__________
*Inspection & Acceptance CAGE, if not at source:__________
*Facility/Subcontractor CAGE (where the asset should be shipped), if not at
source:__________
*Delivery Vehicle (if Delivery Order requested) (if your company has a current 

BOA/IDIQ, for example) :__________________
ALL PRICING IS FIRM. PLEASE CONSIDER THE FOLLOWING WHEN PROVIDING PRICE:
Include repair price with all costs associated with receipt and complete
repair of material that may be in unwhole condition, missing hardware,
damaged, handling damage, missing parts and wear damage.
The Contract Officer would like to exercise a 100% option quantity within
180-days of the effective date of the repair contract award. The contractor
will provide the same delivery turnaround as the base line items. A
modification willbe completed at the time the option is exercised and all
current contract termsand conditions will apply to the option quantity.
Please indicate if the Contracting Officer may exercise the 100% option
quantity for the repair contract.
Yes __ or No __
Please indicate the pricing for the option quantity.
Price Each: $___________
IMPORTANT NOTE: Any asset for which the contractor does not meet the required
RTAT will incur a price reduction per unit/per month the contractor is late -
any delay determined to be excusable (e.g. Government Delay) will not result
in a price reduction. If a price reduction is required due to unexcusable
contractor delay, the Contracting Officer will implement the aforementioned
price reduction via a "reconciliation modification" at the end of the contract
performance. Price reductions made pursuant to this section shall not limit
other remedies available to the Government for failure to meet required RTATs,
including but not limited to the Government's right to terminate for default.
In reference to the above important note, the contractor provides the
followingprice reduction amount per unit per month the contractor does not
meet the RTAT: $__________, up to a maximum of: $_________.
INSPECTION AT ORIGIN
ACCEPTANCE AT ORIGIN

See solicitation for required clauses.