W912EK18R0023_Amendment_0002.pdf

96514782185605

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of Amendment 0002 is to make changes to Section 01 33 00 and the DRAWINGS.

All other terms and conditions of solicitation W912EK18R0023 remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 20-Aug-2018

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912EK18R0023

X 9B. DATED (SEE ITEM 11)

08-Aug-2018

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

20-Aug-2018

CODE

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS

1500 ROCK ISLAND DRIVE

ROCK ISLAND IL 61201

W912EK 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EK18R0023

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

(End of Summary of Changes)

The following items are applicable to this modification:

AMENDMENT 0002

The following modifications are made to Section 01 33 00 and the

DRAWINGS.

SECTION 01 33 00

a. PAGE 01 33 00-8. Delete Page 01 33 00-8 in its entirety, and substitute therefor revised 01 33 00-8, Amendment 0002, dated August 17, 2018, attached hereto.

DRAWINGS (SUPERSEDED)

b. Revised drawings bearing the revision numbers and dates listed below are being issued with this Amendment. Such revised drawings supersede those of the same sheet identification numbers listed in the INDEX OF DRAWINGS included in the set of drawings furnished with Solicitation No.

W912EK18R0023, dated August 8, 2018.

SHEET IDENTIFICATION NO. S-001, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-501, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-502, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-503, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-504, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-505, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-506, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-507, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-508, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-509, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. S-511, Revision Mark 1 dated August 17, 2018.

SHEET IDENTIFICATION NO. M-501, Revision Mark 1 dated August 17, 2018.

ATTACHMENTS: Page 01 33 00-8; S-001, S-501, S-502, S-503, S-504, S-505, S-506, S-507, S-508, S-509, S-511, and M-501

Solicitation No.: W912EK18R0023

Column (m) through (p)List Date related to review actions.

Column (q) List date returned to Fabricator.

1.10.4 Fabricator Action Code and Action Code

Entries for columns (j) and (o), are to be used are as follows (others may be prescribed by Transmittal Form):

NR - Not Received

AN - Approved as noted

A - Approved

RR - Disapproved, Revise, and Resubmit

1.10.5 Copies Delivered to the Government

Submit a copy of the submittal register updated by Fabricator with each invoice request. Deliver in electronic format, unless a paper copy is requested by Contracting Officer.

1.11 SCHEDULING

Schedule and submit concurrently submittals covering component items forming a system or items that are interrelated. Include certifications to be submitted with the pertinent drawings at the same time. No delay damages or time extensions will be allowed for time lost in late submittals. Contracting Officer review will be completed within 30 calendar days after date of submission except for Shop Drawings which will be completed within 60 days (see Section 05 59 13 FABRICATION OF HYDRAULIC STEEL STRUCTURES paragraph SUBMITTALS.

a. Coordinate scheduling, sequencing, preparing, and processing of submittals with performance of work to avoid being delayed by submittal processing. Allow for potential resubmittal of requirements.

b. Submittals called for by the Contract documents will be listed on the register. If a submittal is called for but does not pertain to the Contract work, include the submittal in the register and annotate it "N/A" with a brief explanation. Approval by the Contracting Officer does not relieve the Fabricator of supplying submittals required by the Contract documents but which have been omitted from the register or marked "N/A."

c. Resubmit the submittal register and annotate monthly with the actual submission and approval dates. When all items on the submittal register have been fully approved, no further resubmission is required.

d. Carefully control procurement operations to ensure that each individual submittal is made on or before the Fabricator scheduled submittal date shown on the approved "Submittal Register."

1.12 GOVERNMENT APPROVING AUTHORITY

When approving authority is Contracting Officer, the Government will:

a. Note date on which submittal was received from CQC Manager.

01 33 00-8 AMEND. 0002

17 AUG 2018