16-R-0007_Vol._1.pdf

RFP No. W912EP-16-R-0007

SMALL BUSINESS SET-ASIDE

US Army Corps of Engineers Jacksonville District

Kissimmee River Restoration Project C-38 Reach 2 Backfill Okeechobee and Highlands Counties, Florida

Construction Solicitation and Specifications Volume 1 of 2

16 May 2016

KISSIMMEE RIVER RESTORATION PROJECT, C-38 REACH 2 BACKFILL, OKEECHOBEE AND HIGHLANDS COUNTIES, FLORIDA

DESCRIPTIONOF WORK; REFER TO PARAGRAPH WORK COVERED BY CONTRACT DOCUMENTS IN SECTION 01 11 00 FOR COMPLETE

PROJECT DESCRIPTION.

DRAWINGS: SEE DFARS CLAUSE 252.236-7001, CONTRACT DRAWINGS AND SPECIFICATIONS, IN SECTION 00700.

MAGNITUDE OF CONSTRUCTION IS BETWEEN $10,000,000.00 AND $25,000,000.00. THIS SOLICITATION IS

RESTRICTED TO SMALL BUSINESSES ONLY. THE NAICS CODE FOR THIS PROJECT IS 237990 AND THE SMALL BUSINESS SIZE STANDARD

IS $36.5 MILLION.

***BLOCK 11 - SEE SECTION 00700, CLAUSE 52.211-10 FOR PERIOD OF PERFORMANCE.

***BLOCK 13A - SEE SECTION 00100A FOR NUMBER OF COPIES.

A SITE VISIT HAS BEEN SCHEDULED. SEE SECTION 00100, FAR CLAUSE 52.236-27 Alt I FOR DETAILS.

You must be registered in the System for Aw ard Management (SAM), per FAR Clause: 52.204-7 – SYSTEM FOR AWARD MANAGEMENT

(JULY 2013) in Section 00101, in order to receive an aw ard from this solicitation. The SAM w ebsite is located at http://w w w .sam.gov

JAMES E RANDALL 904-232-1792

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

16-May-2016

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______45 calendar days and complete it w ithin ________730 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________Section 00700

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specified in Item 8 by ___________ local time 16 Jun 2016_____ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

W912EP

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

03:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912EP-16-R-0007 262

See Item 14 document and return _______ copies to issuing office.)

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

OFFER (Must be fully completed by offeror)

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

FACILITY CODE

(Insert any number equal to or greater than

AMENDMENT NO.

DATE

20B. SIGNATURE 20C. OFFER DATE

(To be completed by Government)

SEE SCHEDULE

41 U.S.C. 253(c)

CODE K3M0H00 27. PAYMENT WILL BE MADE BY CODE 964145

USACE FINANCE CENTER

5722 INTEGRITY DRIVE

ATTN: CEFC-AO-P

MILLINGTON, TN 38054-5005

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)

Contractor agrees

31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE 31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

(REV. 4-85) STANDARD FORM 1442 BACK

(Type or print)

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

(Include ZIP Code)

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AWARD

23. ACCOUNTING AND APPROPRIATION DATA

AMOUNTS SEE SCHEDULE OF PRICES

(Type or print)

14. NAME AND ADDRESS OF OFFEROR

CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

18. The offeror agrees to furnish any required performance and payment bonds.

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER

21. ITEMS ACCEPTED:

22. AMOUNT

(4 copies unless otherwise specified)

26. ADMINISTERED BY

US ARMY CORPS OF ENGINEERS,

North Florida Area Office, Seabring Project Office, 939 Mall Ring Road, Seabring, FL 33870

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN

30B. SIGNATURE

NSN 7540-01-155-3212 00010-2

to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by refer-ence in or attached to this contract.

Your offer on this solicitation, is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

28. NEGOTIATED AGREEMENT (Contractor is required to sign this (Contractor is not required to sign this document.)29. AWARD

SECTION 00010A

LINE ITEMS AND PRICING SCHEDULE

W912EP-16-B-0007 00010A-1

LINE ITEM DESCRIPTION QUANTITY UNIT UNIT PRICE TOTAL

0001 MOBILIZATION AND PREPARATORY WORK 1 LUMP SUM $_______________

0002 CLEARING AND GRUBBING - ALL DREDGE 1 LUMP SUM $_______________

DISPOSAL AREAS

0003 CLEARING AND GRUBBING - S-65C 1 LUMP SUM $_______________

TIEBACK LEVEES

0004 DEMOLITION S-65C LOCK, SPILLWAY, LOCK 1 LUMP SUM $_______________

TENDER RESIDENCE, S-65CX, OTHER

STRUCTURES, AND ASSOCIATED UTILITIES

0005 DEGRADE S-65C LOCKS ACCESS ROAD / 84,700 CUBIC YARD $___________ $_______________

TIEBACK LEVEE (ESTIMATED QUANTITY)

0006 DEGRADE S-65C CHANDLER RANCH ROAD / 20,600 CUBIC YARD $___________ $_______________

TIEBACK LEVEE (ESTIMATED QUANTITY)

0007 EXCAVATION - DREDGE DISPOSAL AREA E BERM 16,390 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0008 EXCAVATION - DREDGE DISPOSAL AREA E 1,314,600 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0009 EXCAVATION - DREDGE DISPOSAL AREA F 1,841,300 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0010 EXCAVATION - DREDGE DISPOAL AREA G 961,200 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0011 EXCAVATION - DREDGE DISPOSAL AREA H 3,164,800 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0012 EXCAVATION - DREDGE DISPOSAL AREA I 2,712,900 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0013 EXCAVATION - DREDGE DISPOSAL AREA J 69, 800 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0014 EXCAVATION - DREDGE DISPOSAL AT S-65C 121,700 CUBIC YARD $___________ $_______________

(ESTIMATED QUANTITY)

0015 ENVIRONMENTAL MONITORING 1 LUMP SUM $_______________

0016 TURBIDITY MONITORING 1 LUMP SUM $_______________

0017 LANDSCAPE 1 LUMP SUM $_______________

0018 SAFETY BARRIERS 1 LUMP SUM $_______________

TOTAL BID (LINE ITEMS 0001 THROUGH 0018) $_______________

(CONTINUED ON NEXT PAGE)

OKEECHOBEE AND HIGHLANDS COUNTIES, FLORIDA

KISSIMMEE RIVER RESTORATION PROJECT

C-38 REACH 2 BACKFILL

SECTION 00010A

LINE ITEMS AND PRICING SCHEDULE

W912EP-16-B-0007 00010A-2

OKEECHOBEE AND HIGHLANDS COUNTIES, FLORIDA

KISSIMMEE RIVER RESTORATION PROJECT

C-38 REACH 2 BACKFILL

NOTES: (1) OFFER MUST PRICE ALL LINE ITEMS. SEE PROVISION AT 52.214-18 (SECTION 00100).

(2) FAILURE TO COMPLETE AND RETURN ALL REQUIRED SUBMISSIONS (SF 1442, SECTION 00010A, AND

(5) Digital Terrain Models (DTM) and requisite raw data in XLM format are available for informational purposes only.

The Government assumes no responsibility for any apparent errors that may be present in the DTM or raw data;

nor does the Government assume responsibility for any conclusions or interpretations made by the Contractor based on the provided DTM or raw data. The DTM and raw data are available in compressed (.zip) format for download by offerors with the solicitation on the Federal Business Opportunities (www.fbo.gov) web site.

The available information may include DTM surfaces for the existing site grades, excavation grades, and finished grades. The excavation DTM may not fully define surfaces related to temporary cuts required for site features such as stormwater management and erosion control components. Further, the excavation DTM may not reflect embankment foundation details such as soil benching. The finished DTM may not fully define surfaces related to site features such as stormwater management and erosion control components. Further, the finished grade DTM may not reflect embankment penetrations, internal embankment components such as seepage collection systems, nor embankment slope protection.

(4) ESTIMATED QUANTITIES FOR LINE ITEMS 0005 THRU THRU 0014 DO NOT INCLUDE TOLERANCES (SEE SECTION 01 22 00). OFFERORS ARE RESPONSIBLE FOR CONSIDERING THE COST OF TOLERANCES THEY REQUIRE AND INCLUDE THESE COSTS IN THE UNIT PRICES FOR THE QUANTITIES INDICATED IN THESE LINE ITEMS.

(3) SEE CLAUSE "BIDDER'S CHECKLIST" - CONSTRUCTION/DREDGING CONTRACTS" OF SECTION 00100.

SECTION 00101) COULD RENDER YOUR BID NON-RESPONSIVE.

00010A-A1

SECTION 00010A, Attachment A

INSTRUCTIONS FOR TECHNICAL INQUIRIES AND QUESTIONS

Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at (https://www.projnet.org) No Later Than (NLT) 31 May 2016. To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email, followed by an answer to the comment/question after it has been processed by our technical team.

All timely questions and approved answers will be made available through ProjNet. Approved answers to all timely questions will also be posted on the FedBizOps in the form of a report generated from ProjNet as soon as the comment/question entering period is over and all answers are all finalized.

The Solicitation Number is: W912EP-16-R-0007

The Bidder Inquiry Key is: CKEMNJ-4U6F67

Specific Instructions for ProjNet Bid Inquiry Access from ProjNet home page:

1. Identify the Agency. This should be marked as USACE.

2. Email. Enter the email address you would like to use for communication.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

5. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret

Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

6. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access from ProjNet home page:

1. For future access to ProjNet, you will not be emailed any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. Identify the Agency. This should be marked as USACE.

3. Email. Enter the email address you used to register previously in ProjNet.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

6. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

W912EP-16-R-0007 00100-i

Section 00100

INSTRUCTIONS TO OFFERORS

52.204-6 DATA UNIVERSAL NUMBERING SYSTEM NUMBER JUL 2013

52.204-7 System for Award Management JUL 2013

52.209-7 Information Regarding Responsibility Matters JUL 2013

52.211-2 Availability of Specifications, Standards, and Data Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST) APR 2014

52.215-1 Instructions to Offerors--Competitive Acquisition JAN 2004

52.216-1 Type of Contract APR 1984

52.222-5 Construction Wage Rate Requirements--Secondary Site of the Work MAY 2014

52.222-38 Compliance with Veterans' Employment Reporting Requirements SEP 2010

52.233-2 SERVICE OF PROTEST (SEP 2006) (CESAJ ADAPTATION) OCT 2006

52.236-27 Alt 1 Site Visit (Construction) (Feb 1995) - Alternate I FEB 1995

52.236-28 Preparation of Proposals--Construction OCT 1997

52.252-5 Authorized Deviations in Provisions APR 1984

252.204-7004 Alt A System for Award Management Alternate A FEB 2014

252.225-7031 Secondary Arab Boycott of Israel JUN 2005

999.204-1 HAND-DELIVERING OFFERS TO THE PRUDENTIAL OFFICE BUILDING IN

JACKSONVILLE MAY 2004

999.215-1 NOTICE OF INTENT TO INCORPORATE UNIT PRICES SEP 2004

999.215-4000 OBTAINING INFORMATION REGARDING THIS SOLICITATION DEC 1999

999.215-4003 ELECTRONIC PROPOSALS DEC 1999

999.215-4011 OFFEROR'S CHECKLIST DEC 1999

W912EP-16-R-0007 00100-1

Section 00100

INSTRUCTIONS TO OFFERORS

52.204-6 DATA UNIVERSAL NUMBERING SYSTEM NUMBER (JULY 2013)

(a) Definition. Data Universal Numbering System (DUNS) number, as used in this provision, means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities, which is used as the identification number for Federal Contractors.

(b)The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS+4” followed by the DUNS number or “DUNS+4” that identifies the offeror's name and address exactly as stated in the offer. The DUNS number is a nine-digit number assigned by Dun and Bradstreet, Inc. The DUNS+4 is the DUNS number plus a 4-character suffix that may be assigned at the discretion of the offeror to establish additional System for Award Management records for identifying alternative Electronic Funds Transfer (EFT) accounts (see Subpart 32.11) for the same concern.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number--

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business name.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company physical street address, city, state and Zip Code.

(iv) Company mailing address, city, state and Zip Code (if separate from physical).

(v) Company telephone number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

W912EP-16-R-0007 00100-2

(x) Company Headquarters name and address (reporting relationship within your entity).

(End of provision)

52.204-7 SYSTEM FOR AWARD MANAGEMENT (JULY 2013)

(a) Definitions. As used in this provision--

Data Universal Numbering System (DUNS) number means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

Data Universal Numbering System +4 (DUNS+4) number means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional System for Award Management records for identifying alternative Electronic Funds Transfer (EFT) accounts (see the FAR at Subpart 32.11) for the same parent concern.

Registered in the System for Award Management SAM database means that--

(1) The offeror has entered all mandatory information, including the DUNS number or the DUNS+4 number, the Contractor and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see Subpart 4.14) into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

(b)(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “DUNS” or “DUNS +4” followed by the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

(c) If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number--

W912EP-16-R-0007 00100-3

(i) Via the Internet at http://fedgov.dnb.com/webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and Zip Code.

(iv) Company Mailing Address, City, State and Zip Code (if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering.

Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

(End of clause)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in

W912EP-16-R-0007 00100-4

connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

W912EP-16-R-0007 00100-5

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

(End of provision)

52.211-2 AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM

DESCRIPTIONS LISTED IN THE ACQUISITION STREAMLINING AND STANDARDIZATION

INFORMATION SYSTEM (ASSIST) (APR 2014)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/);

(2) Quick Search (http://quicksearch.dla.mil/);

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

52.215-1 INSTRUCTIONS TO OFFERORS--COMPETITIVE ACQUISITION (JAN 2004)

(a) Definitions. As used in this provision--

“Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer's discretion, result in the offeror being allowed to revise its proposal.

“In writing or written” means any worded or numbered expression which can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation's closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time”, if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

W912EP-16-R-0007 00100-6

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals. (1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages (i) addressed to the office specified in the solicitation, and (ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show--

(i) The solicitation number;

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror's behalf with the Government in connection with this solicitation;

and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent's authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, or revision, of proposals.

(i) Offerors are responsible for submitting proposals, and any modifications, or revisions, so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and--

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

W912EP-16-R-0007 00100-7

(2) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of offers and was under the Government's control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(iii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iv) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(v) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally. If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall--

W912EP-16-R-0007 00100-8

(1) Mark the title page with the following legend: This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed--in whole or in part--for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of--or in connection with-- the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government's right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend: Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award. (1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government's interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror's initial proposal should contain the offeror's best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government's best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more contract line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

W912EP-16-R-0007 00100-9

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency's evaluation of the significant weak or deficient factors in the debriefed offeror's offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

(End of provision)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

(End of provision)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK

(MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

W912EP-16-R-0007 00100-10

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade Goals for female participation for each trade

Okeechobee 30.4%

Highlands 17.1%

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.

The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

W912EP-16-R-0007 00100-11

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is The canal will be backfilled starting approximately 1900 LF north of the US Hwy 98 bridge crossing, continuing north for approximately 34,400 LF stopping just short of the terminus of Reach 1 Backfill in Okeechobee and Highlands Counties, Florida.

(End of provision)

52.222-38 COMPLIANCE WITH VETERANS' EMPLOYMENT REPORTING REQUIREMENTS

(SEP 2010)

By submission of its offer, the offeror represents that, if it is subject to the reporting requirements of 38 U.S.C. 4212(d) (i.e., if it has any contract containing Federal Acquisition Regulation clause 52.222-37, Employment Reports on Veterans), it has submitted the most recent VETS-100A Report required by that clause.

(End of provision)

52.225-12 NOTICE OF BUY AMERICAN ACT REQUIREMENT-- CONSTRUCTION

MATERIALS (MAY 2014) - ALTERNATE I (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American-- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225- 11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute or Balance shall submit the request with its offer, including the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225- 11.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

W912EP-16-R-0007 00100-12

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006) (CESAJ ADAPTATION)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the person identified in item 10 of the Standard Form 33 (if this solicitation is for non-commercial supplies or services), in item 9A of the Standard Form 1442 (if this solicitation is for construction or dredging), in item 7 of the Standard Form 1449 (if this solicitation is for commercial items), or in item 7 of the DA Form 4069-R (if this solicitation is for work funded by a non-appropriated funds instrumentality) at the address shown in item 7 of the SF 33, item 7 of the SF 1442, item 9 of the SF 1449, or item 5 of the DA Form 4069-R.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.236-27 -- SITE VISIT (CONSTRUCTION) (FEB 1995) (ALTERNATE I) (FEB 1995) (CESAJ

ADAPTATION)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been schedule for 19 May 2016 at 8:30 am.

(c) Participants will meet at S-65C Campgrounds. See (d) below.

(d) Participants should email Yvette Powell at Yvette.L.Powell@usace.army.mil or call Ms. Powell at 813-348-0690 prior to 16 May 2016 to make arrangements and ensure no changes to the location or time for scheduled site visit.

W912EP-16-R-0007 00100-13

(e) Core borings are available. (If available, follow the Instructions in the Physical Data paragraph in Section 01 11 00 to make arrangements to inspect the borings. Failure to follow the Instructions may result in a delay ranging in duration from one hour to 4 days.)

(f) After the site visit, a memorandum summarizing the visit will be posted to the EBS Web page under the solicitation number. This posting will be strictly for Informational purposes only. The memorandum will not become a part of the solicitation. If the solicitation needs to be changed as a result of information obtained during the site visit, a written amendment will be made available to all registered vendors.

Questions regarding any information given in the memorandum must be directed to the person whose name appears in Item 9 of the Standard Form 1442.

(End of provision)

52.236-28 PREPARATION OF PROPOSALS--CONSTRUCTION (OCT 1997)

(a) Proposals must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a proposal must initial each erasure or change appearing on any proposal form.

(b) The proposal form may require offerors to submit proposed prices for one or more items on various bases, including--

(1) Lump sum price;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of paragraphs (b)(1) through (b)(3) of this provision.

(c) If the solicitation requires submission of a proposal on all items, failure to do so may result in the proposal being rejected without further consideration. If a proposal on all items is not required, offerors should insert the words “no proposal” in the space provided for any item on which no price is submitted.

(d) Alternate proposals will not be considered unless this solicitation authorizes their submission.

(End of provision)

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b)The use in this solicitation of any (Defense Federal Acquisition Regulation Supplement Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

W912EP-16-R-0007 00100-14

252.204-7004 ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (FEB 2014)

(a) Definitions. As used in this provision—

“System for Award Management (SAM) database” means the primary Government repository for contractor information required for the conduct of business with the Government.

“Commercial and Government Entity (CAGE) code” means—

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an “NCAGE code.”

“Data Universal Numbering System (DUNS) number” means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

“Data Universal Numbering System +4 (DUNS+4) number” means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.) This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR 32.11) for the same parent concern.

“Registered in the System for Award Management (SAM) database” means that—

(1) The contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, and Contractor and Government Entity (CAGE) code into the SAM database; and

(2) The contractor has completed the Core Data, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as part of the SAM registration process; and

(4) The Government has marked the record…