AMD_1_17B01_JBC_Dredging__2017.02.07.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

W912HP-17-B-0001 JBC Maintenance Dredging has been amended to update quantities in unclassified material. FAR Clause 52.211-10 paragraph 2(a) has also been modified. Summary of Changes can be view ed on the continuation page.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 5

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 07-Feb-2017

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912HP-17-B-0001

X 9B. DATED (SEE ITEM 11)

20-Jan-2017

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

07-Feb-2017

CODE

US ARMY CORPS OF ENGINEERS, CHARLESTON

69-A HAGOOD AVENUE

CHARLESTON SC 29403

W912HP 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912HP-17-B-0001

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 10 00 - SOLICITATION, CONTRACT LINE ITEM NUMBER (CLIN) SCHEDULE

The required performance has changed from W912HP-17-B-0001 JBC DredgingThis acquisition is being solicted as a 100% small business set-aside. The NAICS Code is 237990 Other Heavy and Civil Engineering Construction. Small Business Size Standard is $27.5M.The work consists of maintenance dredging approximately 1,568,000 cubic yards of unclassified material from the Joint Base Charleston (JBC) Channel (Shoals 1, 2, 2A, 3A, 4, 4A, 5, 6) and TC Dock located in Charleston and Berkley counties, SC. The material shall be deposited in the Joint Base Charleston Placement Area. The work includes complying with the requirements of the applicable USACE Regulatory issued permits, the Endangered Species Act and the Marine Mammals Protection Act.MAGNITUDE OF WORK: $3,000,000 TO 7,000,000The Contractor must be registered in the System for Award Management (SAM.gov). The Solicitation and any subsequent Amendments will only be available in electronic format downloadable from the internet. Bidders must be registered at the Federal Business Opportunity website (www.fbo.gov) in order to view or download Solicitation documents. It is the responsibility of bidders to monitor the FBO website for Notices and Amendments. to W912HP-17-B-0001 JBC DredgingThis acquisition is being solicted as a 100% small business set-aside. The NAICS Code is 237990 Other Heavy and Civil Engineering Construction. Small Business Size Standard is $27.5M.The work consists of maintenance dredging approximately 1,785,000 cubic yards of unclassified material from the Joint Base Charleston (JBC) Channel (Shoals 1, 2, 2A, 3A, 4, 4A, 5, 6) and TC Dock located in Charleston and Berkley counties, SC. The material shall be deposited in the Joint Base Charleston Placement Area. The work includes complying with the requirements of the applicable USACE Regulatory issued permits, the Endangered Species Act and the Marine Mammals Protection Act.MAGNITUDE OF WORK: $3,000,000 TO 7,000,000The Contractor must be registered in the System for Award Management (SAM.gov). The Solicitation and any subsequent Amendments will only be available in electronic format downloadable from the internet. Bidders must be registered at the Federal Business Opportunity website (www.fbo.gov) in order to view or download Solicitation documents. It is the responsibility of bidders to monitor the FBO website for Notices and Amendments..

CLIN 0002

The pricing detail quantity has increased by 142,000.00 from 313,000.00 to 455,000.00.

CLIN 0003

The pricing detail quantity has decreased by 34,000.00 from 554,000.00 to 520,000.00.

CLIN 0004

The pricing detail quantity has increased by 6,000.00 from 219,000.00 to 225,000.00.

SUBCLIN 0005AC

The pricing detail quantity has increased by 5,000.00 from 45,000.00 to 50,000.00.

CLIN 0006

The pricing detail quantity has increased by 19,000.00 from 51,000.00 to 70,000.00.

CLIN 0007

The pricing detail quantity has increased by 33,000.00 from 57,000.00 to 90,000.00.

CLIN 0008

The pricing detail quantity has increased by 23,000.00 from 72,000.00 to 95,000.00.

CLIN 0010

The pricing detail quantity has increased by 23,000.00 from 252,000.00 to 275,000.00.

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within [SEE SUPPLEMENTAL INSTRUCTION BELOW] calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than. [SEE SUPPLEMENTAL

INSTRUCTION BELOW]

SUPPLEMENTAL INSTRUCTIONS

1. Joint Base Charleston Channel (Shoals 1, 2, 2A, 3A, 4, 4A, 5)

(a) Prosecution of Work

The Contractor will be required to commence dredging work under this contract when directed by the Contracting Officer and to prosecute the dredging work at an average rate of 300,000 cubic yards per month and to complete it within the number of days after the limiting date fixed for commencement; provided that the quantity of material actually removed in any one month shall in no case be less than 250,000 cubic yards.

(b) Continuously Working

The Contractor shall maintain adequate plant on site to have an average production rate of 300,000 cubic yards per month and shall work continuously for every consecutive calendar month until the project is completed.

The number of days allowed for completion after the limiting date fixed for commencement shall be determined by applying the average monthly rate above stipulated to the total quantity of material actually removed and to be paid for under the contract; provided, further that no waiver by the Contracting Officer of any failure of the Contractor to make in any month or series of months the rate of progress required by this paragraph shall be construed as relieving the Contractor from the obligation to make up the deficiency in future months and to complete the entire work within the time allowed by the contract. The time thus determined for completion shall include final clean-up of the premises.

(c) Performing Dredging Work for Others Outside the Requirements of this Contract

In the event the Contractor elects to perform dredging work contiguous to the project area but outside the requirements of this contract, (i.e. for Federal, state or local activities - “third party”) the Contractor shall have approval of the Contracting Officer prior to moving off construction site to perform third party work. Reasonable adjustments in time may be granted to the Contractor to perform this work at the discretion of the Contracting Officer. Time allotted may include time to relocate pipelines, dredge plant, and to perform the third party work; however, it shall not include time for plant maintenance or similar delays that postpone resumption of work under this contract. The Contractor shall also be responsible for the cost of any additional surveys required due to delays caused by this interruption of work.

2. TC Dock and Shoal 6 – NPTU IX-516 Barge Basin

(a) Prosecution of Work

The Contractor will be required to commence dredging work under this contract within 30 days from the issuance of NTP and to prosecute the dredging work at an average rate of 3,000 cubic yards per day and to complete it within the number of days allowed after the commencement of dredging on this shoal.

(b) Continuously Working

The Contractor shall maintain adequate plant on site to have an average production rate of 3,000 cubic yards per day and shall work continuously for every consecutive calendar day until the project is completed.

The number of days allowed for completion after the limiting date fixed for commencement shall be determined by applying the daily rate above stipulated to the total quantity of material actually removed and to be paid for under the contract; provided, further that no waiver by the Contracting Officer of any failure of the Contractor to make in any daily or series of daily the rate of progress required by this paragraph shall be construed as relieving the Contractor from the obligation to make up the deficiency in future days and to complete the entire work within the time allowed by the contract. The time thus determined for completion shall include final clean-up of the premises.

(c) Scheduling of Dredging

Due to regular scheduled TC Dock usage, the dredge may have delays, required pull offs, standby time, etc., until TC Dock is clear of vessels and available for dredging work. The Contractor shall coordinate dredging work with the Joint Base Channel personnel and schedule the dredging of the TC Dock around the pier usage. In addition, the Contractor must comply with Joint Base Charleston safety and security requirements which could result in temporary movement of all vessels to a safe zone, etc.

(d) Performing Dredging Work for Others Outside the Requirements of this Contract:

In the event the Contractor elects to perform dredging work contiguous to the project area but outside the requirements of this contract, (i.e. for Federal, state or local activities - “third party”) the Contractor shall have approval of the Contracting Officer prior to moving off construction site to perform third party work. Reasonable adjustments in time may be granted the Contractor to perform this work at the discretion of the Contracting Officer. Time allotted may include time to relocate pipelines, dredge plant, and to perform the third party work; however, it shall not include time for plant maintenance or similar delays that postpone resumption of work under this contract. The Contractor shall also be responsible for the cost of any additional surveys required due to delays caused by this interruption of work.

(End of supplemental instructions)

(End of Summary of Changes)